Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
CAG2022-213 - Original - KBA, Inc. - S. 212th St. Preservation (Green River Bridge to Orillia Rd./Kent City Limits) - 05/19/2022
ApprovalOriginator:Department: Date Sent:Date Required: Mayor or Designee Date of Council Approval: Grant? Yes No Type:Review/Signatures/RoutingDate Received: City Attorney: Comments: Date Routed: Mayor’s Office City Clerk’s OfficeAgreement InformationVendor Name:Category: Vendor Number:Sub-Category: Project Name: Project Details: Agreement Amount: Start Date: Local Business? Yes No* Business License Verification: If meets requirements per KCC 3.70.100, please complete “Vendor Purchase-Local Exceptions” form on Cityspace. Yes In-Process Exempt (KCC 5.01.045) Notice required prior to disclosure? Yes No Contract Number: This form combines & replaces the Request for Mayor’s Signature and Contract Cover Sheet forms. (Print on pink or cherry colored paper) Visit Documents.KentWA.gov to obtain copies of all agreementsadccW22373_1_20 Budget Account Number: Budget? Yes No Dir Asst: Sup/Mgr: Dir/Dep: rev. 20210513 FOR CITY OF KENT OFFICIAL USE ONLY Agreement Routing Form For Approvals, Signatures and Records Management (Optional) Basis for Selection of Contractor: * Memo to Mayor must be attached Termination Date: Authorized to Sign: DATE: May 17, 2022 TO: Kent City Council SUBJECT: Consultant Agreement with KBA, Inc. for the S. 212th Street Preservation Project - Authorize MOTION: I move to authorize the Mayor to sign the Consultant Agreement with KBA, Inc. in the amount of $205,032 for contract administration, management, quality control, and inspection of the S 212th St Preservation (Green River Bridge to Orillia Rd) project, subject to final terms and conditions acceptable to the Public Works Director and City Attorney. SUMMARY: The S 212th Street Preservation project runs from the Green River Bridge to Orillia Road. This is a federally funded project that includes new asphalt pavement, channelization, and curb ramps on S 212th Street. This consultant contract is needed to provide a Resident Engineer, Inspector, and subconsultants to perform contract administration, construction management, quality control, and inspection on this federally funded project. Our consultant selection process follows Washington State Department of Transportation Local Agency Guideline Manual guidelines. Based on the selection process, staff recommends KBA, Inc. KBA specializes in providing construction management and contract administration on federally funded capital improvement projects for local municipalities throughout Puget Sound. The funding agency requires 19% Disadvantaged Business Enterprise (DBE) participation in contracts during the construction phase of the project. The required DBE participation will be met by KBA via subconsultant contracts with HWA Geosciences, Inc. (quality control) and Jimale Technical Services (contract administration). BUDGET IMPACT: The project will be paid for using a Puget Sound Regional Council Grant, and Business and Occupation Tax Funds. SUPPORTS STRATEGIC PLAN GOAL: Evolving Infrastructure - Connecting people and places through strategic investments in physical and technological infrastructure. ATTACHMENTS: 1.Agreement (PDF) 05/02/22 Public Works Committee MOTION PASSES RESULT: MOTION PASSES [UNANIMOUS] Next: 5/17/2022 7:00 PM MOVER: Marli Larimer, Councilmember SECONDER: Satwinder Kaur, Councilmember AYES: Brenda Fincher, Satwinder Kaur, Marli Larimer Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 1 of 34 Local Agency A&E Professional Services Negotiated Hourly Rate Consultant Agreement Agreement Number: Firm/Organization Legal Name (do not use dba’s): Address Federal Aid Number UBI Number Federal TIN Execution Date Completion Date 1099 Form Required Yes No Federal Participation Yes No Project Title Description of Work Yes No DBE Participation Yes No MBE Participation Yes No WBE Participation Yes No SBE Participation Maximum Amount Payable: Index of Exhibits Exhibit A Exhibit B Exhibit C Exhibit D Exhibit E Exhibit F Exhibit G Exhibit H Exhibit I Exhibit J Scope of Work DBE Participation Preparation and Delivery of Electronic Engineering and Other Data Prime Consultant Cost Computations Sub-consultant Cost Computations Title VI Assurances Certification Documents Liability Insurance Increase Alleged Consultant Design Error Procedures Consultant Claim Procedures Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 2 of 34 THIS AGREEMENT, made and entered into as shown in the “Execution Date” box on page one (1) of this AGREEMENT, between the _________________________________________________________________, hereinafter called the “AGENCY,” and the “Firm / Organization Name” referenced on page one (1) of this AGREEMENT, hereinafter called the “CONSULTANT.” WHEREAS, the AGENCY desires to accomplish the work referenced in “Description of Work” on page one (1) of this AGREEMENT and hereafter called the “SERVICES;” and does not have sufficient staff to meet the required commitment and therefore deems it advisable and desirable to engage the assistance of a CONSULTANT to provide the necessary SERVICES; and WHEREAS, the CONSULTANT represents that they comply with the Washington State Statutes relating to professional registration, if applicable, and has signified a willingness to furnish consulting services to the AGENCY. NOW, THEREFORE, in consideration of the terms, conditions, covenants, and performance contained herein, or attached and incorporated and made a part hereof, the parties hereto agree as follows: I.General Description of Work The work under this AGREEMENT shall consist of the above-described SERVICES as herein defined, and necessary to accomplish the completed work for this project. The CONSULTANT shall furnish all services, labor, and related equipment and, if applicable, sub-consultants and subcontractors necessary to conduct and complete the SERVICES as designated elsewhere in this AGREEMENT. II.General Scope of Work The Scope of Work and projected level of effort required for these SERVICES is described in Exhibit “A” attached hereto and by this reference made a part of this AGREEMENT. The General Scope of Work was developed utilizing performance based contracting methodologies. III.General Requirements All aspects of coordination of the work of this AGREEMENT with outside agencies, groups, or individuals shall receive advance approval by the AGENCY. Necessary contacts and meetings with agencies, groups, and/or individuals shall be coordinated through the AGENCY. The CONSULTANT shall attend coordination, progress, and presentation meetings with the AGENCY and/or such State, Federal, Community, City, or County officials, groups or individuals as may be requested by the AGENCY. The AGENCY will provide the CONSULTANT sufficient notice prior to meetings requiring CONSULTANT participation. The minimum required hours or days’ notice shall be agreed to between the AGENCY and the CONSULTANT and shown in Exhibit “A.” The CONSULTANT shall prepare a monthly progress report, in a form approved by the AGENCY, which will outline in written and graphical form the various phases and the order of performance of the SERVICES in sufficient detail so that the progress of the SERVICES can easily be evaluated. The CONSULTANT, any sub-consultants, and the AGENCY shall comply with all Federal, State, and local laws, rules, codes, regulations, and all AGENCY policies and directives, applicable to the work to be performed under this AGREEMENT. This AGREEMENT shall be interpreted and construed in accordance with the laws of the State of Washington. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 3 of 14 Participation for Disadvantaged Business Enterprises (DBE) or Small Business Enterprises (SBE), if required, per 49 CFR Part 26, shall be shown on the heading of this AGREEMENT. If DBE firms are utilized at the commencement of this AGREEMENT, the amounts authorized to each firm and their certification number will be shown on Exhibit “B” attached hereto and by this reference made part of this AGREEMENT. If the Prime CONSULTANT is, a DBE certified firm they must comply with the Commercial Useful Function (CUF) regulation outlined in the AGENCY’s “DBE Program Participation Plan” and perform a minimum of 30% of the total amount of this AGREEMENT. It is recommended, but not required, that non-DBE Prime CONSULTANTS perform a minimum of 30% of the total amount of this AGREEMENT. In the absents of a mandatory DBE goal, a voluntary SBE goal amount of ten percent of the Consultant Agreement is established. The Consultant shall develop a SBE Participation Plan prior to commencing work. Although the goal is voluntary, the outreach efforts to provide SBE maximum practicable opportunities are not. The CONSULTANT, on a monthly basis, shall enter the amounts paid to all firms (including Prime) involved with this AGREEMENT into the wsdot.diversitycompliance.com program. Payment information shall identify any DBE Participation. All Reports, PS&E materials, and other data furnished to the CONSULTANT by the AGENCY shall be returned. All electronic files, prepared by the CONSULTANT, must meet the requirements as outlined in Exhibit “C – Preparation and Delivery of Electronic Engineering and other Data.” All designs, drawings, specifications, documents, and other work products, including all electronic files, prepared by the CONSULTANT prior to completion or termination of this AGREEMENT are instruments of service for these SERVICES, and are the property of the AGENCY. Reuse by the AGENCY or by others, acting through or on behalf of the AGENCY of any such instruments of service, not occurring, as a part of this SERVICE, shall be without liability or legal exposure to the CONSULTANT. Any and all notices or requests required under this AGREEMENT shall be made in writing and sent to the other party by (i) certified mail, return receipt requested, or (ii) by email or facsimile, to the address set forth below: If to AGENCY: If to CONSULTANT: Name: Name: Agency: Agency: Address: Address: City: State: Zip: City: State: Zip: Email: Email: Phone: Phone: Facsimile: Facsimile: IV.Time for Beginning and Completion The CONSULTANT shall not begin any work under the terms of this AGREEMENT until authorized in writing by the AGENCY. All work under this AGREEMENT shall conform to the criteria agreed upon detailed in the AGREEMENT documents. These SERVICES must be completed by the date shown in the heading of this AGREEMENT titled “Completion Date.” The established completion time shall not be extended because of any delays attributable to the CONSULTANT, but may be extended by the AGENCY in the event of a delay attributable to the AGENCY, or because of unavoidable delays caused by an act of GOD, governmental actions, or other conditions beyond the control of the CONSULTANT. A prior supplemental AGREEMENT issued by the AGENCY is required to extend the established completion time. Eric Connor City of Kent 220 4th Avenue S. Kent WA 98032 EConnor@KentWA.gov (253) 856-5533 (253) 856-6500 Cameron Bloomer KBA, Inc. 11201 SE 8th Street, Suite 160 Bellevue WA 98004 cbloomer@kbacm.co m (206)819-7148 (425) 455-9732 Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 4 of 14 V. Payment Provisions The CONSULTANT shall be paid by the AGENCY for completed SERVICES rendered under this AGREEMENT as provided hereinafter. Such payment shall be full compensation for SERVICES performed or SERVICES rendered and for all labor, materials, supplies, equipment, and incidentals necessary to complete SERVICES. The CONSULTANT shall conform to all applicable portions of 48 CFR Part 31 (www.ecfr.gov). A.Hourly Rates: Hourly rates are comprised of the following elements - Direct (Raw) Labor, Indirect Cost Rate, and Fee (Profit). The CONSULTANT shall be paid by the AGENCY for work done, based upon the negotiated hourly rates shown in Exhibits “D” and “E” attached hereto and by reference made part of this AGREEMENT. These negotiated hourly rates will be accepted based on a review of the CONSULTANT’s direct labor rates and indirect cost rate computations and agreed upon fee. The accepted negotiated rates shall be memorialized in a final written acknowledgment between the parties. Such final written acknowledgment shall be incorporated into, and become a part of, this AGREEMENT. The initially accepted negotiated rates shall be applicable from the approval date, as memorialized in a final written acknowledgment, to 180 days following the CONSULTANT’s fiscal year end (FYE) date. The direct (raw) labor rates and classifications, as shown on Exhibits “D” and “E” shall be subject to renegotiations for each subsequent twelve (12) month period (180 days following FYE date to 180 days following FYE date) upon written request of the CONSULTANT or the AGENCY. The written request must be made to the other party within ninety (90) days following the CONSULTANT’s FYE date. If no such written request is made, the current direct (raw) labor rates and classifications as shown on Exhibits “D” and “E” will remain in effect for the twelve (12) month period. Conversely, if a timely request is made in the manner set forth above, the parties will commence negotiations to determine the new direct (raw) labor rates and classifications that will be applicable for the twelve (12 month period. Any agreed to renegotiated rates shall be memorialized in a final written acknowledgment between the parties. Such final written acknowledgment shall be incorporated into, and become a part of, this AGREEMENT. If requested, the CONSULTANT shall provide current payroll register and classifications to aid in negotiations. If the parties cannot reach an agreement on the direct (raw) labor rates and classifications, the AGENCY shall perform an audit of the CONSULTANT’s books and records to determine the CONSULTANT’s actual costs. The audit findings will establish the direct (raw) labor rates and classifications that will applicable for the twelve (12) month period. The fee as identified in Exhibits “D” and “E” shall represent a value to be applied throughout the life of the AGREEMENT. The CONSULTANT shall submit annually to the AGENCY an updated indirect cost rate within 180 days of the close of its fiscal year. An approved updated indirect cost rate shall be included in the current fiscal year rate under this AGREEMENT, even if/when other components of the hourly rate are not renegotiated. These rates will be applicable for the twelve (12) month period. At the AGENCY’s option, a provisional and/or conditional indirect cost rate may be negotiated. This provisional or conditional indirect rate shall remain in effect until the updated indirect cost rate is completed and approved. Indirect cost rate costs incurred during the provisional or conditional period will not be adjusted. The CONSULTANT may request an extension of the last approved indirect cost rate for the twelve (12) month period. These requests for provisional indirect cost rate and/or extension will be considered on a case-by-case basis, and if granted, will be memorialized in a final written acknowledgment. The CONSULTANT shall maintain and have accessible support data for verification of the components of the hourly rates, i.e., direct (raw) labor, indirect cost rate, and fee (profit) percentage. The CONSULTANT shall bill each employee’s actual classification, and actual salary plus indirect cost rate plus fee. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 5 of 14 A.Direct Non-Salary Costs: Direct Non-Salary Costs will be reimbursed at the actual cost to the CONSULTANT. These charges may include, but are not limited to, the following items: travel, printing, long distance telephone, supplies, computer charges, and fees of sub-consultants. Air or train travel will be reimbursed only to lowest price available, unless otherwise approved by the AGENCY. The CONSULTANT shall comply with the rules and regulations regarding travel costs (excluding air, train, and rental car costs) in accordance with the WSDOT’s Accounting Manual M 13-82, Chapter 10 – Travel Rules and Procedures, and all revisions thereto. Air, train, and rental card costs shall be reimbursed in accordance with 48 Code of Federal Regulations (CFR) Part 31.205-46 “Travel Costs.” The billing for Direct Non-salary Costs shall include an itemized listing of the charges directly identifiable with these SERVICES. The CONSULTANT shall maintain the original supporting documents in their office. Copies of the original supporting documents shall be supplied to the STATE upon request. All above charges must be necessary for the SERVICES provided under this AGREEMENT. B.Maximum Amount Payable: The Maximum Amount Payable by the AGENCY to the CONSULTANT under this AGREEMENT shall not exceed the amount shown in the heading of this AGREEMENT on page one (1.) The Maximum Amount Payable does not include payment for extra work as stipulated in section XIII, “Extra Work.” No minimum amount payable is guaranteed under this AGREEMENT. C.Monthly Progress Payments: Progress payments may be claimed on a monthly basis for all costs authorized in A and B above. Detailed statements shall support the monthly billings for hours expended at the rates established in Exhibit “D,” including names and classifications of all employees, and billings for all direct non-salary expenses. To provide a means of verifying the billed salary costs for the CONSULTANT’s employees, the AGENCY may conduct employee interviews. These interviews may consist of recording the names, titles, salary rates, and present duties of those employees performing work on the SERVICES at the time of the interview. D.Final Payment: Final Payment of any balance due the CONSULTANT of the gross amount earned will be made promptly upon its verification by the AGENCY after the completion of the SERVICES under this AGREEMENT, contingent upon receipt of all PS&E, plans, maps, notes, reports, electronic data, and other related documents, which are required to be furnished under this AGREEMENT. Acceptance of such Final Payment by the CONSULTANT shall constitute a release of all claims for payment, which the CONSULTANT may have against the AGENCY unless such claims are specifically reserved in writing and transmitted to the AGENCY by the CONSULTANT prior to its acceptance. Said Final Payment shall not, however, be a bar to any claims that the AGENCY may have against the CONSULTANT or to any remedies the AGENCY may pursue with respect to such claims. The payment of any billing will not constitute agreement as to the appropriateness of any item and at the time of final audit all required adjustments will be made and reflected in a final payment. In the event that such final audit reveals an overpayment to the CONSULTANT, the CONSULTANT will refund such overpayment to the AGENCY within thirty (30) calendar days of notice of the overpayment. Such refund shall not constitute a waiver by the CONSULTANT for any claims relating to the validity of a finding by the AGENCY of overpayment. Per WSDOT’s “Audit Guide for Consultants,” Chapter 23 “Resolution Procedures,” the CONSULTANT has twenty (20) working days after receipt of the final Post Audit to begin the appeal process to the AGENCY for audit findings E. Inspection of Cost Records: The CONSULTANT and their sub-consultants shall keep available for inspection by representatives of the AGENCY and the United States, for a period of six (6) years after receipt of final payment, the cost records and accounts pertaining to this AGREEMENT and all items related to or bearing upon these records with the following exception: if any litigation, claim or audit arising out of, in connection with, or related to this AGREEMENT is initiated before the expiration of the six (6) year period, the cost records and accounts shall be retained until such litigation, claim, or audit involving the records is completed. An interim or post audit may be performed on this AGREEMENT. The audit, if any, will be performed by the State Auditor, WSDOT’s Internal Audit Office and /or at the request of the AGENCY’s Project Manager. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 6 of 14 VI.Sub-Contracting The AGENCY permits subcontracts for those items of SERVICES as shown in Exhibit “A” attached hereto and by this reference made part of this AGREEMENT. The CONSULTANT shall not subcontract for the performance of any SERVICE under this AGREEMENT without prior written permission of the AGENCY. No permission for subcontracting shall create, between the AGENCY and sub-consultant, any contract or any other relationship. Compensation for this sub-consultant SERVICES shall be based on the cost factors shown on Exhibit “E” attached hereto and by this reference made part of this AGREEMENT. The SERVICES of the sub-consultant shall not exceed its maximum amount payable identified in each sub consultant cost estimate unless a prior written approval has been issued by the AGENCY. All reimbursable direct labor, indirect cost rate, direct non-salary costs and fee costs for the sub-consultant shall be negotiated and substantiated in accordance with section V “Payment Provisions” herein and shall be memorialized in a final written acknowledgment between the parties All subcontracts shall contain all applicable provisions of this AGREEMENT, and the CONSULTANT shall require each sub-consultant or subcontractor, of any tier, to abide by the terms and conditions of this AGREEMENT. With respect to sub-consultant payment, the CONSULTANT shall comply with all applicable sections of the STATE’s Prompt Payment laws as set forth in RCW 39.04.250 and RCW 39.76.011. The CONSULTANT, sub-recipient, or sub-consultant shall not discriminate on the basis of race, color, national origin, or sex in the performance of this AGREEMENT. The CONSULTANT shall carry out applicable requirements of 49 CFR Part 26 in the award and administration of DOT-assisted contracts. Failure by the CONSULTANT to carry out these requirements is a material breach of this AGREEMENT, which may result in the termination of this AGREEMENT or such other remedy as the recipient deems appropriate. VII.Employment and Organizational Conflict of Interest The CONSULTANT warrants that they have not employed or retained any company or person, other than a bona fide employee working solely for the CONSULTANT, to solicit or secure this contract, and that it has not paid or agreed to pay any company or person, other than a bona fide employee working solely for the CONSULTANT, any fee, commission, percentage, brokerage fee, gift, or any other consideration, contingent upon or resulting from the award or making of this contract. For breach or violation of this warrant, the AGENCY shall have the right to annul this AGREEMENT without liability or, in its discretion, to deduct from this AGREEMENT price or consideration or otherwise recover the full amount of such fee, commission, percentage, brokerage fee, gift, or contingent fee. Any and all employees of the CONSULTANT or other persons while engaged in the performance of any work or services required of the CONSULTANT under this AGREEMENT, shall be considered employees of the CONSULTANT only and not of the AGENCY, and any and all claims that may arise under any Workmen’s Compensation Act on behalf of said employees or other persons while so engaged, and any and all claims made by a third party as a consequence of any act or omission on the part of the CONSULTANT’s employees or other persons while so engaged on any of the work or services provided to be rendered herein, shall be the sole obligation and responsibility of the CONSULTANT. The CONSULTANT shall not engage, on a full- or part-time basis, or other basis, during the period of this AGREEMENT, any professional or technical personnel who are, or have been, at any time during the period of this AGREEMENT, in the employ of the United States Department of Transportation or the AGENCY, except regularly retired employees, without written consent of the public employer of such person if he/she will be working on this AGREEMENT for the CONSULTANT. Agreement Number: Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 7 of 14 VIII. Nondiscrimination During the performance of this AGREEMENT, the CONSULTANT, for itself, its assignees, sub-consultants, subcontractors and successors in interest, agrees to comply with the following laws and regulations: •Title VI of the Civil Rights Act of 1964 (42 U.S.C. Chapter 21 Subchapter V § 2000d through 2000d-4a) •Federal-aid Highway Act of 1973 (23 U.S.C. Chapter 3 § 324) •Rehabilitation Act of 1973 (29 U.S.C. Chapter 16 Subchapter V § 794) •Age Discrimination Act of 1975 (42 U.S.C. Chapter 76 § 6101 et. seq.) •Civil Rights Restoration Act of 1987 (Public Law 100-259) •American with Disabilities Act of 1990 (42 U.S.C. Chapter 126 § 12101 et. seq.) •23 CFR Part 200 •49 CFR Part 21 •49 CFR Part 26 • RCW 49.60.180 In relation to Title VI of the Civil Rights Act of 1964, the CONSULTANT is bound by the provisions of Exhibit “F” attached hereto and by this reference made part of this AGREEMENT, and shall include the attached Exhibit “F” in every sub-contract, including procurement of materials and leases of equipment, unless exempt by the Regulations or directives issued pursuant thereto. IX.Termination of Agreement The right is reserved by the AGENCY to terminate this AGREEMENT at any time with or without cause upon ten (10) days written notice to the CONSULTANT. In the event this AGREEMENT is terminated by the AGENCY, other than for default on the part of the CONSULTANT, a final payment shall be made to the CONSULTANT for actual hours charged at the time of termination of this AGREEMENT, plus any direct non-salary costs incurred up to the time of termination of this AGREEMENT. No payment shall be made for any SERVICES completed after ten (10) days following receipt by the CONSULTANT of the notice to terminate. If the accumulated payment made to the CONSULTANT prior to Notice of Termination exceeds the total amount that would be due when computed as set forth in paragraph two (2) of this section, then no final payment shall be due and the CONSULTANT shall immediately reimburse the AGENCY for any excess paid. If the services of the CONSULTANT are terminated by the AGENCY for default on the part of the CONSULTANT, the above formula for payment shall not apply. In the event of a termination for default, the amount to be paid to the CONSULTANT shall be determined by the AGENCY with consideration given to the actual costs incurred by the CONSULTANT in performing SERVICES to the date of termination, the amount of SERVICES originally required which was satisfactorily completed to date of termination, whether that SERVICE is in a form or a type which is usable to the AGENCY at the time of termination, the cost to the AGENCY of employing another firm to complete the SERVICES required and the time which may be required to do so, and other factors which affect the value to the AGENCY of the SERVICES performed at the time of termination. Under no circumstances shall payment made under this subsection exceed the amount, which would have been made using the formula set forth in paragraph two (2) of this section. If it is determined for any reason, that the CONSULTANT was not in default or that the CONSULTANT’s failure to perform is without the CONSULTANT’s or its employee’s fault or negligence, the termination shall be deemed to be a termination for the convenience of the AGENCY. In such an event, the CONSULTANT would be reimbursed for actual costs in accordance with the termination for other than default clauses listed previously. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 8 of 14 The CONSULTANT shall, within 15 days, notify the AGENCY in writing, in the event of the death of any member, partner, or officer of the CONSULTANT or the death or change of any of the CONSULTANT’s supervisory and/or other key personnel assigned to the project or disaffiliation of any principally involved CONSULTANT employee. The CONSULTANT shall also notify the AGENCY, in writing, in the event of the sale or transfer of 50% or more of the beneficial ownership of the CONSULTANT within 15 days of such sale or transfer occurring. The CONSULTANT shall continue to be obligated to complete the SERVICES under the terms of this AGREEMENT unless the AGENCY chooses to terminate this AGREEMENT for convenience or chooses to renegotiate any term(s) of this AGREEMENT. If termination for convenience occurs, final payment will be made to the CONSULTANT as set forth in the second and third paragraphs of this section. Payment for any part of the SERVICES by the AGENCY shall not constitute a waiver by the AGENCY of any remedies of any type it may have against the CONSULTANT for any breach of this AGREEMENT by the CONSULTANT, or for failure of the CONSULTANT to perform SERVICES required of it by the AGENCY. Forbearance of any rights under the AGREEMENT will not constitute waiver of entitlement to exercise those rights with respect to any future act or omission by the CONSULTANT. X.Changes of Work The CONSULTANT shall make such changes and revisions in the completed work of this AGREEMENT as necessary to correct errors appearing therein, without additional compensation thereof. Should the AGENCY find it desirable for its own purposes to have previously satisfactorily completed SERVICES or parts thereof changed or revised, the CONSULTANT shall make such revisions as directed by the AGENCY. This work shall be considered as Extra Work and will be paid for as herein provided under section XIII “Extra Work.” XI.Disputes Any disputed issue not resolved pursuant to the terms of this AGREEMENT shall be submitted in writing within 10 days to the Director of Public Works or AGENCY Engineer, whose decision in the matter shall be final and binding on the parties of this AGREEMENT; provided however, that if an action is brought challenging the Director of Public Works or AGENCY Engineer’s decision, that decision shall be subject to judicial review. If the parties to this AGREEMENT mutually agree, disputes concerning alleged design errors will be conducted under the procedures found in Exhibit “J”. In the event that either party deem it necessary to institute legal action or proceeding to enforce any right or obligation under this AGREEMENT, this action shall be initiated in the Superior Court of the State of Washington, situated in the county in which the AGENCY is located. The parties hereto agree that all questions shall be resolved by application of Washington law and that the parties have the right of appeal from such decisions of the Superior Court in accordance with the laws of the State of Washington. The CONSULTANT hereby consents to the personal jurisdiction of the Superior Court of the State of Washington, situated in the county in which the AGENCY is located. XII.Legal Relations The CONSULTANT, any sub-consultants, and the AGENCY shall comply with all Federal, State, and local laws, rules, codes, regulations and all AGENCY policies and directives, applicable to the work to be performed under this AGREEMENT. This AGREEMENT shall be interpreted and construed in accordance with the laws of the State of Washington. The CONSULTANT shall defend, indemnify, and hold the State of Washington (STATE) and the AGENCY and their officers and employees harmless from all claims, demands, or suits at law or equity arising in whole or in part from the negligence of, or the breach of any obligation under this AGREEMENT by, the CONSULTANT or the CONSULTANT’s agents, employees, sub consultants, subcontractors or vendors, of any tier, or any other persons for whom the CONSULTANT may be legally liable; provided that nothing herein shall require a CONSULTANT Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 9 of 14 to defend or indemnify the STATE and the AGENCY and their officers and employees against and hold harmless the STATE and the AGENCY and their officers and employees from claims, demands or suits based solely upon the negligence of, or breach of any obligation under this AGREEMENT by the STATE and the AGENCY, their agents, officers, employees, sub-consultants, subcontractors or vendors, of any tie , or any other persons for whom the STATE and /or the AGENCY may be legally liable; and provided further that if the claims or suits are caused by or result from the concurrent negligence of (a) the CONSULTANT or the CONSULTANT’s agents, employees, sub-consultants, subcontractors or vendors, of any tier, or any other persons for whom the CONSULTANT is legally liable, and (b) the STATE and/or AGENCY, their agents, officers, employees, sub-consultants, subcontractors and or vendors, of any tier, or any other persons for whom the STATE and/or AGENCY may be legally liable, the defense and indemnity obligation shall be valid and enforceable only to the extent of the CONSULTANT’s negligence or the negligence of the CONSULTANT’s agents, employees, sub-consultants, subcontractors or vendors, of any tier, or any other persons for whom the CONSULTANT may be legally liable. This provision shall be included in any AGREEMENT between CONSULTANT and any sub-consultant, subcontractor and vendor, of any tier. The CONSULTANT shall also defend, indemnify, and hold the STATE and the AGENCY and their officers and employees harmless from all claims, demands, or suits at law or equity arising in whole or in part from the alleged patent or copyright infringement or other allegedly improper appropriation or use of trade secrets, patents, proprietary information, know-how, copyright rights or inventions by the CONSULTANT or the CONSULTANT’s agents, employees, sub-consultants, subcontractors or vendors, of any tier, or any other persons for whom the CONSULTANT may be legally liable, in performance of the Work under this AGREEMENT or arising out of any use in connection with the AGREEMENT of methods, processes, designs, information or other items furnished or communicated to STATE and/or the AGENCY, their agents, officers and employees pursuant to the AGREEMENT; provided that this indemnity shall not apply to any alleged patent or copyright infringement or other allegedly improper appropriation or use of trade secrets, patents, proprietary information, know-how, copyright rights or inventions resulting from STATE and/or AGENCY’s, their agents’, officers and employees’ failure to comply with specific written instructions regarding use provided to STATE and/or AGENCY, their agents, officers and employees by the CONSULTANT, its agents, employees, sub- consultants, subcontractors or vendors, of any tier, or any other persons for whom the CONSULTANT may be legally liable. The CONSULTANT’s relation to the AGENCY shall be at all times as an independent contractor. Notwithstanding any determination by the Executive Ethics Board or other tribunal, the AGENCY may, in its sole discretion, by written notice to the CONSULTANT terminate this AGREEMENT if it is found after due notice and examination by the AGENCY that there is a violation of the Ethics in Public Service Act, Chapter 42.52 RCW; or any similar statute involving the CONSULTANT in the procurement of, or performance under, this AGREEMENT. The CONSULTANT specifically assumes potential liability for actions brought by the CONSULTANT’s own employees or its agents against the STATE and/or the AGENCY and, solely for the purpose of this indemnification and defense, the CONSULTANT specifically waives any immunity under the state industrial insurance law, Title 51 RCW. The Parties have mutually negotiated this waiver. Unless otherwise specified in this AGREEMENT, the AGENCY shall be responsible for administration of construction contracts, if any, on the project. Subject to the processing of a new sole source, or an acceptable supplemental AGREEMENT, the CONSULTANT shall provide On-Call assistance to the AGENCY during contract administration. By providing such assistance, the CONSULTANT shall assume no responsibility for proper construction techniques, job site safety, or any construction contractor’s failure to perform its work in accordance with the contract documents. The CONSULTANT shall obtain and keep in force during the terms of this AGREEMENT, or as otherwise required, the following insurance with companies or through sources approved by the State Insurance Commissioner pursuant to Title 48 RCW. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 10 of 14 Insurance Coverage A.Worker’s compensation and employer’s liability insurance as required by the STATE. B.Commercial general liability insurance written under ISO Form CG 00 01 12 04 or its equivalent with minimum limits of one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000.00) in the aggregate for each policy period. C.Business auto liability insurance written under ISO Form CG 00 01 10 01 or equivalent providing coverage for any “Auto” (Symbol 1) used in an amount not less than a one million dollar ($1,000,000.00) combined single limit for each occurrence. Excepting the Worker’s Compensation Insurance and any Professional Liability Insurance, the STATE and AGENCY, their officers, employees, and agents will be named on all policies of CONSULTANT and any sub- consultant and/or subcontractor as an additional insured (the “AIs”), with no restrictions or limitations concerning products and completed operations coverage. This coverage shall be primary coverage and non- contributory and any coverage maintained by the AIs shall be excess over, and shall not contribute with, the additional insured coverage required hereunder. The CONSULTANT’s and the sub-consultant’s and/or subcontractor’s insurer shall waive any and all rights of subrogation against the AIs. The CONSULTANT shall furnish the AGENCY with verification of insurance and endorsements required by this AGREEMENT. The AGENCY reserves the right to require complete, certified copies of all required insurance policies at any time. All insurance shall be obtained from an insurance company authorized to do business in the State of Washington. The CONSULTANT shall submit a verification of insurance as outlined above within fourteen (14) days of the execution of this AGREEMENT to: Name: Agency: Address: City: State: Zip: Email: Phone: Facsimile: No cancellation of the foregoing policies shall be effective without thirty (30) days prior notice to the AGENCY. The CONSULTANT’s professional liability to the AGENCY, including that which may arise in reference to section IX “Termination of Agreement” of this AGREEMENT, shall be limited to the accumulative amount of the authorized AGREEMENT or one million dollars ($1,000,000.00), whichever is greater, unless the limit of liability is increased by the AGENCY pursuant to Exhibit H. In no case shall the CONSULTANT’s professional liability to third parties be limited in any way. The parties enter into this AGREEMENT for the sole benefit of the parties, and to the exclusion of any third part, and no third party beneficiary is intended or created by the execution of this AGREEMENT. The AGENCY will pay no progress payments under section V “Payment Provisions” until the CONSULTANT has fully complied with this section. This remedy is not exclusive; and the AGENCY may take such other action as is available to it under other provisions of this AGREEMENT, or otherwise in law. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 11 of 14 XIII.Extra Work A.The AGENCY may at any time, by written order, make changes within the general scope of this AGREEMENT in the SERVICES to be performed. B.If any such change causes an increase or decrease in the estimated cost of, or the time required for, performance of any part of the SERVICES under this AGREEMENT, whether or not changed by the order, or otherwise affects any other terms and conditions of this AGREEMENT, the AGENCY shall make an equitable adjustment in the: (1) maximum amount payable; (2) delivery or completion schedule, or both; and (3) other affected terms and shall modify this AGREEMENT accordingly. C.The CONSULTANT must submit any “request for equitable adjustment,” hereafter referred to as “CLAIM,” under this clause within thirty (30) days from the date of receipt of the written order. However, if the AGENCY decides that the facts justify it, the AGENCY may receive and act upon a CLAIM submitted before final payment of this AGREEMENT. D.Failure to agree to any adjustment shall be a dispute under the section XI “Disputes” clause. However, nothing in this clause shall excuse the CONSULTANT from proceeding with the AGREEMENT as changed. E.Notwithstanding the terms and conditions of paragraphs (A.) and (B.) above, the maximum amount payable for this AGREEMENT, shall not be increased or considered to be increased except by specific written supplement to this AGREEMENT. XIV.Endorsement of Plans If applicable, the CONSULTANT shall place their endorsement on all plans, estimates, or any other engineering data furnished by them. XV.Federal Review The Federal Highway Administration shall have the right to participate in the review or examination of the SERVICES in progress. XVI.Certification of the Consultant and the Agency Attached hereto as Exhibit “G-1(a and b)” are the Certifications of the CONSULTANT and the AGENCY, Exhibit “G-2” Certification Regarding Debarment, Suspension and Other Responsibility Matters - Primary Covered Transactions, Exhibit “G-3” Certification Regarding the Restrictions of the Use of Federal Funds for Lobbying and Exhibit “G-4” Certificate of Current Cost or Pricing Data. Exhibit “G-3” is required only in AGREEMENT’s over one hundred thousand dollars ($100,000.00) and Exhibit “G-4” is required only in AGREEMENT’s over five hundred thousand dollars ($500,000.00.) These Exhibits must be executed by the CONSULTANT, and submitted with the master AGREEMENT, and returned to the AGENCY at the address listed in section III “General Requirements” prior to its performance of any SERVICES under this AGREEMENT. XVII.Complete Agreement This document and referenced attachments contain all covenants, stipulations, and provisions agreed upon by the parties. No agent, or representative of either party has authority to make, and the parties shall not be bound by or be liable for, any statement, representation, promise or agreement not set forth herein. No changes, amendments, or modifications of the terms hereof shall be valid unless reduced to writing and signed by the parties as a supplement to this AGREEMENT. XVIII.Execution and Acceptance This AGREEMENT may be simultaneously executed in several counterparts, each of which shall be deemed to be an original having identical legal effect. The CONSULTANT does hereby ratify and adopt all statements, representations, warranties, covenants, and AGREEMENT’s contained in the proposal, and the supporting material submitted by the CONSULTANT, and does hereby accept this AGREEMENT and agrees to all of the terms and conditions thereof. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 12 of 14 XIX.Protection of Confidential Information The CONSULTANT acknowledges that some of the material and information that may come into its possession or knowledge in connection with this AGREEMENT or its performance may consist of information that is exempt from disclosure to the public or other unauthorized persons under either chapter 42.56 RCW or other local, state, or federal statutes (“State’s Confidential Information”). The “State’s Confidential Information” includes, but is not limited to, names, addresses, Social Security numbers, e-mail addresses, telephone numbers, financial profiles credit card information, driver’s license numbers, medical data, law enforcement records (or any other information identifiable to an individual), STATE and AGENCY source code or object code, STATE and AGENCY security data, non-public Specifications, STATE and AGENCY non-publicly available data, proprietary software, STATE and AGENCY security data, or information which may jeopardize any part of the project that relates to any of these types of information. The CONSULTANT agrees to hold the State’s Confidential Information in strictest confidence and not to make use of the State’s Confidential Information for any purpose other than the performance of this AGREEMENT, to release it only to authorized employees, sub- consultants or subcontractors requiring such information for the purposes of carrying out this AGREEMENT, and not to release, divulge, publish, transfer, sell, disclose, or otherwise make it known to any other party without the AGENCY’s express written consent or as provided by law. The CONSULTANT agrees to release such information or material only to employees, sub-consultants or subcontractors who have signed a nondisclosure AGREEMENT, the terms of which have been previously approved by the AGENCY. The CONSULTANT agrees to implement physical, electronic, and managerial safeguards to prevent unauthorized access to the State’s Confidential Information. Immediately upon expiration or termination of this AGREEMENT, the CONSULTANT shall, at the AGENCY’s option: (i) certify to the AGENCY that the CONSULTANT has destroyed all of the State’s Confidential Information; or (ii) returned all of the State’s Confidential Information to the AGENCY; or (iii) take whatever other steps the AGENCY requires of the CONSULTANT to protect the State’s Confidential Information. As required under Executive Order 00-03, the CONSULTANT shall maintain a log documenting the following: the State’s Confidential Information received in the performance of this AGREEMENT; the purpose(s) for which the State’s Confidential Information was received; who received, maintained, and used the State’s Confidential Information; and the final disposition of the State’s Confidential Information. The CONSULTANT’s records shall be subject to inspection, review, or audit upon reasonable notice from the AGENCY. The AGENCY reserves the right to monitor, audit, or investigate the use of the State’s Confidential Information collected, used, or acquired by the CONSULTANT through this AGREEMENT. The monitoring, auditing, or investigating may include, but is not limited to, salting databases. Violation of this section by the CONSULTANT or its sub-consultants or subcontractors may result in termination of this AGREEMENT and demand for return of all State’s Confidential Information, monetary damages, or penalties It is understood and acknowledged that the CONSULTANT may provide the AGENCY with information, which is proprietary and/or confidential during the term of this AGREEMENT. The parties agree to maintain the confidentiality of such information during the term of this AGREEMENT and afterwards. All materials containing such proprietary and/or confidential information shall be clearly identified and marked as “Confidential” and shall be returned to the disclosing party at the conclusion of the SERVICES under this AGREEMENT. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 13 of 14 The CONSULTANT shall provide the AGENCY with a list of all information and materials it considers confidential and/or proprietary in nature: (a) at the commencement of the term of this AGREEMENT, or (b) as soon as such confidential or proprietary material is developed. “Proprietary and/or confidential information” is not meant to include any information which, at the time of its disclosure: (i) is already known to the other party; (ii) is rightfully disclosed to one of the parties by a third party that is not acting as an agent or representative for the other party; (iii) is independently developed by or for the other party; (iv) is publicly known; or (v) is generally utilized by unaffiliated third parties engaged in the same business or businesses as the CONSULTANT. The parties also acknowledge that the AGENCY is subject to Washington State and federal public disclosure laws. As such, the AGENCY shall maintain the confidentiality of all such information marked proprietary and or confidential or otherwise exempt, unless such disclosure is required under applicable state or federal law. If a public disclosure request is made to view materials identified as “Proprietary and/or confidential information” or otherwise exempt information, the AGENCY will notify the CONSULTANT of the request and of the date that such records will be released to the requester unless the CONSULTANT obtains a court order from a court of competent jurisdiction enjoining that disclosure. If the CONSULTANT fails to obtain the court order enjoining disclosure, the AGENCY will release the requested information on the date specified. The CONSULTANT agrees to notify the sub-consultant of any AGENCY communication regarding disclosure that may include a sub-consultant’s proprietary and/or confidential information. The CONSULTANT notification to the sub-consultant will include the date that such records will be released by the AGENCY to the requester and state that unless the sub-consultant obtains a court order from a court of competent jurisdiction enjoining that disclosure the AGENCY will release the requested information. If the CONSULTANT and/or sub-consultant fail to obtain a court order or other judicial relief enjoining the AGENCY by the release date, the CONSULTANT shall waive and release and shall hold harmless and indemnify the AGENCY from all claims of actual or alleged damages, liabilities, or costs associated with the AGENCY’s said disclosure of sub- consultants’ information. XX.Records Maintenance During the progress of the Work and SERVICES provided hereunder and for a period of not less than six (6) years from the date of final payment to the CONSULTANT, the CONSULTANT shall keep, retain, and maintain all “documents” pertaining to the SERVICES provided pursuant to this AGREEMENT. Copies of all “documents” pertaining to the SERVICES provided hereunder shall be made available for review at the CONSULTANT’s place of business during normal working hours. If any litigation, claim, or audit is commenced, the CONSULTANT shall cooperate with AGENCY and assist in the production of all such documents. “Documents” shall be retained until all litigation, claims or audit findings have been resolved even though such litigation, claim, or audit continues past the six (6) year retention period. For purposes of this AGREEMENT, “documents” means every writing or record of every type and description, including electronically stored information (“ESI”), that is in the possession, control, or custody of the CONSULTANT, including, without limitation, any and all correspondences, contracts, AGREEMENTs, appraisals, plans, designs, data, surveys, maps, spreadsheets, memoranda, stenographic or handwritten notes, reports, records, telegrams, schedules, diaries, notebooks, logbooks, invoices, accounting records, work sheets, charts, notes, drafts, scribblings, recordings, visual displays, photographs, minutes of meetings, tabulations, computations, summaries, inventories, and writings regarding conferences, conversations or telephone conversations, and any and all other taped, recorded, written, printed or typed matters of any kind or description; every copy of the foregoing whether or not the original is in the possession, custody, or control of the CONSULTANT, and every copy of any of the foregoing, whether or not such copy is a copy identical to an original, or whether or not such copy contains any commentary or notation whatsoever that does not appear on the original. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Page 14 of 14 For purposes of this AGREEMENT, “ESI” means any and all computer data or electronic recorded media of any kind, including “Native Files”, that are stored in any medium from which it can be retrieved and examined, either directly or after translation into a reasonably useable form. ESI may include information and/or documentation stored in various software programs such as Email, Outlook, Word, Excel, Access, Publisher, PowerPoint, Adobe Acrobat, SQL databases, or any other software or electronic communication programs or databases that the CONSULTANT may use in the performance of its operations. ESI may be located on network servers, backup tapes, smart phones, thumb drives, CDs, DVDs, floppy disks, work computers, cell phones, laptops, or any other electronic device that CONSULTANT uses in the performance of its Work or SERVICES hereunder, including any personal devices used by the CONSULTANT or any sub-consultant at home. “Native files” are a subset of ESI and refer to the electronic format of the application in which such ESI is normally created, viewed, and /or modified The CONSULTANT shall include this section XX “Records Maintenance” in every subcontract it enters into in relation to this AGREEMENT and bind the sub-consultant to its terms, unless expressly agreed to otherwise in writing by the AGENCY prior to the execution of such subcontract. In witness whereof, the parties hereto have executed this AGREEMENT as of the day and year shown in the “Execution Date” box on page one (1) of this AGREEMENT. Signature Date Signature Date Any modification, change, or reformation of this AGREEMENT shall require approval as to form by the Office of the Attorney General. 05/19/2022 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 5/11/2022 AssuredPartners Design Professionals Insurance Services,LLC 3697 Mt.Diablo Blvd Suite 230 Lafayette CA 94549 Brittini Alberty brittini.alberty@assuredpartners.com License#:6003745 The Travelers Indemnity Company 25658 KBAINC0-03 Travelers Casualty and Surety Co of America 31194KBA,Inc. 11201 SE 8th Street,Ste 160 Bellevue WA 98004 253801276 A X 1,000,000 X 1,000,000 X Contractual Liab 10,000 Included 1,000,000 2,000,000 X X Y Y 6806N033449 5/10/2022 5/10/2023 2,000,000 A 1,000,000 X X X Y Y BA7R748905 5/10/2022 5/10/2023 A X6806N0334495/10/2022 5/10/2023 WA STOP GAP 1,000,000 1,000,000 1,000,000 B Professional Liability & Contractor's Pollution Legal Liability 107633573 5/10/2022 5/10/2023 Per Claim Annual Aggregate $1,000,000 $1,000,000 RE:Project Name:212th St.Preservation (GRB to Orillia Rd)/Project Number:022011-01 the STATE and AGENCY,their officers,employees,and agents are named as Additional Insured as respects General and Auto Liability as required per written contract or agreement.The General Liability and Automobile Liability policies include an automatic Additional Insured endorsement that provides Additional Insured status to the Certificate Holder,only when there is a written contract that requires such status,and only with regard to work performed on behalf of the named insured.The General Liability policy contains a special endorsement with Primary and Noncontributory wording,when required by written contract.The Automobile Liability policy contains a special endorsement with Primary wording,when required by written contract.30 Days Notice of Cancellation 30 Day Notice of Cancellation City of Kent Attn:Nancy Yoshitake 220 Fourth Avenue S. Kent WA 98032 Policy #: BA7R748905 ÐÑÔ×ÝÇÒËÓÞÛÎ COMMERCIAL GENERAL LIABILITY ISSUED DATE: ÌØ×ÍÛÒÜÑÎÍÛÓÛÒÌÝØßÒÙÛÍÌØÛÐÑÔ×ÝÇòÐÔÛßÍÛÎÛßÜ×ÌÝßÎÛÚËÔÔÇò ̸·»²¼±®»³»²¬³±¼·º·»·²«®¿²½»°®±ª·¼»¼«²¼»®¬¸»º±´´±©·²¹æ ÝÑÓÓÛÎÝ×ßÔÙÛÒÛÎßÔÔ×ßÞ×Ô×ÌÇÝÑÊÛÎßÙÛÐßÎÌ øײº±®³¿¬·±²®»¯«·®»¼¬±½±³°´»¬»¬¸·Í½¸»¼«´»ô·º²±¬¸±©²¿¾±ª»ô©·´´¾»¸±©²·²¬¸»Ü»½´¿®¿¬·±²ò÷ Í»½¬·±²×× É¸±×߲ײ«®»¼·¿³»²¼»¼¬±·²ó ̸··²«®¿²½»¼±»²±¬¿°°´§¬±þ¾±¼·´§·²¶«®§þ±® ½´«¼»¿¿²¿¼¼·¬·±²¿´·²«®»¼¬¸»°»®±²ø÷±® þ°®±°»®¬§¼¿³¿¹»þ±½½«®®·²¹ô±®°»®±²¿´·²¶«®§Œ ±®¹¿²·¦¿¬·±²ø÷¸±©²·²¬¸»Í½¸»¼«´»ô¾«¬±²´§ ±®¿¼ª»®¬··²¹·²¶«®§Œ¿®··²¹±«¬±º¿²±ºº»²» ©·¬¸®»°»½¬¬±´·¿¾·´·¬§º±®þ¾±¼·´§·²¶«®§þôþ°®±°»®¬§ ½±³³·¬¬»¼ô¿º¬»®æ ¼¿³¿¹»þôþ°»®±²¿´·²¶«®§Œ±®¿¼ª»®¬··²¹·²¶«®§þ ß´´©±®µô·²½´«¼·²¹³¿¬»®·¿´ô°¿®¬±®»¯«·°ó½¿«»¼ô·²©¸±´»±®·²°¿®¬ô¾§æ ³»²¬º«®²·¸»¼·²½±²²»½¬·±²©·¬¸«½¸©±®µô DZ«®¿½¬±®±³··±²å±®±²¬¸»°®±¶»½¬ø±¬¸»®¬¸¿²»®ª·½»ô³¿·²¬»ó ²¿²½»±®®»°¿·®÷¬±¾»°»®º±®³»¼¾§±®±²Ì¸»¿½¬±®±³··±²±º¬¸±»¿½¬·²¹±²§±«®¾»¸¿´º±º¬¸»¿¼¼·¬·±²¿´·²«®»¼ø÷¿¬¬¸»´±½¿ó¾»¸¿´ºå ¬·±²±º¬¸»½±ª»®»¼±°»®¿¬·±²¸¿¾»»²½±³ó·²¬¸»°»®º±®³¿²½»±º§±«®±²¹±·²¹±°»®¿¬·±²º±®°´»¬»¼å±®¬¸»¿¼¼·¬·±²¿´·²«®»¼ø÷¿¬¬¸»´±½¿¬·±²ø÷¼»·¹ó ̸¿¬°±®¬·±²±ºþ§±«®©±®µþ±«¬±º©¸·½¸¬¸»²¿¬»¼¿¾±ª»ò ·²¶«®§±®¼¿³¿¹»¿®·»¸¿¾»»²°«¬¬±·¬·²óÉ·¬¸®»°»½¬¬±¬¸»·²«®¿²½»¿ºº±®¼»¼¬±¬¸»»¬»²¼»¼«»¾§¿²§°»®±²±®±®¹¿²·¦¿¬·±²¿¼¼·¬·±²¿´·²«®»¼ô¬¸»º±´´±©·²¹¿¼¼·¬·±²¿´»¨½´«ó ±¬¸»®¬¸¿²¿²±¬¸»®½±²¬®¿½¬±®±®«¾½±²¬®¿½ó·±²¿°°´§æ ¬±®»²¹¿¹»¼·²°»®º±®³·²¹±°»®¿¬·±²º±®¿ °®·²½·°¿´¿¿°¿®¬±º¬¸»¿³»°®±¶»½¬ò ݱ°§®·¹¸¬îððë̸»Í¬òп«´Ì®¿ª»´»®Ý±³°¿²·»ôײ½òß´´®·¹¸¬®»»®ª»¼ò п¹»ï±ºï ײ½´«¼»½±°§®·¹¸¬»¼³¿¬»®·¿´±º×²«®¿²½»Í»®ª·½»Ñºº·½»ôײ½ò©·¬¸·¬°»®³··±²ò Any person or organization that you agree in a written contract, on this Coverage Part, provided that such written contract was signed and executed by you before, and is in effect when the "bodily injury" or "property damage" occurs or the "personal injury" or "advertising injury" offense is committed. Any project to which an applicable written contract with the described in the Name of Additional Insured Person(s) or Organization(s) section of this Schedule applies. 6806N033449 5/11/2022 ÐÑÔ×ÝÇÒËÓÞÛÎæ COMMERCIAL GENERAL LIABILITY ISSUED DATE: ÌØ×ÍÛÒÜÑÎÍÛÓÛÒÌÝØßÒÙÛÍÌØÛÐÑÔ×ÝÇòÐÔÛßÍÛÎÛßÜ×ÌÝßÎÛÚËÔÔÇò ̸·»²¼±®»³»²¬³±¼·º·»·²«®¿²½»°®±ª·¼»¼«²¼»®¬¸»º±´´±©·²¹æ ÝÑÓÓÛÎÝ×ßÔÙÛÒÛÎßÔÔ×ßÞ×Ô×ÌÇÝÑÊÛÎßÙÛÐßÎÌ ×²º±®³¿¬·±²®»¯«·®»¼¬±½±³°´»¬»¬¸·Í½¸»¼«´»ô·º²±¬¸±©²¿¾±ª»ô©·´´¾»¸±©²·²¬¸»Ü»½´¿®¿¬·±²ò ·¿³»²¼»¼¬±·²ó ´±½¿¬·±²¼»·¹²¿¬»¼¿²¼¼»½®·¾»¼·²¬¸»½¸»¼«´»±º ½´«¼»¿¿²¿¼¼·¬·±²¿´·²«®»¼¬¸»°»®±²ø÷±®±®ó ¬¸·»²¼±®»³»²¬°»®º±®³»¼º±®¬¸¿¬¿¼¼·¬·±²¿´·²ó ¹¿²·¦¿¬·±²ø÷¸±©²·²¬¸»Í½¸»¼«´»ô¾«¬±²´§©·¬¸ «®»¼¿²¼·²½´«¼»¼·²¬¸»þ°®±¼«½¬ó½±³°´»¬»¼±°»®¿ó ®»°»½¬¬±´·¿¾·´·¬§º±®þ¾±¼·´§·²¶«®§þ±®þ°®±°»®¬§¼¿³ó ¬·±²¸¿¦¿®¼þò ¿¹»þ½¿«»¼ô·²©¸±´»±®·²°¿®¬ô¾§þ§±«®©±®µþ¿¬¬¸» ×ÍÑЮ±°»®¬·»ôײ½òôîððì п¹»ï±ºï Any person or organization that you agree in a written contract to include as an additional insured on this Coverage Part for "bodily injury" or "property damage" included in the "products- completed operations hazard", provided that such contract was signed and executed by you before, and is in effect when, the bodily injury or property damage occurs. Any project to which an applicable contract described in the Name of Additional Insured Person(s) or Organization(s) section of this Schedule applies. 5/11/20226806N033449 COMMERCIAL GENERAL LIABILITY c. Method Of Sharing If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this methoo, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. d. Primary And Non-Contributory Insurance If Required By Written Contract If you specifically agree in a written contract or agreement that the insurance afforded to an insured under this Coverage Part must apply on a primary basis, or a primary and non- contributory basis. this insurance is primary to other insurance that is available to such insured which covers such insured as a named insured, and we will not share with that other insurance, provided that: (1) The "bodily injury'' or "property damage" for which coverage is sought occurs; and (2) The "personal and advertising injury" for which coverage is sought is caused by an offense that is committed; subsequent to the signing of that contract or agreement by you. 5. Premium Audit a. We will compute all premiums for this Coverage Part in accordance with our rules and rates. b. Premium shown in this Coverage Part as advance premium is a deposit premium only. At the close of each audit perioo we will compute the earned premium for that period and send notice to the first Named Insured. The due date for audit and retrospective premiums is the date shown as the due date on the bill. If the sum of the advance and audit premiums paid for the policy period is greater than the earned premium, we will return the excess to the first Named Insured. c. The first Named Insured must keep records of the information we need for premium computation , and send us copies at such times as we may request. 6. Representations By accepting this policy, you agree: a. The statements in the Declarations are accurate and complete; b. Those statements are based upon representations you made to us; and c. We have issued this policy in reliance upon your representations. The unintentional omission of, or unintentional error in, any information provided by you which we relied upon in issuing this policy will not prejudice your rights under this insurance. However, this provision does not affect our right to collect additional premium or to exercise our rights of cancellation or nonrenewal in accordance with applicable insurance laws or regulations. 7. Separation Of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this Coverage Part to the first Named Insured, this insurance applies: a. As if each Named Insured were the only Named Insured; and b. Separately to each insured against whom claim is made or "suit" is brought. 8. Transfer Of Rights Of Recovery Against Others To Us If the insured has rights to recover all or part of any payment we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. 9. When We Do Not Renew If we decide not to renew this Coverage Part, we will mail or deliver to the first Named Insured shown in the Declarations written not ice of the nonrenewal not less than 30 days before the expiration date. If notice is mailed, proof of mailing will be sufficient proof of notice. SECTION V -DEFINITIONS 1. "Advertisement" means a notice that is broadcast or published to the general public or specific market segments about your goods, products or services for the purpose of attracting customers or supporters. For the purposes of this definition: a. Notices that are published include material placed on the Internet or on similar electronic means of communication; and b. Regarding websites, only that part of a website that is about your goods, prooucts or services for the purposes of attracting customers or supporters is considered an advertisement. Page 16 of 21 © 2017 The Travelers Indemnity Company. All rights reserved. CG T1000219 Includes copyrighted material of Insurance Services Office, Inc. with its permiss ion. Policy #6806N033449 6806N0334496806N033449 COMMERCIAL GENERAL LIABILITY that is available to any of your "employees"occupational therapist or occupational for "bodily injury" that arises out of providingtherapy assistant, physical therapist or or failing to provide "incidental medicalspeech-language pathologist; or services" to any person to the extent not(b)First aid or "Good Samaritan services"subject to Paragraph 2.a.(1)of Section II –by any of your "employees" or "volunteer Who Is An Insured.workers", other than an employed or volunteer doctor. Any such "employees"K. MEDICAL PAYMENTS – INCREASED LIMIT or "volunteer workers" providing or failing The following replaces Paragraph 7.ofto provide first aid or "Good Samaritan SECTION III – LIMITS OF INSURANCE:services" during their work hours for you 7.Subject to Paragraph 5.above, the Medicalwill be deemed to be acting within the scope of their employment by you or Expense Limit is the most we will pay under performing duties related to the conduct Coverage C for all medical expenses of your business.because of "bodily injury" sustained by any one person, and will be the higher of:3.The following replaces the last sentence of Paragraph 5.of SECTION III – LIMITS OF a.$10,000; orINSURANCE: b.The amount shown in the Declarations ofFor the purposes of determining the this Coverage Part for Medical Expenseapplicable Each Occurrence Limit, all related Limit.acts or omissions committed in providing or failing to provide "incidental medical L. AMENDMENT OF EXCESS INSURANCE services", first aid or "Good Samaritan CONDITION – PROFESSIONAL LIABILITYservices" to any one person will be deemed The following is added to Paragraph 4.b.,to be one "occurrence".Excess Insurance, of SECTION IV –4.The following exclusion is added to COMMERCIAL GENERAL LIABILITYParagraph2.,Exclusions, of SECTION I –CONDITIONS: COVERAGES – COVERAGE A – BODILY This insurance is excess over any of the otherINJURY AND PROPERTY DAMAGE insurance, whether primary, excess, contingentLIABILITY:or on any other basis, that is ProfessionalSale Of Pharmaceuticals Liability or similar coverage, to the extent the "Bodily injury" or "property damage" arising loss is not subject to the professional services out of the violation of a penal statute or exclusion of Coverage A or Coverage B. ordinance relating to the sale of M. BLANKET WAIVER OF SUBROGATION –pharmaceuticals committed by, or with the WHEN REQUIRED BY WRITTEN CONTRACTknowledge or consent of the insured.OR AGREEMENT5.The following is added to the DEFINITIONS The following is added to Paragraph 8.,TransferSection: Of Rights Of Recovery Against Others To Us,"Incidental medical services" means:of SECTION IV – COMMERCIAL GENERAL a.Medical, surgical, dental, laboratory, x-LIABILITY CONDITIONS: ray or nursing service or treatment,If the insured has agreed in a written contract oradvice or instruction, or the related agreement to waive that insured's right offurnishing of food or beverages; or recovery against any person or organization, we b.The furnishing or dispensing of drugs or waive our right of recovery against such personmedical, dental, or surgical supplies or or organization, but only for payments we makeappliances.because of: 6.The following is added to Paragraph 4.b.,a."Bodily injury" or "property damage" thatExcess Insurance, of SECTION IV –occurs; orCOMMERCIAL GENERAL LIABILITY b."Personal and advertising injury" caused byCONDITIONS: an offense that is committed;This insurance is excess over any valid and subsequent to the signing of that contract orcollectible other insurance, whether primary, excess, contingent or on any other basis,agreement. CG D3 79 02 19 ú 2017 The Travelers Indemnity Company. All rights reserved.Page 5 of 6 Includes copyrighted material of Insurance Services Office, Inc. with its permission. Policy #6806N033449 Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit A Scope of Work Project No. KBA, Inc. 4/19/2022 P:\Public\PROJECTS\_In Design\20-3012 S 212th Orilla (City limits to Green River Bridge)\50 Consultant Selection & Contracts\50.9 Construction\KBA Contract Documents\KBA Proposal and Contract Request\KBA-SCOPE-TEMPLATE-Kent 212th GRB to Orillia Rd.docx 1 of 7 EXHIBIT A SCOPE OF SERVICES for S. 212th St Pavement Preservation, Green River Bridge to Orillia Rd KBA, Inc. (Consultant) will provide Construction Management (CM) services to the City of Kent (Client), for the project known as S. 212th St Pavement Preservation, Green River Bridge to Orillia Rd (Project). These services will include consultation, contract administration, field observation, documentation, and material testing, as required during the construction of the Project, as detailed below. Project Description: This project includes planing and HMA Overlay of S. 212th Street between the Green River Bridge and Orillia Rd. Other work elements include the replacement of curb ramps, installing pedestrian push buttons, sidewalk repairs, vehicle detection loops, and channelization. The Designer of Record on this Project is the City of Kent (Designer). I. CONSTRUCTION MANAGEMENT SERVICES A. Consultant Contract and Team Management: Provide overall day-to-day management of the Consultant contract and Team, including: 1. Decide on best modes and frequency of communication with Client and Designer. Liaison and coordinate with Client on a regular basis to discuss Project issues and status. 2. Manage Consultant Team, comprised of Consultant’s staff and its subconsultants, if any. Organize and layout work for Consultant Team. 3. Review monthly expenditures and Consultant Team scope activities. Prepare and submit to Client monthly, an invoice and progress report describing services provided that period. Prepare and submit reporting required by funding source(s), if any. Deliverables Monthly invoices and progress reports B. Preconstruction Services 1. Review Contract Documents to familiarize team with Project requirements. 2. Organize and lead preconstruction conference: a. Prepare and distribute notices. b. Prepare agenda. c. Conduct the meeting. d. Prepare and distribute meeting notes to attendees and affected agencies. 3. Provide one set of preconstruction photographs. Deliverables Preconstruction Conference Notice, Agenda, and Notes Preconstruction photos, digital files on electronic storage medium C. Construction Phase Services – Contract Administration 1. Liaison with the Client, construction contractor, Designer, appropriate agencies, adjacent property owners, and utilities. KBA, Inc. 4/19/2022 P:\Public\PROJECTS\_In Design\20-3012 S 212th Orilla (City limits to Green River Bridge)\50 Consultant Selection & Contracts\50.9 Construction\KBA Contract Documents\KBA Proposal and Contract Request\KBA-SCOPE-TEMPLATE-Kent 212th GRB to Orillia Rd.docx 2 of 7 2. In concurrence with Progress Estimates, provide the Client with brief construction progress reports, highlighting progress and advising of issues that are likely to impact cost, schedule, or quality/scope. 3. Schedule Review: a. Review construction contractor’s schedules for compliance with Contract Documents. b. Monitor the construction contractor’s conformance to schedule and request revised schedules when needed. Advise Client of schedule changes. 4. Progress Meetings. Lead regular (usually weekly) progress meetings with the construction contractor, including Client pre-briefing. Prepare weekly meeting agenda and meeting notes and distribute copies to attendees. Track outstanding issues on a weekly basis. 5. Manage Submittal Process. Track and review, or cause to be reviewed by other appropriate party, work plans, shop drawings, samples, test reports, and other data submitted by the construction contractor, for general conformance to the Contract Documents. 6. Record of Materials. Maintain records of material compliance documentation received and advise Client of any known deficiencies. 7. Prepare weekly statement of working days and distribute to the Client and Contractor. 8. Manage RFI (Request for Information) process. Track and review/evaluate or cause to be reviewed/evaluated by other appropriate party, RFIs. Manage responses to RFIs. 9. Change Management. Evaluate entitlement, and prepare scope, impact, and independent estimate for change orders. Facilitate resolution of change orders. 10. Monthly Pay Requests. Prepare monthly progress estimates for payment. Review payment requests submitted by construction contractor for comparison and reconcile differences. Review with Client and construction contractor and recommend approval, as appropriate. a. Evaluate construction contractor’s Schedule of Values for lump sum items. Review the Contract Price allocations and verify that such allocations are made in accordance with the requirements of the Contract Documents. 11. Notify construction contractor of work found in noncompliance with the requirements of the contract. 12. Assist the Client in the investigation of malfunctions or failures observed during construction. 13. Public Information. Provide information for Client to prepare media communications and public notices on Project status. Provide information for Client’s inclusion into a Project website and/or newsletter, if requested. 14. Record Drawings. Review not less than monthly, the construction contractor’s redline set of contract plans. Maintain a CM Team set of conformed drawings tracking plan changes, location of discovered anomalies and other items, as encountered by Consultant Team. Use these markups to check the progress of the Contractor-prepared Record Drawings. 15. Document Control. Establish and maintain document filing and tracking systems, following Client guidelines and meeting funding agency requirements. Collect, organize, and prepare documentation on the Project. a. If requested, one hard copy of files will be kept in the Project field office. b. Electronic documentation will be stored in a Project Website, using SharePoint, managed and hosted by the Consultant. The Client will be provided with licenses for their and the construction contractor’s use of the SharePoint website during the Project. Consultant will provide one training session for Client and construction contractor users of the SharePoint system. KBA, Inc. 4/19/2022 P:\Public\PROJECTS\_In Design\20-3012 S 212th Orilla (City limits to Green River Bridge)\50 Consultant Selection & Contracts\50.9 Construction\KBA Contract Documents\KBA Proposal and Contract Request\KBA-SCOPE-TEMPLATE-Kent 212th GRB to Orillia Rd.docx 3 of 7 c. The Project SharePoint site will transition to “read-only” access upon expiration of the Agreement, or upon project completion and transfer of final records, whichever occurs first. Transference of final records will include a digital copy of the files stored in the Project SharePoint site. Access to SharePoint will expire following that date. 16. To comply with Article XIX. Protection of Confidential Information of the LAG Agreement, maintain a log documenting the following: the State’s Confidential Information received in the performance of this AGREEMENT; the purpose(s) for which the State’s Confidential Information was received; who received, maintained and used the State’s Confidential Information; and the final disposition of the State’s Confidential Information. 17. Project Closeout. If requested, prepare or assist with preparation of Certificate Letters of Substantial, Physical, and Final Completion for Client approval and signature, to include punch list. Prepare final pay estimate for Client approval and processing. 18. Final Records. Compile and convey final Project records, transferring to the Client for its archiving at final acceptance of the Project. Should Consultant’s work end prior to full completion of the Project, its records will be transferred to the Client prior to departure from the Project. Records will consist of electronic records on electronic storage medium, hardcopies can be provided upon request for additional cost. Deliverables Monthly Construction Progress Reports Schedule Review Comments Meeting Agendas and Notes Submittal Log Record of Materials RFI Log Change Order(s) Progress Pay Requests Certificate Letters of Completion Final records - electronic D. Construction Phase Services – Field 1. Observe the technical conduct of the construction, including providing day-to-day contact with the construction contractor, Client, utilities, and other stakeholders, and monitor for adherence to the Contract Documents. The Consultant’s personnel will act in accordance with Sections 1-05.1 and 1-05.2 of the WSDOT/APWA Standard Specifications. 2. Observe material, workmanship, and construction areas for compliance with the Contract Documents and applicable codes. Advise the Client of any non-conforming work observed during site visits. 3. Prepare Inspector Daily Reports (IDRs), recording the construction contractor’s operations as actually observed by the Consultant; includes quantities of work placed that day, contractor’s equipment and crews, photos of work performed, and other pertinent information. 4. Interpret Construction Contract Documents, in coordination with Designer. 5. Evaluate and report to Client issues that may arise as to the quality and acceptability of material furnished, work performed, and rate of progress of work performed by the construction contractor. 6. Establish communications with adjacent property owners. Respond to questions from property owners and the general public. 7. Coordinate with permit holders on the Project to monitor compliance with approved permits, if applicable. KBA, Inc. 4/19/2022 P:\Public\PROJECTS\_In Design\20-3012 S 212th Orilla (City limits to Green River Bridge)\50 Consultant Selection & Contracts\50.9 Construction\KBA Contract Documents\KBA Proposal and Contract Request\KBA-SCOPE-TEMPLATE-Kent 212th GRB to Orillia Rd.docx 4 of 7 8. Prepare field records, daily reports of force account worked, and other payment source documents to help facilitate administration of the Project in accordance with funding agency requirements. 9. Attend and actively participate in regular on-site meetings. 10. Take periodic digital photographs during the course of construction. Photographs to be labeled and organized in accordance with Client protocol. 11. Punch List. Upon substantial completion of work, coordinate with the Client and affected agencies, to prepare a ‘punch list’ of items to be completed or corrected. Coordinate final inspection with those agencies. 12. Testing. Conduct materials and laboratory tests. Coordinate the work of the Field Representative(s) and testing laboratories in the observation and testing of materials used in the construction; document and evaluate results of testing; and inform Client and construction contractor of deficiencies. Deliverables IDRs with Project photos – submitted on a weekly basis Field Note Records and Daily Reports of Force Account Worked Additional Project photos not included in IDRs Punch List(s) Test reports E. Assumptions 1. Budget: a. Staffing levels are anticipated in accordance with the attached budget estimate. Consultant services are budgeted for a 5-month period, from May through September 2022. This is intended to span the originally planned construction duration of 70 contractor working days, plus time allotted for Project setup and closeout. Overtime has been figured at 6%, or an average of 8.5 hours per day for the inspector, and 4.25 hrs per day for the Resident Engineer. b. Consultant will work up to the limitations of the authorized budget. If additional budget is needed to cover instances, including but not limited to the following, Client and Consultant will negotiate a Supplement to this Agreement: i. The contractor’s schedule requires inspection coverage of extra crews and shifts. ii. The construction contract runs longer than the time period detailed above. iii. Any added scope tasks. iv. Adjustment of Consultant Indirect Cost Rate (ICR) percentage pursuant to the terms as outlined in Section V of the LAG Agreement. c. The work is anticipated to be performed during daytime hours, with the exception of plaining and HMA paving. A 15 percent differential for labor is being applied to all night shift hours worked by Consultant’s employees. d. Client to provide office with internet access, bathroom facilities, drinking water, and office furniture. e. The budget allocations shown in Exhibit B are itemized to aid in Project tracking purposes only. The budget may be transferred between tasks or people, or between labor and expenses, provided the total contracted amount is not exceeded without prior authorization. KBA, Inc. 4/19/2022 P:\Public\PROJECTS\_In Design\20-3012 S 212th Orilla (City limits to Green River Bridge)\50 Consultant Selection & Contracts\50.9 Construction\KBA Contract Documents\KBA Proposal and Contract Request\KBA-SCOPE-TEMPLATE-Kent 212th GRB to Orillia Rd.docx 5 of 7 f. The budget assumes that Consultant’s standard forms, logs, and processes will be used on the Project SharePoint site. Any customization to meet specialized Client requirements will be Extra Work. g. Should Consultant’s level of effort extend beyond the time period detailed in the attached Exhibit B - Estimate, and into a new year, labor rates will adjust annually on January 1, with 30-day written notice to Agency. 2. Items and Services Client will provide: a. Meeting arrangements and facilities for pre-bid and preconstruction meetings. Prepare and distribute meeting notes from pre-bid meeting(s), if any. b. Field office, including: i. workstations (desk, chair, and storage) for 2 staff members ii. conference table and chairs iii. combination printer/copier/scanner machine with these capabilities: 11x17 size, color, and of business quality, if needed iv. high-speed, dedicated connection, including static IP v. miscellaneous office supplies vi. utilities and sanitary facilities c. Retain Engineer of Record for shop drawing review, RFIs, design changes, and final record drawings. d. Coordination with and enforcement of utility franchise agreements and/or contracts and schedules for services related to this Project. e. Verify that the required permits, bonds, and insurance have been obtained and submitted by the construction contractor. Obtain all permits not required to be provided by construction contractor. f. Construction Survey. Provide project control survey and staking that is not already assigned to the construction contractor. g. Client will download certified payrolls from L&I site and provide them to the Consultant for tracking and filing. 3. Scope: a. The SharePoint tool being used on this Project is proprietary to the Consultant (KBA, Inc.), and may not be used by any other party or on any other project without the written permission and involvement of KBA, Inc. b. Consultant will provide observation services for the days/hours that its’ Inspector(s) personnel is/are on-site. The Inspector(s) will not be able to observe or report construction activities, or collect documentation, during the time they are not on-site. c. The Consultant’s monitoring of the construction contractor's activities is to ascertain whether or not they are performing the work in accordance with the Contract Documents; in case of noncompliance, Consultant will reject non-conforming work and pursue the other remedies in the interests of the Client, as detailed in the Contract Documents. The Consultant cannot guarantee the construction contractor’s performance, and it is understood that Consultant shall assume no responsibility for proper construction means, methods, techniques, Project site safety, safety precautions or programs, or for the failure of any other entity to perform its work in accordance with laws, contracts, regulations, or Client’s expectations. d. Definitions and Roles. The use of the term “inspect” in relation to Consultant services is synonymous with “construction observation,” and reference to the “Inspector” role is synonymous with “Field Representative,” and means: performing on-site observations of KBA, Inc. 4/19/2022 P:\Public\PROJECTS\_In Design\20-3012 S 212th Orilla (City limits to Green River Bridge)\50 Consultant Selection & Contracts\50.9 Construction\KBA Contract Documents\KBA Proposal and Contract Request\KBA-SCOPE-TEMPLATE-Kent 212th GRB to Orillia Rd.docx 6 of 7 the progress and quality of the Work and determining, in general, if the Work is being performed in conformance with the Contract Documents; and notifying the Client if Work does not conform to the Contract Documents or requires special inspection or testing. Where “Specialty Inspector” or “specialty inspection” is used, it refers to inspection by a Building Official or independent agent of the Building Official, or other licensed/certified inspector who provides a certified inspection report in accordance with an established standard. e. Because of the prior use of the Project site, there is a possibility of the presence of toxic or hazardous materials. Consultant shall have no responsibility for the discovery, presence, handling, removal or disposal of toxic or hazardous materials, or for exposure of persons to toxic or hazardous materials in any form at the Project site, including but not limited to asbestos, asbestos products, polychlorinated biphenyl (PCB), or other toxic substances. If the Consultant suspects the presence of hazardous materials, they will notify the Client immediately for resolution. f. Review of Shop Drawings, samples, and other submittals will be for general conformance with the design concept and general compliance with the requirements of the contract for construction. Such review will not relieve the Contractor from its responsibility for performance in accordance with the contract for construction, nor is such review a guarantee that the work covered by the shop drawings, samples and submittals is free of errors, inconsistencies or omissions. g. Any opinions of probable construction cost provided by the Consultant will be on the basis of experience and professional judgment. However, since Consultant has no control over competitive bidding or market conditions, the Consultant cannot and does not warrant that bids or ultimate construction costs will not vary from these opinions of probable construction costs. h. Quantity takeoffs and calculated quantities are for the purpose of comparing with Designer’s and/or bidders’ quantities and are not a guarantee of final quantities. i. Development of construction schedules and/or sequencing, and/or reviewing and commenting on contractor’s schedules, is for the purpose of estimating number of days to complete a project, for identifying potential schedule and coordination challenges, and determining compliance with the construction contract. It is not a guarantee that a construction contractor will complete the Project in that sequence or timeline, as means and methods are the responsibility of the construction contractor. j. Consultant is not responsible for any costs, claims or judgments arising from or in any way connected with errors, omissions, conflicts or ambiguities in the Contract Documents prepared by others. The Consultant does not have responsibility for the professional quality or technical adequacy or accuracy of the design plans or specifications, nor for their timely completion by others. k. If Consultant provides Value Analysis or Value Engineering services, it is understood that any ideas, advice, or recommendations generated by the Consultant are made based only on the information presented to them, and need engineering analysis by the Designer to verify; Consultant is not responsible for the final design product. l. Client agrees to include a statement in the construction Bid Documents for this Project, requiring construction contractor to name KBA, Inc. as an additional insured via endorsement to the contractor’s commercial general liability and automobile insurance policies. m. RCW 4.24.115 is applicable to Consultant’s services provided under this Agreement. n. Consultant’s insurance carrier provides coverage on ISO equivalent endorsement forms. o. Services provided by the Consultant under this Agreement will be performed in a manner consistent with that degree of care and skill ordinarily exercised by members of the same KBA, Inc. 4/19/2022 P:\Public\PROJECTS\_In Design\20-3012 S 212th Orilla (City limits to Green River Bridge)\50 Consultant Selection & Contracts\50.9 Construction\KBA Contract Documents\KBA Proposal and Contract Request\KBA-SCOPE-TEMPLATE-Kent 212th GRB to Orillia Rd.docx 7 of 7 profession currently practicing under similar circumstances, in the same geographical area and time period. p. Nothing in the Agreement is intended to create, nor shall it be construed to create, a fiduciary duty owed by either party to the other. Consultant makes no warranties, guarantees, express or implied, under this Agreement or otherwise in connection with Consultant’s services. q. Client agrees that Consultant will not be held liable for the completeness, correctness, readability, or compatibility of any electronic media submitted to Client, after an acceptance period of 30 days after delivery of the electronic files, because data stored on electronic media can deteriorate undetected or can be modified without Consultant’s knowledge. r. Consultant will not be liable for any damage to the field office premises or utilities provided by Client, unless caused by Consultant’s own negligence. s. XIX. Protection of Confidential Information, of the LAG Agreement, KBA will perform services under the following assumptions, and such assumptions are assumed acceptable to the AGENCY and the STATE: The AGENCY and/or the STATE will identify each and any item considered to be “State’s Confidential Information” as “confidential”, as detailed below. Any information received by CONSULTANT that is not so labeled, will be assumed by CONSULTANT to not be “State’s Confidential Information”. CONSULTANT will return all items pre-identified as State’s Confidential Information, to the AGENCY, and will not be required to take any other steps to protect that information. II. OPTIONAL SERVICES All services not detailed above, are considered Optional Services, which, along with any other Extra Work requested by the Client, will be performed only when a mutually negotiated Supplement to this Agreement is executed, specifying scope of services and budget. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit B DBE Participation Plan In the absents of a mandatory DBE goal, a voluntary SBE goal amount of ten percent of the Consultant Agreement is established. The Consultant shall develop a SBE Participation Plan prior to commencing work. Although the goal is voluntary, the outreach efforts to provide SBE maximum practicable opportunities are not. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit C Preparation and Delivery of Electronic Engineering and Other Data In this Exhibit the agency, as applicable, is to provide a description of the format and standards the consultant is to use in preparing electronic files for transmission to the agency. The format and standards to be provided may include, but are not limited to, the following: I.Surveying, Roadway Design & Plans Preparation Section A.Survey Data B.Roadway Design Files C.Computer Aided Drafting Files Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 D.Specify the Agency’s Right to Review Product with the Consultant E.Specify the Electronic Deliverables to Be Provided to the Agency F.Specify What Agency Furnished Services and Information Is to Be Provided Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 II.Any Other Electronic Files to Be Provided III.Methods to Electronically Exchange Data Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 A.Agency Software Suite B.Electronic Messaging System C.File Transfers Format Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit D Prime Consultant Cost Computations ORIGINAL AGREEMENT APR 2022 MAY 2022 JUN 2022 JUL 2022 AUG 2022 SEP 2022 OCT 2022 City of Kent 21 21 22 20 23 21 21 KBA Job No.168 168 176 160 184 168 168 Cost + Net fee (on DSC Only)6% 6% 6% 6% 6% 6% 6% Prepared On: 4/19/2022 178 178 187 170 195 178 178 Prepared by: Cameron Bloomer Annual Escalation on DSC 5%PRECONSTRUCTION ESTIMATE OF COSTS CLOSEOUT KBA Hours Class Title/Role Task 2022 Rate 2023 Rate Total Hours Original Agreement Total APR 2022 MAY 2022 JUN 2022 JUL 2022 AUG 2022 SEP 2022 OCT 2022 H Sam Schuyler M2 Manager II 01.00 $80.24 $84.25 12 12 3 2 2 2 3 H Jill Carter A4 Administrator IV 02.00 $44.00 $46.20 20 20 4 4 4 4 4 F Cameron Bloomer E5 Engineer / Professional V 01.00 $61.88 $64.97 397 397 40 94 85 98 80 F Inspector E3 E3 Engineer / Professional III 02.00 $45.00 $47.25 552 552 40 187 170 75 80 F Inspector E3 (Night) E3 Engineer / Professional III 03.00 $51.75 $54.34 120 120 120 Subtotal - KBA Labor Hours 1,101 1,101 - 87 287 261 299 167 - Project Expenses Rate Tax Loaded Rate Total Costs Original Agreement Total APR 2022 MAY 2022 JUN 2022 JUL 2022 AUG 2022 SEP 2022 OCT 2022 Vehicle - 4 Door SUV Monthly Lease Rate DE 1,000$ 10.4% $1,104 3,312$ 3,312 $1,104 $1,104 $1,104 Daily Rate DE 50.00$ 10.4% $55 828$ 828 276 552 Hourly Rate DE 6.25$ 10.4% $7 2,739$ 2,739 276 649 587 676 552 Miscellaneous Expenses Office Supplies 150$ 150 150 Subtotal - Direct Expenses 7,029 7,029 - 702 1,753 1,691 1,780 1,104 - Subconsultants Task Total Costs Original Agreement Total APR 2022 MAY 2022 JUN 2022 JUL 2022 AUG 2022 SEP 2022 OCT 2022 Materials Testing Sub1 26,428$ 26,428 5,297 6,738 6,125 7,044 1,225 GeoTech Sub2 12,601$ 12,601 12,601 Subtotal - Subconsultant Costs 39,029 39,029 - 5,297 6,738 6,125 19,645 1,225 - Task 2022 Rate 2023 Rate Total DSC Original Agreement Total APR 2022 MAY 2022 JUN 2022 JUL 2022 AUG 2022 SEP 2022 OCT 2022 H Sam Schuyler M2 Manager II 01.00 $80.24 $84.25 963 963 - 241 160 160 160 241 - H Jill Carter A4 Administrator IV 02.00 $44.00 $46.20 880 880 - 176 176 176 176 176 - F Cameron Bloomer E5 Engineer / Professional V 01.00 $61.88 $64.97 24,566 24,566 - 2,475 5,817 5,260 6,064 4,950 - F Inspector E3 E3 Engineer / Professional III 02.00 $45.00 $47.25 24,840 24,840 - 1,800 8,415 7,650 3,375 3,600 - F Inspector E3 (Night) E3 Engineer / Professional III 03.00 $51.75 $54.34 6,210 6,210 - - - - 6,210 - - 2022 2023 57,459$ 57,459 - 4,692 14,568 13,246 15,986 8,967 - 155.78% 155.78% 2,871 2,871 - 649 524 524 524 649 - 146.37% 146.37% 81,406 81,406 - 6,258 20,831 18,896 22,906 12,515 - 2021 2022 84,277$ 84,277 - 6,907 21,355 19,420 23,430 13,164 - 30.00% 30.00% 17,238 17,238 - 1,408 4,370 3,974 4,796 2,690 - 158,974$ 158,974 - 13,006 40,294 36,640 44,211 24,822 - 7,029 7,029 - 702 1,753 1,691 1,780 1,104 - 39,029 39,029 - 5,297 6,738 6,125 19,645 1,225 - - - - - - - - - - TOTAL INVOICED 205,032 205,032 - 19,005 48,784 44,456 65,636 27,151 - CONSTRUCTION - 70 Working Days CONFIDENTIAL & PROPRIETARY TO KBA, INC. S. 212th St. Preservation (Green River Bridge to Orillia Rd / Kent City Limits) Preconstruction May 24 - May 31 Construction June 1 - Sept 8 Closeout Sept 9 to Sept 23rd Combined Costs Jimale Technical Services, LLC. HWA Geosciences Rates last Updated: Rates last Updated: Direct Salary Costs Overhead (Home) @ Overhead (Field) @ Fee on DSC Subtotal (DSC + OH + Fee) Management Reserve Subtotal Overhead Direct Expenses (No Markup) Subconsultant(s) Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit E Sub-consultant Cost Computations If no sub-consultant participation listed at this time. The CONSULTANT shall not sub-contract for the performance of any work under this AGREEMENT without prior written permission of the AGENCY. Refer to section VI “Sub-Contracting” of this AGREEMENT. Project Cost Estimate HWA Ref: 2022-065 Construction Inspection and Testing S 212th St Preservation - Green River Bridge to Orillia Rd Date: 5-Apr-22 Kent, WA Prepared By: BKH/BS Prepared For: Cameron Bloomer, KBA PROPOSED WORK SCOPE: This cost estimate is based on plans and information provided by the Client. 1. Sampling of HMA aggregate for acceptance testing (3 samples). Sampling of HMA aggregate and oil at the plant for ignition oven correction factor testing (1 sample). 2. Sampling and testing HMA during paving for Rice density, extraction and gradation (minimum: one test sample per 1000 tons). 3. Inspection and testing of HMA placement and compaction (minimum: one test per 100 tons). 4. Written field reports will be prepared for all inspections and reviewed for QC. Material Testing - ESTIMATED HWA LABOR: Engr VII Geol V Inspector Clerical TOTAL TOTAL $78.00 $48.50 $28.00 $25.50 HOURS AMOUNT Asphalt Inspection and Testing, including: Inspection and Testing during HMA Placement for Roadway (up to 8 visits)64 64 $1,792 HMA Oven Ignition Correction Sampling of Aggregate and Oil (1 mix)4 4 $112 HMA/Aggregate Sampling at Batch Plant during placement (5 samples)20 20 $560 Project Management Preconstruction Meeting 1 1 $49 QA Review, Reporting, Submittal Reviews, and Report Distribution 4 2 6 $409 DIRECT SALARY COST 4 3 88 0 95 $2,922 Material Testing - LABORATORY TESTING ESTIMATE: LABORATORY EXPENSE DESCRIPTION Est No.Unit Test TOTAL Asphalt Ignition Oven Correction (1 mix, 3 burns)3 $140 $420 HMA Aggregate Acceptance (Voids, FF, SE) (1 mix) at WSDOT intervals 3 $310 $930 Bitumen Content by Extraction with Gradation of Aggregate (1 mix design) at WSDOT intervals 5 $185 $925 Maximum Theoretical Specific Gravity of HMA (Rice Density) (1 mix design) at WSDOT intervals 5 $140 $700 LABORATORY TOTAL:$2,975 Scope of Services 2022 PERSONNEL & HOURLY RATES S 212th St Preservation - Green River Bridge to Orillia Rd 1 of 2 HWA GeoSciences Inc. EXPENSES: $480 $320 $240 EXPENSE TOTAL:$1,040 ESTIMATED PROJECT TOTALS AND SUMMARY: Direct Salary Cost (DSC)$2,922 OH @ 1.6390 * DSC $4,788 FF @ 30% * (DSC)$876 Total Labor Cost $8,586 Laboratory Testing $2,975 Direct Expenses $1,040 ESTIMATED PROJECT TOTAL:$12,601 Assumptions: 1. These estimates may require adjustment due to the Contractor's rate of construction, weather delays, source changes and/or other factors beyond our control. 2. The HWA PM reserves the right to shift hours between the various subtasks as required. 3. The HWA work scope does not include safety assessment nor work pertaining to any environmental issues. 4. This cost estimate was prepared with the understanding that the Client will schedule inspection as needed. 5. All night work is charged at an 8 hour minimum segment. Night work cancelled within 12 hrs of scheduled time will be charged 4 hrs. 6. All weekend work is charged at an 4 hour minimum segment. Weekend work cancelled within 12 hrs of scheduled time will be charged 4 hrs. 7. Per Client, all concrete used will be 3000psi Commercial mix, and therefore will not be tested. 8. This cost estimate assumes temporary HMA will not be tested. 9. Per Client, aggregates will not be sampled. Compacted aggregates for ADA Ramps and Sidewalk will not be tested. Mileage to and from the job site for all inspections at IRS mileage rate (8 trips) Mileage for HMA and HMA aggregate sampling, assuming 6 trips EXPENSE DESCRIPTION Total Cost Thin Lift (HMA Testing) Nuclear Gauge Rental ($60/day), assuming 8 days S 212th St Preservation - Green River Bridge to Orillia Rd 2 of 2 HWA GeoSciences Inc. Jimale Technical Services Prepared by Tanya Jimale DCN 2205 City of Kent S 212th St Preservation/Green R Br to Orillia Rd Contract City of Kent. Client KBA Cameron Bloomer Level of Effort for JTS Inpection Services JTS Acting Assistant Service Operations Manager Lynda Tonne-Oveson Jimale Technical Services NTP 5/16/2022 Cost Projections 80 bus-days 9/6/2022 total hours 340 JTS Project Admin Mary Lynum HOURS May-22 Jun-22 Jul-22 Aug-22 Sep-22 Total hrs 64 88 80 92 16 320 Hrs Reg Hrs 0 0 0 0 0 labor rate 32.59$ OT Hrs 64 88 80 92 16 overhear rate 113.57% fee 10% HOURS for regular pay and premium pay May-22 Jun-22 Jul-22 Aug-22 Sep-22 Total hrs 44 88 80 92 16 JTS Sr. Project Admin/Quality ControlsMary Lynum Reg Hrs 44 88 80 92 16 Premium Hrs 0 0 0 0 0 20 Hrs labor rate 41.03$ DIRECT LABOR,$ overhear rate 113.57%May-22 Jun-22 Jul-22 Aug-22 Sep-22 fee 10% Total dl$ 2,254.56$ 2,867.92$ 2,607.20$ 2,998.28$ 521.44$ Reg dl$ 2,254.56$ 2,867.92$ 2,607.20$ 2,998.28$ 521.44$ Premium$ -$ -$ -$ -$ -$ OVERHEAD,$ May-22 Jun-22 Jul-22 Aug-22 Sep-22 Total ovhd$ 2,560.50$ 3,257.10$ 2,961.00$ 3,405.15$ 592.20$ ovhd% x Reg dl$ 2,560.50$ 3,257.10$ 2,961.00$ 3,405.15$ 592.20$ Premium$ x ovhd$ -$ -$ -$ -$ -$ Fee,$ May-22 Jun-22 Jul-22 Aug-22 Sep-22 Total fee$ 481.51$ 612.50$ 556.82$ 640.34$ 111.36$ (Reg dl$ + ovhd$) x fee$ 481.51$ 612.50$ 556.82$ 640.34$ 111.36$ Premium fee$ -$ -$ -$ -$ -$ SUMMARY,$ May-22 Jun-22 Jul-22 Aug-22 Sep-22 Total by month,$ 5,296.57$ 6,737.52$ 6,125.02$ 7,043.77$ 1,225.00$ Direct Labor,$ 2,254.56$ 2,867.92$ 2,607.20$ 2,998.28$ 521.44$ Premium DLabor on OT,$ -$ -$ -$ -$ -$ Overhead$ 2,560.50$ 3,257.10$ 2,961.00$ 3,405.15$ 592.20$ Premium ovhd on OT,$ -$ -$ -$ -$ -$ Fee,$ 481.51$ 612.50$ 556.82$ 640.34$ 111.36$ Proposed work order amount 26,427.88$ Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit F - Title VI Assurances Appendix A & E APPENDIX A During the performance of this contract, the contractor, for itself, its assignees, and successors in interest (hereinafter referred to as the "contractor") agrees as follows: 1.Compliance with Regulations: The contractor (hereinafter includes consultants) will comply with the Acts and the Regulations relative to Non-discrimination in Federally-assisted programs of the U.S. Department of Transportation, (Title of Modal Operating Administration), as they may be amended from time to time, which are herein incorporated by reference and made a part of this contract. 2.Non-discrimination: The contractor, with regard to the work performed by it during the contract, will not discriminate on the grounds of race, color, or national origin in the selection and retention of subcontractors, including procurements of materials and leases of equipment. The contractor will not participate directly or indirectly in the discrimination prohibited by the Acts and the Regulations, including employment practices when the contract covers any activity, project, or program set forth in Appendix B of 49 CFR Part 21. [Include Modal Operating Administration specific program requirements.] 3.Solicitations for Subcontracts, Including Procurements of Materials and Equipment: In all solicitations, either by competitive bidding, or negotiation made by the contractor for work to be performed under a subcontract, including procurements of materials, or leases of equipment, each potential subcontractor or supplier will be notified by the contractor of the contractor's obligations under this contract and the Acts and the Regulations relative to Non-discrimination on the grounds of race, color, or national origin. [Include Modal Operating Administration specific program requirements.] 4.Information and Reports: The contractor will provide all information and reports required by the Acts, the Regulations, and directives issued pursuant thereto and will permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the Recipient or the (Title of Modal Operating Administration) to be pertinent to ascertain compliance with such Acts, Regulations, and instructions. Where any information required of a contractor is in the exclusive possession of another who fails or refuses to furnish the information, the contractor will so certify to the Recipient or the (Title of Modal Operating Administration), as appropriate, and will set forth what efforts it has made to obtain the information. 5.Sanctions for Noncompliance: In the event of a contractor's noncompliance with the Non- discrimination provisions of this contract, the Recipient will impose such contract sanctions as it or the (Title of Modal Operating Administration) may determine to be appropriate, including, but not limited to: a.withholding payments to the contractor under the contract until the contractor complies; and/or b.cancelling, terminating, or suspending a contract, in whole or in part. 6.Incorporation of Provisions: The contractor will include the provisions of paragraphs one through six in every subcontract, including procurements of materials and leases of equipment, unless exempt by the Acts, the Regulations and directives issued pursuant thereto. The contractor will take action with respect to any subcontract or procurement as the Recipient or the (Title of Modal Operating Administration) may direct as a means of enforcing such provisions including sanctions for noncompliance. Provided, that if the contractor becomes involved in, or is threatened with litigation by a subcontractor, or supplier because of such direction, the contractor may request the Recipient to enter into any litigation to protect the interests of the Recipient. In addition, the contractor may request the United States to enter into the litigation to protect the interests of the United States. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit F - Title VI Assurances Appendix A & E APPENDIX E During the performance of this contract, the contractor, for itself, its assignees, and successors in interest (hereinafter referred to as the "contractor") agrees to comply with the following non-discrimination statutes and authorities; including but not limited to: Pertinent Non-Discrimination Authorities: •Title VI of the Civil Rights Act of 1964 (42 U.S.C. § 2000d et seq., 78 stat. 252), (prohibits discrimination on the basis of race, color, national origin); and 49 CFR Part 21. •The Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970, (42 U.S.C. § 4601), (prohibits unfair treatment of persons displaced or whose property has been acquired because of Federal or Federal-aid programs and projects); •Federal-Aid Highway Act of 1973, (23 U.S.C. § 324 et seq.), (prohibits discrimination on the basis of sex); •Section 504 of the Rehabilitation Act of 1973, (29 U.S.C. § 794 et seq.), as amended, (prohibits discrimination on the basis of disability); and 49 CFR Part 27; •The Age Discrimination Act of 1975, as amended, (42 U.S.C. § 6101 et seq.), (prohibits discrimination on the basis of age); •Airport and Airway Improvement Act of 1982, (49 USC § 471, Section 47123), as amended, (prohibits discrimination based on race, creed, color, national origin, or sex); •The Civil Rights Restoration Act of 1987, (PL 100-209), (Broadened the scope, coverage and applicability of Title VI of the Civil Rights Act of 1964, The Age Discrimination Act of 1975 and Section 504 of the Rehabilitation Act of 1973, by expanding the definition of the terms "programs or activities" to include all of the programs or activities of the Federal-aid recipients, sub-recipients and contractors, whether such programs or activities are Federally funded or not); •Titles II and III of the Americans with Disabilities Act, which prohibit discrimination on the basis of disability in the operation of public entities, public and private transportation systems, places of public accommodation, and certain testing entities (42 U.S.C. §§ 12131-12189) as implemented by Department of Transportation regulations at 49 C.F.R. parts 37 and 38; •The Federal Aviation Administration's Non-discrimination statute (49 U.S.C. § 47123) (prohibits discrimination on the basis of race, color, national origin, and sex); •Executive Order 12898, Federal Actions to Address Environmental Justice in Minority Populations and Low-Income Populations, which ensures discrimination against minority populations by discouraging programs, policies, and activities with disproportionately high and adverse human health or environmental effects on minority and low-income populations; •Executive Order 13166, Improving Access to Services for Persons with Limited English Proficiency, and resulting agency guidance, national origin discrimination includes discrimination because of limited English proficiency (LEP). To ensure compliance with Title VI, you must take reasonable steps to ensure that LEP persons have meaningful access to your programs (70 Fed. Reg. at 74087 to 74100); •Title IX of the Education Amendments of 1972, as amended, which prohibits you from discriminating because of sex in education programs or activities (20 U.S.C. 1681 et seq). Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit G Certification Document Exhibit G-1(a) Certification of Consultant Exhibit G-1(b) Certification of Exhibit G-2 Exhibit G-3 Certification Regarding Debarment, Suspension and Other Responsibility Matters - Primary Covered Transactions Certification Regarding the Restrictions of the Use of Federal Funds for Lobbying Certificate of Current Cost or Pricing Data Exhibit G-4 Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit G-1(a) Certification of Consultant I hereby certify that I am the and duly authorized representative of the firm of ______________________________________________________________________________________ whose address is ______________________________________________________________________________________ and that neither the above firm nor I have a)Employed or retained for a commission, percentage, brokerage, contingent fee, or other consideration, any firm or person (other than a bona fide employee working solely for me or the above CONSULTANT) to solicit or secure this AGREEMENT; b)Agreed, as an express or implied condition for obtaining this contract, to employ or retain the services of any firm or person in connection with carrying out this AGREEMENT; or c)Paid, or agreed to pay, to any firm, organization or person (other than a bona fide employee working solely for me or the above CONSULTANT) any fee, contribution, donation, or consideration of any kind for, or in connection with, procuring or carrying out this AGREEMENT; except as hereby expressly stated (if any); I acknowledge that this certificate is to be furnished to the _________________________________________ and the Federal Highway Administration, U.S. Department of Transportation in connection with this AGREEMENT involving participation of Federal-aid highway funds, and is subject to applicable State and Federal laws, both criminal and civil. Consultant (Firm Name) Signature (Authorized Official of Consultant) Date Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit G-1(b) Certification of ________________________________________ I hereby certify that I am the: Other of the _______________________________________, and ________________________________________ or its representative has not been required, directly or indirectly as an express or implied condition in connection with obtaining or carrying out this AGREEMENT to: a)Employ or retain, or agree to employ to retain, any firm or person; o b)Pay, or agree to pay, to any firm, person, or organization, any fee, contribution, donation, or consideration of any kind; except as hereby expressly stated (if any): I acknowledge that this certificate is to be furnished to the ___________________________________________ and the Federal Highway Administration, U.S. Department of Transportation, in connection with this AGREEMENT involving participation of Federal-aid highway funds, and is subject to applicable State and Federal laws, both criminal and civil. Signature Date 05/24/2022 Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit G-2 Certification Regarding Debarment Suspension and Other Responsibility Matters - Primary Covered Transactions I.The prospective primary participant certifies to the best of its knowledge and belief, that it and its principals: A.Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal department or agency; B.Have not within a three (3) year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State anti-trust statues or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; C.Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State, or local) with commission of any of the offenses enumerated in paragraph (1)(b) of this certification; an D.Have not within a three (3) year period preceding this application / proposal had one or more public transactions (Federal, State and local) terminated for cause or default. II.Where the prospective primary participant is unable to certify to any of the statements in this certification such prospective participant shall attach an explanation to this proposal. Consultant (Firm Name) Signature (Authorized Official of Consultant) Date Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit G-3 Certification Regarding the Restrictions of the Use of Federal Funds for Lobbying The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that: 1.No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or any employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative AGREEMENT, and the extension, continuation, renewal, amendment, or modification of Federal contract, grant, loan or cooperative AGREEMENT. 2.If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan or cooperative AGREEMENT, the undersigned shall complete and submit Standard Form - LLL, “Disclosure Form to Report Lobbying,” in accordance with its instructions. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by Section 1352, Title 31, U.S. Code. Any person who fails to file the require certification shall be subject to a civil penalty of not less than $10,000.00, and not more than $100,000.00 for each such failure. The prospective participant also agrees by submitting his or her bid or proposal that he or she shall require that the language of this certification be included in all lower tier sub-contracts, which exceed $100,000 and that all such sub-recipients shall certify and disclose accordingly. Consultant (Firm Name) Signature (Authorized Official of Consultant) Date Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Exhibit J Consultant Claim Procedures The purpose of this exhibit is to describe a procedure regarding claim(s) on a consultant agreement. The following procedures should only be utilized on consultant claims greater than $1,000. If the consultant’s claim(s) total a $1,000 or less, it would not be cost effective to proceed through the outlined steps. It is suggested that the Director of Public Works or Agency Engineer negotiate a fair and reasonable price for the consultant’s claim(s) that total $1,000 or less. This exhibit will outline the procedures to be followed by the consultant and the agency to consider a potential claim by the consultant. Step 1 Consultant Files a Claim with the Agency Project Manager If the consultant determines that they were requested to perform additional services that were outside of the agreement’s scope of work, they may be entitled to a claim. The first step that must be completed is the request for consideration of the claim to the Agency’s project manager. The consultant’s claim must outline the following: •Summation of hours by classification for each firm that is included in the claim •Any correspondence that directed the consultant to perform the additional work; •Timeframe of the additional work that was outside of the project scope; •Summary of direct labor dollars, overhead costs, profit and reimbursable costs associated with the additional work; and •Explanation as to why the consultant believes the additional work was outside of the agreement scope of work. Step 2 Review by Agency Personnel Regarding the Consultant’s Claim for Additional Compensation After the consultant has completed step 1, the next step in the process is to forward the request to the Agency’s project manager. The project manager will review the consultant’s claim and will met with the Director of Public Works or Agency Engineer to determine if the Agency agrees with the claim. If the FHWA is participating in the project’s funding, forward a copy of the consultant’s claim and the Agency’s recommendation for federal participation in the claim to the WSDOT Local Programs through the Region Local Programs Engineer. If the claim is not eligible for federal participation, payment will need to be from agency funds. If the Agency project manager, Director of Public Works or Agency Engineer, WSDOT Local Programs (if applicable), and FHWA (if applicable) agree with the consultant’s claim, send a request memo, including backup documentation to the consultant to either supplement the agreement, or create a new agreement for the claim. After the request has been approved, the Agency shall write the supplement and/or new agreement and pay the consultant the amount of the claim. Inform the consultant that the final payment for the agreement is subject to audit. No further action in needed regarding the claim procedures. If the Agency does not agree with the consultant’s claim, proceed to step 3 of the procedures. Local Agency A&E Professional Services Agreement Number ____________ Negotiated Hourly Rate Consultant Agreement Revised 02/01/2021 Step 3 Preparation of Support Documentation Regarding Consultant’s Claim(s) If the Agency does not agree with the consultant’s claim, the project manager shall prepare a summary for the Director of Public Works or Agency Engineer that included the following: •Copy of information supplied by the consultant regarding the claim; •Agency’s summation of hours by classification for each firm that should be included in the claim •Any correspondence that directed the consultant to perform the additional work; •Agency’s summary of direct labor dollars, overhead costs, profit and reimbursable costs associate with the additional work; •Explanation regarding those areas in which the Agency does/does not agree with the consultant’s claim(s); •Explanation to describe what has been instituted to preclude future consultant claim(s); and •Recommendations to resolve the claim. Step 4 Director of Public Works or Agency Engineer Reviews Consultant Claim and Agency Documentation The Director of Public Works or Agency Engineer shall review and administratively approve or disapprove the claim, or portions thereof, which may include getting Agency Council or Commission approval (as appropriate to agency dispute resolution procedures). If the project involves federal participation, obtain concurrence from WSDOT Local Programs and FHWA regarding final settlement of the claim. If the claim is not eligible for federal participation, payment will need to be from agency funds. Step 5 Informing Consultant of Decision Regarding the Claim The Director of Public Works or Agency Engineer shall notify (in writing) the consultant of their final decision regarding the consultant’s claim(s). Include the final dollar amount of the accepted claim(s) and rationale utilized for the decision. Step 6 Preparation of Supplement or New Agreement for the Consultant’s Claim(s) The agency shall write the supplement and/or new agreement and pay the consultant the amount of the claim. Inform the consultant that the final payment for the agreement is subject to audit