Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
CAG2022-209 - Original - KBA, Inc. - Summit Landsburg Road and Rock Creek Culvert Replacement - 05/16/2022
Nancy Yoshitake for Jason Barry Public Works 05/12/2022 05/19/2022 05/03/2022 W20005 N/A KBA, Inc.Contract Other Summit Landsburg Road and Rock Creek Culvert Replacement Provide construction management services for the project. $206,771 Other 5/12/22 Original CAG2022-209 5/20/22 DATE: May 3, 2022 TO: Kent City Council SUBJECT: Consultant Services Agreement with KBA, Inc. for the Rock Creek Culvert Project - Authorize MOTION: I move to authorize the Mayor to sign the consultant services agreement with KBA, Inc. in the amount of $206,771.00, for contract administration, management, quality control and inspection on the Summit Landsburg Road and Rock Creek Culvert Replacement project, subject to final terms and conditions acceptable to the Public Works Director and City Attorney. SUMMARY: The Summit Landsburg Road and Rock Creek Culvert Replacement project is located in the City of Kent Clark Springs Watershed just east of Maple Valley. This is a water utility funded project that will replace three existing 36-inch culverts with a new two- passage to return where the creek crosses the road. This consultant contract is needed to provide on-site inspection services while assisting with contract administration, construction management, and overall quality control. Through our selection process we have selected KBA, Inc. They specialize in providing construction management and contract administration on capital improvement projects throughout the Puget Sound region. BUDGET IMPACT: This project will be paid for using City of Kent Water Utility funds. SUPPORTS STRATEGIC PLAN GOAL: Evolving Infrastructure - Connecting people and places through strategic investments in physical and technological infrastructure. ATTACHMENTS: 1. Agreement (PDF) 04/18/22 Public Works Committee MOTION PASSES RESULT: MOTION PASSES [UNANIMOUS] Next: 5/3/2022 7:00 PM MOVER: Satwinder Kaur, Councilmember SECONDER: Marli Larimer, Councilmember AYES: Brenda Fincher, Satwinder Kaur, Marli Larimer CONSULTANT SERVICES AGREEMENT - 1 (Over $20,000) CONSULTANT SERVICES AGREEMENT between the City of Kent and KBA, Inc. THIS AGREEMENT is made between the City of Kent, a Washington municipal corporation (hereinafter the "City"), and KBA, Inc. organized under the laws of the State of Washington, located and doing business at 11201 SE 8th Street, Suite 160, Bellevue, WA 98004-6455, Phone: (425) 455-9720, Contact: Sam Schuyler (hereinafter the "Consultant"). I. DESCRIPTION OF WORK. The Consultant shall perform the following services for the City in accordance with the following described plans and/or specifications: The Consultant shall provide construction management services for the Summit Landsburg Road and Rock Creek Culvert Replacement Project. For a description, see the Consultant's Scope of Work which is attached as Exhibit A and incorporated by this reference. The Consultant further represents that the services furnished under this Agreement will be performed in accordance with generally accepted professional practices within the Puget Sound region in effect at the time those services are performed. II. TIME OF COMPLETION. The parties agree that work will begin on the tasks described in Section I above immediately upon the effective date of this Agreement. The Consultant shall complete the work described in Section I by December 31, 2022. III. COMPENSATION. A. The City shall pay the Consultant, based on time and materials, an amount not to exceed Two Hundred Six Thousand, Seven Hundred Seventy One Dollars ($206,771), for the services described in this Agreement. This is the maximum amount to be paid under this Agreement for the work described in Section I above, and shall not be exceeded without the prior written authorization of the City in the form of a negotiated and executed amendment to this agreement. The Consultant agrees that the hourly or flat rate charged by it for its services contracted for herein shall remain locked at the negotiated rate(s) for a period of one (1) year from the effective date of this Agreement. The Consultant's billing rates shall be as delineated in Exhibit A. B. The Consultant shall submit monthly payment invoices to the City for work performed, and a final bill upon completion of all services described in this Agreement. The City shall provide payment within forty-five (45) days of receipt of an invoice. If the City objects to all or any portion of an invoice, it shall notify the Consultant and reserves the option to only pay that portion of the invoice not in dispute. In that event, the parties will immediately make every effort to settle the disputed portion. C. Card Payment Program. The Consultant may elect to participate in automated credit card payments provided for by the City and its financial institution. This Program is provided as an alternative to payment by check and is available for the convenience of the Consultant. If the CONSULTANT SERVICES AGREEMENT - 2 (Over $20,000) Consultant voluntarily participates in this Program, the Consultant will be solely responsible for any fees imposed by financial institutions or credit card companies. The Consultant shall not charge those fees back to the City. IV. INDEPENDENT CONTRACTOR. The parties intend that an Independent Contractor- Employer Relationship will be created by this Agreement. By their execution of this Agreement, and in accordance with Ch. 51.08 RCW, the parties make the following representations: A. The Consultant has the ability to control and direct the performance and details of its work, the City being interested only in the results obtained under this Agreement. B. The Consultant maintains and pays for its own place of business from which the Consultant’s services under this Agreement will be performed. C. The Consultant has an established and independent business that is eligible for a business deduction for federal income tax purposes that existed before the City retained the Consultant’s services, or the Consultant is engaged in an independently established trade, occupation, profession, or business of the same nature as that involved under this Agreement. D. The Consultant is responsible for filing as they become due all necessary tax documents with appropriate federal and state agencies, including the Internal Revenue Service and the state Department of Revenue. E. The Consultant has registered its business and established an account with the state Department of Revenue and other state agencies as may be required by the Consultant’s business, and has obtained a Unified Business Identifier (UBI) number from the State of Washington. F. The Consultant maintains a set of books dedicated to the expenses and earnings of its business. V. TERMINATION. Either party may terminate this Agreement, with or without cause, upon providing the other party thirty (30) days written notice at its address set forth on the signature block of this Agreement. After termination, the City may take possession of all records and data within the Consultant’s possession pertaining to this project, which may be used by the City without restriction. If the City’s use of the Consultant’s records or data is not related to this project, it shall be without liability or legal exposure to the Consultant. VI. FORCE MAJEURE. Neither party shall be liable to the other for breach due to delay or failure in performance resulting from acts of God, acts of war or of the public enemy, riots, pandemic, fire, flood, or other natural disaster or acts of government (“force majeure event”). Performance that is prevented or delayed due to a force majeure event shall not result in liability to the delayed party. Both parties represent to the other that at the time of signing this Agreement, they are able to perform as required and their performance will not be prevented, hindered, or delayed by the current COVID-19 pandemic, any existing state or national declarations of emergency, or any current social distancing restrictions or personal protective equipment requirements that may be required under federal, state, or local law in response to the current pandemic. If any future performance is prevented or delayed by a force majeure event, the party whose performance is prevented or delayed shall promptly notify the other party of the existence and nature of the force majeure event causing the prevention or delay in performance. Any excuse from liability shall be effective only to the extent and duration of the force majeure event causing the prevention or delay in performance and, provided, that the party prevented or delayed has not caused such event to occur and continues to use diligent, good faith efforts to avoid the effects of such event and to perform the obligation. Notwithstanding other provisions of this section, the Consultant shall not be entitled to, and the City shall not be liable for, the payment of any part of the contract price during a force majeure event, or any CONSULTANT SERVICES AGREEMENT - 3 (Over $20,000) costs, losses, expenses, damages, or delay costs incurred by the Consultant due to a force majeure event. Performance that is more costly due to a force majeure event is not included within the scope of this Force Majeure provision. If a force majeure event occurs, the City may direct the Consultant to restart any work or performance that may have ceased, to change the work, or to take other action to secure the work or the project site during the force majeure event. The cost to restart, change, or secure the work or project site arising from a direction by the City under this clause will be dealt with as a change order, except to the extent that the loss or damage has been caused or exacerbated by the failure of the Consultant to fulfill its obligations under this Agreement. Except as expressly contemplated by this section, all other costs will be borne by the Consultant. VII. DISCRIMINATION. In the hiring of employees for the performance of work under this Agreement or any subcontract, the Consultant, its subcontractors, or any person acting on behalf of the Consultant or subcontractor shall not, by reason of race, religion, color, sex, age, sexual orientation, national origin, or the presence of any sensory, mental, or physical disability, discriminate against any person who is qualified and available to perform the work to which the employment relates. The Consultant shall execute the attached City of Kent Equal Employment Opportunity Policy Declaration, Comply with City Administrative Policy 1.2, and upon completion of the contract work, file the attached Compliance Statement. VIII. INDEMNIFICATION. The Consultant shall defend, indemnify and hold the City, its officers, officials, employees, agents and volunteers harmless from any and all claims, injuries, damages, losses or suits, including all legal costs and attorney fees, arising out of or in connection with the Consultant's performance of this Agreement, except for that portion of the injuries and damages caused by the City's negligence. The City's inspection or acceptance of any of the Consultant's work when completed shall not be grounds to avoid any of these covenants of indemnification. Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Consultant and the City, its officers, officials, employees, agents and volunteers, the Consultant's duty to defend, indemnify, and hold the City harmless, and the Consultant’s liability accruing from that obligation shall be only to the extent of the Consultant's negligence. IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THE INDEMNIFICATION PROVIDED HEREIN CONSTITUTES THE CONSULTANT'S WAIVER OF IMMUNITY UNDER INDUSTRIAL INSURANCE, TITLE 51 RCW, SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PARTIES FURTHER ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER. In the event the Consultant refuses tender of defense in any suit or any claim, if that tender was made pursuant to this indemnification clause, and if that refusal is subsequently determined by a court having jurisdiction (or other agreed tribunal) to have been a wrongful refusal on the Consultant’s part, then the Consultant shall pay all the City’s costs for defense, including all reasonable expert witness fees and reasonable attorneys’ fees, plus the City’s legal costs and fees incurred because there was a wrongful refusal on the Consultant’s part. The provisions of this section shall survive the expiration or termination of this Agreement. IX. INSURANCE. The Consultant shall procure and maintain for the duration of the Agreement, insurance of the types and in the amounts described in Exhibit B attached and incorporated by this reference. X. EXCHANGE OF INFORMATION. The City will provide its best efforts to provide reasonable accuracy of any information supplied by it to the Consultant for the purpose of completion of the work under this Agreement. CONSULTANT SERVICES AGREEMENT - 4 (Over $20,000) XI. OWNERSHIP AND USE OF RECORDS AND DOCUMENTS. Original documents, drawings, designs, reports, or any other records developed or created under this Agreement shall belong to and become the property of the City. All records submitted by the City to the Consultant will be safeguarded by the Consultant. The Consultant shall make such data, documents, and files available to the City upon the City’s request. The Consultant acknowledges that the City is a public agency subject to the Public Records Act codified in Chapter 42.56 of the Revised Code of Washington. As such, the Consultant agrees to cooperate fully with the City in satisfying the City’s duties and obligations under the Public Records Act. The City’s use or reuse of any of the documents, data, and files created by the Consultant for this project by anyone other than the Consultant on any other project shall be without liability or legal exposure to the Consultant. XII. CITY'S RIGHT OF INSPECTION. Even though the Consultant is an independent contractor with the authority to control and direct the performance and details of the work authorized under this Agreement, the work must meet the approval of the City and shall be subject to the City's general right of inspection to secure satisfactory completion. XIII. WORK PERFORMED AT CONSULTANT'S RISK. The Consultant shall take all necessary precautions and shall be responsible for the safety of its employees, agents, and subcontractors in the performance of the contract work and shall utilize all protection necessary for that purpose. All work shall be done at the Consultant's own risk, and the Consultant shall be responsible for any loss of or damage to materials, tools, or other articles used or held for use in connection with the work. XIV. MISCELLANEOUS PROVISIONS. A. Recyclable Materials. Pursuant to Chapter 3.80 of the Kent City Code, the City requires its contractors and consultants to use recycled and recyclable products whenever practicable. A price preference may be available for any designated recycled product. B. Non-Waiver of Breach. The failure of the City to insist upon strict performance of any of the covenants and agreements contained in this Agreement, or to exercise any option conferred by this Agreement in one or more instances shall not be construed to be a waiver or relinquishment of those covenants, agreements or options, and the same shall be and remain in full force and effect. C. Resolution of Disputes and Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of Washington. If the parties are unable to settle any dispute, difference or claim arising from the parties’ performance of this Agreement, the exclusive means of resolving that dispute, difference or claim, shall only be by filing suit exclusively under the venue, rules and jurisdiction of the King County Superior Court, King County, Washington, unless the parties agree in writing to an alternative dispute resolution process. In any claim or lawsuit for damages arising from the parties' performance of this Agreement, each party shall pay all its legal costs and attorney's fees incurred in defending or bringing such claim or lawsuit, including all appeals, in addition to any other recovery or award provided by law; provided, however, nothing in this paragraph shall be construed to limit the City's right to indemnification under Section VIII of this Agreement. D. Written Notice. All communications regarding this Agreement shall be sent to the parties at the addresses listed on the signature page of the Agreement, unless notified to the contrary. Any written notice hereunder shall become effective three (3) business days after the date of mailing by registered or certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated in this Agreement or such other address as may be hereafter specified in writing. E. Assignment. Any assignment of this Agreement by either party without the written consent of the non-assigning party shall be void. If the non-assigning party gives its consent to any assignment, the terms of this Agreement shall continue in full force and effect and no further assignment shall be made without additional written consent. F. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of the City and the Consultant. CONSULTANT SERVICES AGREEMENT - 5 (Over $20,000) G. Entire Agreement. The written provisions and terms of this Agreement, together with any Exhibits attached hereto, shall supersede all prior verbal statements of any officer or other representative of the City, and such statements shall not be effective or be construed as entering into or forming a part of or altering in any manner this Agreement. All of the above documents are hereby made a part of this Agreement. However, should any language in any of the Exhibits to this Agreement conflict with any language contained in this Agreement, the terms of this Agreement shall prevail. H. Compliance with Laws. The Consultant agrees to comply with all federal, state, and municipal laws, rules, and regulations that are now effective or in the future become applicable to the Consultant's business, equipment, and personnel engaged in operations covered by this Agreement or accruing out of the performance of those operations. I. Public Records Act. The Consultant acknowledges that the City is a public agency subject to the Public Records Act codified in Chapter 42.56 of the Revised Code of Washington and documents, notes, emails, and other records prepared or gathered by the Consultant in its performance of this Agreement may be subject to public review and disclosure, even if those records are not produced to or possessed by the City of Kent. As such, the Consultant agrees to cooperate fully with the City in satisfying the City’s duties and obligations under the Public Records Act. J. City Business License Required. Prior to commencing the tasks described in Section I, Contractor agrees to provide proof of a current city of Kent business license pursuant to Chapter 5.01 of the Kent City Code. CONSULTANT SERVICES AGREEMENT - 6 (Over $20,000) K. Counterparts and Signatures by Fax or Email. This Agreement may be executed in any number of counterparts, each of which shall constitute an original, and all of which will together constitute this one Agreement. Further, upon executing this Agreement, either party may deliver the signature page to the other by fax or email and that signature shall have the same force and effect as if the Agreement bearing the original signature was received in person. IN WITNESS, the parties below execute this Agreement, which shall become effective on the last date entered below. All acts consistent with the authority of this Agreement and prior to its effective date are ratified and affirmed, and the terms of the Agreement shall be deemed to have applied. CONSULTANT: By: Print Name: Its DATE: CITY OF KENT: By: Print Name: Dana Ralph Its Mayor DATE: NOTICES TO BE SENT TO: CONSULTANT: Sam Schuyler KBA, Inc. 11201 SE 8th Street, Suite 160 Bellevue, WA 98004-6455 (425) 455-9720 (telephone) N/A (facsimile) NOTICES TO BE SENT TO: CITY OF KENT: Chad Bieren, P.E. City of Kent 220 Fourth Avenue South Kent, WA 98032 (253) 856-5500 (telephone) (253) 856-6500 (facsimile) APPROVED AS TO FORM: Kent Law Department ATTEST: Kent City Clerk KBA - Rock Creek/Barry May 5, 2022 EEO COMPLIANCE DOCUMENTS - 1 DECLARATION CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY POLICY The City of Kent is committed to conform to Federal and State laws regarding equal opportunity. As such all contractors, subcontractors and suppliers who perform work with relation to this Agreement shall comply with the regulations of the City’s equal employment opportunity policies. The following questions specifically identify the requirements the City deems necessary for any contractor, subcontractor or supplier on this specific Agreement to adhere to. An affirmative response is required on all of the following questions for this Agreement to be valid and binding. If any contractor, subcontractor or supplier willfully misrepresents themselves with regard to the directives outlines, it will be considered a breach of contract and it will be at the City’s sole determination regarding suspension or termination for all or part of the Agreement; The questions are as follows: 1. I have read the attached City of Kent administrative policy number 1.2. 2. During the time of this Agreement I will not discriminate in employment on the basis of sex, race, color, national origin, age, or the presence of all sensory, mental or physical disability. 3. During the time of this Agreement the prime contractor will provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 4. During the time of the Agreement I, the prime contractor, will actively consider hiring and promotion of women and minorities. 5. Before acceptance of this Agreement, an adherence statement will be signed by me, the Prime Contractor, that the Prime Contractor complied with the requirements as set forth above. By signing below, I agree to fulfill the five requirements referenced above. By: ___________________________________________ For: __________________________________________ Title: _________________________________________ Date: _________________________________________ May 5, 2022 EEO COMPLIANCE DOCUMENTS - 2 CITY OF KENT ADMINISTRATIVE POLICY NUMBER: 1.2 EFFECTIVE DATE: January 1, 1998 SUBJECT: MINORITY AND WOMEN SUPERSEDES: April 1, 1996 CONTRACTORS APPROVED BY Jim White, Mayor POLICY: Equal employment opportunity requirements for the City of Kent will conform to federal and state laws. All contractors, subcontractors, consultants and suppliers of the City must guarantee equal employment opportunity within their organization and, if holding Agreements with the City amounting to $10,000 or more within any given year, must take the following affirmative steps: 1. Provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 2.Actively consider for promotion and advancement available minorities and women. Any contractor, subcontractor, consultant or supplier who willfully disregards the City’s nondiscrimination and equal opportunity requirements shall be considered in breach of contract and subject to suspension or termination for all or part of the Agreement. Contract Compliance Officers will be appointed by the Directors of Planning, Parks, and Public Works Departments to assume the following duties for their respective departments. 1. Ensuring that contractors, subcontractors, consultants, and suppliers subject to these regulations are familiar with the regulations and the City’s equal employment opportunity policy. 2. Monitoring to assure adherence to federal, state and local laws, policies and guidelines. EEO COMPLIANCE DOCUMENTS - 3 CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE STATEMENT This form shall be filled out AFTER COMPLETION of this project by the Contractor awarded the Agreement. I, the undersigned, a duly represented agent of Company, hereby acknowledge and declare that the before-mentioned company was the prime contractor for the Agreement known as that was entered into on the (date), between the firm I represent and the City of Kent. I declare that I complied fully with all of the requirements and obligations as outlined in the City of Kent Administrative Policy 1.2 and the Declaration City of Kent Equal Employment Opportunity Policy that was part of the before-mentioned Agreement. By: ___________________________________________ For: __________________________________________ Title: _________________________________________ Date: _________________________________________ Construction Management Services for Summit Landsburg Road and Rock Creek Culvert Replacement Deliverables Deliverables EXHIBIT A Deliverables Deliverables KBA, Inc. 4/06/2022 August, then 8 hour days to completion as shown in the estimate Exhibit. No night -shift work was included. b. Consultant will work up to the limitations of the authorized budget. If additional budget is needed to cover such instances as the following, Agency and Consultant will negotiate a supplement to this Agreement: i. The contractor's schedule requires inspection coverage of extra crews and shifts. ii. The construction contract runs longer than the time period detailed above. iii. Any added scope tasks. c. The work is anticipated to be performed during daytime hours. Should night work be necessary, a 15 percent differential for labor will be applied to all night shift hours worked by Consultant's staff. d. The budget allocations shown in Exhibit D, are itemized to aid in Project tracking purposes only. The budget may be transferred between people, or between labor and expenses, provided the total contracted amount is not exceeded without prior authorization. e. The budget assumes that Consultant's standard forms, logs, and processes will be used on the Project SharePoint site. Any customization to meet specialized Client requirements will be Extra Work. f. Should consultant's level of effort extend beyond the time period detailed in the attached Exhibit and into a new year, labor rates will adjust annually on January 1, with 30 day written notice to the Client. 2. Items and Services Client will provide: a. Meeting arrangements and facilities. b. Client to provide field office, as detailed in construction contract. c. Coordination with and enforcement of utility franchise agreements and/or contracts and schedules for services related to this Project. d. Verify that the required permits, bonds, and insurance have been obtained and submitted by the construction contractor. Obtain all permits not required to be provided by construction contractor. e. Construction Survey. Provide project control survey and staking that is not already assigned to the construction contractor. 3. Scope: a. The SharePoint tool being used on this Project is proprietary to the Consultant (KBA, Inc.), and may not be used by any other party or on any other project without the written permission and involvement of KBA, Inc. b. Consultant will provide inspection services for the days/hours that its' Inspector(s) personnel is/are on -site. The Inspector(s) will not be able to observe or report construction activities, or collect documentation, during the time they are not on -site. c. The Consultant's monitoring of the construction contractor's activities is to ascertain whether the contractor is performing the work in accordance with the Contract Documents; in case of noncompliance, Consultant will assist the Client in rejection of non -conforming work and pursue the other remedies in the interests of the Client, as detailed in the Contract Documents. The Consultant cannot guarantee the construction contractor's performance, and it is understood that Consultant shall assume no responsibility for proper construction means, methods, techniques, Project site safety, safety precautions or programs, or for the failure of any other entity to perform its work in accordance with laws, contracts, regulations, or Client expectations. City of Kent — Summit Landsburg Road and Rock Creek Culvert Replacement 4 of 6 KBA, Inc. 4/06/2022 d. Definitions and Roles. The use of the term "inspect" in relation to Consultant services is synonymous with "construction observation, and reference to the "Inspector" role is synonymous with "Field Representative," and means: performing on -site observations of the progress and quality of the work and determining, in general, if the work is being performed in conformance with the Contract Documents; and notifying the Client if work does not conform to the Contract Documents or requires special inspection or testing. Where "Specialty Inspector" or "specialty inspection" is used, it refers to inspection by a Building Official or independent agent of the Building Official, or other licensed/certified inspector who provides a certified inspection report in accordance with established industry standards. e. Because of the prior use of the Project site, there is a possibility of the presence of toxic or hazardous materials. Consultant shall have no responsibility for the discovery, presence, handling, removal or disposal of toxic or hazardous materials, or for exposure of persons to toxic or hazardous materials in any form at the Project site, including but not limited to asbestos, asbestos products, polychlorinated biphenyl (PCB), or other toxic substances. If the Consultant suspects the presence of hazardous materials, they will notify the Client immediately for resolution. f. Review of Shop Drawings, samples, and other submittals will be for general conformance with the design concept and general compliance with the requirements of the contract for construction. Such review will not relieve the Contractor from its responsibility for performance in accordance with the contract for construction, nor is such review a guarantee that the work covered by the shop drawings, samples and submittals is free of errors, inconsistencies or omissions. g. Any opinions of probable construction cost provided by the Consultant will be on the basis of experience and professional judgment. However, since Consultant has no control over competitive bidding or market conditions, the Consultant cannot and does not warrant that bids or ultimate construction costs will not vary from these opinions of probable construction costs. h. Quantity takeoffs and calculated quantities are for the purpose of comparing with Designer's and/or bidders' quantities and are not a guarantee of final quantities. i. Reviewing and commenting on contractor's schedules, is for the purpose of estimating number of days to complete a project, for identifying potential schedule and coordination challenges and determining compliance with the construction contract. It is not a guarantee that a construction contractor will complete the Project in that sequence or timeline, as means and methods are the responsibility of the construction contractor. j. Consultant is not responsible for any costs, claims or judgments arising from or in any way connected with errors, omissions, conflicts or ambiguities in the Contract Documents prepared by others. The Consultant does not have responsibility for the professional quality or technical adequacy or accuracy of the design plans or specifications, nor for their timely completion by others. k. RCW 4.24.115 is applicable to Consultant's services provided under this Agreement. I. Consultant's insurance carrier provides coverage on ISO equivalent endorsement forms. m. Services provided by the Consultant under this Agreement will be performed in a manner consistent with that degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances, in the same geographical area and time period. n. Noting in the Agreement is intended to create, nor shall it be construed to create, a fiduciary duty owed by either party to the other. Consultant makes no warranties, guarantees, express or implied, under this Agreement of otherwise in connection with Consultant's services. City of Kent — Summit Landsburg Road and Rock Creek Culvert Replacement 5 of 6 KBA, Inc. 4/06/2022 o. Client agrees that Consultant will not be held liable for the completeness, correctness, readability, or compatibility of any electronic media submitted to Client, after an acceptance period of 30 days after delivery of the electronic files, because data stored on electronic media can deteriorate undetected or can be modified without Consultant's knowledge. II. OPTIONAL SERVICES All services not detailed above, are considered Optional Services, which, along with any other Extra Work requested by the Agency, will be performed only when a mutually negotiated Supplement to this Agreement is executed, specifying scope of services and budget. City of Kent — Summit Landsburg Road and Rock Creek Culvert Replacement 6 of 6 . i9 ii ill I I I Summit Landbur9 Road and Rock Creek Culvert Ory&0em C,,i 21 20 23 21 21 22 20 -,NP 168 160 1. 166, IN. 176 1. 1. 1. is. 1. l60 est. et ke (DnOX Only) Extra -1, F% 8% 12% 12% 12% 12% 12% 12% 11% 11% 113% 1% I—. .. A620R -C) 178 173 .1 189 tas 197 in aas 188 186 176 Z.- ESTIMATE OF 00815 CONFIDENTIAL & PROPRIETARY TO KEA. INC. Sams "2 11111 11 $a.. W. : .1,2 11 E.,� I I I.Z .... I— lo 1 1: 1 .1: �1: 17� 11,111,11 11—i-11111 1 $1.. 112M '3o 16: 16: lill Carter Iv .,D� . $A. 14 1 3 2 2 m6l.m $ mmimm Combined Costs 2- 1.., x am Sc u R- Di--1 DSC T_1 "2 1 11 11 Dal Ca 111. IvIll 2 117. :7. 111" memn L"cl) M. 6 ill C-1 A. 7. =l.ry— 2022 7,20,271 N—) . 1111E% —rh- (H.Id) @ 11- 16 ; 1`1 E.bl..I Ed 2022 106,408 fee C IC — 21.- 21663 sl6—1 , ON , J-) 2.,310 Oem sea MO .."M 6ALl 640 1 �11 1 �6�1 161 11 1.1 1'� -0 14,30D 13 - 14,950 10,920 IRA 1" 68 M EE 1:0 2 1,951 11,211 14111 12, 11 1. 1 - 1 _ 17 1 715 1.0 1,— 12,.11 16 1 1� lAl 2,929 22,852 20,— 23,803 17,905 17,969 EXHIBIT B INSURANCE REQUIREMENTS FORCONTRACTS Insurance The Contractor shall procure and maintain for the duration of the Agreement, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees or subcontractors. A. Minimum Scope of Insurance Contractor shall obtain insurance of the types described below: 1. Commercial General Liability insurance shall be written on ISO occurrence form CG 00 01 and shall cover liability arising from premises, operations, independent contractors, products-completed operations, personal injury and advertising injury, and liability assumed under an insured contract. The City shall be named as an insured under the Contractor’s Commercial General Liability insurance policy with respect to the work performed for the City using ISO additional insured endorsement CG 20 10 11 85 or a substitute endorsement providing equivalent coverage. 2. Automobile Liability insurance covering all owned, non-owned, hired and leased vehicles. Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. 3. Workers’ Compensation coverage as required by the Industrial Insurance laws of the State of Washington. B. Minimum Amounts of Insurance Contractor shall maintain the following insurance limits: 1.Commercial General Liability insurance shall be written with limits no less than $2,000,000 each occurrence, $2,000,000 general aggregate and a $2,000,000 products-completed operations aggregate limit. 2. Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1,000,000 per accident. EXHIBIT B (Continued) C. Other Insurance Provisions The insurance policies are to contain, or be endorsed to contain, the following provisions for Automobile Liability and Commercial General Liability insurance: 1. The Contractor’s insurance coverage shall be primary insurance as respect the City. Any Insurance, self-insurance, or insurance pool coverage maintained by the City shall be excess of the Contractor’s insurance and shall not contribute with it. 2. The Contractor’s insurance shall be endorsed to state that coverage shall not be cancelled by either party, except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City. 3. The City of Kent shall be named as an additional insured on all policies (except Professional Liability) as respects work performed by or on behalf of the contractor and a copy of the endorsement naming the City as additional insured shall be attached to the Certificate of Insurance. The City reserves the right to receive a certified copy of all required insurance policies. The Contractor’s Commercial General Liability insurance shall also contain a clause stating that coverage shall apply separately to each insured against whom claim is made or suit is brought, except with respects to the limits of the insurer’s liability. D. Acceptability of Insurers Insurance is to be placed with insurers with a current A.M. Best rating of not less than A:VII. E. Verification of Coverage Contractor shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the insurance requirements of the Contractor before commencement of the work. F. Subcontractors Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor. All coverages for subcontractors shall be subject to all of the same insurance requirements as stated herein for the Contractor. / A� " CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) 5/12/2022 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER AssuredPartners Design Professionals Insurance Services, LLC 3697 Mt. Diablo Blvd Suite 230 Lafayette CA 94549 CONTACT NAME: Brlttlnl Alberty PHONE FAX A/C No Ext : A/C No), ADDRESS: brittini.alberty@assuredpartners.com INSURER(S) AFFORDING COVERAGE NAIC # INSURER A: Travelers Property Casualty Company of America 25674 License#: 6003745 INSURED KBAINCO-03 INSURER B: The Travelers Indemnity Company 25658 KBA, Inc. 11201 SE 8th Street, Ste 160 INSURER C : Travelers Casualty and Surety Co of America 31194 INSURER D : Bellevue WA 98004 INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER:63161390 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER EFF MM DDPOLICYYYYY Y EXP MM DDYYYY LIMITS B X COMMERCIAL GENERAL LIABILITY Y Y 6806N033449 5/10/2022 5/10/2023 EACH OCCURRENCE $1,000,000 F —V� CLAIMS -MADE OCCUR DAMAGE TO TED PREMISESlccurrrence)$ (E. occurrence) 1,000,000 X MED EXP (Any one person) $ 10,000 Contractual Liab Included PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 POLICY ❑X PRO ❑ LOC JECT PRODUCTS - COMP/OP AGG $ 2,000,000 $ OTHER: B AUTOMOBILE LIABILITY Y Y BA7R748905 5/10/2022 5/10/2023 COMBINED SINGLE LIMIT Ea accident $ 1,000,000 X BODILY INJURY (Per person) $ ANY AUTO OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY (Per accident) $ X PROPERTY DAMAGE Per accident $ HIRED X NON -OWNED AUTOS ONLY AUTOS ONLY A X UMBRELLALIAB X OCCUR Y Y CUP6N036187 5/10/2022 5/10/2023 EACH OCCURRENCE $ 9,000,000 AGGREGATE $ 9,000,000 EXCESS LIAB CLAIMS -MADE DED X RETENTION $ in nnn $ g WORKERS COMPENSATION AND EMPLOYERS' LIABILITY Y / N 6806N033449 5/10/2022 5/10/2023 X STATUTE ER WA STOP GAP ANYPROPRIETOR/PARTNER/EXECUTIVE E.L. EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? ❑ N/A E.L. DISEASE - EA EMPLOYEE $ 1,000,000 (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $ 1,000,000 C Professional Liability+ 107633573 5/10/2022 5/10/2023 Per Claim $2,000,000 Contractors Pollution Liability Annual Aggregate $4,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Umbrella Liability policy is a follow -form underlying General Liability/Auto Liability/Employers Liability. Project Name: Kent Summit Landsburg Rock Creek Culvert Replacement City of Kent is named as Additional Insured as respects General and Auto Liability as required per written contract or agreement. General Liability and Auto Liability are Primary/Non-Contributory per policy form wording. Insurance coverage includes waiver of subrogation per the attached. 30 Days Notice of Cancellation CERTIFICATE HOLDER CANCELLATION 30 Day Notice of Cancellation SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Kent ACCORDANCE WITH THE POLICY PROVISIONS. Attn: Nancy Yoshitake AUTHORIZED REPRESENTATIVE 220 Fourth Avenue S. Kent WA 98032 A ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD COMMERCIAL GENERAL LIABILITY POLICY NUMBER: 6806NO33449 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): Any person or organization that you agree in a written contract to include as an additional insured on this Coverage Part for "bodily injury" or "property damage" included in the "products - completed operations hazard", provided that such contract was signed and executed by you before, and is in effect when, the bodily injury or property damage occurs. Location And Description Of Completed Operations Any project to which an applicable contract described in the Name of Additional Insured Person(s) or Organization(s) section of this Schedule applies. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Section II — Who Is An Insured is amended to in- clude as an additional insured the person(s) or or- ganization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property dam- age" caused, in whole or in part, by "your work" at the location designated and described in the schedule of this endorsement performed for that additional in- sured and included in the "products -completed opera- tions hazard". CG 20 37 07 04 © ISO Properties, Inc., 2004 Page 1 of 1 CG T8 02 XX XX DATE OF ISSUE: 05/10/2022 COMMERCIAL GENERAL LIABILITY POLICY NUMBER 6806NO33449 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Names of Additional Insured Person(s) or Organ ization(s): Any person or organization that you agree in a written contract to include as an additional insured on this Coverage Part, provided that such written contract was signed by you before, and is in effect when, the "bodily injury" or "property damage" occurs or the "personal injury" or "advertising injury" offense is committed. Location of Covered Operations: Any project to which a written contract with the Additional Insured Person(s) or Organization(s) in the Schedule applies. (Information required to complete this Schedule, if not shown above, will be shown in the Declarations.) A. Section II — Who Is An Insured is amended to in- clude as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage", "personal injury" or "advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) desig- nated above. B. With respect to the insurance afforded to these additional insureds, the following additional exclu- sions apply: This insurance does not apply to "bodily injury" or "property damage" occurring, or "personal injury" or "advertising injury" arising out of an offense committed, after: 1. All work, including materials, parts or equip- ment furnished in connection with such work, on the project (other than service, mainte- nance or repairs) to be performed by or on behalf of the additional insured(s) at the loca- tion of the covered operations has been com- pleted; or 2. That portion of "your work" out of which the injury or damage arises has been put to its in- tended use by any person or organization other than another contractor or subcontrac- tor engaged in performing operations for a principal as a part of the same project. CG D3 61 03 05 Copyright 2005 The St. Paul Travelers Companies, Inc. All rights reserved. Page 1 of 1 CG T8 01 XX XX Includes copyrighted material of Insurance Services Office, Inc. with its permission. DATE OF ISSUE: 05/10/2022 Policy #: BA7R748905 COMMERCIAL AUTO THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BUSINESS AUTO EXTENSION ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM GENERAL DESCRIPTION OF COVERAGE — This endorsement broadens coverage. However, coverage for any injury, damage or medical expenses described in any of the provisions of this endorsement may be excluded or limited by another endorsement to the Coverage Part, and these coverage broadening provisions do not apply to the extent that coverage is excluded or limited by such an endorsement. The following listing is a general cover- age description only. Limitations and exclusions may apply to these coverages. Read all the provisions of this en- dorsement and the rest of your policy carefully to determine rights, duties, and what is and is not covered. A. BROAD FORM NAMED INSURED B. BLANKET ADDITIONAL INSURED C. EMPLOYEE HIRED AUTO D. EMPLOYEES AS INSURED E. SUPPLEMENTARY PAYMENTS — INCREASED LIMITS F. HIRED AUTO — LIMITED WORLDWIDE COV- ERAGE — INDEMNITY BASIS G. WAIVER OF DEDUCTIBLE — GLASS =OL Pi [a]►PI A. BROAD FORM NAMED INSURED The following is added to Paragraph A.1., Who Is An Insured, of SECTION II — COVERED AUTOS LIABILITY COVERAGE: Any organization you newly acquire or form dur- ing the policy period over which you maintain 50% or more ownership interest and that is not separately insured for Business Auto Coverage. Coverage under this provision is afforded only un- til the 180th day after you acquire or form the or- ganization or the end of the policy period, which- ever is earlier. B. BLANKET ADDITIONAL INSURED The following is added to Paragraph c. in A.1., Who Is An Insured, of SECTION II — COVERED AUTOS LIABILITY COVERAGE: Any person or organization who is required under a written contract or agreement between you and that person or organization, that is signed and executed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period, to be named as an addi- tional insured is an "insured" for Covered Autos Liability Coverage, but only for damages to which H. HIRED AUTO PHYSICAL DAMAGE — LOSS OF USE — INCREASED LIMIT I. PHYSICAL DAMAGE — TRANSPORTATION EXPENSES — INCREASED LIMIT J. PERSONAL PROPERTY K. AIRBAGS L. NOTICE AND KNOWLEDGE OF ACCIDENT OR LOSS M. BLANKET WAIVER OF SUBROGATION N. UNINTENTIONAL ERRORS OR OMISSIONS this insurance applies and only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Section II. C. EMPLOYEE HIRED AUTO 1. The following is added to Paragraph A.1., Who Is An Insured, of SECTION II — COV- ERED AUTOS LIABILITY COVERAGE: An "employee" of yours is an "insured" while operating an "auto" hired or rented under a contract or agreement in an "employee's" name, with your permission, while performing duties related to the conduct of your busi- ness. 2. The following replaces Paragraph b. in B.S., Other Insurance, of SECTION IV — BUSI- NESS AUTO CONDITIONS: b. For Hired Auto Physical Damage Cover- age, the following are deemed to be cov- ered "autos" you own: (1) Any covered "auto" you lease, hire, rent or borrow; and (2) Any covered "auto" hired or rented by your "employee" under a contract in an "employee's" name, with your CA T3 53 02 15 © 2015 The Travelers Indemnity Company. All rights reserved. Page 1 of 4 Includes copyrighted material of Insurance Services Office, Inc. with its permission. COMMERCIAL AUTO permission, while performing duties related to the conduct of your busi- ness. However, any "auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto". D. EMPLOYEES AS INSURED The following is added to Paragraph A.1., Who Is An Insured, of SECTION II — COVERED AUTOS LIABILITY COVERAGE: Any "employee" of yours is an "insured" while us- ing a covered "auto" you don't own, hire or borrow in your business or your personal affairs. E. SUPPLEMENTARY PAYMENTS — INCREASED LIMITS 1. The following replaces Paragraph A.2.a.(2), of SECTION II — COVERED AUTOS LIABIL- ITY COVERAGE: (2) Up to $3,000 for cost of bail bonds (in- cluding bonds for related traffic law viola- tions) required because of an "accident" we cover. We do not have to furnish these bonds. 2. The following replaces Paragraph A.2.a.(4), of SECTION II — COVERED AUTOS LIABIL- ITY COVERAGE: (a) With respect to any claim made or "suit" brought outside the United States of America, the territories and possessions of the United States of America, Puerto Rico and Canada: (i) You must arrange to defend the "in- sured" against, and investigate or set- tle any such claim or "suit" and keep us advised of all proceedings and ac- tions. (ii) Neither you nor any other involved "insured" will make any settlement without our consent. (iii) We may, at our discretion, participate in defending the "insured" against, or in the settlement of, any claim or "suit". (iv) We will reimburse the "insured" for sums that the "insured" legally must pay as damages because of "bodily injury" or "property damage" to which this insurance applies, that the "in- sured" pays with our consent, but only up to the limit described in Para- graph C., Limits Of Insurance, of SECTION II — COVERED AUTOS LIABILITY COVERAGE. (4) All reasonable expenses incurred by the (v) We will reimburse the "insured" for "insured" at our request, including actual the reasonable expenses incurred loss of earnings up to $500 a day be- with our consent for your investiga- cause of time off from work. tion of such claims and your defense of the "insured" against any such F. HIRED AUTO — LIMITED WORLDWIDE COV- "suit", but only up to and included ERAGE — INDEMNITY BASIS within the limit described in Para - The following replaces Subparagraph (5) in Para- graph C., Limits Of Insurance, of graph B.7., Policy Period, Coverage Territory, SECTION II — COVERED AUTOS of SECTION IV — BUSINESS AUTO CONDI- LIABILITY COVERAGE, and not in TIONS: addition to such limit. Our duty to make such payments ends when we (5) Anywhere in the world, except any country or have used up the applicable limit of jurisdiction while any trade sanction, em- insurance in payments for damages, bargo, or similar regulation imposed by the settlements or defense expenses. United States of America applies to and pro- hibits the transaction of business with or (b) This insurance is excess over any valid within such country or jurisdiction, for Cov- and collectible other insurance available ered Autos Liability Coverage for any covered to the "insured" whether primary, excess, "auto" that you lease, hire, rent or borrow contingent or on any other basis. without a driver for a period of 30 days or less (c) This insurance is not a substitute for re - and that is not an "auto" you lease, hire, rent quired or compulsory insurance in any or borrow from any of your "employees", country outside the United States, its ter - partners (if you are a partnership), members ritories and possessions, Puerto Rico and (if you are a limited liability company) or Canada. members of their households. Page 2 of 4 © 2015 The Travelers Indemnity Company. All rights reserved. CA T3 53 02 15 Includes copyrighted material of Insurance Services Office, Inc. with its permission. You agree to maintain all required or compulsory insurance in any such coun- try up to the minimum limits required by local law. Your failure to comply with compulsory insurance requirements will not invalidate the coverage afforded by this policy, but we will only be liable to the same extent we would have been liable had you complied with the compulsory in- surance requirements. (d) It is understood that we are not an admit- ted or authorized insurer outside the United States of America, its territories and possessions, Puerto Rico and Can- ada. We assume no responsibility for the furnishing of certificates of insurance, or for compliance in any way with the laws of other countries relating to insurance. G. WAIVER OF DEDUCTIBLE — GLASS The following is added to Paragraph D., Deducti- ble, of SECTION III — PHYSICAL DAMAGE COVERAGE: No deductible for a covered "auto' will apply to glass damage if the glass is repaired rather than replaced. H. HIRED AUTO PHYSICAL DAMAGE — LOSS OF USE — INCREASED LIMIT The following replaces the last sentence of Para- graph AA.b., Loss Of Use Expenses, of SEC- TION III — PHYSICAL DAMAGE COVERAGE: However, the most we will pay for any expenses for loss of use is $65 per day, to a maximum of $750 for any one "accident'. PHYSICAL DAMAGE — TRANSPORTATION EXPENSES — INCREASED LIMIT The following replaces the first sentence in Para- graph A.4.a., Transportation Expenses, of SECTION III — PHYSICAL DAMAGE COVER- AGE: We will pay up to $50 per day to a maximum of $1,500 for temporary transportation expense in- curred by you because of the total theft of a cov- ered "auto' of the private passenger type. J. PERSONAL PROPERTY The following is added to Paragraph AA., Cover- age Extensions, of SECTION III — PHYSICAL DAMAGE COVERAGE: Personal Property We will pay up to $400 for "loss" to wearing ap- parel and other personal property which is: (1) Owned by an "insured"; and COMMERCIAL AUTO (2) In or on your covered "auto". This coverage applies only in the event of a total theft of your covered "auto". No deductibles apply to this Personal Property coverage. K. AIRBAGS The following is added to Paragraph B.3., Exclu- sions, of SECTION III — PHYSICAL DAMAGE COVERAGE: Exclusion 3.a. does not apply to "loss" to one or more airbags in a covered "auto" you own that in- flate due to a cause other than a cause of "loss" set forth in Paragraphs A.1.b. and A.1.c., but only: a. If that "auto' is a covered "auto" for Compre- hensive Coverage under this policy; b. The airbags are not covered under any war- ranty; and c. The airbags were not intentionally inflated. We will pay up to a maximum of $1,000 for any one "loss". L. NOTICE AND KNOWLEDGE OF ACCIDENT OR LOSS The following is added to Paragraph A.2.a., of SECTION IV — BUSINESS AUTO CONDITIONS: Your duty to give us or our authorized representa- tive prompt notice of the "accident' or "loss" ap- plies only when the "accident' or "loss" is known to: (a) You (if you are an individual); (b) A partner (if you are a partnership); (c) A member (if you are a limited liability com- pany); (d) An executive officer, director or insurance manager (if you are a corporation or other or- ganization); or (e) Any "employee" authorized by you to give no- tice of the "accident' or "loss". M. BLANKET WAIVER OF SUBROGATION The following replaces Paragraph A.5., Transfer Of Rights Of Recovery Against Others To Us, of SECTION IV — BUSINESS AUTO CONDI- TIONS: 5. Transfer Of Rights Of Recovery Against Others To Us We waive any right of recovery we may have against any person or organization to the ex- tent required of you by a written contract signed and executed prior to any "accident' or "loss", provided that the "accident' or "loss" arises out of operations contemplated by CA T3 53 02 15 © 2015 The Travelers Indemnity Company. All rights reserved. Page 3 of 4 Includes copyrighted material of Insurance Services Office, Inc. with its permission. COMMERCIAL AUTO such contract. The waiver applies only to the person or organization designated in such contract. N. UNINTENTIONAL ERRORS OR OMISSIONS The following is added to Paragraph B.2., Con- cealment, Misrepresentation, Or Fraud, of SECTION IV — BUSINESS AUTO CONDITIONS: The unintentional omission of, or unintentional error in, any information given by you shall not prejudice your rights under this insurance. How- ever this provision does not affect our right to col- lect additional premium or exercise our right of cancellation or non -renewal. Page 4 of 4 © 2015 The Travelers Indemnity Compa ny. All rights reserved . CA T3 53 02 15 Includes copyrighted material of Insurance Services Office, Inc. with its permission. Policy # 6806NO33449 COMMERCIAL GENERAL LIABILITY c. Method Of Sharing If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. d. Primary And Non -Contributory Insurance If Required By Written Contract If you specifically agree in a written contract or agreement that the insurance afforded to an insured under this Coverage Part must apply on a primary basis, or a primary and non- contributory basis, this insurance is primary to other insurance that is available to such insured which covers such insured as a named insured, and we will not share with that other insurance, provided that: (1) The "bodily injury' or"property damage" for which coverage is sought occurs; and (2) The "personal and advertising injury" for which coverage is sought is caused by an offense that is committed; subsequent to the signing of that contract or agreement by you. a. We will compute all premiums for this Coverage Part in accordance with our rules and rates. b. Premium shown in this Coverage Part as advance premium is a deposit premium only. At the close of each audit period we will compute the earned premium for that period and send notice to the first Named Insured. The due date for audit and retrospective premiums is the date shown as the due date on the bill. If the sum of the advance and audit premiums paid for the policy period is greater than the earned premium, we will return the excess to the first Named Insured. a. The statements in the Declarations are accurate and complete; b. Those statements are based upon representations you made to us; and c. We have issued this policy in reliance upon your representations. The unintentional omission of, or unintentional error in, any information provided by you which we relied upon in issuing this policy will not prejudice your rights under this insurance. However, this provision does not affect our right to collect additional premium or to exercise our rights of cancellation or nonrenewal in accordance with applicable insurance . Separation Of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this Coverage Part to the first Named Insured, this insurance applies: a. As if each Named Insured were the only Named Insured; and b. Separately to each insured against whom claim is made or "suit" is brought. 8. Transfer Of Rights Of Recovery Against Others To Us If the insured has rights to recover all or part of any payment we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. 9. When We Do Not Renew If we decide not to renew this Coverage Part, we will mail or deliver to the first Named Insured shown in the Declarations written notice of the nonrenewal not less than 30 days before the expiration date. If notice is mailed, proof of mailing will be sufficient proof of notice. SECTION V — DEFINITIONS 1. "Advertisement" means a notice that is broadcast or published to the general public or specific market segments about your goods, products or services for the purpose of attracting customers or supporters. For the purposes of this definition: c. The first Named Insured must keep records of a. Notices that are published include material the information we need for premium placed on the Internet or on similar electronic computation, and send us copies at such times means of communication; and as we may request. b. Regarding websites, only that part of a website 6. Representations that is about your goods, products or services By accepting this policy, you agree: for the purposes of attracting customers or supporters is considered an advertisement. Page 16 of 21 © 2017 The Travelers Indemnity Company. All rights reserved. CG T1 00 02 19 Includes copyrighted material of Insurance Services Office, Inc. with its permission. Policy # 6806NO33449 COMMERCIAL GENERAL LIABILITY occupational therapist or occupational therapy assistant, physical therapist or speech -language pathologist; or (b) First aid or "Good Samaritan services" by any of your "employees" or "volunteer workers", other than an employed or volunteer doctor. Any such "employees" or "volunteer workers" providing or failing to provide first aid or "Good Samaritan services" during their work hours for you will be deemed to be acting within the scope of their employment by you or performing duties related to the conduct of your business. 3. The following replaces the last sentence of Paragraph 5. of SECTION III — LIMITS OF INSURANCE: For the purposes of determining the applicable Each Occurrence Limit, all related acts or omissions committed in providing or failing to provide "incidental medical services", first aid or "Good Samaritan services" to any one person will be deemed to be one "occurrence". 4. The following exclusion is added to Paragraph 2., Exclusions, of SECTION I — COVERAGES — COVERAGE A — BODILY INJURY AND PROPERTY DAMAGE LIABILITY: Sale Of Pharmaceuticals "Bodily injury" or "property damage" arising out of the violation of a penal statute or ordinance relating to the sale of pharmaceuticals committed by, or with the knowledge or consent of the insured. 5. The following is added to the DEFINITIONS Section: "Incidental medical services" means: a. Medical, surgical, dental, laboratory, x- ray or nursing service or treatment, advice or instruction, or the related furnishing of food or beverages; or b. The furnishing or dispensing of drugs or medical, dental, or surgical supplies or appliances. 6. The following is added to Paragraph 4.b., Excess Insurance, of SECTION IV — COMMERCIAL GENERAL LIABILITY CONDITIONS: This insurance is excess over any valid and collectible other insurance, whether primary, excess, contingent or on any other basis, that is available to any of your "employees" for "bodily injury" that arises out of providing or failing to provide "incidental medical services" to any person to the extent not subject to Paragraph 2.a.(1) of Section II — Who Is An Insured. K. MEDICAL PAYMENTS — INCREASED LIMIT The following replaces Paragraph 7. of SECTION III — LIMITS OF INSURANCE: 7. Subject to Paragraph 5. above, the Medical Expense Limit is the most we will pay under Coverage C for all medical expenses because of "bodily injury" sustained by any one person, and will be the higher of: a. $10,000; or b. The amount shown in the Declarations of this Coverage Part for Medical Expense Limit. L. AMENDMENT OF EXCESS INSURANCE CONDITION — PROFESSIONAL LIABILITY The following is added to Paragraph 4.b., Excess Insurance, of SECTION IV — COMMERCIAL GENERAL LIABILITY CONDITIONS: This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis, that is Professional Liability or similar coverage, to the extent the loss is not subject to the professional services exclusion oT L;overaae A or uoveraae b. M. BLANKET WAIVER OF SUBROGATION — WHEN REQUIRED BY WRITTEN CONTRACT OR AGREEMENT The following is added to Paragraph 8., Transfer Of Rights Of Recovery Against Others To Us, of SECTION IV — COMMERCIAL GENERAL LIABILITY CONDITIONS: If the insured has agreed in a written contract or agreement to waive that insured's right of recovery against any person or organization, we waive our right of recovery against such person or organization, but only for payments we make because of: a. "Bodily injury" or "property damage" that occurs; or b. "Personal and advertising injury" caused by an offense that is committed; subsequent to the signing of that contract or agreement. CG D3 79 02 19 © 2017 The Travelers Indemnity Company. All rights reserved. Page 5 of 6 Includes copyrighted material of Insurance Services Office, Inc. with its permission. Policy #: BA7R748905 COMMERCIAL AUTO THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET ADDITIONAL INSURED - PRIMARY AND NON-CONTRIBUTORY WITH OTHER INSURANCE This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM PROVISIONS 1. The following is added to Paragraph A.1.c., Who Is An Insured, of SECTION II — COVERED AUTOS LIABILITY COVERAGE: This includes any person or organization who you are required under a written contract or agreement between you and that person or organization, that is signed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period, to name as an additional insured for Covered Autos Liability Coverage, but only for damages to which this insurance applies and only to the extent of that person's or organization's liability for the conduct of another "insured". 2. The following is added to Paragraph B.5., Other Insurance of SECTION IV — BUSINESS AUTO CONDITIONS: Regardless of the provisions of paragraph a. and paragraph d. of this part 5. Other Insurance, this insurance is primary to and non-contributory with applicable other insurance under which an additional insured person or organization is the first named insured when the written contract or agreement between you and that person or organization, that is signed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period, requires this insurance to be primary and non-contributory. CA T4 74 02 16 © 2016 The Travelers Indemnity Company. All rights reserved. Page 1 of 1 Includes copyrighted material of Insurance Services Office, Inc. with its permission.