Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
CAG2024-323 - Original - Auburn Mechanical, Inc - Half Lion Water/Gas/Hot Water Tank - 6/30/24
FOR CITY OF KENT OFFICIAL USE ONLY Sup/Mgr: Agreement Routing Form DirAsst: KK� • For Approvals,Signatures and Records Management Dir/Dep: SZ, BL KENT This form combines&replaces the Request for Mayor's Signature and Contract Cover (optional) W A S H I N G T O N Sheet forms. (Print on pink or cherry colored paper) Originator: Department: Leah Bryant for Kris Zorer Parks, Recreation & Community Services Date Sent: Date Required: > 06/14/2024 6/20/2024 0 Q Authorized to Sign: Date of Council Approval: QMayor or Designee NA Budget Account Number: Grant? Yes NOW] G20038.64110.9476 Budget?W]Yes EINo Type: N/A Vendor Name: Category: AUBURN MECHANICAL, INC. Contract Vendor Number: NEW— Sub-Category: = 66581 Original g Project Name: FAC24-15 Half Lion water/ as sub meter/ New hot water tank 3- Project Details: As described in the attached Exhibit A, incorporated herein,the contractor shall provide all labor and 0 materials to replumb water and gas lines to add owner supplied cellular sub-meters,which separate C Riverbend's water and gas usage from the restaurant's water and gas usage.Additionally,the contractor shall install a new hot water tank and expansion tank,then replumb accordingly C Basis for Selection of Contractor: � Agreement Amoun $33 280.40 Other E ' *Memo to Mayor must be attached i Start Date: June 2024 Termination Date: 09/13/2024 Q Local Business? Yes Who*If meets requirements per KCC3.70.100,please complete"VendorPurchose-Locol Exceptions"form onCityspace. Business License Verification: W1 Yes In-ProcessD Exempt(KCC 5.01.045) W1 Authorized Signer Verified Notice required prior to disclosure? Contract Number: Yes W1 No CAG2024-323 Comments: i 3 f0 a1 C C a1 Vf � 3 0 a, cc Date Received:City Attorney: 6/26/24 Date Routed:Mayor's Office?/2/24 City Clerk's Office 7/2/24 adccW22373_1_20 Visit Documents.KentWA.gov to obtain copies of all agreements rev.20221201 KENT WASHINGTON PUBLIC WORKS AGREEMENT between City of Kent and AUBURN MECHANICAL, INC. THIS AGREEMENT is made by and between the City of Kent, a Washington municipal corporation (hereinafter the "City"), and AUBURN MECHANICAL, INC. organized under the laws of the State of Washington, located and doing business at 2623 W Valley Hwy N., Auburn, WA 98071, 253-838-9780 (hereinafter the "Contractor"). AGREEMENT The parties agree as follows: I. DESCRIPTION OF WORK. The Contractor shall perform the following services for the City in accordance with the following described plans and/or specifications: As described in the attached Exhibit A, incorporated herein, the contractor shall provide all labor and materials to replumb water and gas lines to add owner supplied cellular sub-meters, which separate Riverbend's water and gas usage from the restaurant's water and gas usage. Additionally, the contractor shall install a new hot water tank and expansion tank, then replumb accordingly The Contractor further represents that the services furnished under this Agreement will be performed in accordance with generally accepted professional practices within the Puget Sound region in effect at the time such services are performed. II. TIME OF COMPLETION. The parties agree that work will begin on the tasks described in Section I above within 10 working days after the City issues its Notice to Proceed. Upon the effective date of this Agreement, all physical work shall thereafter be completed by 9/13/2024. The term of this Agreement shall continue until all work has been completed, final acceptance has occurred, and all Contractor obligations have been fulfilled. III. COMPENSATION. The City shall pay the Contractor a total amount not to exceed $33,280.40, including any applicable Washington State Sales Tax, for the work and services contemplated in this Agreement. The City shall pay the Contractor eighty-five percent (85%) of the Contract amount upon completion and acceptance of the work by the City, or at such earlier time as the City may determine is appropriate. The City will pay the remaining Contract amount upon fulfillment of the conditions listed below and throughout this Agreement. Card Payment Program. The Contractor may elect to participate in automated credit card payments provided for by the City and its financial institution. This Program is provided as an alternative to payment by check and is available for the convenience of the Contractor. If the Contractor voluntarily participates in this Program, the Contractor will be solely responsible for any fees imposed by financial institutions or credit card companies. The Contractor shall not charge those fees back to the City. PUBLIC WORKS AGREEMENT - 1 (Over$20K and No Performance Bond) A. No Payment and Performance Bond. Because this contract, including applicable sales tax, is less than $150,000, and pursuant to Chapter 39.08 RCW, the Contractor, in lieu of providing the City a payment and performance bond, has elected to have the City retain the final ten percent (10%) of the Contract amount for a period of thirty (30) days after the date of final acceptance, or until receipt of all necessary releases from the State Department of Revenue, the State Department of Labor & Industries, and the State Employment Security Department, and until settlement of any liens filed under Chapter 60.28 RCW, whichever is later. B. Retainaae. The City shall also hold back a retainage in the amount of five percent (5%) of any and all payments made to the Contractor for a period of sixty (60) days after the date of final acceptance, or until receipt of all necessary releases from the State Department of Revenue, the State Department of Labor & Industries, and the State Employment Security Department, and until settlement of any liens filed under Chapter 60.28 RCW, whichever is later. The amount retained shall be placed in a fund by the City pursuant to RCW 60.28.011(4)(a), unless otherwise instructed by the Contractor within fourteen (14) calendar days of the Contractor's signature on the Agreement. C. Defective or Unauthorized Work. The City reserves its right to withhold payment from the Contractor for any defective or unauthorized work. Defective or unauthorized work includes, without limitation: work and materials that do not conform to the requirements of this Agreement; and extra work and materials furnished without the City's written approval. If the Contractor is unable, for any reason, to satisfactorily complete any portion of the work, the City may complete the work by contract or otherwise, and the Contractor shall be liable to the City for any additional costs incurred by the City. "Additional costs"shall mean all reasonable costs, including legal costs and attorney fees, incurred by the City beyond the maximum Contract price specified above. The City further reserves its right to deduct the cost to complete the Contract work, including any Additional Costs, from any and all amounts due or to become due the Contractor. D. Final Payment: Waiver of Claims. THE CONTRACTOR'S ACCEPTANCE OF FINAL PAYMENT (EXCLUDING WITHHELD RETAINAGE) SHALL CONSTITUTE A WAIVER OF CONTRACTOR'S CLAIMS, EXCEPT THOSE PREVIOUSLY AND PROPERLY MADE AND IDENTIFIED BY CONTRACTOR AS UNSETTLED AT THE TIME FINAL PAYMENT IS MADE AND ACCEPTED. IV. INDEPENDENT CONTRACTOR. The parties intend that an Independent Contractor- Employer Relationship will be created by this Agreement. By their execution of this Agreement, and in accordance with Ch. 51.08 RCW, the parties make the following representations: A. The Contractor has the ability to control and direct the performance and details of its work, the City being interested only in the results obtained under this Agreement. B. The Contractor maintains and pays for its own place of business from which the Contractor's services under this Agreement will be performed. C. The Contractor has an established and independent business that is eligible for a business deduction for federal income tax purposes that existed before the City retained the Contractor's services and is a service other than that furnished by the City, or the Contractor is engaged in an independently established trade, occupation, profession, or business of the same nature as that involved under this Agreement. D. The Contractor is responsible for filing as they become due all necessary tax documents with appropriate federal and state agencies, including the Internal Revenue Service and the state Department of Revenue. PUBLIC WORKS AGREEMENT - 2 (Over$20K and No Performance Bond) E. The Contractor has registered its business and established an account with the state Department of Revenue and other state agencies as may be required by the Contractor's business, and has obtained a Unified Business Identifier (UBI) number from the State of Washington. F. The Contractor has a valid contractor registration pursuant to Ch. 18.27 RCW or an electrical contractor license pursuant to Ch. 19.28 RCW. G. The Contractor maintains a set of books dedicated to the expenses and earnings of its business. V. TERMINATION. The City may terminate this Agreement for good cause. "Good cause"shall include, without limitation, any one or more of the following events: A. The Contractor's refusal or failure to supply a sufficient number of properly skilled workers or proper materials for completion of the Contract work. B. The Contractor's failure to complete the work within the time specified in this Agreement. C. The Contractor's failure to make full and prompt payment to subcontractors or for material or labor. D. The Contractor's persistent disregard of federal, state or local laws, rules or regulations. E. The Contractor's filing for bankruptcy or becoming adjudged bankrupt. F. The Contractor's breach of any portion of this Agreement. If the City terminates this Agreement for good cause, the Contractor shall not receive any further money due under this Agreement until the Contract work is completed. After termination, the City may take possession of all records and data within the Contractor's possession pertaining to this project which may be used by the City without restriction. VI. PREVAILING WAGES. The Contractor shall file a "Statement of Intent to Pay Prevailing Wages," with the State of Washington Department of Labor & Industries prior to commencing the Contract work. The Contractor shall pay prevailing wages in effect on the date the bid is accepted or executed by the Contractor, and comply with Chapter 39.12 of the Revised Code of Washington, as well as any other applicable prevailing wage rate provisions. The latest prevailing wage rate revision issued by the Department of Labor and Industries is attached. VII. CHANGES. The City may issue a written change order for any change in the Contract work during the performance of this Agreement. If the Contractor determines, for any reason, that a change order is necessary, the Contractor must submit a written change order request to the person listed in the notice provision section of this Agreement, Section XVI(D), within fourteen (14) calendar days of the date the Contractor knew or should have known of the facts and events giving rise to the requested change. If the City determines that the change increases or decreases the Contractor's costs or time for performance, the City will make an equitable adjustment. The City will attempt, in good faith, to reach agreement with the Contractor on all equitable adjustments. However, if the parties are unable to agree, the City will determine the equitable adjustment as it deems appropriate. The Contractor shall proceed with the change order work upon receiving either a written change order from the City or an oral order from the City before actually receiving the written change order. If the Contractor fails to require a change order within the time specified in this paragraph, the Contractor waives its right to make any claim or submit subsequent change order requests for that portion of the contract work. If the Contractor disagrees with the equitable PUBLIC WORKS AGREEMENT - 3 (Over$20K and No Performance Bond) adjustment, the Contractor must complete the change order work; however, the Contractor may elect to protest the adjustment as provided in subsections A through E of Section IX, Claims, below. The Contractor accepts all requirements of a change order by: (1) endorsing it, (2) writing a separate acceptance, or (3) not protesting in the way this section provides. A change order that is accepted by the Contractor as provided in this section shall constitute full payment and final settlement of all claims for contract time and for direct, indirect and consequential costs, including costs of delays related to any work, either covered or affected by the change. VIII. FORCE MAJEURE. Neither party shall be liable to the other for breach due to delay or failure in performance resulting from acts of God, acts of war or of the public enemy, riots, pandemic, fire, flood, or other natural disaster or acts of government ("force majeure event"). Performance that is prevented or delayed due to a force majeure event shall not result in liability to the delayed party. Both parties represent to the other that at the time of signing this Agreement, they are able to perform as required and their performance will not be prevented, hindered, or delayed by the current COVID-19 pandemic, any existing state or national declarations of emergency, or any current social distancing restrictions or personal protective equipment requirements that may be required under federal, state, or local law in response to the current pandemic. If any future performance is prevented or delayed by a force majeure event, the party whose performance is prevented or delayed shall promptly notify the other party of the existence and nature of the force majeure event causing the prevention or delay in performance. Any excuse from liability shall be effective only to the extent and duration of the force majeure event causing the prevention or delay in performance and, provided, that the party prevented or delayed has not caused such event to occur and continues to use diligent, good faith efforts to avoid the effects of such event and to perform the obligation. Notwithstanding other provisions of this section, the Contractor shall not be entitled to, and the City shall not be liable for, the payment of any part of the contract price during a force majeure event, or any costs, losses, expenses, damages, or delay costs incurred by the Contractor due to a force majeure event. Performance that is more costly due to a force majeure event is not included within the scope of this Force Majeure provision. If a force majeure event occurs, the City may direct the Contractor to restart any work or performance that may have ceased, to change the work, or to take other action to secure the work or the project site during the force majeure event. The cost to restart, change, or secure the work or project site arising from a direction by the City under this clause will be dealt with as a change order, except to the extent that the loss or damage has been caused or exacerbated by the failure of the Contractor to fulfill its obligations under this Agreement. Except as expressly contemplated by this section, all other costs will be borne by the Contractor. IX. CLAIMS. If the Contractor disagrees with anything required by a change order, another written order, or an oral order from the City, including any direction, instruction, interpretation, or determination by the City, the Contractor may file a claim as provided in this section. The Contractor shall give written notice to the City of all claims within fourteen (14) calendar days of the occurrence of the events giving rise to the claims, or within fourteen (14) calendar days of the date the Contractor knew or should have known of the facts or events giving rise to the claim, whichever occurs first . Any claim for damages, additional payment for any reason, or extension of time, whether under this Agreement or otherwise, shall be conclusively deemed to have been waived by the Contractor unless a timely written claim is made in strict accordance with the applicable provisions of this Agreement. At a minimum, a Contractor's written claim shall include the information set forth in subsections A, items 1 through 5 below. FAILURE TO PROVIDE A COMPLETE, WRITTEN NOTIFICATION OF CLAIM WITHIN THE TIME ALLOWED SHALL BE AN ABSOLUTE WAIVER OF ANY CLAIMS ARISING IN ANY WAY FROM THE FACTS OR EVENTS SURROUNDING THAT CLAIM OR CAUSED BY THAT DELAY. PUBLIC WORKS AGREEMENT - 4 (Over$20K and No Performance Bond) A. Notice of Claim. Provide a signed written notice of claim that provides the following information: 1. The date of the Contractor's claim; 2. The nature and circumstances that caused the claim; 3. The provisions in this Agreement that support the claim; 4. The estimated dollar cost, if any, of the claimed work and how that estimate was determined; and 5. An analysis of the progress schedule showing the schedule change or disruption if the Contractor is asserting a schedule change or disruption. B. Records. The Contractor shall keep complete records of extra costs and time incurred as a result of the asserted events giving rise to the claim. The City shall have access to any of the Contractor's records needed for evaluating the protest. The City will evaluate all claims, provided the procedures in this section are followed. If the City determines that a claim is valid, the City will adjust payment for work or time by an equitable adjustment. No adjustment will be made for an invalid protest. C. Contractor's Duty to Complete Protested Work. In spite of any claim, the Contractor shall proceed promptly to provide the goods, materials and services required by the City under this Agreement. D. Failure to Protest Constitutes Waiver. By not protesting as this section provides, the Contractor also waives any additional entitlement and accepts from the City any written or oral order (including directions, instructions, interpretations, and determination). E. Failure to Follow Procedures Constitutes Waiver. By failing to follow the procedures of this section, the Contractor completely waives any claims for protested work and accepts from the City any written or oral order (including directions, instructions, interpretations, and determination). X. LIMITATION OF ACTIONS. CONTRACTOR MUST, IN ANY EVENT, FILE ANY LAWSUIT ARISING FROM OR CONNECTED WITH THIS AGREEMENT WITHIN 120 CALENDAR DAYS FROM THE DATE THE CONTRACT WORK IS COMPLETE OR CONTRACTOR'S ABILITY TO FILE THAT CLAIM OR SUIT SHALL BE FOREVER BARRED. THIS SECTION FURTHER LIMITS ANY APPLICABLE STATUTORY LIMITATIONS PERIOD. XI. WARRANTY. The Contractor warrants that it will faithfully and satisfactorily perform all work provided under this Agreement in accordance with the provisions of this Agreement. The Contractor shall promptly correct all defects in workmanship and materials: (1) when the Contractor knows or should have known of the defect, or (2) upon the Contractor's receipt of notification from the City of the existence or discovery of the defect. In the event any parts are repaired or replaced, only original replacement parts shall be used—rebuilt or used parts will not be acceptable. When defects are corrected, the warranty for that portion of the work shall extend for an additional year beyond the original warranty period applicable to the overall work. The Contractor shall begin to correct any defects within seven (7) calendar days of its receipt of notice from the City of the defect. If the Contractor does not accomplish the corrections within a reasonable time as determined by the City, the City may complete the corrections and the Contractor shall pay all costs incurred by the City in order to accomplish the correction. XII. DISCRIMINATION. In the hiring of employees for the performance of work under this Agreement or any sub-contract, the Contractor, its sub-contractors, or any person acting on behalf of the Contractor or sub-contractor shall not, by reason of race, religion, color, sex, age, sexual orientation, national origin, or the presence of any sensory, mental, or physical disability, discriminate against any person who is qualified and available to perform the work to which the employment relates. The Contractor shall execute the attached City of Kent Non-Discrimination Policy Declaration, and comply with City Administrative Policy 1.2. PUBLIC WORKS AGREEMENT - 5 (Over$20K and No Performance Bond) XIII. INDEMNIFICATION. The Contractor shall defend, indemnify and hold the City, its officers, officials, employees, agents and volunteers harmless from any and all claims, injuries, damages, losses or suits, including all legal costs and attorney fees, arising out of or in connection with the Contractor's performance of this Agreement, except for that portion of the injuries and damages caused by the City's negligence. The City's inspection or acceptance of any of the Contractor's work when completed shall not be grounds to avoid any of these covenants of indemnification. Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Contractor and the City, its officers, officials, employees, agents and volunteers, the Contractor's duty to defend, indemnify, and hold the City harmless, and the Contractor's liability accruing from that obligation shall be only to the extent of the Contractor's negligence. IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THE INDEMNIFICATION PROVIDED HEREIN CONSTITUTES THE CONTRACTOR'S WAIVER OF IMMUNITY UNDER INDUSTRIAL INSURANCE, TITLE 51 RCW, SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PARTIES FURTHER ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER. In the event the Contractor refuses tender of defense in any suit or any claim, if that tender was made pursuant to this indemnification clause, and if that refusal is subsequently determined by a court having jurisdiction (or other agreed tribunal) to have been a wrongful refusal on the Contractor's part, then the Contractor shall pay all the City's costs for defense, including all reasonable expert witness fees and reasonable attorneys'fees, plus the City's legal costs and fees incurred because there was a wrongful refusal on the Contractor's part. The provisions of this section shall survive the expiration or termination of this Agreement. XIV. INSURANCE. The Contractor shall procure and maintain for the duration of the Agreement, insurance of the types and in the amounts described in Exhibit B attached and incorporated by this reference. XV. WORK PERFORMED AT CONTRACTOR'S RISK. The Contractor shall take all necessary precautions and shall be responsible for the safety of its employees, agents, and subcontractors in the performance of the contract work and shall utilize all protection necessary for that purpose. All work shall be done at the Contractor's own risk, and the Contractor shall be responsible for any loss of or damage to materials, tools, or other articles used or held for use in connection with the work. XVI. MISCELLANEOUS PROVISIONS. A. Recyclable Materials. Pursuant to Chapter 3.80 of the Kent City Code, the City requires its contractors and consultants to use recycled and recyclable products whenever practicable. A price preference may be available for any designated recycled product. B. Non-Waiver of Breach. The failure of the City to insist upon strict performance of any of the covenants and agreements contained in this Agreement, or to exercise any option conferred by this Agreement in one or more instances shall not be construed to be a waiver or relinquishment of those covenants, agreements or options, and the same shall be and remain in full force and effect. C. Resolution of Disputes and Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of Washington. If the parties are unable to settle any dispute, difference or claim arising from the parties' performance of this Agreement, the exclusive means of resolving that dispute, difference or claim, shall only be by filing suit exclusively under the venue, rules and jurisdiction of the King County Superior Court, King County, Washington, unless the parties agree in writing to an alternative dispute resolution process. In any claim or lawsuit for damages arising from the parties' performance of this Agreement, each party shall pay all its legal costs and attorney's fees incurred PUBLIC WORKS AGREEMENT - 6 (Over$20K and No Performance Bond) in defending or bringing such claim or lawsuit, including all appeals, in addition to any other recovery or award provided by law; provided, however, nothing in this paragraph shall be construed to limit the City's right to indemnification under Section XIII of this Agreement. D. Written Notice. All communications regarding this Agreement shall be sent to the parties at the addresses listed on the signature page of the Agreement, unless notified to the contrary. Any written notice hereunder shall become effective three (3) business days after the date of mailing by registered or certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated in this Agreement or such other address as may be hereafter specified in writing. E. Assignment. Any assignment of this Agreement by either party without the written consent of the non-assigning party shall be void. If the non-assigning party gives its consent to any assignment, the terms of this Agreement shall continue in full force and effect and no further assignment shall be made without additional written consent. F. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of the City and the Contractor. G. Entire Agreement. The written provisions and terms of this Agreement, together with any Exhibits attached hereto, shall supersede all prior verbal statements of any officer or other representative of the City, and such statements shall not be effective or be construed as entering into or forming a part of or altering in any manner this Agreement. All of the above documents are hereby made a part of this Agreement. However, should any language in any of the Exhibits to this Agreement conflict with any language contained in this Agreement, the terms of this Agreement shall prevail. H. Compliance with Laws. The Contractor agrees to comply with all federal, state, and municipal laws, rules, and regulations that are now effective or in the future become applicable to the Contractor's business, equipment, and personnel engaged in operations covered by this Agreement or accruing out of the performance of those operations. I. Public Records Act. The Contractor acknowledges that the City is a public agency subject to the Public Records Act codified in Chapter 42.56 of the Revised Code of Washington and documents, notes, emails, and other records prepared or gathered by the Contractor in its performance of this Agreement may be subject to public review and disclosure, even if those records are not produced to or possessed by the City of Kent. As such, the Contractor agrees to cooperate fully with the City in satisfying the City's duties and obligations under the Public Records Act. J. City Business License Required. Prior to commencing the tasks described in Section I, the Contractor agrees to provide proof of a current city of Kent business license pursuant to Chapter 5.01 of the Kent City Code. K. Counterparts and Signatures by Fax or Email. This Agreement may be executed in any number of counterparts, each of which shall constitute an original, and all of which will together constitute this one Agreement. Further, upon executing this Agreement, either party may deliver the signature page to the other by fax or email and that signature shall have the same force and effect as if the Agreement bearing the original signature was received in person. IN WITNESS, the parties below execute this Agreement, which shall become effective on the last date entered below. All acts consistent with the authority of this Agreement and prior PUBLIC WORKS AGREEMENT - 7 (Over$20K and No Performance Bond) to its effective date are ratified and affirmed, and the terms of the Agreement shall be deemed to have applied. CONTRACTOR: CITY OF KENT: joh;i A Ta�iie By:John A Payne(Jun 18,2 408:49 PDT) By Print Name: Print A Payne Print Name: Dana Ralph Its Vice President-Service Division Its Mayor DATE:Jun 18,2024 DATE: 07/01/2024 NOTICES TO BE SENT TO: NOTICES TO BE SENT TO: CONTRACTOR: CITY OF KENT: John Payne Leah Bryant Auburn Mechanical, INC City of Kent 2623 W Valley Hwy N 220 Fourth Avenue South Auburn, WA 98001 Kent, WA 98032 253-838-9780 (telephone) (253) 856-5084 (telephone) johnpayne@au burn mechanical.corn (email) LBryant@kentwa.gov (email) APPROVED AS TO FORM: jq&Vt- 0"�tv Kent Law Department ATTEST: k Kent Cit Clerk [In this field,you may enter the electronic filepath where the contract has been saved] PUBLIC WORKS AGREEMENT - 8 (Over$20K and No Performance Bond) DECLARATION CITY OF KENT NON-DISCRIMINATION POLICY The City of Kent (City) is committed to conform to Federal and State laws regarding equal opportunity. As such all contractors, subcontractors, consultants, vendors, and suppliers who perform work with relation to this Agreement shall comply with the regulations of the City's equal employment opportunity policies. The City of Kent and its contractors are subject to and will comply with the following: • Title VI of the Civil Rights Act of 1964 (42 U.S.C. § 2000d et seq., 78 stat. 252), (prohibits discrimination on the basis of race, color, national origin); • 49 C.F.R. Part 21 (entitled Non-discrimination In Federally-Assisted Programs Of The Department Of Transportation-Effectuation Of Title VI Of The Civil Rights Act Of 1964); • 28 C.F.R. section 50.3 (U.S. Department of Justice Guidelines for Enforcement of Title VI of the Civil Rights Act of 1964). • Ch. 49.60 RCW (Washington Law Against Discrimination) The preceding statutory and regulatory cites hereinafter are referred to as "the Acts and Regulations". The following statements specifically identify the requirements the City deems necessary for any contractor, subcontractor, or supplier on this specific Agreement to adhere to. An affirmation of all of the following is required for this Agreement to be valid and binding. If any contractor, subcontractor, or supplier willfully misrepresents themselves with regard to the directives outlined below, it will be considered a breach of contract and it will be at the City's sole determination regarding suspension or termination for all or part of the Agreement. The statements are as follows: 1. I have read the attached City of Kent administrative policy number 1.2. 2. During the time of this Agreement I will not discriminate in employment on the basis of sex, race, color, national origin, age, or the presence of all sensory, mental or physical disability. 3. During the time of this Agreement I, the prime contractor, will provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 4. During the time of the Agreement I, the prime contractor, will actively consider hiring and promotion of women and minorities. 5. During the performance of this contract, the contractor, for itself, its assignees, and successors in interest (hereinafter referred to as the "contractor") agrees as follows: PUBLIC WORKS AGREEMENT - 9 (Over$20K and No Performance Bond) A. Compliance with Regulations: The contractor, subcontractor, consultant, vendor, and supplier (hereinafter "Contractor") will comply with all Acts and the Regulations relative to non-discrimination, including those applicable to Federally- assisted programs of the U.S. Department of Transportation, State-assisted programs through the Washington State Department of Transportation, and generally under Washington's Law Against Discrimination, Ch. 49.60 RCW, as they may be amended from time to time, which are herein incorporated by reference and made a part of this contract. B. Non-discrimination: The contractor, with regard to the work performed by it during the contract, will not discriminate on the grounds of race, color, or national origin in the selection and retention of subcontractors, including procurements of materials and leases of equipment. The contractor will not participate directly or indirectly in the discrimination prohibited by the Acts and the Regulations, including employment practices when the contract covers any activity, project, or program set forth in Appendix B of 49 CFR Part 21. C. Solicitations for Subcontracts, Including Procurements of Materials and Equipment: In all solicitations, either by competitive bidding, or negotiation made by the contractor for work to be performed under a subcontract, including procurements of materials, or leases of equipment, each potential subcontractor or supplier will be notified by the contractor of the contractor's obligations under this contract and the Acts and the Regulations relative to non-discrimination on the grounds of race, color, or national origin. D. Information and Reports: The contractor will provide all information and reports required by the Acts and Regulations and directives issued pursuant thereto and will permit access to its books, records, accounts, other sources of information, and its facilities as may be determined applicable to contractor's contract by the City or the Washington State Department of Transportation to be pertinent to ascertain compliance with such Acts and Regulations and instructions. Where any information required of a contractor is in the exclusive possession of another who fails or refuses to furnish the information, the contractor will so certify to the City or the Washington State Department of Transportation, as appropriate, and will set forth what efforts it has made to obtain the information. E. Sanctions for Noncompliance: In the event of a contractor's noncompliance with the non-discrimination provisions of this contract, the City will impose such contract sanctions as it or the Washington State Department of Transportation may determine to be appropriate, including, but not limited to: a. withholding payments to the contractor under the contract until the contractor complies; and/or b. cancelling, terminating, or suspending a contract, in whole or in part. F. Incorporation of Provisions: The contractor will include the provisions of paragraphs (A) through (F) above in every subcontract, including procurements of materials and leases of equipment, unless exempt by the Acts and Regulations and directives issued pursuant thereto. The contractor will take action with respect to any subcontract or procurement as the City or the Washington State Department of Transportation may direct as a means of enforcing such provisions including PUBLIC WORKS AGREEMENT - 10 (Over$20K and No Performance Bond) sanctions for noncompliance. Provided, that if the contractor becomes involved in, or is threatened with litigation by a subcontractor, or supplier because of such direction, the contractor may request the City to enter into any litigation to protect the interests of the City. In addition, the contractor may request the United States to enter into the litigation to protect the interests of the United States. 6. During the performance of this contract, the contractor, for itself, its assignees, and successors in interest agrees to comply with the following non-discrimination statutes and authorities; including but not limited to: Pertinent Non-Discrimination Authorities: i. Title VI of the Civil Rights Act of 1964 (42 U.S.C. § 2000d et seq., 78 stat. 252), (prohibits discrimination on the basis of race, color, national origin); and 49 CFR Part 21. ii. The Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970, (42 U.S.C. § 4601), (prohibits unfair treatment of persons displaced or whose property has been acquired because of Federal or Federal-aid programs and projects); iii. Federal-Aid Highway Act of 1973, (23 U.S.C. § 324 et seq.), (prohibits discrimination on the basis of sex); iv. Section 504 of the Rehabilitation Act of 1973, (29 U.S.C. § 794 et seq.), as amended, (prohibits discrimination on the basis of disability); and 49 CFR Part 27; V. The Age Discrimination Act of 1975, as amended, (42 U.S.C. § 6101 et seq.), (prohibits discrimination on the basis of age); vi. Airport and Airway Improvement Act of 1982, (49 USC § 471, Section 47123), as amended, (prohibits discrimination based on race, creed, color, national origin, or sex); vii. The Civil Rights Restoration Act of 1987, (PL 100-209), (Broadened the scope, coverage and applicability of Title VI of the Civil Rights Act of 1964, The Age Discrimination Act of 1975 and Section 504 of the Rehabilitation Act of 1973, by expanding the definition of the terms "programs or activities" to include all of the programs or activities of the Federal-aid recipients, sub-recipients and contractors, whether such programs or activities are Federally funded or not); viii. Titles II and III of the Americans with Disabilities Act, which prohibit discrimination on the basis of disability in the operation of public entities, public and private transportation systems, places of public accommodation, and certain testing entities (42 U.S.C. §§ 12131-12189) as implemented by Department of Transportation regulations at 49 C.F.R. parts 37 and 38; ix. The Federal Aviation Administration's Non-discrimination statute (49 U.S.C. § 47123) (prohibits discrimination on the basis of race, color, national origin, and sex); X. Executive Order 12898, Federal Actions to Address Environmental Justice in Minority Populations and Low-Income Populations, which ensures Non-discrimination against minority populations by discouraging programs, policies, and activities with disproportionately high and adverse human health or environmental effects on minority and low-income populations; PUBLIC WORKS AGREEMENT - 11 (Over $20K and No Performance Bond) xi. Executive Order 13166, Improving Access to Services for Persons with Limited English Proficiency, and resulting agency guidance, national origin discrimination includes discrimination because of Limited English proficiency (LEP). To ensure compliance with Title VI, you must take reasonable steps to ensure that LEP persons have meaningful access to your programs (70 Fed. Reg. at 74087 to 74100); xii. Title IX of the Education Amendments of 1972, as amended, which prohibits you from discriminating because of sex in education programs or activities (20 U.S.C. 1681 et seq). xiii. Washington Law Against Discrimination (Ch. 49.60 RCW) 7. The submission of the final invoice for this contract will constitute a reaffirmation that the preceding statements were complied with during the course of the contract's performance. By signing below, I agree to fulfill the five requirements referenced above. ,7ohii A Tay a By:John A Payne(Jun 18,2 408:49 PDT) For: Auburn Mechanical Inc Title: Vice President-Service Division Date: Jun 18,2024 PUBLIC WORKS AGREEMENT - 12 (Over $20K and No Performance Bond) CITY OF KENT ADMINISTRATIVE POLICY NUMBER: 1.2 EFFECTIVE DATE: October 20, 2022 SUBJECT: INCLUSIVE CONTRACTING SUPERSEDES: January 1, 1998 APPROVED BY Dana Ralph, Mayor POLICY: Equal employment opportunity and non-discrimination in contracting requirements for the City of Kent will conform to federal and state laws. All contractors, subcontractors, consultants, and suppliers of the City must guarantee equal employment opportunity within their organization and, if holding Agreements with the City amounting to $10,000 or more within any given year, must take the following affirmative steps: 1. Provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 2. Actively consider for promotion and advancement available minorities and women. Further, all contractors, subcontractors, consultants, suppliers, grantees, or subgrantees of the City, regardless of the value of the Agreement, are required to sign the City's Non-Discrimination Policy Declaration, prior to commencing performance. Any contractor, subcontractor, consultant or supplier who willfully disregards the City's nondiscrimination and equal opportunity requirements shall be considered in breach of contract and subject to suspension or termination for all or part of the Agreement. Contract Compliance Officers will be appointed by the Directors of Planning, Parks, and Public Works Departments to coordinate with the City's Title VI coordinator, and perform the following duties for their respective departments. 1. Ensuring that contractors, subcontractors, consultants, and suppliers subject to these regulations are familiar with the regulations and the City's equal employment opportunity policy. 2. Monitoring to assure adherence to federal, state and local laws, policies and guidelines. PUBLIC WORKS AGREEMENT - 13 (Over$20K and No Performance Bond) BIDDER RESPONSIBILITY CRITERIA Certification of Compliance with Wage Payment Statutes This certification is required by state law (RCW 39.04.350(2)) to be submitted to the City before the contract can be awarded. The bidder hereby certifies that, within the three-year period immediately preceding the bid solicitation date (5/9/2024), the bidder is not a 'willful" violator, as defined in RCW 49.48.082, of any provision of chapters 49.46, 49.48, or 49.52 RCW, as determined by a final and binding citation and notice of assessment issued by the Department of Labor and Industries or through a civil judgment entered by a court of limited or general jurisdiction. I certify under penalty of perjury under the laws of the State of Washington that the foregoing is true and correct. AUBURN MECHANICAL, INC. johii A Tame By: John A Payne(Jun 18,2 2408.49 PDT) Signature of Authorized Official* Printed Name: John A Payne Title: Vice President-Service Division Date: Jun 18,2024 City and State: Auburn, WA *If a corporation, proposal must be executed in the corporate name by the president or vice- president (or any other corporate officer accompanied by evidence of authority to sign). If a co- partnership, proposal must be executed by a partner. PUBLIC WORKS AGREEMENT - 14 (Over$20K and No Performance Bond) performanceAuburn / 4-15-2024, rev 5-9-2024 EXHIBIT A Project Location: City of Kent Facilities Half Lion 400 W. Gowe St 2019 W. Meeker St Kent, WA 98032 Kent, WA 98032 Attn: Kris Zorer #253-508-9461 kzorer@kentwa.gov Project Scope• Install client provided natural gas deduct meter (qty 1) and water deduct meter (qty 1) Replace existing gas fired water heater and expansion tank Proiect Inclusions: • Client to determine and purchase preferred gas and water deduct meter • Site walk with crew to discuss water and gas shut down • Install gas deduct meter on 1" branch line by main gas meter • Coordinate gas shut off and restore with Puget Sound Energy • Shut down cold water supply and drain down • Disconnect, drain, and remove existing water heater to gain access to piping where water deduct meter is to be installed • Locate water deduct meter in an area where it can be read easily • Reroute cold water supply to shop so it connects to piping before deduct meter • Set (1) new Rheem G100 20ONG water heater in original location and fill • Set new expansion tank and secure and seismic strapping • Piping and fittings will be replaced as necessary from after existing ball valves to tank • Purge air from system and start up water heater • Water heater venting and gas piping to remain as is • All work to be completed during evening hours • Site clean up and haul away of removed water heater • Puget Sound Energy, Engineering, permitting, and or plan review costs to be passed directly through to client Proiect Exclusions: Engineering, permitting and or plan review. Commodity materials increases after quote expiration (30 days from above date). Good Faith Asbestos and or Lead survey. Repairs to plumbing and or gas systems. Providing gas and or water deduct meters and or read outs for meters. Electrical or communication wiring Auburn Mechanical Presents: $30,200.00 plus sales tax Auburn Mechanical I PO Box 249 Auburn,WA 98071 1 PH: 253-838-9780 1 http://www.auburnmechanical.com Signature: 17ohii A Ta�iie John A Payne(Jun 26,2r2416:00 PDT) Email: jimperkins@auburnmechanical.com Thank you for considering Auburn Mechanical, Inc. for your project. I look forward to your favorable response to this proposal. Please sign and return this quote to me as your authorization to proceed. You can email it back to me at jimperkins@auburnmechanical.com. This quote will be subject to review and subsequent revisions after 30 days. AUBURN MECHANICAL, INC. Thank you, `� Jim Perkins Service Account Manager ACCEPTANCE OF PROPOSAL By signature below, the proposal, scope of work and pricing outlined above by Auburn Mechanical, Inc. (the "agreement") is accepted by (name of entity or individual) ("Buyer"). The person executing this acceptance warrants that he/she has the authority to bind Buyer to the terms and conditions of the -7aagreement. - r JP .ill be paid fee by B yeF rsempletieR of the BuyeF agFees to make payment in full feF all ameunts due undeF this pFepE)sal RE) FRE)Fe than (30) days fellewing tegetheF with aRy taxes due f8F SbIeh W8FIE. BuyeF affees that iRteFest eR past due balaRrses iR the statuteFy amewnt ef twelve peFeent (12%) peF annum shall be added te payments FneFe than fifteen (15) ealenda-F .damys Fd. In the event any action is required to enforce the terms of the agreement or to collect amounts justly due and owing under it, the prevailing party shall be entitled to recover its attorney's fees, costs and interest. The Buyer specifically agrees that the venue of any action to enforce this agreement shall be King County, Washington. AGREED: By Title: Date: Exhibit B Insurance Requirements Insurance Contractor shall procure and maintain for the duration of the Agreement, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees, or subcontractors. A. Minimum Scope of Insurance Contractor shall obtain insurance of the types described below: Commercial General Liability insurance shall be written on Insurance Services Office (ISO) occurrence form CG 00 01 and shall cover liability arising from premises, operations, independent contractors, products-completed operations, personal injury and advertising injury, and liability assumed under an insured contract. The Commercial General Liability insurance shall be endorsed to provide the Aggregate Per Project Endorsement ISO form CG 25 03 11 85. The City shall be named as an insured under the Contractor's Commercial General Liability insurance policy with respect to the work performed for the City using ISO additional insured endorsement CG 20 10 11 85 or a substitute endorsement providing equivalent coverage. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location or the general aggregate limit shall be twice the required occurrence limit. Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this Agreement. This form of insurance will be acceptable if all the Primary and Umbrella or Excess Policies shall provide all the insurance coverages herein required. The Umbrella or Excess policies shall be provided on a true "following form" or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. Automobile Liability insurance providing bodily injury and property damage liability coverage for all automobiles/vehicles used in the performance of this Agreement. This coverage must be on a primary and non-contributory basis only. Coverage shall be written on ISO form CA 00 01, or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. Professional Liability or Errors & Omissions insurance appropriate to the Contractor's profession. Workers' Compensation coverage for the employees of Contractor and subcontractors as required by the Industrial Insurance laws of the State of Washington. B. Minimum Amounts of Insurance Contractor shall maintain the following insurance limits: Commercial General Liability insurance shall be written with limits no less than $2,000,000 per occurrence, $2,000,000 general aggregate, and $2,000,000 products-completed operations aggregate limit. Primary Non-Contributory Additional Insured coverage for the City of Kent, et. al. Stop Gap Liability - $1,000,000/$1,000,000/$1,000,000 Waiver of Subrogation Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1,000,000 per occurrence. Professional Liability or Errors & Omissions insurance shall be written with limits no less than $1,000,000 per occurrence, $1,000,000 general aggregate. If the Contractor maintains broader coverage and/or higher limits than the minimums shown above, the City requires and shall be entitled to the broader coverage and/or the higher limits maintained by the Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. The above policy limits may be obtained with excess liability (umbrella) insurance. C. Other Insurance Provisions The insurance policies are to contain, or be endorsed to contain, the following provisions: 1. Contractor's insurance coverage shall be primary insurance with respect to the City. Any insurance, self-insurance, or insurance pool coverage maintained by the City shall be in excess of the Contractor's insurance policies and shall not contribute to the Contractor's insurance policies. 2. Contractor's insurer must deliver or mail written notice of cancellation to the named insured at least forty-five (45) days before the effective date of the cancellation. The Contractor's insurance policy shall include an endorsement that provides the City with written notice of cancellation forty-five (45) days before the effective date of the cancellation. If Contractor's insurer fails to provide the City with a copy of the notice of cancellation endorsement, the Contractor must notify the City of any cancellation, nonrenewal or termination within two (2) business days of their receipt of such notice. 3. The City of Kent shall be named as an additional insured on all policies (except Professional Liability) with respect to work performed by or on behalf of the Contractor and a copy of the endorsement naming the City as an additional insured shall be attached to the Certificate of Insurance. The City reserves the right to receive a certified copy of all required insurance policies. The Contractor's Commercial General Liability insurance shall also contain a clause stating that coverage shall apply separately to each insured against whom claims are made or suit is brought, except with respect to the limits of the insurer's liability. D. Acceptability of Insurers Insurance is to be placed with insurers with a current A.M. Best rating of not less than A:VII. E. Verification of Coverage Contractor shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the insurance requirements of the Contractor before commencement of the work. The City waives no rights, and the Contractor is not excused from performance if Contractor fails to provide the City with a copy of the endorsement naming the City as a Primary Non-Contributory Additional Insured. F. Subcontractors Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor. All coverage for subcontractors shall be subject to all the same insurance requirements as stated herein for the Contractor. AUBUMEC-01 MJOHNSON ACORO CERTIFICATE OF LIABILITY INSURANCE DATE 1 6/14/214/2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Hub International Northwest LLC PHONE FAX PO Box 3018 (A/C,No,EXt): (425)489-4500 (A/C,No):(425)485-8489 Bothell,WA 98041 ADDRESS:now.info@hubinternational.com INSURERS AFFORDING COVERAGE NAIC# INSURER A:American Guarantee&Liability Insurance Company 26247 INSURED INSURER B:Zurich American Insurance Company 16535 Auburn Mechanical, Inc. INSURER C:Vantage Risk Specialty Insurance Company 16275 2623 W.Valley Hwy.N. INSURER D: Auburn,WA 98001 INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF POLICY EXP LIMITS LTR INSD WVD MM DD YYYY MM DD YY A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR GLO 3600359-00 10/1/2023 10/1/2024 DAMAGE TO RENTED 1,000,000 X X PREMISES Ea occurrence $ MED EXP(Any oneperson) $ 15,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY�X JECOT- LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT 1,000,000 Ea accident X ANY AUTO X X BAP 3600360-00 10/1/2023 10/1/2024 BODILY INJURY Perperson) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY Per accident $ HIRED NON-OWNED PROPERTY DAMAGE AUTOS ONLY AUTOS ONLY Per accident $ A X UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ 1,000,000 EXCESS LIAB CLAIMS-MADE X X SXS 3432740-00 10/1/2023 10/1/2024 AGGREGATE $ 1,000,000 DED X RETENTION$ 0 $ B WORKERS COMPENSATION PER X OTH- AND EMPLOYERS'LIABILITY STATUTE ER YIN WC 3600357-00 10/1/2023 10/1/2024 1,000,000 ANY PROPRIETOR/PARTNER/EXECUTIVE ❑ E.L.EACH ACCIDENT $ OFFICato/ry in NE)EXCLUDED? N/A 1,000,000 E.L.DISEASE-EA EMPLOYEE $ If yes,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ C Poll/Prof P03CP0000044060 10/1/2023 10/1/2024 OCC/AGG: 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) City of Kent is included as Additional Insured,coverage is primary and non-contributory and waiver of subrogation applies per the attached forms/endorsements.Professional Liability N/A to Additional Insured.Umbrella follows form over GL,AUTO and Employers Liability. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Kent Facilities THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Y ACCORDANCE WITH THE POLICY PROVISIONS. 220 4th Ave South Kent,WA 98032 AUTHORIZED REPRESENTATIVE ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD Additional Insured — Automatic — Owners, Lessees Or Z U RI C H Contractors THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Policy No. GLO 3600359 -00 Effective Date: 10/01/2023 This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part A. Section II —Who Is An Insured is amended to include as an additional insured any person or organization whom you are required to add as an additional insured under a written contract or written agreement executed by you, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" and subject to the following: 1. If such written contract or written agreement specifically requires that you provide that the person or organization be named as an additional insured under one or both of the following endorsements: a. The Insurance Services Office (ISO) ISO CG 20 10 (10/01 edition); or b. The ISO CG 20 37 (10/01 edition), such person or organization is then an additional insured with respect to such endorsement(s), but only to the extent that"bodily injury", "property damage" or"personal and advertising injury" arises out of: (1) Your ongoing operations, with respect to Paragraph 1.a. above; or (2) "Your work", with respect to Paragraph 1.b. above, which is the subject of the written contract or written agreement. However, solely with respect to this Paragraph 1., insurance afforded to such additional insured: (a) Only applies if the"bodily injury", "property damage"or"personal and advertising injury"offense occurs during the policy period and subsequent to your execution of the written contract or written agreement; and (b) Does not apply to "bodily injury" or"property damage" caused by "your work" and included within the "products-completed operations hazard" unless the written contract or written agreement specifically requires that you provide such coverage to such additional insured. 2. If such written contract or written agreement specifically requires that you provide that the person or organization be named as an additional insured under one or both of the following endorsements: a. The Insurance Services Office (ISO) ISO CG 20 10 (07/04 edition); or b. The ISO CG 20 37 (07/04 edition), such person or organization is then an additional insured with respect to such endorsement(s), but only to the extent that"bodily injury", "property damage" or"personal and advertising injury" is caused, in whole or in part, by: (1) Your acts or omissions; or (2) The acts or omissions of those acting on your behalf, U-GL-2162-A CW(02/19) Page 1 of 4 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. in the performance of: (a) Your ongoing operations, with respect to Paragraph 2.a. above; or (b) "Your work" and included in the "products-completed operations hazard", with respect to Paragraph 2.b. above, which is the subject of the written contract or written agreement. However, solely with respect to this Paragraph 2., insurance afforded to such additional insured: (i) Only applies if the "bodily injury", "property damage" or "personal and advertising injury" offense occurs during the policy period and subsequent to your execution of the written contract or written agreement; and (ii) Does not apply to "bodily injury" or"property damage" caused by "your work" and included within the "products-completed operations hazard" unless the written contract or written agreement specifically requires that you provide such coverage to such additional insured. 3. If neither Paragraph 1. nor Paragraph 2. above apply and such written contract or written agreement requires that you provide that the person or organization be named as an additional insured: a. Under the ISO CG 20 10 (04/13 edition, any subsequent edition or if no edition date is specified); or b. With respect to ongoing operations (if no form is specified), such person or organization is then an additional insured only to the extent that "bodily injury", "property damage" or"personal and advertising injury" is caused, in whole or in part by: (1) Your acts or omissions; or (2) The acts or omissions of those acting on your behalf, in the performance of your ongoing operations,which is the subject of the written contract or written agreement. However, solely with respect to this Paragraph 3., insurance afforded to such additional insured: (a) Only applies to the extent permitted by law; (b) Will not be broader than that which you are required by the written contract or written agreement to provide for such additional insured; and (c) Only applies if the"bodily injury", "property damage"or"personal and advertising injury"offense occurs during the policy period and subsequent to your execution of the written contract or written agreement. 4. If neither Paragraph 1. nor Paragraph 2. above apply and such written contract or written agreement requires that you provide that the person or organization be named as an additional insured: a. Under the ISO CG 20 37 (04/13 edition, any subsequent edition or if no edition date is specified); or b. With respect to the"products-completed operations hazard" (if no form is specified), such person or organization is then an additional insured only to the extent that"bodily injury"or"property damage" is caused, in whole or in part by "your work" and included in the "products-completed operations hazard", which is the subject of the written contract or written agreement. However, solely with respect to this Paragraph 4., insurance afforded to such additional insured: (1) Only applies to the extent permitted by law; (2) Will not be broader than that which you are required by the written contract or written agreement to provide for such additional insured; (3) Only applies if the "bodily injury" or "property damage" occurs during the policy period and subsequent to your execution of the written contract or written agreement; and (4) Does not apply to "bodily injury" or "property damage" caused by "your work" and included within the "products-completed operations hazard" unless the written contract or written agreement specifically requires that you provide such coverage to such additional insured. U-GL-2162-A CW(02/19) Page 2 of 4 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. B. Solely with respect to the insurance afforded to any additional insured referenced in Section A. of this endorsement, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or failure to render, any professional architectural, engineering or surveying services including: 1. The preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or 2. Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the 'occurrence"which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional architectural, engineering or surveying services. C. Solely with respect to the coverage provided by this endorsement, the following is added to Paragraph 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit of Section IV—Commercial General Liability Conditions: The additional insured must see to it that: (1) We are notified as soon as practicable of an 'occurrence" or offense that may result in a claim; (2) We receive written notice of a claim or"suit" as soon as practicable; and (3) A request for defense and indemnity of the claim or"suit"will promptly be brought against any policy issued by another insurer under which the additional insured may be an insured in any capacity. This provision does not apply to insurance on which the additional insured is a Named Insured if the written contract or written agreement requires that this coverage be primary and non-contributory. D. Solely with respect to the coverage provided by this endorsement: 1. The following is added to the Other Insurance Condition of Section IV — Commercial General Liability Conditions: Primary and Noncontributory insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured provided that: a. The additional insured is a Named Insured under such other insurance; and b. You are required by written contract or written agreement that this insurance be primary and not seek contribution from any other insurance available to the additional insured. 2. The following paragraph is added to Paragraph 4.b. of the Other Insurance Condition under Section IV — Commercial General Liability Conditions: This insurance is excess over: Any of the other insurance,whether primary, excess, contingent or on any other basis, available to an additional insured, in which the additional insured on our policy is also covered as an additional insured on another policy providing coverage for the same 'occurrence", offense, claim or "suit'. This provision does not apply to any policy in which the additional insured is a Named Insured on such other policy and where our policy is required by a written contract or written agreement to provide coverage to the additional insured on a primary and non- contributory basis. E. This endorsement does not apply to an additional insured which has been added to this Coverage Part by an endorsement showing the additional insured in a Schedule of additional insureds, and which endorsement applies specifically to that identified additional insured. F. Solely with respect to the insurance afforded to an additional insured under Paragraph A.3. or Paragraph A.4. of this endorsement, the following is added to Section III — Limits Of Insurance: Additional Insured—Automatic—Owners, Lessees Or Contractors Limit The most we will pay on behalf of the additional insured is the amount of insurance: U-GL-2162-A CW(02/19) Page 3 of 4 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. 1. Required by the written contract or written agreement referenced in Section A. of this endorsement; or 2. Available under the applicable Limits of Insurance shown in the Declarations, whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. All other terms, conditions, provisions and exclusions of this policy remain the same. U-GL-2162-A CW(02/19) Page 4 of 4 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. POLICY NUMBER: GLO 3600359-00 COMMERCIAL GENERAL LIABILITY CG 25 03 05 09 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED CONSTRUCTION PROJECT(S) GENERAL AGGREGATE LIMIT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Construction Project(s): Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. For all sums which the insured becomes legally 3. Any payments made under Coverage A for obligated to pay as damages caused by 'occur- damages or under Coverage C for medical rences" under Section I —Coverage A, and for all expenses shall reduce the Designated Con- medical expenses caused by accidents under struction Project General Aggregate Limit for Section I — Coverage C, which can be attributed that designated construction project. Such only to ongoing operations at a single designated payments shall not reduce the General Ag- construction project shown in the Schedule gregate Limit shown in the Declarations nor above: shall they reduce any other Designated Con- 1. A separate Designated Construction Project struction Project General Aggregate Limit for General Aggregate Limit applies to each des- any other designated construction project ignated construction project, and that limit is shown in the Schedule above. equal to the amount of the General Aggregate 4. The limits shown in the Declarations for Each Limit shown in the Declarations. Occurrence, Damage To Premises Rented To 2. The Designated Construction Project General You and Medical Expense continue to apply. Aggregate Limit is the most we will pay for the However, instead of being subject to the sum of all damages under Coverage A, ex- General Aggregate Limit shown in the Decla- cept damages because of "bodily injury" or rations, such limits will be subject to the appli- "property damage" included in the "products- cable Designated Construction Project Gen- completed operations hazard", and for medi- eral Aggregate Limit. cal expenses under Coverage C regardless of the number of: a. Insureds; b. Claims made or"suits" brought; or c. Persons or organizations making claims or bringing "suits". CG 25 03 05 09 © Insurance Services Office, Inc., 2008 Page 1 of 2 Wolters Kluwer Financial Services I Uniform FormsTI B. For all sums which the insured becomes legally C. When coverage for liability arising out of the obligated to pay as damages caused by 'occur- "products-completed operations hazard" is pro- rences" under Section I —Coverage A, and for all vided, any payments for damages because of medical expenses caused by accidents under "bodily injury" or "property damage" included in Section I — Coverage C, which cannot be at- the "products-completed operations hazard" will tributed only to ongoing operations at a single reduce the Products-completed Operations Ag- designated construction project shown in the gregate Limit, and not reduce the General Ag- Schedule above: gregate Limit nor the Designated Construction 1. Any payments made under Coverage A for Project General Aggregate Limit. damages or under Coverage C for medical D. If the applicable designated construction project expenses shall reduce the amount available has been abandoned, delayed, or abandoned under the General Aggregate Limit or the and then restarted, or if the authorized contract- Products-completed Operations Aggregate ing parties deviate from plans, blueprints, de- Limit, whichever is applicable; and signs, specifications or timetables, the project will 2. Such payments shall not reduce any Desig- still be deemed to be the same construction pro- nated Construction Project General Aggre- ject. gate Limit. E. The provisions of Section III — Limits Of Insur- ance not otherwise modified by this endorsement shall continue to apply as stipulated. Page 2 of 2 © Insurance Services Office, Inc., 2008 CG 25 03 05 09 0 Waiver Of Subrogation (Blanket) Endorsement Z U RI C H Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff.Date of End. Producer AddT Prem Return Prem. GLO 3600359-00 10/01/2023 10/01/2024 10/01/2023 $ $ THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: If you are required by a written contract or agreement,which is executed before a loss,to waive your rights of recovery from oth- ers,we agree to waive our rights of recovery. This waiver of rights shall not be construed to be a waiver with respect to any other operations in which the insured has no contractual interest. U-GL-925-B CW(12/01) Pagel of 1 Coverage Extension Endorsement ZURICH THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Policy No. BAP 3600360 -00 Effective Date: 10/01/2023 This endorsement modifies insurance provided under the: Business Auto Coverage Form Motor Carrier Coverage Form A. Amended Who Is An Insured 1. The following is added to the Who Is An Insured Provision in Section II—Covered Autos Liability Coverage: The following are also "insureds": a. Any "employee" of yours is an "insured" while using a covered "auto" you don't own, hire or borrow for acts performed within the scope of employment by you. Any"employee"of yours is also an"insured"while operating an "auto" hired or rented under a contract or agreement in an "employee's" name, with your permission, while performing duties related to the conduct of your business. b. Anyone volunteering services to you is an "insured"while using a covered "auto"you don't own, hire or borrow to transport your clients or other persons in activities necessary to your business. c. Anyone else who furnishes an "auto" referenced in Paragraphs A.1.a. and A.1.b. in this endorsement. d. Where and to the extent permitted by law, any person(s) or organization(s) where required by written contract or written agreement with you executed prior to any "accident", including those person(s) or organization(s) directing your work pursuant to such written contract or written agreement with you, provided the "accident" arises out of operations governed by such contract or agreement and only up to the limits required in the written contract or written agreement, or the Limits of Insurance shown in the Declarations, whichever is less. 2. The following is added to the Other Insurance Condition in the Business Auto Coverage Form and the Other Insurance— Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form: Coverage for any person(s) or organization(s), where required by written contract or written agreement with you executed prior to any "accident", will apply on a primary and non-contributory basis and any insurance maintained by the additional "insured" will apply on an excess basis. However, in no event will this coverage extend beyond the terms and conditions of the Coverage Form. B. Amendment—Supplementary Payments Paragraphs a.(2) and a.(4) of the Coverage Extensions Provision in Section II —Covered Autos Liability Coverage are replaced by the following: (2) Up to $5,000 for the cost of bail bonds (including bonds for related traffic law violations) required because of an "accident"we cover. We do not have to furnish these bonds. (4) All reasonable expenses incurred by the"insured"at our request, including actual loss of earnings up to$500 a day because of time off from work. C. Fellow Employee Coverage The Fellow Employee Exclusion contained in Section II —Covered Autos Liability Coverage does not apply. U-CA-424-H CW(10/21) Page 1 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. D. Driver Safety Program Liability and Physical Damage Coverage 1. The following is added to the Racing Exclusion in Section II—Covered Autos Liability Coverage: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. 2. The following is added to Paragraph 2. in B. Exclusions of Section III — Physical Damage Coverage of the Business Auto Coverage Form and Paragraph 2.b. in B. Exclusions of Section IV— Physical Damage Coverage of the Motor Carrier Coverage Form: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. E. Lease or Loan Gap Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Lease Or Loan Gap Coverage In the event of a total "loss"to a covered "auto", we will pay any unpaid amount due on the lease or loan for a covered "auto", less: a. Any amount paid under the Physical Damage Coverage Section of the Coverage Form; and b. Any: (1) Overdue lease or loan payments at the time of the 'loss"; (2) Financial penalties imposed under a lease for excessive use, abnormal wear and tear or high mileage; (3) Security deposits not returned by the lessor; (4) Costs for extended warranties, credit life insurance, health, accident or disability insurance purchased with the loan or lease; and (5) Carry-over balances from previous leases or loans. F. Towing and Labor Paragraph A.2. of the Physical Damage Coverage Section is replaced by the following: We will pay up to$75 for towing and labor costs incurred each time a covered "auto"that is a "private passenger type", light truck or medium truck is disabled. However, the labor must be performed at the place of disablement. As used in this provision, "private passenger type"means a private passenger or station wagon type"auto"and includes an "auto" of the pickup or van type if not used for business purposes. G. Extended Glass Coverage The following is added to Paragraph A.3.a. of the Physical Damage Coverage Section: If glass must be replaced, the deductible shown in the Declarations will apply. However, if glass can be repaired and is actually repaired rather than replaced,the deductible will be waived. You have the option of having the glass repaired rather than replaced. H. Hired Auto Physical Damage—Increased Loss of Use Expenses The Coverage Extension for Loss Of Use Expenses in the Physical Damage Coverage Section is replaced by the following: Loss Of Use Expenses For Hired Auto Physical Damage, we will pay expenses for which an "insured" becomes legally responsible to pay for loss of use of a vehicle rented or hired without a driver under a written rental contract or written rental agreement. We will pay for loss of use expenses if caused by: (1) Other than collision only if the Declarations indicate that Comprehensive Coverage is provided for any covered "auto"; U-CA-424-H CW(10/21) Page 2 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. (2) Specified Causes Of Loss only if the Declarations indicate that Specified Causes Of Loss Coverage is provided for any covered "auto"; or (3) Collision only if the Declarations indicate that Collision Coverage is provided for any covered "auto". However, the most we will pay for any expenses for loss of use is $100 per day, to a maximum of$3000. I. Personal Effects Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Personal Effects Coverage a. We will pay up to $750 for"loss"to personal effects which are: (1) Personal property owned by an "insured"; and (2) In or on a covered "auto". b. Subject to Paragraph a. above, the amount to be paid for"loss"to personal effects will be based on the lesser of: (1) The reasonable cost to replace; or (2) The actual cash value. c. The coverage provided in Paragraphs a. and b. above, only applies in the event of a total theft of a covered "auto". No deductible applies to this coverage. However,we will not pay for"loss"to personal effects of any of the following: (1) Accounts, bills, currency, deeds, evidence of debt, money, notes, securities, or commercial paper or other documents of value. (2) Bullion, gold,silver, platinum, or other precious alloys or metals;furs or fur garments;jewelry,watches, precious or semi-precious stones. (3) Paintings, statuary and other works of art. (4) Contraband or property in the course of illegal transportation or trade. (5) Tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. Any coverage provided by this Provision is excess over any other insurance coverage available for the same 'loss". J. Tapes, Records and Discs Coverage 1. The Exclusion in Paragraph B.4.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph B.2.c. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply. 2. The following is added to Paragraph 1.a.Comprehensive Coverage under the Coverage Provision of the Physical Damage Coverage Section: We will pay for "loss" to tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. We will pay only if the tapes, records, discs or other similar audio, visual or data electronic devices: (a) Are the property of an "insured"; and (b) Are in a covered "auto" at the time of"loss". The most we will pay for such"loss"to tapes, records,discs or other similar devices is$500. The Physical Damage Coverage Deductible Provision does not apply to such "loss". K. Airbag Coverage The Exclusion in Paragraph B.3.a. of Section III— Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph B.4.a. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply to the accidental discharge of an airbag. L. Two or More Deductibles The following is added to the Deductible Provision of the Physical Damage Coverage Section: U-CA-424-H CW(10/21) Page 3 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. If an accident is covered both by this policy or Coverage Form and by another policy or Coverage Form issued to you by us, the following applies for each covered "auto" on a per vehicle basis: 1. If the deductible on this policy or Coverage Form is the smaller(or smallest) deductible, it will be waived; or 2. If the deductible on this policy or Coverage Form is not the smaller(or smallest)deductible, it will be reduced by the amount of the smaller(or smallest)deductible. M. Temporary Substitute Autos— Physical Damage 1. The following is added to Section I—Covered Autos: Temporary Substitute Autos— Physical Damage If Physical Damage Coverage is provided by this Coverage Form on your owned covered "autos", the following types of vehicles are also covered "autos"for Physical Damage Coverage: Any "auto" you do not own when used with the permission of its owner as a temporary substitute for a covered "auto"you do own but is out of service because of its: 1. Breakdown; 2. Repair; 3. Servicing; 4. "Loss"; or 5. Destruction. 2. The following is added to the Paragraph A. Coverage Provision of the Physical Damage Coverage Section: Temporary Substitute Autos— Physical Damage We will pay the owner for"loss" to the temporary substitute "auto" unless the "loss" results from fraudulent acts or omissions on your part. If we make any payment to the owner, we will obtain the owner's rights against any other party. The deductible for the temporary substitute "auto" will be the same as the deductible for the covered "auto" it replaces. N. Amended Duties In The Event Of Accident, Claim, Suit Or Loss Paragraph a. of the Duties In The Event Of Accident, Claim, Suit Or Loss Condition is replaced by the following: a. In the event of"accident", claim, "suit"or"loss", you must give us or our authorized representative prompt notice of the "accident", claim, "suit" or"loss". However, these duties only apply when the "accident", claim, "suit" or"loss" is known to you (if you are an individual), a partner(if you are a partnership), a member(if you are a limited liability company)or an executive officer or insurance manager(if you are a corporation). The failure of any agent, servant or employee of the "insured" to notify us of any "accident", claim, "suit" or"loss" shall not invalidate the insurance afforded by this policy. Include, as soon as practicable: (1) How, when and where the"accident" or"loss"occurred and if a claim is made or"suit" is brought,written notice of the claim or"suit" including, but not limited to, the date and details of such claim or"suit"; (2) The "insured's" name and address; and (3) To the extent possible, the names and addresses of any injured persons and witnesses. If you report an"accident",claim, "suit"or"loss"to another insurer when you should have reported to us,your failure to report to us will not be seen as a violation of these amended duties provided you give us notice as soon as practicable after the fact of the delay becomes known to you. O. Waiver of Transfer Of Rights Of Recovery Against Others To Us The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: U-CA-424-H CW(10/21) Page 4 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. This Condition does not apply to the extent required of you by a written contract, executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises out of operations contemplated by such contract. This waiver only applies to the person or organization designated in the contract. P. Employee Hired Autos— Physical Damage Paragraph b. of the Other Insurance Condition in the Business Auto Coverage Form and Paragraph f. of the Other Insurance— Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form are replaced by the following: For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own: (1) Any covered "auto"you lease, hire, rent or borrow; and (2) Any covered "auto" hired or rented under a written contract or written agreement entered into by an "employee" or elected or appointed official with your permission while being operated within the course and scope of that "employee's" employment by you or that elected or appointed official's duties as respect their obligations to you. However, any"auto"that is leased, hired, rented or borrowed with a driver is not a covered "auto". Q. Unintentional Failure to Disclose Hazards The following is added to the Concealment, Misrepresentation Or Fraud Condition: However, we will not deny coverage under this Coverage Form if you unintentionally: (1) Fail to disclose any hazards existing at the inception date of this Coverage Form; or (2) Make an error, omission, improper description of"autos" or other misstatement of information. You must notify us as soon as possible after the discovery of any hazards or any other information that was not provided to us prior to the acceptance of this policy. R. Hired Auto—World Wide Coverage Paragraph 7.b.(5) of the Policy Period, Coverage Territory Condition is replaced by the following: (5) Anywhere else in the world if a covered "auto" is leased, hired, rented or borrowed for a period of 60 days or less, S. Bodily Injury Redefined The definition of"bodily injury" in the Definitions Section is replaced by the following: "Bodily injury" means bodily injury, sickness or disease, sustained by a person including death or mental anguish, resulting from any of these at any time. Mental anguish means any type of mental or emotional illness or disease. T. Expected Or Intended Injury The Expected Or Intended Injury Exclusion in Paragraph B. Exclusions under Section II —Covered Auto Liability Coverage is replaced by the following: Expected Or Intended Injury "Bodily injury"or"property damage" expected or intended from the standpoint of the"insured". This exclusion does not apply to"bodily injury"or"property damage" resulting from the use of reasonable force to protect persons or property. U. Physical Damage—Additional Temporary Transportation Expense Coverage Paragraph A.4.a. of Section III— Physical Damage Coverage is replaced by the following: 4. Coverage Extensions a. Transportation Expenses We will pay up to $50 per day to a maximum of$1,000 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. We will pay for temporary transportation expenses incurred during the period beginning 48 hours after the theft and ending, regardless of the policy's expiration, when the covered "auto" is returned to use or we pay for its "loss". U-CA-424-H CW(10/21) Page 5 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. V. Replacement of a Private Passenger Auto with a Hybrid or Alternative Fuel Source Auto The following is added to Paragraph A. Coverage of the Physical Damage Coverage Section: In the event of a total "loss" to a covered "auto" of the private passenger type that is replaced with a hybrid "auto" or "auto" powered by an alternative fuel source of the private passenger type, we will pay an additional 10% of the cost of the replacement"auto", excluding tax, title, license, other fees and any aftermarket vehicle upgrades, up to a maximum of$2500. The covered "auto" must be replaced by a hybrid "auto" or an "auto" powered by an alternative fuel source within 60 calendar days of the payment of the "loss"and evidenced by a bill of sale or new vehicle lease agreement. To qualify as a hybrid "auto", the "auto" must be powered by a conventional gasoline engine and another source of propulsion power. The other source of propulsion power must be electric, hydrogen, propane, solar or natural gas, either compressed or liquefied. To qualify as an "auto" powered by an alternative fuel source, the "auto" must be powered by a source of propulsion power other than a conventional gasoline engine. An "auto" solely propelled by biofuel, gasoline or diesel fuel or any blend thereof is not an "auto" powered by an alternative fuel source. W. Return of Stolen Automobile The following is added to the Coverage Extension Provision of the Physical Damage Coverage Section: If a covered "auto" is stolen and recovered,we will pay the cost of transport to return the"auto"to you. We will pay only for those covered "autos"for which you carry either Comprehensive or Specified Causes of Loss Coverage. All other terms, conditions, provisions and exclusions of this policy remain the same. U-CA-424-H CW(10/21) Page 6 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Policy 4 SXS 3432740 - 00 Straight Excess Liability Policy Z U RI C H There are provisions in this policy that restrict coverage. Read the entire policy carefully to determine rights, duties and what is and is not covered. Throughout this policy, the words "you" and "your' refer to the Named Insured shown in the Declarations, and any other person or organization qualifying as such in underlying insurance. The words "we", "us" and "our" refer to the company providing this insurance. The word "insured(s)" means any person or organization qualifying as such in underlying insurance but only to the extent and within the scope for which such "insured(s)"qualify for coverage in underlying insurance. Words and phrases that are printed in bold-face type are defined in this policy. These definitions are found in SECTION VI. DEFINITIONS of this policy or in the specific policy provision where they appear. In consideration of the payment of the premium and in reliance upon the statements in the Declarations and in accordance with the provisions of this policy, we agree with you to provide coverage as follows: Insuring Agreements SECTION I. COVERAGE A. We will pay on behalf of the insured those damages covered by this insurance in excess of the total Applicable Limits of underlying insurance. This policy includes: 1. The terms and conditions of underlying insurance to the extent such terms and conditions are not inconsistent or do not conflict with the terms and conditions referred to in Paragraph 2. below; and 2. The terms and conditions that apply to this policy. B. Notwithstanding anything to the contrary contained in Paragraph A. above, if underlying insurance does not apply to damages for reasons other than exhaustion of total applicable limits of insurance by payment of loss, then this policy does not apply to such damages. C. The amount we will pay under this policy is limited as described in SECTION II. LIMITS OF INSURANCE. D. We have no obligation under this policy with respect to any settlement made without our consent. E. The insurance afforded under this policy applies to bodily injury or property damage only if prior to the Policy Period, neither you nor any authorized person knew that the bodily injury or property damage had occurred, in whole or in part. If you or any authorized person knew, prior to the Policy Period, that the bodily injury or property damage occurred, then any continuation, change or resumption of such bodily injury or property damage during or after the Policy Period will be deemed to have been known prior to the Policy Period. Bodily injury or property damage which occurs during the Policy Period and was not, prior to the Policy Period, known to have occurred by you or any authorized person includes any continuation, change or resumption of that bodily injury or property damage after the Policy Period; and Bodily injury or property damage will be deemed to have been known to have occurred at the earliest time when you or any authorized person: 1. Reports all or any part of, the bodily injury or property damage to us or any other insurer; 2. Receives a written or verbal demand or claim for damages because of the bodily injury or property damage; or 3. Becomes aware by any other means that bodily injury or property damage has occurred or has begun to occur. U-SXS-100-A CW(09/11) Page 1 of 10 SECTION II. LIMITS OF INSURANCE A. The Limits of Insurance shown in the Declarations and the rules below describe the most we will pay regardless of the number of: 1. Insureds; 2. Claims made or suits brought; or 3. Persons or organizations making claims or bringing suits. B. The Limits of Insurance of this policy will apply as follows: 1. The limit shown in Item 4.13. of the Declarations for the Other Aggregate is the most we will pay for all loss to which this policy applies, except for: a. Loss covered under the products/completed operations hazard; and b. Loss covered in underlying insurance to which no underlying aggregate limit applies. In addition, if a policy listed in the Schedule of Underlying Insurance contains aggregate limits, other than an aggregate limit applying to the products/completed operations hazard, the Other Aggregate limit shown in Item 4.113. of the Declarations will apply in the same manner as such other aggregate limits of each policy listed in the Schedule of Underlying Insurance. 2. The limit shown in Item 4.C. of the Declarations for the Products/Completed Operations Aggregate is the most we will pay for all loss to which this policy applies under the products/completed operations hazard. 3. Subject to Paragraph 13.1. or B.2. above, whichever applies, the limit shown in Item 4.A. of the Declarations for Occurrence is the most we will pay for all loss arising out of any one occurrence to which this policy applies. C. Coverage applies only in excess of the greater of the actual limits of insurance of underlying insurance or the Applicable Limits of insurance shown in the Schedule of Underlying Insurance forming a part of this policy. D. The Limits of Insurance of this policy apply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the beginning of the Policy Period shown in the Declarations, unless the Policy Period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the preceding period for purposes of determining the Limits of Insurance. E. Subject to Paragraphs B.1., B.2., B.3. and C.above: 1. If the limits of underlying insurance have been reduced solely by payment of loss for which coverage is afforded under this policy, this policy will drop down to become immediately excess of the reduced underlying limit; or 2. If the limits of underlying insurance have been exhausted solely by payment of loss for which coverage is afforded under this policy, this policy will continue in force as underlying insurance. SECTION III. DEFENSE AND SUPPLEMENTARY PAYMENTS A. We have the right and duty to assume control of the investigation and settlement of any claim, or defense of any suit against the insured for damages covered by this policy when the applicable limit of underlying insurance and other insurance has been exhausted by payment of loss for which coverage is afforded under this policy. B. In those circumstances where Paragraph A. above applies we will pay our expenses and the following to the extent that they are not included in underlying insurance: 1. Up to $2,000 for the cost of bail bonds. We do not have to furnish these bonds. 2. The cost of bonds to release attachments, but only for bond amounts within the amount of insurance available. We do not have to furnish these bonds. 3. Reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or suit, including actual loss of earnings because of time off from work. 4. All court costs taxed against the insured in the suit. However, these payments do not include attorneys' fees or attorneys' expenses taxed against the insured. U-SXS-100-A CW(09/11) Page 2 of 10 5. Pre-judgment interest awarded against the insured on that part of the judgment we pay. However, if we make an offer to pay the applicable limit of insurance, we will not pay any pre-judgment interest based on that period of time after the offer. 6. All interest on the full amount of any judgment that accrues after entry of the judgment and before we have paid, offered to pay, or deposited in court that part of the judgment that is within the applicable limits of insurance. When our expenses and the payments described in this paragraph above are not included in the definition of loss, they will not reduce the Limits of Insurance. C. In those circumstances where Paragraph A. above does not apply, we do not have the duty to assume control of the investigation and settlement of any claim, or defense of any suit against the insured. We do, however, have the right to participate in the investigation and settlement of any claim, or defense of any suit that we feel may create liability on our part under the terms of this policy. If we exercise this right, we will do so at our expense. We will not investigate and settle any claim, or defend any suit after we have exhausted the applicable Limit of Insurance as shown in Item 4. of the Declarations. If we are prevented by law from carrying out the provisions of Paragraph A. above, we will pay any expense incurred with our consent. SECTION IV. EXCLUSIONS This policy does not apply to any liability, damage, loss, cost or expense: ASBESTOS A. Arising out of or relating in any way to: 1. Asbestos or which would not have occurred in whole or in part but for the actual, alleged or threatened discharge, dispersal, release, leakage, leaching,friability, flaking escape or presence of asbestos, regardless of whether any other cause, event, material or product contributed concurrently or in any sequence to the injury or damage; or 2. Any: a. Request, demand, order, statutory or regulatory requirement, direction or determination, that any insured or others test for, investigate, monitor, clean up, remove, study, contain, treat, encapsulate, control or take any other action regarding asbestos; or b. Claim or suit for damages arising out of or relating in any way to any request, demand, order, statutory or regulatory requirement, direction or determination than any insured or others test for, investigate, monitor, clean up, remove, study, contain, treat, encapsulate, control or take any other action regarding asbestos. POLLUTION B. 1. Arising directly or indirectly out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of pollutants: a. At or from any premises, site or location which is or was at any time owned or occupied by, or rented or loaned to, any insured. However, this subparagraph does not apply to: (1) Bodily injury if sustained within a building and caused by smoke, fumes, vapor or soot produced by or originating from equipment that is used to heat, cool or dehumidify the building, or equipment that is used to heat water for personal use, by the building's occupants or their guests; (2) Bodily injury or property damage for which you may be held liable, if you are a contractor, and the owner or lessee of such premises, site or location has been added to underlying insurance as an additional insured with respect to your ongoing operations performed for that additional insured at that premises, site or location and such premises, site or location is not and never was owned or occupied by, or rented or loaned to, any insured, other than that additional insured; or (3) Bodily injury or property damage arising out of heat, smoke or fumes from a hostile fire; b. At or from any premises, site or location which is or was at any time used by or for any insured or others for the handling, storage, disposal, processing or treatment of waste; U-SXS-100-A CW(09/11) Page 3 of 10 c. Which are or were at any time transported, handled, stored, treated, disposed of, or processed as waste by or for any insured or any person or organization for whom you maybe legally responsible; or d. At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the pollutants are brought on or to the premises, site or location in connection with such operations by such insured, contractor or subcontractor. However, this subparagraph does not apply to: (1) Bodily injury or property damage arising out of the escape of fuels, lubricants or other operating fluids which are needed to perform the normal electrical, hydraulic or mechanical functions necessary for the operation of mobile equipment or its parts, if such fuels, lubricants or other operating fluids escape from a vehicle part designed to hold, store or receive them. This exception does not apply if the bodily injury or property damage arises out of the intentional discharge, dispersal or release of the fuels, lubricants or other operating fluids, or if such fuels, lubricants or other operating fluids are brought on or to the premises, site or location with the intent that they be discharged, dispersed or released as part of the operations being performed by such insured, contractor or subcontractor; (2) Bodily injury or property damage sustained within a building and caused by the release of gases, fumes or vapors from materials brought into that building in connection with operations being performed by you or on your behalf by a contractor or subcontractor; or (3) Bodily injury or property damage arising out of heat, smoke or fumes from a hostile fire. e. At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the operations are to test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, pollutants. f. That are, or that are contained in any property that is: (1) Being transported or towed by, handled, or handled for movement into, onto or from, any auto for which coverage is provided by underlying insurance; (2) Otherwise in the course of transit by or on behalf of any insured; or (3) Being stored, disposed of, treated or processed in or upon any auto. However, this subparagraph f.does not apply to bodily injury or property damage arising out of: (1) The escape of fuels, lubricants, other operating fluids, exhaust gases or other similar pollutants that are needed for or result from the normal electrical, hydraulic or mechanical functioning of a covered auto; or (2) The escape of pollutants from a covered auto that directly results from the collision, upset or overturn of such auto while in the course of transit away from any premises owned by or rented to any insured. 2. Arising out of any: a. Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, pollutants; or b. Claim or suit brought by or on behalf of a governmental authority for damages because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, pollutants. However, this Paragraph, 13.2., does not apply to liability, damage, loss, cost or expense because of property damage that the insured would have in the absence of such request, demand, order or statutory or regulatory requirements, or such claim or suit by or on behalf of a governmental agency. NUCLEAR C. 1. With respect to which any insured under this policy is also an insured under a nuclear energy liability policy issued by Nuclear Energy Liability Insurance Association, Mutual Atomic, Energy Liability Underwriters, Nuclear Insurance Association of Canada or any of their successors, or would be an insured under any such policy but for its termination upon exhaustion of its Limits of Insurance; or U-SXS-100-A CW(09/11) Page 4 of 10 2. Resulting from the hazardous properties of nuclear material and with respect to which: a. A person or organization is required to maintain financial protection pursuant to the Atomic Energy Act of 1954, or any law amendatory thereof; or b. Any insured is, or had this policy not been issued would be, entitled to indemnity from the United States of America, or any agency thereof, under any agreement entered into by the United States of America, or any agency thereof, with any person or organization; or 3. Any injury or nuclear property damage resulting from the hazardous properties of nuclear material, if: a. The nuclear material: (1) Is at any nuclear facility owned by, or operated by or on behalf of, any insured; or (2) Has been discharged or dispersed therefrom; b. The nuclear material is contained in spent fuel or waste at any time possessed, handled, used, processed, stored, transported or disposed of by or on behalf of any insured; or C. The injury or nuclear property damage arises out of the furnishing by any insured of services, materials, parts or equipment in connection with the planning, construction, maintenance operation or use of any nuclear facility, but if such facility is located within the United States of America, its territories or possessions or Canada, this subparagraph c. applies only to nuclear property damage to such nuclear facility and any property thereat. As used in this exclusion: 1. Hazardous properties include radioactive, toxic or explosive properties; 2. Nuclear Facility means: a. Any nuclear reactor; b. Any equipment or device designed or used for: (1) Separating the isotopes of uranium or plutonium, (2) Processing or utilizing spent fuel, or (3) Handling, processing or packaging waste; C. Any equipment or device used for the processing, fabricating or alloying of special nuclear material if at any time the total amount of such material in the custody of insured at the premises where such equipment or device is located consists of or contains more than 25 grams of plutonium or uranium 233 or any combination thereof, or more than 250 grams of uranium 235; or d. Any structure, basin, excavation, premises or place prepared or used for the storage or disposal of waste, and includes the site on which any of the foregoing is located, all operations conducted on such site and all premises used for such operations; 3. Nuclear material means source material, special nuclear material or by-product material; 4. Nuclear property damage includes all forms of radioactive contamination of property; 5. Nuclear reactor means any apparatus designed or used to sustain nuclear fission in a self-supporting chain reaction or to contain a critical mass of fissionable material; 6. Source material, special nuclear material and by-product material have the meanings given them in the Atomic Energy Act of 1954 or in any law amendatory thereof; 7. Spent fuel means any fuel element or fuel component, solid or liquid, which has been used or exposed to radiation in a nuclear reactor; 8. Waste means any waste material; a. Containing by-product material other than the tailings or wastes produced by the extraction or concentration of uranium or thorium from any ore processed primarily for its source material content, and U-SXS-100-A CW(09/11) Page 5 of 10 b. Resulting from the operation by any person or organization of any nuclear facility included under the first two Paragraphs of the definition of nuclear facility. SUBLIMITED UNDERLYING INSURANCE D. Which is covered by any underlying insurance but is subject to a sublimit unless such sublimited coverage is specifically endorsed to this policy. VIOLATION OF STATUTES E. Resulting from or arising directly or indirectly out of any action or omission that violates or is alleged to violate: 1. The Telephone Consumer Protection Act(TCPA), including any amendment of or addition to such law; 2. The CAN-SPAM Act of 2003, including any amendment of or addition to such law; 3. The Fair Credit Reporting Act(FCRA)and any amendment or addition to such law including the Fair and Accurate Credit Transactions Act (FACTA); or 4. Any federal, state or local statute, ordinance, or regulation, other than the TCPA, CAN-SPAM Act of 2003 or FCRA and their amendments and additions, that addresses, prohibits or limits the printing, dissemination, disposal, collecting, recording, sending, transmitting, communicating or distribution of material or information. WAR F. Arising, directly or indirectly, out of: 1. War, including undeclared or civil war; 2. Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or 3. Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these, regardless of any other cause or event that contributes concurrently or in any sequence to injury or damage. EMPLOYMENT PRACTICES G. Arising out of any bodily injury or personal and advertising injury to: 1. A person arising out of any: a. Failure to employ or promote that person; b. Termination of that person's employment, including actual or alleged constructive dismissal; or c. Employment-related practices, policies, acts or omissions, including but not limited to injury arising from coercion, demotion, evaluation, reassignment, discipline, defamation, harassment, molestation, humiliation, retaliation, hostile work environment, discrimination or malicious prosecution directed at that person; or 2. The spouse, domestic partner, child, parent, brother or sister of that person as a consequence of any bodily injury or personal and advertising injury to that person at whom any of the employment related practices described in subparagraphs a., b.or C. above is directed. This exclusion applies: 1. Whether the injury causing event described in subparagraph G.1. above occurs before employment, during employment or after employment of that person; 2. Whether the insured may be held liable as an employer or in any other capacity; or 3. To any obligation to share damages with or repay someone who must pay damages because of the injury. LAWS, MISCELLANEOUS H. Under any of the following: 1. Any uninsured/underinsu red motorist or auto no-fault or first party personal injury law; U-SXS-100-A CW(09/11) Page 6 of 10 2. Any workers' compensation, unemployment compensation, or disability benefits law or any similar law; or 3. The Employees' Retirement Income Security Act(E.R.I.S.A.) of 1974 as now or hereafter amended. LOSS OF, OR LOSS OF USE OF INTANGIBLE PROPERTY I. Arising out of the loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate or process intangible property. For purposes of this policy, electronic data is intangible property and means information, facts or programs stored as or on, created or used on, or transmitted to or from computer software, including systems and applications software, hard or floppy disks, CD-ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment. SECTION V. CONDITIONS A. Appeals In the event you or any underlying insurer elects not to appeal a judgment in excess of the amount of the underlying insurance, we may elect to appeal at our expense. If we do so elect, we will be liable for the costs and additional interest accruing during this appeal. In no event will this provision increase our liability beyond the applicable Limits of Insurance described in SECTION II. LIMITS OF INSURANCE of this policy. B. Bankruptcy or Insolvency The insolvency, bankruptcy or inability to pay of any insured will not relieve us from our obligation to pay damages covered by this policy. In the event of insolvency, bankruptcy, refusal,or inability to pay, of any underlying insurer, the insurance afforded by this policy will not replace such underlying insurance, but will apply as if all the limits of any underlying insurance are fully available and collectible. C. Cancellation 1. The first Named Insured shown in Item 1. of the Declarations may cancel this policy by mailing or delivering to us advance written notice stating when the cancellation is to take effect. 2. We may cancel this policy. If we cancel because of non-payment of premium, we will mail or deliver to the first Named Insured not less than ten (10) days advance written notice when the cancellation is to take effect. If we cancel for any other reason, we will mail or deliver to the first Named Insured not less than ninety (90) days advance written notice stating the reason(s) for cancellation, as well as the date when the cancellation is to take effect. Mailing notice to the first Named Insured's mailing address shown in Item 2. of the Declarations will be sufficient to prove notice. 3. The Policy Period will end on the day and hour shown in the cancellation notice. 4. If this policy is cancelled, the final premium will be calculated pro rata based on the time this policy was in force. 5. Premium adjustment may be made at the time of cancellation or as soon as practicable thereafter but the cancellation will be effective even if we have not made or offered any refund due the first Named Insured. Our check or our representative's check, mailed or delivered, will be sufficient tender of any refund due the first Named Insured. 6. The first Named Insured shown in Item 1. of the Declarations will act on behalf of all other insureds with respect to the giving and receiving of notice of cancellation and the receipt of any premium refund that may become payable under this policy. D. Maintenance of Underlying Insurance During the Policy Period, you agree: 1. To keep the policies listed in the Schedule of Underlying Insurance in full force and effect; 2. That the Applicable Limits of insurance of the policies shown in the Schedule of Underlying Insurance will be maintained except for any reduction or exhaustion of limits by payment of claims or suits for loss covered by underlying insurance; 3. The policies listed in the Schedule of Underlying Insurance may not be canceled or nonrenewed by you without notifying us, and you agree to notify us as soon as practicable before the cancellation or nonrenewal effective date in the event an insurance company cancels or declines to renew any policy listed in the Schedule of Underlying Insurance; and U-SXS-100-A CW(09/11) Page 7 of 10 4. Renewals or replacements of the policies listed in the Schedule of Underlying Insurance will not be materially changed without our agreement. If you fail to comply with these requirements, we will only be liable to the same extent that we would have been had you fully complied with these requirements. E. Nonrenewal If we decide not to renew this policy, we will mail or deliver to the first Named Insured shown in Item 1. of the Declarations written notice of the nonrenewal not less than thirty (30) days before the expiration date. If notice is mailed, proof of mailing will be sufficient proof of notice. F. Notice of Occurrence 1. You must see to it that we are notified as soon as practicable of an occurrence which may result in damages covered by this policy. To the extent possible, notice will include: a. How, when and where the occurrence took place; b. The names and addresses of any injured persons and witnesses; and c. The nature and location of any injury or damage arising out of the occurrence. 2. Knowledge of an occurrence by the agent, servant or employee of yours, shall not in itself constitute knowledge by the insured unless you or any authorized person receives such notice from the agent, servants or employee. 3. If a claim or suit against any insured is reasonably likely to involve this policy, you must notify us in writing as soon as practicable. 4. You and any other involved insured must: a. Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or suit; b. Authorize us to obtain records and other information; C. Cooperate with us in the investigation, settlement or defense of the claim or suit; and d. Assist us, upon our request, in the enforcement of any right against any person or organization which may be liable to the insured because of injury or damage to which this policy may also apply. 5. The insureds will not, except at their own cost, voluntarily make a payment, assume any obligation, or incur any expense, other than for first aid, without our consent. 6. Your failure to give notice of an occurrence to us shall not invalidate coverage under this policy if the occurrence was inadvertently reported to another insurer. However, you shall report any such occurrence to us as soon as practicable once you become aware of such error. G. Other Insurance If other insurance applies to damages that are also covered by this policy, this policy will apply excess of the other insurance. Nothing herein will be construed to make this policy subject to the terms, conditions and limitations of such other insurance. However, this provision will not apply if the other insurance is written to be excess of this policy. Other insurance includes any type of self-insurance or other mechanism by which an insured arranges for funding of legal liabilities. H. Terms Conformed to Statute The terms of this policy which are in conflict with the statutes, laws, ordinances or regulations in any country, jurisdiction, state or province where this policy is issued are amended to conform to such statutes, laws, ordinances or regulations. If we are prevented by law or statute from paying on behalf of the insured, then we will, where permitted by law or statute, indemnify the insured. U-SXS-100-A CW(09/11) Page 8 of 10 I. Transfer of Rights of Recovery Against Others to Us 1. If the insured has rights to recover all or part of any payment we have made under this insurance, those rights are transferred to us. The insured must do nothing after the loss to impair them. At our request, the insured will bring suit or transfer those rights to us and help us enforce them. However, if any insured is required to waive their rights of recovery from others by a written contract or agreement executed before a loss, we agree to waive our rights of recovery to the extent required by the written contract or agreement. This waiver of rights will not be construed to be a waiver with respect to any other operations for which the insured has not waived their rights of recovery by contract. 2. Any amount recovered will be apportioned in the inverse order of payment of loss to the extent of actual payment. The expenses of all such recovery proceedings will be apportioned in the ratio of respective recoveries. J. Unintentional Errors and Omissions Any unintentional error or omission in the description of, or failure to describe completely, any premises or operations intended to be covered by this policy, shall not invalidate or affect the coverage for those operations or premises. However, the insured must report such error or omission to the company as soon as practicable after its discovery. K. When Loss is Payable Coverage under this policy will not apply unless and until the insured or the insured's underlying insurer has paid or is legally obligated to pay the full amount of the total Applicable Limits of underlying insurance. When the amount of loss is determined by an agreed settlement or a final judgment against an insured obtained after an actual trial, we will promptly pay on behalf of the insured the amount of loss covered under the terms of this policy. L. Audit of Books and Records We may audit and examine your books and records as they relate to this policy at any time during the period of this policy and for up to three (3)years after the expiration or termination of this policy. M. Changes Notice to any agent or knowledge possessed by any agent or any other person will not effect a waiver or a change in any part of this policy. This policy can only be changed by a written endorsement that becomes a part of this policy. N. First Named Insured The person or organization first named in Item 1. of the Declarations is responsible for the payment of all premiums. The first Named Insured will act on behalf of all other insureds for the giving and receiving of notice of cancellation or any other notice required under this policy or by statute or regulation, for the receipt and acceptance of this policy and any endorsements forming a part of this policy, and for the receiving of any return premiums that become payable under this policy. O. Inspection We have the right, but are not obligated to inspect the insured's premises and operations at any time. Our inspections are not safety inspections. They relate only to the insurability of the premises and operations and the premium to be charged. We may provide reports on the conditions we find. We may also recommend changes. While these reports may help reduce losses, we do not undertake to perform the duty of any person or organization to provide for the health or safety of workers or the public. We do not warrant that the premises or operations are safe or healthful, or that they comply with laws, regulations, codes or standards. P. Legal Action Against Us There will be no right of action against us under this insurance unless: 1. You have complied with all the terms of this policy; and 2. The amount you owe has been determined by settlement with our consent or by actual trial and final judgment. This insurance does not give anyone the right to add us as a party in an action against you to determine your liability. U-SXS-100-A CW(09/11) Page 9 of 10 Q. Premium The premium for this policy as stated in Item 5. of the Declarations is a flat premium. It is not subject to adjustment unless an endorsement is attached to this policy. R. Separation of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned to the first Named Insured, this insurance applies: 1. As if each named insured were the only named insured; and 2. Separately to each insured against whom claim is made or suit is brought. S. Transfer of Your Rights and Duties Your rights and duties under this insurance may not be transferred without our written consent. If you die, then your rights and duties will be transferred to your legal representative, but only while acting within the scope of duties as your legal representative. Until your legal representative is appointed, anyone having temporary custody of your property will have your rights and duties but only with respect to that property. T. Violation of Economic or Trade Sanctions If coverage for a claim or suit under this policy is in violation of any economic or trade sanctions of the United States of America then coverage for that claim or suit will be null and void. SECTION VI. DEFINITIONS In this policy, words and phrases appearing in bold-face type have the definitions shown below: A. Authorized person means any person who may receive notice of an occurrence or claim in underlying insurance. B. Hostile fire means one which becomes uncontrollable or breaks out from where it was intended to be. C. Loss means those sums actually paid that the insured is legally obligated to pay as damages for the settlement or satisfaction of a claim because of injury or offense after making proper deductions for all recoveries and salvage. However, 1. Loss also includes defense expenses and supplementary payments if underlying insurance includes defense expenses and supplementary payments in the Limits of Insurance; and 2. Loss does not include defense expenses and supplementary payments if underlying insurance does not include defense expenses and supplementary payments in the Limits of Insurance. D. Occurrence means covered event as defined in underlying insurance. E. Other insurance means a policy of insurance providing coverage that this policy also provides. Other insurance includes any type of self-insurance or other mechanisms by which an insured arranges for funding of legal liabilities. Other insurance does not include underlying insurance or a policy of insurance specifically purchased to be excess of this policy providing coverage that this policy also provides. F. Pollutants means any solid, liquid, gaseous, or thermal irritant or contaminant including smoke, vapor, soot, fumes, acid, alkalis, chemicals and waste. Waste includes material to be recycled, reconditioned or reclaimed. G. Underlying insurance means the policy or policies of insurance listed in the Schedule of Underlying Insurance forming a part of this policy. We will only be liable for amounts in excess of the Applicable Limits of insurance shown in the Schedule of Underlying Insurance for any underlying insurance. U-SXS-100-A CW(09/11) Page 10 of 10 4 City of Dent General Business License 2024� r License Number 2110360 4 UBI 6000749680010001 City of Kent Licensee: 220 4th Avenue S Auburn Mechanical, Inc . Kent, WA 98032 Auburn Mechanical, Inc 253-856-5200 2623 W Valley Hwy N er Kentwa.gov Auburn, WA 98001-1621 # customerservice@kentwa.gov i ► License is issued for this application i www.FileLocal.org u � A S Issued: 01/08/2024 Expires: 12/31/2024 Not Transferable, Post Conspicuously State of Washington Department of Labor & Industries Prevailing Wage Section - Telephone 360-902-5335 PO Box 44540, Olympia, WA 98504-4540 Washington State Prevailing Wage The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, worker's wage and benefit rates must add to not less than this total. A brief description of overtime calculation requirements are provided on the Benefit Code Key. Journey Level Prevailing Wage Rates for the Effective Date: 05/09/2024 County_ Trade Job Classification Wage Holiday Overtime Note *Risk Class King Asbestos Abatement Workers Journey Level $59.07 5D 1 H View King Boilermakers Journey Level $74.29 5N 1C View King Brick Mason Journey Level $69.07 7E 1 N View King Brick Mason Pointer-Caulker-Cleaner $69.07 7E 1 N View King Building Service Employees Janitor $29.33 5S 2F View King Building Service Employees Traveling Waxer/Shampooer $29.78 5S 2F View King Building Service Employees Window Cleaner (Non-Scaffold) $32.93 5S 2F View King Building Service Employees Window Cleaner (Scaffold) $33.93 5S 2F View King Cabinet Makers (In Shop) Journey Level $22.74 1 View King Carpenters Acoustical Worker $74.96 15J 4C View King Carpenters Bridge, Dock And Wharf $74.96 15J 4C View Carpenters King Carpenters Floor Layer Et Floor Finisher $74.96 15J 4C View King Carpenters Journey Level $74.96 15J 4C View King Carpenters Scaffold Erector $74.96 15J 4C View King Cement Masons Application of all Composition $72.87 15J 41J View Mastic King Cement Masons Application of all Epoxy $72.37 15J 41J View Material King Cement Masons Application of all Plastic $72.87 15J 41J View Material King Cement Masons Application of Sealing $72.37 15J 41J View Compound King Cement Masons Application of Underlayment $72.87 15J 41J View King Cement Masons Building General $72.37 15J 41J View King Cement Masons Composition or Kalman Floors $72.87 15J 41J View King Cement Masons Concrete Paving $72.37 15J 41J View King Cement Masons Curb Et Gutter Machine $72.87 15J 41J View King Cement Masons Curb Et Gutter, Sidewalks $72.37 15J 41J View King Cement Masons Curing Concrete $72.37 15J 41J View King Cement Masons Finish Colored Concrete $72.87 15J 41J View King Cement Masons Floor Grinding $72.87 15J 4U View King Cement Masons Floor Grinding/Polisher $72.37 15J 4U View King Cement Masons Green Concrete Saw, self- $72.87 15J 4U View powered King Cement Masons Grouting of all Plates $72.37 15J 4U View King Cement Masons Grouting of all Tilt-up Panels $72.37 15J 4U View King Cement Masons Gunite Nozzleman $72.87 15J 4U View King Cement Masons Hand Powered Grinder $72.87 15J 4U View King Cement Masons Journey Level $72.37 15J 4U View King Cement Masons Patching Concrete $72.37 15J 4U View King Cement Masons Pneumatic Power Tools $72.87 15J 4U View King Cement Masons Power Chipping Et Brushing $72.87 15J 4U View King Cement Masons Sand Blasting Architectural $72.87 15J 4U View Finish King Cement Masons Screed Et Rodding Machine $72.87 15J 4U View King Cement Masons Spackling or Skim Coat $72.37 15J 4U View Concrete King Cement Masons Troweling Machine Operator $72.87 15J 4U View King Cement Masons Troweling Machine Operator on $72.87 15J 4U View Colored Slabs King Cement Masons Tunnel Workers $72.87 15J 4U View King Divers Et Tenders Bell/Vehicle or Submersible $129.71 15J 4C View Operator (Not Under Pressure) King Divers Et Tenders Dive Supervisor/Master $93.94 15J 4C View King Divers Et Tenders Diver $129.71 15J 4C 8V View King Divers Et Tenders Diver On Standby $88.94 15J 4C View King Divers Et Tenders Diver Tender $80.82 15J 4C _ View King Divers Et Tenders Hyperbaric Worker - $93.26 15J 4C View Compressed Air Worker 0-30.00 PSI L King Divers Et Tenders Hyperbaric Worker - $98.26 15J 4C View Compressed Air Worker 30.01 - 44.00 PSI King Divers Et Tenders Hyperbaric Worker - $102.26 15J 4C View Compressed Air Worker 44.01 - 54.00 PSI King Divers Et Tenders Hyperbaric Worker - $107.26 15J 4C View Compressed Air Worker 54.01 - 60.00 PSI King Divers Et Tenders Hyperbaric Worker - $109.76 15J 4C View Compressed Air Worker 60.01 - 64.00 PSI King Divers Et Tenders Hyperbaric Worker - $114.76 15J 4C View Compressed Air Worker 64.01 68.00 PSI King Divers Et Tenders Hyperbaric Worker - $116.76 15J 4C View Compressed Air Worker 68.01 - 70.00 PSI King Divers Et Tenders Hyperbaric Worker - $118.76 15J 4C View Compressed Air Worker 70.01 72.00 PSI King Divers Et Tenders Hyperbaric Worker - $120.76 15J 4C View Compressed Air Worker 72.01 74.00 PSI King Divers Et Tenders Manifold Operator $80.82 15J 4C View King Divers Et Tenders Manifold Operator Mixed Gas $85.82 15J 4C View King Divers Et Tenders Remote Operated Vehicle $80.82 15J 4C View Operator/Technician King Divers Et Tenders Remote Operated Vehicle $75.41 15J 4C View Tender King Dredge Workers Assistant Engineer $79.62 5D 3F View King Dredge Workers Assistant Mate (Deckhand) $79.01 5D 3F View King Dredge Workers Boatmen $79.62 5D 3F View King Dredge Workers Engineer Welder $81.15 5D 3F View King Dredge Workers Leverman, Hydraulic $82.77 5D 3F View King Dredge Workers Mates $79.62 5D 3F View King Dredge Workers Oiler $79.01 5D 3F View King Drywall Applicator Journey Level $75.73 150 11S View King mall Tapers Journey Level $75.73 150 11S View King Electrical Fixture Maintenance Journey Level $38.69 5L 1 E View Workers King Electricians - Inside Cable Splicer $109.35 7C 4E View King Electricians - Inside Cable Splicer (tunnel) $117.52 7C 4E View King Electricians - Inside Certified Welder $105.63 7C 4E View King Electricians - Inside Certified Welder (tunnel) $113.43 7C 4E View King Electricians - Inside Construction Stock Person $51.53 7C 4E View King Electricians - Inside Journey Level $101.92 7C 4E View King Electricians - Inside Journey Level (tunnel) $109.35 7C 4E View King Electricians - Motor Shop Journey Level $48.68 5A 1 B View King Electricians - Powerline Cable Splicer $93.00 5A 4D View Construction King Electricians - Powerline Certified Line Welder $85.42 5A 4D View Construction King Electricians - Powerline Groundperson $55.27 5A 4D View Construction King Electricians - Powerline Heavy Line Equipment $85.42 5A 4D View Construction Operator King Electricians - Powerline Journey Level Lineperson $85.42 5A 4D View Construction King Electricians - Powerline Line Equipment Operator $73.35 5A 4D View Construction King Electricians - Powerline Meter Installer $55.27 5A 4D 8W View Construction King Electricians - Powerline Pole Sprayer $85.42 5A 4D View Construction King Electricians - Powerline Powderperson $63.50 5A 4D View Construction King Electronic Technicians Journey Level $65.66 7E 1 E View King Elevator Constructors Mechanic $111.26 7D 4A View King Elevator Constructors Mechanic In Charge $120.27 7D 4A View King Fabricated Precast Concrete All Classifications - In-Factory $21.34 5B 1R View Products Work Only King Fence Erectors Fence Erector $50.07 15J lip 8Y View King Fence Erectors Fence Laborer $50.07 15J lip 8Y View King Flaggers Journey Level $50.07 15J lip 8Y View King Glaziers Journey Level $79.16 7L 1Y View King Heat Et Frost Insulators And Journey Level $87.15 15H 11C View Asbestos Workers King Heating Equipment Mechanics Journey Level $96.42 7F 1 E View King Hod Carriers Et Mason Tenders Journey Level $62.49 15J lip 8Y View King Industrial Power Vacuum Journey Level $16.28 1 View Cleaner _ King Inland Boatmen Boat Operator $61.41 5B 1K View King Inland Boatmen Cook $56.48 5B 1K View King Inland Boatmen Deckhand $57.48 5B 1K View King Inland Boatmen Deckhand Engineer $58.81 5B 1K View King Inland Boatmen Launch Operator $58.89 5B 1K _ View King Inland Boatmen Mate $57.31 5B 1K View King Inspection/Cleaning/Sealing Of Cleaner Operator $49.48 15M 110 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Foamer Operator $49.48 15M 110 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Grout Truck Operator $49.48 15M 110 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Head Operator $47.41 15M 110 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Technician $41.20 15M 110 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of TV Truck Operator $44.31 15M 110 View Sewer Et Water Systems By Remote Control King Insulation Applicators Journey Level $74.96 15J 4C View King Ironworkers Journeyman $87.80 15K 11 N View King Laborers Air, Gas Or Electric Vibrating $59.07 15J lip 8Y View Screed King Laborers Airtrac Drill Operator $60.90 15J 11P 8Y View King Laborers Ballast Regular Machine $59.07 15J lip 8Y View King Laborers Batch Weighman $50.07 15J lip 8Y View King Laborers Brick Pavers $59.07 15J lip 8Y View King Laborers Brush Cutter $59.07 15J lip 8Y View King Laborers Brush Hog Feeder $59.07 15J lip 8Y View King Laborers Burner $59.07 15J lip 8Y View King Laborers Caisson Worker $60.90 15J lip 8Y View King Laborers Carpenter Tender $59.07 15J lip 8Y View King Laborers Cement Dumper-paving $60.15 15J lip 8Y View King Laborers Cement Finisher Tender $59.07 15J lip 8Y View King Laborers Change House Or Dry Shack $59.07 15J lip 8Y View King Laborers Chipping Gun (30 Lbs. And $60.15 15J lip 8Y View Over) King Laborers Chipping Gun (Under 30 Lbs.) $59.07 15J 11P 8Y View King Laborers Choker Setter $59.07 15J lip 8Y View King Laborers Chuck Tender $59.07 15J lip 8Y View King Laborers Clary Power Spreader $60.15 15J lip 8Y View King Laborers Clean-up Laborer $59.07 15J 11P 8Y View King Laborers Concrete Dumper/Chute $60.15 15J lip 8Y View Operator King Laborers Concrete Form Stripper $59.07 15J lip 8Y View King Laborers Concrete Placement Crew $60.15 15J lip 8Y View King Laborers Concrete Saw Operator/Core $60.15 15J lip 8Y View Driller King Laborers Crusher Feeder $50.07 15J lip 8Y View King Laborers Curing Laborer $59.07 15J lip 8Y View King Laborers Demolition: Wrecking Et Moving $59.07 15J lip 8Y View (Incl. Charred Material) King Laborers Ditch Digger $59.07 15J lip 8Y View King Laborers Diver $60.90 15J lip 8Y View King Laborers Drill Operator (Hydraulic, $60.15 15J lip 8Y View Diamond) King Laborers Dry Stack Walls $59.07 15J lip 8Y View King Laborers Dump Person $59.07 15J lip 8Y View King Laborers Epoxy Technician $59.07 15J lip 8Y View King Laborers Erosion Control Worker $59.07 15J lip 8Y View King Laborers Faller Et Bucker Chain Saw $60.15 15J lip 8Y View King Laborers Fine Graders $59.07 15J lip 8Y View King Laborers Firewatch $50.07 15J lip 8Y View King Laborers Form Setter $60.15 15J lip 8Y View King Laborers Gabian Basket Builders $59.07 15J lip 8Y View King Laborers General Laborer $59.07 15J lip 8Y View King Laborers Grade Checker Et Transit Person $62.49 15J lip 8Y View King Laborers Grinders $59.07 15J lip 8Y View King Laborers Grout Machine Tender $59.07 15J lip 8Y View King Laborers Groutmen (Pressure) Including $60.15 15J lip 8Y View Post Tension Beams King Laborers Guardrail Erector $59.07 15J 11P 8Y View King Laborers Hazardous Waste Worker (Level $60.90 15J lip 8Y View A) King Laborers Hazardous Waste Worker (Level $60.15 15J lip 8Y View B) King Laborers Hazardous Waste Worker (Level $59.07 15J lip 8Y View C) King Laborers High Scaler $60.90 15J lip 8Y View King Laborers Jackhammer $60.15 15J lip 8Y View King Laborers Laserbeam Operator $60.15 15J lip 8Y View King Laborers Maintenance Person $59.07 15J lip 8Y View King Laborers Manhole Builder-Mudman $60.15 15J 11P 8Y View King Laborers Material Yard Person $59.07 15J lip 8Y View King Laborers Mold Abatement Worker $59.07 15J lip 8Y View King Laborers Motorman-Dinky Locomotive $62.59 15J lip 8Y View King Laborers nozzleman (concrete pump, $62.49 15J lip 8Y View green cutter when using combination of high pressure air Et water on concrete Et rock, sandblast, gunite, shotcrete, water blaster, vacuum blaster) King Laborers Pavement Breaker $60.15 15J lip 8Y View King Laborers Pilot Car $50.07 15J 11P 8Y View King Laborers Pipe Layer (Lead) $62.49 15J lip 8Y View King Laborers Pipe Layer/Tailor $60.15 15J lip 8Y View King Laborers Pipe Pot Tender $60.15 15J lip 8Y View King Laborers Pipe Reliner $60.15 15J lip 8Y View King Laborers Pipe Wrapper $60.15 15J lip 8Y View King Laborers Pot Tender $59.07 15J lip 8Y View King Laborers Powderman $60.90 15J lip 8Y View King Laborers Powderman's Helper $59.07 15J lip 8Y View King Laborers Power Jacks $60.15 15J lip 8Y View King Laborers Railroad Spike Puller - Power $60.15 15J 11P 8Y View King Laborers Raker -Asphalt $62.49 15J lip 8Y View King Laborers Re-timberman $60.90 15J lip 8Y View King Laborers Remote Equipment Operator $60.15 15J lip 8Y View King Laborers Rigger/Signal Person $60.15 15J lip 8Y View King Laborers Rip Rap Person $59.07 15J lip 8Y View King Laborers Rivet Buster $60.15 15J lip 8Y View King Laborers Rodder $60.15 15J lip 8Y View King Laborers Scaffold Erector $59.07 15J lip 8Y View King Laborers Scale Person $59.07 15J lip 8Y View King Laborers Sloper (Over 20") $60.15 15J lip 8Y View King Laborers Sloper Sprayer $59.07 15J lip 8Y View King Laborers Spreader (Concrete) $60.15 15J lip 8Y View King Laborers Stake Hopper $59.07 15J lip 8Y View King Laborers Stock Piler $59.07 15J 11P 8Y View King Laborers Swinging Stage/Boatswain $50.07 15J 11P 8Y View Chair King Laborers Tamper Et Similar Electric, Air $60.15 15J lip 8Y View Et Gas Operated Tools King Laborers Tamper (Multiple Et Self- $60.15 15J lip 8Y View propelled) King Laborers Timber Person - Sewer (Lagger, $60.15 15J lip 8Y View Shorer Et Cribber) King Laborers Toolroom Person (at Jobsite) $59.07 15J lip 8Y View King Laborers Topper $59.07 15J lip 8Y View King Laborers Track Laborer $59.07 15J lip 8Y View King Laborers Track Liner (Power) $60.15 15J lip 8Y View King Laborers Traffic Control Laborer $53.54 15J lip 9C View King Laborers Traffic Control Supervisor $56.73 15J lip 9C View King Laborers Truck Spotter $59.07 15J lip 8Y View King Laborers Tugger Operator $60.15 15J lip 8Y View King Laborers Tunnel Work-Compressed Air $175.79 15J lip 9B View Worker 0-30 psi King Laborers Tunnel Work-Compressed Air $180.82 15J lip 9B View Worker 30.01-44.00 psi King Laborers Tunnel Work-Compressed Air $184.50 15J lip 9B View Worker 44.01-54.00 psi King Laborers Tunnel Work-Compressed Air $190.20 15J lip 9B View Worker 54.01-60.00 psi King Laborers Tunnel Work-Compressed Air $192.32 15J lip 9B View Worker 60.01-64.00 psi King Laborers Tunnel Work-Compressed Air $197.42 15J lip 9B View Worker 64.01-68.00 psi King Laborers Tunnel Work-Compressed Air $199.32 15J lip 9B View Worker 68.01-70.00 psi King Laborers Tunnel Work-Compressed Air $201.32 15J lip 9B View Worker 70.01-72.00 psi King Laborers Tunnel Work-Compressed Air $203.32 15J lip 9B View Worker 72.01-74.00 psi King Laborers Tunnel Work-Guage and Lock $62.59 15J lip 8Y View Tender King Laborers Tunnel Work-Miner $62.59 15J lip 8Y View King Laborers Vibrator $60.15 15J lip 8Y View King Laborers Vinyl Seamer $59.07 15J lip 8Y View King Laborers Watchman $45.51 15J lip 8Y View King Laborers Welder $60.15 15J lip 8Y View King Laborers Well Point Laborer $60.15 15J lip 8Y View King Laborers Window Washer/Cleaner $45.51 15J lip 8Y View King Laborers - Underground Sewer General Laborer Et Topman $59.07 15J lip 8Y View Et Water King Laborers - Underground Sewer Pipe Layer $60.15 15J lip 8Y View Et Water King Landscape Construction Landscape $45.51 15J lip 8Y View Construction/Landscaping Or Planting Laborers King Landscape Construction Landscape Operator $82.25 15J 11 G 8X View King Landscape Maintenance Groundskeeper $17.87 1 View King Lathers Journey Level $75.73 150 11S View King Marble Setters Journey Level $69.07 7E 1 N View King Metal Fabrication In Shop). Fitter/Certified Welder $42.17 151 11 E View King Metal Fabrication In Shop). General Laborer $30.07 151 11 E View King Metal Fabrication In Shop). Mechanic $43.63 151 11 E View King Metal Fabrication In Shop). Welder/Burner $39.28 151 11 E View King Millwright Journey Level $76.51 15J 4C View King Modular Buildings Cabinet Assembly $16.28 1 View King Modular Buildings Electrician $16.28 1 View King Modular Buildings Equipment Maintenance $16.28 1 View King Modular Buildings Plumber $16.28 1 View King Modular Buildings Production Worker $16.28 1 View King Modular Buildings Tool Maintenance $16.28 1 View King Modular Buildings Utility Person $16.28 1 View King Modular Buildings Welder $16.28 1 View King Painters Journey Level $51.71 6Z 11J View King Pile Driver Crew Tender $80.82 15J 4C View King Pile Driver Journey Level $75.41 15J 4C View King Plasterers Journey Level $70.91 7Q 1 R View King Plasterers Nozzleman $74.91 7Q 1 R View King Playground Et Park Equipment Journey Level $16.28 1 View Installers King Plumbers Et Pipefitters Journey Level $103.19 6Z 1G View King Power Equipment Operators Asphalt Plant Operators $83.62 15J 11G 8X View King Power Equipment Operators Assistant Engineer $78.65 15J 11G 8X View King Power Equipment Operators Barrier Machine (zipper) $82.88 15J 11G 8X View King Power Equipment Operators Batch Plant Operator: concrete $82.88 15J 11G 8X View King Power Equipment Operators Boat Operator $83.95 7A 11 H 8X View King Power Equipment Operators Bobcat $78.65 15J 11G 8X View King Power Equipment Operators Brokk - Remote Demolition $78.65 15J 11G 8X View Equipment King Power Equipment Operators Brooms $78.65 15J 11G 8X View King Power Equipment Operators Bump Cutter $82.88 15J 11G 8X View King Power Equipment Operators Cableways $83.62 15J 11G 8X View King Power Equipment Operators Chipper $82.88 15J 11G 8X View King Power Equipment Operators Compressor $78.65 15J 11G 8X View King Power Equipment Operators Concrete Finish Machine - $78.65 15J 11G 8X View Laser Screed King Power Equipment Operators Concrete Pump - Mounted Or $82.25 15J 11G 8X View Trailer High Pressure Line Pump, Pump High Pressure King Power Equipment Operators Concrete Pump: Truck Mount $83.62 15J 11G 8X View With Boom Attachment Over 42 M King Power Equipment Operators Concrete Pump: Truck Mount $82.88 15J 11G 8X View With Boom Attachment Up To 42m King Power Equipment Operators Conveyors $82.25 15J 11G 8X View King Power Equipment Operators Cranes Friction: 200 tons and $86.48 7A 11 H 8X View over King Power Equipment Operators Cranes, A-frame: 10 tons and $78.95 7A 11 H 8X View under King Power Equipment Operators Cranes: 100 tons through 199 $84.77 7A 11 H 8X View tons, or 150' of boom (including jib with attachments) King Power Equipment Operators Cranes: 20 tons through 44 $83.20 7A 11 H 8X View tons with attachments King Power Equipment Operators Cranes: 200 tons- 299 tons, or $85.66 7A 11 H 8X View 250'of boom including jib with attachments King Power Equipment Operators Cranes: 300 tons and over or $86.48 7A 11 H 8X View 300'of boom including jib with attachments King Power Equipment Operators Cranes: 45 tons through 99 $83.95 7A 11 H 8X View tons, under 150' of boom(including jib with attachments) King Power Equipment Operators Cranes: Friction cranes through $85.66 7A 11 H 8X View 199 tons King Power Equipment Operators Cranes: through 19 tons with $82.56 7A 11 H 8X View attachments, a-frame over 10 tons King Power Equipment Operators Crusher $82.88 15J 11G 8X View King Power Equipment Operators Deck Engineer/Deck Winches $82.88 15J 11G 8X View (power) King Power Equipment Operators Derricks, On Building Work $83.62 15J 11G 8X View King Power Equipment Operators Dozers D-9 Et Under $82.25 15J 11G 8X View King Power Equipment Operators Drill Oilers: Auger Type, Truck $82.25 15J 11G 8X View Or Crane Mount King Power Equipment Operators Drilling Machine $84.46 15J 11G 8X View King Power Equipment Operators Elevator and man-lift: $78.65 15J 11G 8X View permanent and shaft type King Power Equipment Operators Finishing Machine, Bidwell And $82.88 15J 11G 8X View Gamaco Et Similar Equipment King Power Equipment Operators Forklift: 3000 lbs and over with $82.25 15J 11G 8X View attachments King Power Equipment Operators Forklifts: under 3000 lbs. with $78.65 15J 11G 8X View attachments King Power Equipment Operators Grade Engineer: Using Blue $82.88 15J 11G 8X View Prints, Cut Sheets, Etc King Power Equipment Operators Gradechecker/Stakeman $78.65 15J 11G 8X View King Power Equipment Operators Guardrail Punch $82.88 15J 11G 8X View King Power Equipment Operators Hard Tail End Dump $83.62 15J 11G 8X View Articulating Off- Road Equipment 45 Yards. Et Over King Power Equipment Operators Hard Tail End Dump $82.88 15J 11G 8X View Articulating Off-road Equipment Under 45 Yards King Power Equipment Operators Horizontal/Directional Drill $82.25 15J 11G 8X View Locator King Power Equipment Operators Horizontal/Directional Drill $82.88 15J 11G 8X View Operator King Power Equipment Operators Hydralifts/Boom Trucks Over $82.56 7A 11 H 8X View 10 Tons King Power Equipment Operators Hydralifts/boom trucks: 10 $78.95 7A 11 H 8X View tons and under King Power Equipment Operators Leverman $85.33 15J 11G 8X View King Power Equipment Operators Loader, Overhead, 6 Yards. But $83.62 15J 11G 8X View Not Including 8 Yards King Power Equipment Operators Loaders, Overhead Under 6 $82.88 15J 11G 8X View Yards King Power Equipment Operators Loaders, Plant Feed $82.88 15J 11G 8X View King Power Equipment Operators Loaders: Elevating Type Belt $82.25 15J 11G 8X View King Power Equipment Operators Locomotives, All $82.88 15J 11G 8X View King Power Equipment Operators Material Transfer Device $82.88 15J 11G 8X View King Power Equipment Operators Mechanics: All (Leadmen - $84.46 15J 11G 8X View $0.50 per hour over mechanic) King Power Equipment Operators Motor Patrol Graders $83.62 15J 11G 8X View King Power Equipment Operators Mucking Machine, Mole, Tunnel $83.62 15J 11G 8X View Drill, Boring, Road Header And/or Shield King Power Equipment Operators Oil Distributors, Blower $78.65 15J 11G 8X View Distribution Et Mulch Seeding Operator King Power Equipment Operators Outside Hoists (Elevators and $82.25 15J 11G 8X View Manlifts), Air Tuggers, Strato King Power Equipment Operators Overhead, bridge type Crane: $83.20 7A 11 H 8X View 20 tons through 44 tons King Power Equipment Operators Overhead, bridge type: 100 $84.77 7A 11 H 8X View tons and over King Power Equipment Operators Overhead, bridge type: 45 tons $83.95 7A 11 H 8X View through 99 tons King Power Equipment Operators Pavement Breaker $78.65 15J 11G 8X View King Power Equipment Operators Pile Driver (other Than Crane $82.88 15J 11G 8X View Mount) King Power Equipment Operators Plant Oiler -Asphalt, Crusher $82.25 15J 11G 8X View King Power Equipment Operators Posthole Digger, Mechanical $78.65 15J 11G 8X View King Power Equipment Operators Power Plant $78.65 15J 11G 8X View King Power Equipment Operators Pumps - Water $78.65 15J 11G 8X View King Power Equipment Operators Quad 9, Hd 41, D10And Over $83.62 15J 11G 8X View King Power Equipment Operators Quick Tower: no cab, under $82.88 15J 11G 8X View 100 feet in height base to boom King Power Equipment Operators Remote Control Operator On $83.62 15J 11G 8X View Rubber Tired Earth Moving Equipment King Power Equipment Operators Rigger and Bellman $78.95 7A 11 H 8X View King Power Equipment Operators Rigger/Signal Person, $82.56 7A 11 H 8X View Bellman(Certified) King Power Equipment Operators Rollagon $83.62 15J 11G 8X View King Power Equipment Operators Roller, Other Than Plant Mix $78.65 15J 11G 8X View King Power Equipment Operators Roller, Plant Mix Or Multi-lift $82.25 15J 11G 8X View Materials King Power Equipment Operators Roto-mill, Roto-grinder $82.88 15J 11G 8X View King Power Equipment Operators Saws - Concrete $82.25 15J 11G 8X View King Power Equipment Operators Scraper, Self Propelled Under $82.88 15J 11G 8X View 45 Yards King Power Equipment Operators Scrapers - Concrete Et Carry All $82.25 15J 11G 8X View King Power Equipment Operators Scrapers, Self-propelled: 45 $83.62 15J 11G 8X View Yards And Over King Power Equipment Operators Service Engineers: Equipment $82.25 15J 11G 8X View King Power Equipment Operators Shotcrete/Gunite Equipment $78.65 15J 11G 8X View King Power Equipment Operators Shovel, Excavator, Backhoe, $82.25 15J 11G 8X View Tractors Under 15 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoe: $83.62 15J 11G 8X View Over 30 Metric Tons To 50 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes, $82.88 15J 11G 8X View Tractors: 15 To 30 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes: $84.46 15J 11G 8X View Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes: $85.33 15J 11G 8X View Over 90 Metric Tons King Power Equipment Operators Slipform Pavers $83.62 15J 11G 8X View King Power Equipment Operators Spreader, Topsider Et $83.62 15J 11G 8X View Screedman King Power Equipment Operators Subgrader Trimmer $82.88 15J 11G 8X View King Power Equipment Operators Tower Bucket Elevators $82.25 15J 11G 8X View King Power Equipment Operators Tower Crane: over 175' through $85.66 7A 11 H 8X View 250' in height, base to boom King Power Equipment Operators Tower crane: up to 175' in $84.77 7A 11 H 8X View height base to boom King Power Equipment Operators Tower Cranes: over 250' in $86.48 7A 11 H 8X View height from base to boom King Power Equipment Operators Transporters, All Track Or Truck $83.62 15J 11G 8X View Type King Power Equipment Operators Trenching Machines $82.25 15J 11G 8X View King Power Equipment Operators Truck Crane Oiler/Driver: 100 $83.20 7A 11H 8X View tons and over King Power Equipment Operators Truck crane oiler/driver: under $82.56 7A 11 H 8X View 100 tons King Power Equipment Operators Truck Mount Portable Conveyor $82.88 15J 11G 8X View King Power Equipment Operators Vac Truck (Vactor Guzzler, $82.88 15J 11G 8X View Hydro Excavator) King Power Equipment Operators Welder $83.62 15J 11G 8X View King Power Equipment Operators Wheel Tractors, Farman Type $78.65 15J 11G 8X View King Power Equipment Operators Yo Yo Pay Dozer $82.88 15J 11G 8X View King Power Equipment Operators- Asphalt Plant Operators $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Assistant Engineer $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Barrier Machine (zipper) $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Batch Plant Operator, Concrete $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Boat Operator $83.95 7A 11 H 8X View Underground Sewer Et Water King Power Equipment Operators- Bobcat $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Brokk - Remote Demolition $78.65 15J 11G 8X View Underground Sewer Et Water Equipment King Power Equipment Operators- Brooms $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Bump Cutter $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Cableways $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Chipper $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Compressor $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Concrete Finish Machine - $78.65 15J 11G 8X View Underground Sewer Et Water Laser Screed King Power Equipment Operators- Concrete Pump - Mounted Or $82.25 15J 11G 8X View Underground Sewer Et Water Trailer High Pressure Line Pump, Pump High Pressure King Power Equipment Operators- Concrete Pump: Truck Mount $83.62 15J 11G 8X View Underground Sewer Et Water With Boom Attachment Over 42 M King Power Equipment Operators- Concrete Pump: Truck Mount $82.88 15J 11G 8X View Underground Sewer Et Water With Boom Attachment Up To 42m King Power Equipment Operators- Conveyors $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Cranes Friction: 200 tons and $86.48 7A 11 H 8X View Underground Sewer Et Water over King Power Equipment Operators- Cranes, A-frame: 10 tons and $78.95 7A 11 H 8X View Underground Sewer Et Water under King Power Equipment Operators- Cranes: 100 tons through 199 $84.77 7A 11 H 8X View Underground Sewer Et Water tons, or 150' of boom (including jib with attachments) King Power Equipment Operators- Cranes: 20 tons through 44 $83.20 7A 11 H 8X View Underground Sewer Et Water tons with attachments King Power Equipment Operators- Cranes: 200 tons- 299 tons, or $85.66 7A 11 H 8X View Underground Sewer Et Water 250'of boom including jib with attachments King Power Equipment Operators- Cranes: 300 tons and over or $86.48 7A 11 H 8X View Underground Sewer Et Water 300'of boom including jib with attachments King Power Equipment Operators- Cranes: 45 tons through 99 $83.95 7A 11 H 8X View Underground Sewer Et Water tons, under 150' of boom(including jib with attachments) King Power Equipment Operators- Cranes: Friction cranes through $85.66 7A 11 H 8X View Underground Sewer Et Water 199 tons King Power Equipment Operators- Cranes: through 19 tons with $82.56 7A 11 H 8X View Underground Sewer Et Water attachments, a-frame over 10 tons King Power Equipment Operators- Crusher $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Deck Engineer/Deck Winches $82.88 15J 11G 8X View Underground Sewer Et Water (power) King Power Equipment Operators- Derricks, On Building Work $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Dozers D-9 Et Under $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Drill Oilers: Auger Type, Truck $82.25 15J 11G 8X View Underground Sewer Et Water Or Crane Mount King Power Equipment Operators- Drilling Machine $84.46 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Elevator and man-lift: $78.65 15J 11G 8X View Underground Sewer Et Water permanent and shaft type King Power Equipment Operators- Finishing Machine, Bidwell And $82.88 15J 11G 8X View Underground Sewer Et Water Gamaco Et Similar Equipment King Power Equipment Operators- Forklift: 3000 lbs and over with $82.25 15J 11G 8X View Underground Sewer Et Water attachments King Power Equipment Operators- Forklifts: under 3000 lbs. with $78.65 15J 11G 8X View Underground Sewer Et Water attachments King Power Equipment Operators- Grade Engineer: Using Blue $82.88 15J 11G 8X View Underground Sewer Et Water Prints, Cut Sheets, Etc King Power Equipment Operators- Gradechecker/Stakeman $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Guardrail Punch $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Hard Tail End Dump $83.62 15J 11G 8X View Underground Sewer Et Water Articulating Off- Road Equipment 45 Yards. Et Over King Power Equipment Operators- Hard Tail End Dump $82.88 15J 11G 8X View Underground Sewer Et Water Articulating Off-road Equipment Under 45 Yards King Power Equipment Operators- Horizontal/Directional Drill $82.25 15J 11G 8X View Underground Sewer Et Water Locator King Power Equipment Operators- Horizontal/Directional Drill $82.88 15J 11G 8X View Underground Sewer Et Water Operator King Power Equipment Operators- Hydralifts/boom trucks: 10 $78.95 7A 11 H 8X View Underground Sewer Et Water tons and under King Power Equipment Operators- Hydralifts/boom trucks: over $82.56 7A 11 H 8X View Underground Sewer Et Water 10 tons King Power Equipment Operators- Leverman $85.33 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Loader, Overhead, 6 Yards. But $83.62 15J 11G 8X View Underground Sewer Et Water Not Including 8 Yards King Power Equipment Operators- Loaders, Overhead Under 6 $82.88 15J 11G 8X View Underground Sewer Et Water Yards King Power Equipment Operators- Loaders, Plant Feed $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Loaders: Elevating Type Belt $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Locomotives, All $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Material Transfer Device $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Mechanics: All (Leadmen - $84.46 15J 11G 8X View Underground Sewer Et Water $0.50 per hour over mechanic) King Power Equipment Operators- Motor Patrol Graders $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Mucking Machine, Mole, Tunnel $83.62 15J 11G 8X View Underground Sewer Et Water Drill, Boring, Road Header And/or Shield King Power Equipment Operators- Oil Distributors, Blower $78.65 15J 11G 8X View Underground Sewer Et Water Distribution Et Mulch Seeding Operator King Power Equipment Operators- Outside Hoists (Elevators and $82.25 15J 11G 8X View Underground Sewer Et Water Manlifts), Air Tuggers, Strato King Power Equipment Operators- Overhead, bridge type Crane: $83.20 7A 11 H 8X View Underground Sewer Et Water 20 tons through 44 tons King Power Equipment Operators- Overhead, bridge type: 100 $84.77 7A 11 H 8X View Underground Sewer Et Water tons and over King Power Equipment Operators- Overhead, bridge type: 45 tons $83.95 7A 11 H 8X View Underground Sewer Et Water through 99 tons King Power Equipment Operators- Pavement Breaker $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Pile Driver (other Than Crane $82.88 15J 11G 8X View Underground Sewer Et Water Mount) King Power Equipment Operators- Plant Oiler -Asphalt, Crusher $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Posthole Digger, Mechanical $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Power Plant $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Pumps - Water $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Quad 9, Hd 41, D10And Over $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Quick Tower: no cab, under $82.88 15J 11G 8X View Underground Sewer Et Water 100 feet in height base to boom King Power Equipment Operators- Remote Control Operator On $83.62 15J 11G 8X View Underground Sewer Et Water Rubber Tired Earth Moving Equipment King Power Equipment Operators- Rigger and Bellman $78.95 7A 11 H 8X View Underground Sewer Et Water King Power Equipment Operators- Rigger/Signal Person, $82.56 7A 11 H 8X View Underground Sewer Et Water Bellman(Certified) King Power Equipment Operators- Rollagon $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Roller, Other Than Plant Mix $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Roller, Plant Mix Or Multi-lift $82.25 15J 11G 8X View Underground Sewer Et Water Materials King Power Equipment Operators- Roto-mill, Roto-grinder $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Saws - Concrete $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Scraper, Self Propelled Under $82.88 15J 11G 8X View Underground Sewer Et Water 45 Yards King Power Equipment Operators- Scrapers - Concrete Et Carry All $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Scrapers, Self-propelled: 45 $83.62 15J 11G 8X View Underground Sewer Et Water Yards And Over King Power Equipment Operators- Shotcrete/Gunite Equipment $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Shovel, Excavator, Backhoe, $82.25 15J 11G 8X View Underground Sewer Et Water Tractors Under 15 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoe: $83.62 15J 11G 8X View Underground Sewer Et Water Over 30 Metric Tons To 50 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes, $82.88 15J 11G 8X View Underground Sewer Et Water Tractors: 15 To 30 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes: $84.46 15J 11G 8X View Underground Sewer Et Water Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes: $85.33 15J 11G 8X View Underground Sewer Et Water Over 90 Metric Tons King Power Equipment Operators- Slipform Pavers $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Spreader, Topsider Et $83.62 15J 11G 8X View Underground Sewer Et Water Screedman King Power Equipment Operators- Subgrader Trimmer $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Tower Bucket Elevators $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Tower Crane: over 175' through $85.66 7A 11 H 8X View Underground Sewer Et Water 250' in height, base to boom King Power Equipment Operators- Tower crane: up to 175' in $84.77 7A 11 H 8X View Underground Sewer Et Water height base to boom King Power Equipment Operators- Tower Cranes: over 250' in $86.48 7A 11 H 8X View Underground Sewer Et Water height from base to boom King Power Equipment Operators- Transporters, All Track Or Truck $83.62 15J 11G 8X View Underground Sewer Et Water Type King Power Equipment Operators- Trenching Machines $82.25 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Truck Crane Oiler/Driver: 100 $83.20 7A 11H 8X View Underground Sewer Et Water tons and over King Power Equipment Operators- Truck crane oiler/driver: under $82.56 7A 11 H 8X View Underground Sewer Et Water 100 tons King Power Equipment Operators- Truck Mount Portable Conveyor $82.88 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Vac Truck (Vactor Guzzler, $82.88 15J 11G 8X View Underground Sewer Et Water Hydro Excavator) King Power Equipment Operators- Welder $83.62 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Wheel Tractors, Farman Type $78.65 15J 11G 8X View Underground Sewer Et Water King Power Equipment Operators- Yo Yo Pay Dozer $82.88 15J 11G 8X View Underground Sewer Et Water King Power Line Clearance Tree Journey Level In Charge $57.22 5A 4A View Trimmers King Power Line Clearance Tree Spray Person $54.32 5A 4A View Trimmers King Power Line Clearance Tree Tree Equipment Operator $57.22 5A 4A View Trimmers King Power Line Clearance Tree Tree Trimmer $51.18 5A 4A View Trimmers King Power Line Clearance Tree Tree Trimmer Groundperson $38.99 5A 4A View Trimmers King Refrigeration Et Air Conditioning Journey Level $95.89 6Z 1G View Mechanics King Residential Brick Mason Journey Level $69.07 7E 1 N View King Residential Carpenters Journey Level $36.44 1 View King Residential Cement Masons Journey Level $46.64 1 View King Residential Drywall Applicators Journey Level $74.96 15J 4C View King Residential Drywall Tapers Journey Level $36.36 1 View King Residential Electricians Journey Level $48.80 1 View King Residential Glaziers Journey Level $28.93 1 View King Residential Insulation Journey Level $28.18 1 View Applicators King Residential Laborers Journey Level $29.73 1 View King Residential Marble Setters Journey Level $27.38 1 View King Residential Painters Journey Level $23.47 1 View King Residential Plumbers Et Journey Level $45.40 1 View Pipefitters King Residential Refrigeration Et Air Journey Level $96.42 7F 1 E View Conditioning Mechanics King Residential Sheet Metal Journey Level $96.42 7F 1 E View Workers King Residential Soft Floor Lavers Journey Level $57.11 5A 3J View King Residential Sprinkler Fitters Journey Level $63.61 1 View ,(Fire Protection), King Residential Stone Masons Journey Level $69.07 7E 1 N View King Residential Terrazzo Workers Journey Level $62.36 7E 1 N View King Residential Terrazzo/Tile Journey Level $24.39 1 View Finishers King Residential Tile Setters Journey Level $21.04 1 View King Roofers Journey Level $64.45 5A 3H View King Roofers Using Irritable Bituminous $67.39 5A 3H View Materials King Sheet Metal Workers Journey Level (Field or Shop) $96.42 7F 1 E View King Shipbuilding Et Ship Repair New Construction Boilermaker $51.85 7X 4.1 View King Shipbuilding Et Ship Repair New Construction Carpenter $51.85 7X 4.1 View King Shipbuilding Et Ship Repair New Construction Crane $43.16 7V 1 View Operator King Shipbuilding Et Ship Repair New Construction Electrician $51.85 7X 4.1 View King Shipbuilding Et Ship Repair New Construction Heat Et Frost $87.15 15H 11C View Insulator King Shipbuilding Et Ship Repair New Construction Laborer $51.85 7X 4J View King Shipbuilding Et Ship Repair New Construction Machinist $51.85 7X 4.1 View King Shipbuilding Et Ship Repair New Construction Operating $43.16 7V 1 View Engineer King Shipbuilding Et Ship Repair New Construction Painter $51.95 7X 4J View King Shipbuilding Et Ship Repair New Construction Pipefitter $51.85 7X 4.1 View King Shipbuilding Et Ship Repair New Construction Rigger $51.85 7X 4J View King Shipbuilding Et Ship Repair New Construction Sheet Metal $51.85 7X 4.1 View King Shipbuilding Et Ship Repair New Construction Shipwright $51.85 7X 4.1 View King Shipbuilding Et Ship Repair New Construction $43.16 7V 1 View Warehouse/Teamster King Shipbuilding Et Ship Repair New Construction Welder / $51.85 7X 4J View Burner King Shipbuilding Et Ship Repair Ship Repair Boilermaker $51.85 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Carpenter $51.85 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Crane Operator $45.06 7Y 4K View King Shipbuilding Et Ship Repair Ship Repair Electrician $51.85 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Heat Et Frost $87.15 15H 11C View Insulator King Shipbuilding Et Ship Repair Ship Repair Laborer $51.85 7X 4.1 View King Shipbuilding Et Ship Repair Ship Repair Machinist $51.85 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Operating Engineer $45.06 7Y 4K View King Shipbuilding Et Ship Repair Ship Repair Painter $51.95 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Pipefitter $51.85 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Rigger $51.85 7X 4.1 View King Shipbuilding Et Ship Repair Ship Repair Sheet Metal $51.85 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Shipwright $51.85 7X 4.1 View King Shipbuilding Et Ship Repair Ship Repair Warehouse / $45.06 7Y 4K View Teamster King Sign Makers Et Installers Journey Level $58.04 0 1 View .(Electrical) King Sign Makers Et Installers (Non- Journey Level $37.08 0 1 View Electrical), King Soft Floor Lavers Journey Level $66.32 15J 4C View King Solar Controls For Windows Journey Level $16.28 1 View King Sprinkler Fitters (Fire Journey Level $95.49 5C 1X View Protection), King Stage Rigging Mechanics (Non Journey Level $16.28 1 View Structural). King Stone Masons Journey Level $69.07 7E 1 N View King Street And Parking Lot Sweeper Journey Level $19.09 1 View Workers King Surveyors Assistant Construction Site $82.56 7A 11 H 8X View Surveyor King Surveyors Chainman $78.95 7A 11 H 8X View King Surveyors Construction Site Surveyor $83.95 7A 11 H 8X View King Surveyors Drone Operator (when used in $78.95 7A 11 H 8X View conjunction with survey work only) King Surveyors Ground Penetrating Radar $78.95 7A 11 H 8X View Operator King Telecommunication Technicians Journey Level $65.66 7E 1 E View King Telephone Line Construction - Cable Splicer $40.36 5A 2B View Outside King Telephone Line Construction - Hole Digger/Ground Person $26.92 5A 2B View Outside King Telephone Line Construction - Telephone Equipment Operator $33.74 5A 2B View Outside (Light) King Telephone Line Construction - Telephone Lineperson $38.15 5A 2B View Outside King Terrazzo Workers Journey Level $62.36 7E 1 N View King Tile Setters Journey Level $62.36 7E 1 N View King Tile, Marble Et Terrazzo Finisher $53.19 7E 1 N View Finishers King Traffic Control Stripers Journey Level $89.54 15L 1 K View King Truck Drivers Asphalt Mix Over 16 Yards $74.95 15J 11M 8L View King Truck Drivers Asphalt Mix To 16 Yards $74.02 15J 11M 8L View King Truck Drivers Dump Truck $74.02 15J 11M 8L View King Truck Drivers Dump Truck Et Trailer $74.95 15J 11M 8L View King Truck Drivers Other Trucks $74.95 15J 11M 8L View King Truck Drivers - Ready Mix Transit Mix $74.95 15J 11M 8L View King Well Drillers Et Irrigation Pump Irrigation Pump Installer $17.71 1 View Installers King Well Drillers Et Irrigation Pump Oiler $16.28 1 View Installers King Well Drillers Et Irrigation Pump Well Driller $18.00 1 View Installers Signature: Signature: Kent Parks 18,20 Email: nharper@kentwa.gov Email: parkscontracts@kentwa.gov Signature: 8ria��Brian Levenhagen(Jun 18,202 12:15 PDT) Email: bjlevenhagen@kentwa.gov FAC-061424-Auburn Mechanical-Half Lion Final Audit Report 2024-06-18 Created: 2024-06-17 By: Leah Bryant(Ibryant@kentwa.gov) Status: Signed Transaction ID: CBJCHBCAABAAwVmXYY8vOL5rDYMzX99AxN3zD3Xgjkrs "FAC-061424-Auburn Mechanical-Half Lion" History Document created by Leah Bryant(Ibryant@kentwa.gov) 2024-06-17-9:07:44 PM GMT Document emailed to nharper@kentwa.gov for signature 2024-06-17-9:11:08 PM GMT s Email viewed by nharper@kentwa.gov 2024-06-17-9:13:20 PM GMT C:'Q, Signer nharper@kentwa.gov entered name at signing as Nathen C. Harper 2024-06-17-9:14:40 PM GMT �}o Document e-signed by Nathen C. Harper(nharper@kentwa.gov) Signature Date:2024-06-17-9:14:42 PM GMT-Time Source:server Document emailed to johnpayne@auburnmechanical.com for signature 2024-06-17-9:14:45 PM GMT Email viewed by johnpayne@auburnmechanical.com 2024-06-18-0:02:42 AM GMT o Signer johnpayne@auburnmechanical.com entered name at signing as John A Payne 2024-06-18-3:49:09 PM GMT �>o Document e-signed by John A Payne (johnpayne@auburnmechanical.com) Signature Date:2024-06-18-3:49:11 PM GMT-Time Source:server Document emailed to Kent Parks (parkscontracts@kentwa.gov)for signature 2024-06-18-3:49:14 PM GMT s Email viewed by Kent Parks (parkscontracts@kentwa.gov) 2024-06-18-6:20:49 PM GMT Powered by r � Adobe T Acrobat Sign Document e-signed by Kent Parks (parkscontracts@kentwa.gov) Signature Date:2024-06-18-7:05:25 PM GMT-Time Source:server Document emailed to bjlevenhagen@kentwa.gov for signature 2024-06-18-7:05:29 PM GMT s Email viewed by bjlevenhagen@kentwa.gov 2024-06-18-7:10:15 PM GMT Signer bjlevenhagen@kentwa.gov entered name at signing as Brian Levenhagen 2024-06-18-7:15:54 PM GMT Document e-signed by Brian Levenhagen (bjlevenhagen@kentwa.gov) Signature Date:2024-06-18-7:15:56 PM GMT-Time Source:server Agreement completed. 2024-06-18-7:15:56 PM GMT Powered by r � Adobe K T Acrobat Sign 3-City of Kent Half Lion rev 5-9-24 Final Audit Report 2024-06-26 Created: 2024-06-24 By: Leah Bryant(Ibryant@kentwa.gov) Status: Signed Transaction ID: CBJCHBCAABAA7JyJszOnNlaQg00P7gmzjfwHs9gLazVw "3-City of Kent Half Lion rev 5-9-24" History Document created by Leah Bryant(Ibryant@kentwa.gov) 2024-06-24-10:24:48 PM GMT Document emailed to jimperkins@auburnmechanical.com for signature 2024-06-24-10:25:14 PM GMT Email viewed by jimperkins@auburnmechanical.com 2024-06-25-4:27:18 PM GMT 1 Signer jimperkins@auburnmechanical.com entered name at signing as John A Payne 2024-06-26-10:59:58 PM GMT Document e-signed by John A Payne (jimperkins@auburnmechanical.com) Signature Date:2024-06-26-11:00:00 PM GMT-Time Source:server Agreement completed. 2024-06-26-11:00:00 PM GMT Powered by r � Adobe ` � T Acrobat Sign