HomeMy WebLinkAboutCAG2021-286 - Original - Skycorp Ltd - Mill Creek Earthworks Park Staircase Demolition - 06/17/20216/14/21
OK to sign, 6/15/2021, TW.
CAG2021-286
6/17/21
PUBLIC WORKS AGREEMENT - 1
(Over $20K and No Performance Bond)
PUBLIC WORKS AGREEMENT
between City of Kent and
Skycorp, Ltd.
THIS AGREEMENT is made by and between the City of Kent, a Washington municipal corporation
(hereinafter the "City"), and Skycorp, Ltd. organized under the laws of the State of Washington, located and
doing business at 526 Northwest Avenue, Suite 11, Arlington, WA 98223 (hereinafter the "Contractor").
AGREEMENT
The parties agree as follows:
I. DESCRIPTION OF WORK.
The Contractor shall perform the following services for the City in accordance with the following
described plans and/or specifications:
As described in the attached Exhibit A, incorporated herein, contractor shall demolish wood
staircase, cut concrete posts off at ground level, remove all debris and restore grass area
beneath removed staircase at Mill Creek Earthworks Park.
The Contractor further represents that the services furnished under this Agreement will be performed
in accordance with generally accepted professional practices within the Puget Sound region in effect at the
time such services are performed.
II. TIME OF COMPLETION. The parties agree that work will begin on the tasks described in
Section I above within 10 calendar days after the City issues its Notice to Proceed. Upon the effective date
of this Agreement, all physical work shall thereafter be completed by 09/30/2021. The term of this
Agreement shall continue until all work has been completed, final acceptance has occurred, and all
Contractor obligations have been fulfilled.
III. COMPENSATION. The City shall pay the Contractor a total amount not to exceed
$85,377.05, including any applicable Washington State Sales Tax, for the work and services contemplated
in this Agreement. The City shall pay the Contractor eighty-five percent (85%) of the Contract amount
upon completion and acceptance of the work by the City, or at such earlier time as the City may determine
is appropriate. The City will pay the remaining Contract amount upon fulfillment of the conditions listed
below and throughout this Agreement.
Card Payment Program. The Contractor may elect to participate in automated credit card payments
provided for by the City and its financial institution. This Program is provided as an alternative to payment
by check and is available for the convenience of the Contractor. If the Contractor voluntarily participates in
this Program, the Contractor will be solely responsible for any fees imposed by financial institutions or credit
card companies. The Contractor shall not charge those fees back to the City.
PUBLIC WORKS AGREEMENT - 2
(Over $20K and No Performance Bond)
A. No Payment and Performance Bond. Because this contract, including applicable sales
tax, is less than $150,000, and pursuant to Chapter 39.08 RCW, the Contractor, in lieu
of providing the City a payment and performance bond, has elected to have the City
retain the final ten percent (10%) of the Contract amount for a period of thirty (30)
days after the date of final acceptance, or until receipt of all necessary releases from
the State Department of Revenue, the State Department of Labor & Industries, and
the State Employment Security Department, and until settlement of any liens filed
under Chapter 60.28 RCW, whichever is later.
B. Retainage. The City shall also hold back a retainage in the amount of five percent
(5%) of any and all payments made to the Contractor for a period of sixty (60) days
after the date of final acceptance, or until receipt of all necessary releases from the
State Department of Revenue, the State Department of Labor & Industries, and the
State Employment Security Department, and until settlement of any liens filed under
Chapter 60.28 RCW, whichever is later. The amount retained shall be placed in a fund
by the City pursuant to RCW 60.28.011(4)(a), unless otherwise instructed by the
Contractor within fourteen (14) calendar days of the Contractor’s signature on the
Agreement.
C. Defective or Unauthorized Work. The City reserves its right to withhold payment from
the Contractor for any defective or unauthorized work. Defective or unauthorized work
includes, without limitation: work and materials that do not conform to the
requirements of this Agreement; and extra work and materials furnished without the
City’s written approval. If the Contractor is unable, for any reason, to satisfactorily
complete any portion of the work, the City may complete the work by contract or
otherwise, and the Contractor shall be liable to the City for any additional costs
incurred by the City. “Additional costs” shall mean all reasonable costs, including legal
costs and attorney fees, incurred by the City beyond the maximum Contract price
specified above. The City further reserves its right to deduct the cost to complete the
Contract work, including any Additional Costs, from any and all amounts due or to
become due the Contractor.
D. Final Payment: Waiver of Claims. THE CONTRACTOR’S ACCEPTANCE OF FINAL
PAYMENT (EXCLUDING WITHHELD RETAINAGE) SHALL CONSTITUTE A WAIVER OF
CONTRACTOR’S CLAIMS, EXCEPT THOSE PREVIOUSLY AND PROPERLY MADE AND
IDENTIFIED BY CONTRACTOR AS UNSETTLED AT THE TIME FINAL PAYMENT IS MADE
AND ACCEPTED.
IV. INDEPENDENT CONTRACTOR. The parties intend that an Independent Contractor-
Employer Relationship will be created by this Agreement. By their execution of this Agreement, and in
accordance with Ch. 51.08 RCW, the parties make the following representations:
A. The Contractor has the ability to control and direct the performance and details of its
work, the City being interested only in the results obtained under this Agreement.
B. The Contractor maintains and pays for its own place of business from which the
Contractor’s services under this Agreement will be performed.
C. The Contractor has an established and independent business that is eligible for a
business deduction for federal income tax purposes that existed before the City
retained the Contractor’s services and is a service other than that furnished by the
City, or the Contractor is engaged in an independently established trade, occupation,
profession, or business of the same nature as that involved under this Agreement.
D. The Contractor is responsible for filing as they become due all necessary tax
documents with appropriate federal and state agencies, including the Internal Revenue
Service and the state Department of Revenue.
PUBLIC WORKS AGREEMENT - 3
(Over $20K and No Performance Bond)
E. The Contractor has registered its business and established an account with the state
Department of Revenue and other state agencies as may be required by the
Contractor’s business, and has obtained a Unified Business Identifier (UBI) number
from the State of Washington.
F. The Contractor has a valid contractor registration pursuant to Ch. 18.27 RCW or an
electrical contractor license pursuant to Ch. 19.28 RCW.
G. The Contractor maintains a set of books dedicated to the expenses and earnings of its
business.
V. TERMINATION. The City may terminate this Agreement for good cause. “Good cause” shall
include, without limitation, any one or more of the following events:
A. The Contractor’s refusal or failure to supply a sufficient number of properly skilled
workers or proper materials for completion of the Contract work.
B. The Contractor’s failure to complete the work within the time specified in this
Agreement.
C. The Contractor’s failure to make full and prompt payment to subcontractors or for
material or labor.
D. The Contractor’s persistent disregard of federal, state or local laws, rules or
regulations.
E. The Contractor’s filing for bankruptcy or becoming adjudged bankrupt.
F. The Contractor’s breach of any portion of this Agreement.
If the City terminates this Agreement for good cause, the Contractor shall not receive any further
money due under this Agreement until the Contract work is completed. After termination, the City may
take possession of all records and data within the Contractor’s possession pertaining to this project which
may be used by the City without restriction.
VI. PREVAILING WAGES. The Contractor shall file a “Statement of Intent to Pay Prevailing
Wages,” with the State of Washington Department of Labor & Industries prior to commencing the Contract
work. The Contractor shall pay prevailing wages in effect on the date the bid is accepted or executed by
the Contractor, and comply with Chapter 39.12 of the Revised Code of Washington, as well as any other
applicable prevailing wage rate provisions. The latest prevailing wage rate revision issued by the
Department of Labor and Industries is attached.
VII. CHANGES. The City may issue a written change order for any change in the Contract work
during the performance of this Agreement. If the Contractor determines, for any reason, that a change
order is necessary, the Contractor must submit a written change order request to the person listed in the
notice provision section of this Agreement, Section XVI(D), within fourteen (14) calendar days of the date
the Contractor knew or should have known of the facts and events giving rise to the requested change. If
the City determines that the change increases or decreases the Contractor's costs or time for performance,
the City will make an equitable adjustment. The City will attempt, in good faith, to reach agreement with
the Contractor on all equitable adjustments. However, if the parties are unable to agree, the City will
determine the equitable adjustment as it deems appropriate. The Contractor shall proceed with the change
order work upon receiving either a written change order from the City or an oral order from the City before
actually receiving the written change order. If the Contractor fails to require a change order within the time
specified in this paragraph, the Contractor waives its right to make any claim or submit subsequent change
order requests for that portion of the contract work. If the Contractor disagrees with the equitable
PUBLIC WORKS AGREEMENT - 4
(Over $20K and No Performance Bond)
adjustment, the Contractor must complete the change order work; however, the Contractor may elect to
protest the adjustment as provided in subsections A through E of Section IX, Claims, below.
The Contractor accepts all requirements of a change order by: (1) endorsing it, (2) writing a separate
acceptance, or (3) not protesting in the way this section provides. A change order that is accepted by the
Contractor as provided in this section shall constitute full payment and final settlement of all claims for
contract time and for direct, indirect and consequential costs, including costs of delays related to any work,
either covered or affected by the change.
VIII. FORCE MAJEURE. Neither party shall be liable to the other for breach due to delay or failure
in performance resulting from acts of God, acts of war or of the public enemy, riots, pandemic, fire, flood,
or other natural disaster or acts of government (“force majeure event”). Performance that is prevented or
delayed due to a force majeure event shall not result in liability to the delayed party. Both parties represent
to the other that at the time of signing this Agreement, they are able to perform as required and their
performance will not be prevented, hindered, or delayed by the current COVID-19 pandemic, any existing
state or national declarations of emergency, or any current social distancing restrictions or personal
protective equipment requirements that may be required under federal, state, or local law in response to
the current pandemic.
If any future performance is prevented or delayed by a force majeure event, the party whose
performance is prevented or delayed shall promptly notify the other party of the existence and nature of
the force majeure event causing the prevention or delay in performance. Any excuse from liability shall be
effective only to the extent and duration of the force majeure event causing the prevention or delay in
performance and, provided, that the party prevented or delayed has not caused such event to occur and
continues to use diligent, good faith efforts to avoid the effects of such event and to perform the obligation.
Notwithstanding other provisions of this section, the Contractor shall not be entitled to, and the City
shall not be liable for, the payment of any part of the contract price during a force majeure event, or any
costs, losses, expenses, damages, or delay costs incurred by the Contractor due to a force majeure event.
Performance that is more costly due to a force majeure event is not included within the scope of this Force
Majeure provision.
If a force majeure event occurs, the City may direct the Contractor to restart any work or
performance that may have ceased, to change the work, or to take other action to secure the work or the
project site during the force majeure event. The cost to restart, change, or secure the work or project site
arising from a direction by the City under this clause will be dealt with as a change order, except to the
extent that the loss or damage has been caused or exacerbated by the failure of the Contractor to fulfill its
obligations under this Agreement. Except as expressly contemplated by this section, all other costs will be
borne by the Contractor.
IX. CLAIMS. If the Contractor disagrees with anything required by a change order, another
written order, or an oral order from the City, including any direction, instruction, interpretation, or
determination by the City, the Contractor may file a claim as provided in this section. The Contractor shall
give written notice to the City of all claims within fourteen (14) calendar days of the occurrence of the events
giving rise to the claims, or within fourteen (14) calendar days of the date the Contractor knew or should
have known of the facts or events giving rise to the claim, whichever occurs first . Any claim for damages,
additional payment for any reason, or extension of time, whether under this Agreement or otherwise, shall
be conclusively deemed to have been waived by the Contractor unless a timely written claim is made in
strict accordance with the applicable provisions of this Agreement.
At a minimum, a Contractor's written claim shall include the information set forth in subsections A,
items 1 through 5 below.
FAILURE TO PROVIDE A COMPLETE, WRITTEN NOTIFICATION OF CLAIM WITHIN
THE TIME ALLOWED SHALL BE AN ABSOLUTE WAIVER OF ANY CLAIMS ARISING IN
ANY WAY FROM THE FACTS OR EVENTS SURROUNDING THAT CLAIM OR CAUSED BY
THAT DELAY.
PUBLIC WORKS AGREEMENT - 5
(Over $20K and No Performance Bond)
A. Notice of Claim. Provide a signed written notice of claim that provides the following
information:
1. The date of the Contractor's claim;
2. The nature and circumstances that caused the claim;
3. The provisions in this Agreement that support the claim;
4. The estimated dollar cost, if any, of the claimed work and how that estimate
was determined; and
5. An analysis of the progress schedule showing the schedule change or disruption
if the Contractor is asserting a schedule change or disruption.
B. Records. The Contractor shall keep complete records of extra costs and time incurred as a
result of the asserted events giving rise to the claim. The City shall have access to any of the
Contractor's records needed for evaluating the protest.
The City will evaluate all claims, provided the procedures in this section are followed. If the
City determines that a claim is valid, the City will adjust payment for work or time by an
equitable adjustment. No adjustment will be made for an invalid protest.
C. Contractor's Duty to Complete Protested Work. In spite of any claim, the Contractor shall
proceed promptly to provide the goods, materials and services required by the City under this
Agreement.
D. Failure to Protest Constitutes Waiver. By not protesting as this section provides, the
Contractor also waives any additional entitlement and accepts from the City any written or
oral order (including directions, instructions, interpretations, and determination).
E. Failure to Follow Procedures Constitutes Waiver. By failing to follow the procedures of this
section, the Contractor completely waives any claims for protested work and accepts from the
City any written or oral order (including directions, instructions, interpretations, and
determination).
X. LIMITATION OF ACTIONS. CONTRACTOR MUST, IN ANY EVENT, FILE ANY LAWSUIT
ARISING FROM OR CONNECTED WITH THIS AGREEMENT WITHIN 120 CALENDAR DAYS FROM THE DATE
THE CONTRACT WORK IS COMPLETE OR CONTRACTOR’S ABILITY TO FILE THAT CLAIM OR SUIT SHALL BE
FOREVER BARRED. THIS SECTION FURTHER LIMITS ANY APPLICABLE STATUTORY LIMITATIONS PERIOD.
XI. WARRANTY. The Contractor warrants that it will faithfully and satisfactorily perform all work
provided under this Agreement in accordance with the provisions of this Agreement. The Contractor shall
promptly correct all defects in workmanship and materials: (1) when the Contractor knows or should have
known of the defect, or (2) upon the Contractor’s receipt of notification from the City of the existence or
discovery of the defect. In the event any parts are repaired or replaced, only original replacement parts
shall be used—rebuilt or used parts will not be acceptable. When defects are corrected, the warranty for
that portion of the work shall extend for an additional year beyond the original warranty period applicable
to the overall work. The Contractor shall begin to correct any defects within seven (7) calendar days of its
receipt of notice from the City of the defect. If the Contractor does not accomplish the corrections within a
reasonable time as determined by the City, the City may complete the corrections and the Contractor shall
pay all costs incurred by the City in order to accomplish the correction.
XII. DISCRIMINATION. In the hiring of employees for the performance of work under this
Agreement or any sub-contract, the Contractor, its sub-contractors, or any person acting on behalf of the
Contractor or sub-contractor shall not, by reason of race, religion, color, sex, age, sexual orientation,
national origin, or the presence of any sensory, mental, or physical disability, discriminate against any
person who is qualified and available to perform the work to which the employment relates.
PUBLIC WORKS AGREEMENT - 6
(Over $20K and No Performance Bond)
The Contractor shall execute the attached City of Kent Equal Employment Opportunity Policy
Declaration, Comply with City Administrative Policy 1.2, and upon completion of the contract work, file the
attached Compliance Statement.
XIII. INDEMNIFICATION. The Contractor shall defend, indemnify and hold the City, its officers,
officials, employees, agents and volunteers harmless from any and all claims, injuries, damages, losses or
suits, including all legal costs and attorney fees, arising out of or in connection with the Contractor's
performance of this Agreement, except for that portion of the injuries and damages caused by the City's
negligence.
The City's inspection or acceptance of any of the Contractor's work when completed shall not be
grounds to avoid any of these covenants of indemnification.
Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115,
then, in the event of liability for damages arising out of bodily injury to persons or damages to property
caused by or resulting from the concurrent negligence of the Contractor and the City, its officers, officials,
employees, agents and volunteers, the Contractor's duty to defend, indemnify, and hold the City harmless,
and the Contractor’s liability accruing from that obligation shall be only to the extent of the Contractor's
negligence.
IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THE INDEMNIFICATION
PROVIDED HEREIN CONSTITUTES THE CONTRACTOR'S WAIVER OF IMMUNITY UNDER INDUSTRIAL
INSURANCE, TITLE 51 RCW, SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PARTIES
FURTHER ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER.
In the event the Contractor refuses tender of defense in any suit or any claim, if that tender was
made pursuant to this indemnification clause, and if that refusal is subsequently determined by a court
having jurisdiction (or other agreed tribunal) to have been a wrongful refusal on the Contractor’s part, then
the Contractor shall pay all the City’s costs for defense, including all reasonable expert witness fees and
reasonable attorneys’ fees, plus the City’s legal costs and fees incurred because there was a wrongful refusal
on the Contractor’s part.
The provisions of this section shall survive the expiration or termination of this Agreement.
XIV. INSURANCE. The Contractor shall procure and maintain for the duration of the Agreement,
insurance of the types and in the amounts described in Exhibit B attached and incorporated by this reference.
XV. WORK PERFORMED AT CONTRACTOR'S RISK. The Contractor shall take all necessary
precautions and shall be responsible for the safety of its employees, agents, and subcontractors in the
performance of the contract work and shall utilize all protection necessary for that purpose. All work shall
be done at the Contractor's own risk, and the Contractor shall be responsible for any loss of or damage to
materials, tools, or other articles used or held for use in connection with the work.
XVI. MISCELLANEOUS PROVISIONS.
A. Recyclable Materials. Pursuant to Chapter 3.80 of the Kent City Code, the City requires its
contractors and consultants to use recycled and recyclable products whenever practicable. A price
preference may be available for any designated recycled product.
B. Non-Waiver of Breach. The failure of the City to insist upon strict performance of any of the
covenants and agreements contained in this Agreement, or to exercise any option conferred by this
Agreement in one or more instances shall not be construed to be a waiver or relinquishment of those
covenants, agreements or options, and the same shall be and remain in full force and effect.
C. Resolution of Disputes and Governing Law. This Agreement shall be governed by and
construed in accordance with the laws of the State of Washington. If the parties are unable to settle any
dispute, difference or claim arising from the parties’ performance of this Agreement, the exclusive means
PUBLIC WORKS AGREEMENT - 7
(Over $20K and No Performance Bond)
of resolving that dispute, difference or claim, shall only be by filing suit exclusively under the venue, rules
and jurisdiction of the King County Superior Court, King County, Washington, unless the parties agree in
writing to an alternative dispute resolution process. In any claim or lawsuit for damages arising from the
parties' performance of this Agreement, each party shall pay all its legal costs and attorney's fees incurred
in defending or bringing such claim or lawsuit, including all appeals, in addition to any other recovery or
award provided by law; provided, however, nothing in this paragraph shall be construed to limit the City's
right to indemnification under Section XIII of this Agreement.
D. Written Notice. All communications regarding this Agreement shall be sent to the parties at
the addresses listed on the signature page of the Agreement, unless notified to the contrary. Any written
notice hereunder shall become effective three (3) business days after the date of mailing by registered or
certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated in this
Agreement or such other address as may be hereafter specified in writing.
E. Assignment. Any assignment of this Agreement by either party without the written consent
of the non-assigning party shall be void. If the non-assigning party gives its consent to any assignment,
the terms of this Agreement shall continue in full force and effect and no further assignment shall be made
without additional written consent.
F. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement
shall be binding unless in writing and signed by a duly authorized representative of the City and the
Contractor.
G. Entire Agreement. The written provisions and terms of this Agreement, together with any
Exhibits attached hereto, shall supersede all prior verbal statements of any officer or other representative
of the City, and such statements shall not be effective or be construed as entering into or forming a part of
or altering in any manner this Agreement. All of the above documents are hereby made a part of this
Agreement. However, should any language in any of the Exhibits to this Agreement conflict with any
language contained in this Agreement, the terms of this Agreement shall prevail.
H. Compliance with Laws. The Contractor agrees to comply with all federal, state, and municipal
laws, rules, and regulations that are now effective or in the future become applicable to the Contractor's
business, equipment, and personnel engaged in operations covered by this Agreement or accruing out of
the performance of those operations.
I. Public Records Act. The Contractor acknowledges that the City is a public agency subject to
the Public Records Act codified in Chapter 42.56 of the Revised Code of Washington and documents, notes,
emails, and other records prepared or gathered by the Contractor in its performance of this Agreement may
be subject to public review and disclosure, even if those records are not produced to or possessed by the
City of Kent. As such, the Contractor agrees to cooperate fully with the City in satisfying the City’s duties
and obligations under the Public Records Act.
J. City Business License Required. Prior to commencing the tasks described in Section I, the
Contractor agrees to provide proof of a current city of Kent business license pursuant to Chapter 5.01 of the
Kent City Code.
K. Counterparts and Signatures by Fax or Email. This Agreement may be executed in any
number of counterparts, each of which shall constitute an original, and all of which will together constitute
this one Agreement. Further, upon executing this Agreement, either party may deliver the signature page
to the other by fax or email and that signature shall have the same force and effect as if the Agreement
bearing the original signature was received in person.
IN WITNESS, the parties below execute this Agreement, which shall become effective on
the last date entered below. All acts consistent with the authority of this Agreement and prior
PUBLIC WORKS AGREEMENT - 8
(Over $20K and No Performance Bond)
to its effective date are ratified and affirmed, and the terms of the Agreement shall be deemed
to have applied.
CONTRACTOR:
By:
Print Name:
Its
DATE:
CITY OF KENT:
By:
Print Name: Dana Ralph
Its Mayor
DATE:
NOTICES TO BE SENT TO:
CONTRACTOR:
Skylar Waldal
Skycorp
526 Northwest Ave, Ste 11
Arlington, WA 98223
360-926-8989 (telephone)
skycorpltd@yahoo.com (facsimile)
NOTICES TO BE SENT TO:
CITY OF KENT:
Bryan Higgins
City of Kent
220 Fourth Avenue South
Kent, WA 98032
(253) 856-5113 (telephone)
(253) bhiggins@kentwa.gov (facsimile)
APPROVED AS TO FORM:
Kent Law Department
ATTEST:
Kent City Clerk
P:\Planning\Mill Creek Earthworks Park\Stairs\Skycorp-Stair Demo-CONTRACT
06/17/2021
PUBLIC WORKS AGREEMENT - 9
(Over $20K and No Performance Bond)
DECLARATION
CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY POLICY
The City of Kent is committed to conform to Federal and State laws regarding equal opportunity.
As such all contractors, subcontractors and suppliers who perform work with relation to this
Agreement shall comply with the regulations of the City’s equal employment opportunity policies.
The following questions specifically identify the requirements the City deems necessary for any
contractor, subcontractor or supplier on this specific Agreement to adhere to. An affirmative
response is required on all of the following questions for this Agreement to be valid and binding.
If any contractor, subcontractor or supplier willfully misrepresents themselves with regard to the
directives outlines, it will be considered a breach of contract and it will be at the City’s sole
determination regarding suspension or termination for all or part of the Agreement;
The questions are as follows:
1.I have read the attached City of Kent administrative policy number 1.2.
2.During the time of this Agreement I will not discriminate in employment on the basis of sex,
race, color, national origin, age, or the presence of all sensory, mental or physical disability.
3.During the time of this Agreement the prime contractor will provide a written statement to
all new employees and subcontractors indicating commitment as an equal opportunity
employer.
4.During the time of the Agreement I, the prime contractor, will actively consider hiring and
promotion of women and minorities.
5.Before acceptance of this Agreement, an adherence statement will be signed by me, the
Prime Contractor, that the Prime Contractor complied with the requirements as set forth
above.
By signing below, I agree to fulfill the five requirements referenced above.
By: __________________________________________
For: _________________________________________
Title: ________________________________________
Date: ________________________________________
PUBLIC WORKS AGREEMENT - 10
(Over $20K and No Performance Bond)
CITY OF KENT
ADMINISTRATIVE POLICY
NUMBER: 1.2 EFFECTIVE DATE: January 1, 1998
SUBJECT: MINORITY AND WOMEN SUPERSEDES: April 1, 1996
CONTRACTORS APPROVED BY Jim White, Mayor
POLICY:
Equal employment opportunity requirements for the City of Kent will conform to federal and state
laws. All contractors, subcontractors, consultants and suppliers of the City must guarantee equal
employment opportunity within their organization and, if holding Agreements with the City
amounting to $10,000 or more within any given year, must take the following affirmative steps:
1. Provide a written statement to all new employees and subcontractors indicating
commitment as an equal opportunity employer.
2. Actively consider for promotion and advancement available minorities and women.
Any contractor, subcontractor, consultant or supplier who willfully disregards the City’s
nondiscrimination and equal opportunity requirements shall be considered in breach of contract
and subject to suspension or termination for all or part of the Agreement.
Contract Compliance Officers will be appointed by the Directors of Planning, Parks, and Public
Works Departments to assume the following duties for their respective departments.
1. Ensuring that contractors, subcontractors, consultants, and suppliers subject to these
regulations are familiar with the regulations and the City’s equal employment opportunity
policy.
2. Monitoring to assure adherence to federal, state and local laws, policies and guidelines.
PUBLIC WORKS AGREEMENT - 11
(Over $20K and No Performance Bond)
CITY OF KENT
EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE STATEMENT
This form shall be filled out AFTER COMPLETION of this project by the Contractor awarded the
Agreement.
I, the undersigned, a duly represented agent of
Company, hereby acknowledge and declare that the before-mentioned company was the prime
contractor for the Agreement known as that was entered into on
the (date), between the firm I represent and the City of
Kent.
I declare that I complied fully with all of the requirements and obligations as outlined in the City
of Kent Administrative Policy 1.2 and the Declaration City of Kent Equal Employment Opportunity
Policy that was part of the before-mentioned Agreement.
By: __________________________________________
For: _________________________________________
Title: ________________________________________
Date: ________________________________________
BIDDER RESPONSIBILITY CRITERIA
Certification of Compliance with Wage Payment Statutes
This certification is required by state law (RCW 39.04.350(2)) to be submitted to the City
before the contract can be awarded.
The bidder hereby certifies that, within the three-year period immediately preceding the bid
solicitation date (), the bidder is not a “willful” violator, as defined in RCW 49.48.082,
of any provision of chapters 49.46, 49.48, or 49.52 RCW, as determined by a final and
binding citation and notice of assessment issued by the Department of Labor and Industries or
through a civil judgment entered by a court of limited or general jurisdiction.
I certify under penalty of perjury under the laws of the State of Washington that the foregoing is
true and correct.
Skycorp, Ltd.
By: __________________________________________
Signature of Authorized Official*
Printed Name: _________________________________
Title: ________________________________________
Date: ________________________________________
City and State: _________________________________
*If a corporation, proposal must be executed in the corporate name by the president or vice-
president (or any other corporate officer accompanied by evidence of authority to sign). If a co-
partnership, proposal must be executed by a partner.
PUBLIC WORKS AGREEMENT - 12
(Over $20K and No Performance Bond)
Parcel Number 1922059049
Staircase at Earthworks Park
100 Reiten Road Kent WA 98030
Staircase Demolition Scope of work
1.Provide the city with a work start date one month prior to starting work.
2.Meet with the project manager on site to review existing conditions, staging area, and discuss
work prior to starting any demolition work.
3.Install temporary erosion control measures (silt fencing) along Mill Creek in the vicinity of the
stairs. This is a requirement.
4.Protect parking lot, asphalt paths, and staging area from damage to asphalt. Any damage done
to asphalt will be the contractor’s responsibility to repair.
5.Minimize excavator travel in work area as much as possible.
6.Secure entry from Smith Street Sidewalk with permanent barrier matching height of adjacent
barriers, in the same look and material of existing barriers.
7.Demolish and remove from the site the existing staircase.
8.Haul and properly dispose of all debris associated with the staircase.
9.Cut off concrete posts at ground level.
10.Remove or prune trees as necessary and as identified by the project manager to facilitate
removal of the staircase.
11.Do not remove or damage rock retaining wall or wooden bridge to the viewing mound.
12.Repair grass below stairs. Bring in topsoil as needed to restore area to new condition. Hydro seed
all exposed ground and areas disturbed during the removal of the structure.
13.If Contractor elects to work on smith street, contractor will be required to submit a traffic control
plan to the city traffic engineer for approval. Once approved, contractor is responsible for all
traffic control costs for the duration of the project.
14.Remove any temporary erosion measures that may have been utilized during the demolition.
15.Recycle as much demolition material as possible.
16.Notify the project manager upon completion to schedule a walk thru.
Notes
Please see attached exhibits for a sample contract and insurance requirements for the project.
Pre bid inspection of staircase is recommended. Equipment access to the staircase is limited.
The city will obtain a demolition permit, if needed.
Recycling of wood, concrete and metal is strongly recommended.
Contractor will have 60 Days from NTP to complete all work.
Work shall be completed only during the months of July and August.
Please include WSST in your bid.
Contact Project Manager Bryan Higgins at 253 856 5113 for additional information.
PROPOSAL / CONTRACT
April 27, 2021
To: City of Kent
Bryan Higgins
bhiggins@kentwa.gov
Re: Parcel # 1922059049 Staircase at Earthworks Park 100 Reiten Road Kent, WA 98030
SkyCorp, Ltd. proposes to furnish all materials and perform all labor necessary to complete the following:
Scope of work:
Mobilization of equipment to the project location. Demolition and removal of the exciting
(1) Staircase located off of Smith Street Sidewalk at Earthworks Park per scope of work dated on
April 20 th 2021 by Bryan Higgins.
Total Price (Including WSST) $85,377.05
Clarifications:
1.Proposal is based on one mobilization.
2.Proposal valid for 30 days.
3.Parking lot must be closed for staging.
4.Mutually agreed upon schedule and contract.
5.Price does not include asbestos and abatement removal or any other hazardous material testing.
6.Price only includes the specific areas listed above.
7.Additional work performed per hourly rate sheet. (per request)
8.SkyCorp, Ltd. will file Puget Sound Clean Air Permits.
9.Any and all salvage material belongs to SkyCorp, Ltd.
Exclusions:
1.Engineering, soils testing, lay out and surveying
2.Irrigation
3.Permanent fencing
4.Tree protection fencing
5.All fees and special additional inspections
6.Relocating or shutting off utilities
7.Private locates
8.Import or export of any fill material (topsoil as needed)
9.Dewatering
10.All other permits
11.Independent third party, on-site air monitoring
12.Additional Asbestos survey and abatement work
13.Unforeseen or presumed asbestos materials
14.All other work not included in this proposal
Thank you for considering our proposal.
Sincerely,
Skyler Waldal
SkyCorp Ltd
425-367-7887 cell
360-926-8989 office
360-926-8987 fax
Accepted this______day of____________________,20______
by:__________________________________________________________________________
Signature Print Name
EXHIBIT BINSURANCE REQUIREMENTS FOR SERVICE CONTRACTS
Insurance
The Contractor shall procure and maintain for the duration of the Agreement,
insurance against claims for injuries to persons or damage to property which
may arise from or in connection with the performance of the work hereunder
by the Contractor, their agents, representatives, employees or
subcontractors.
A. Minimum Scope of Insurance
Contractor shall obtain insurance of the types described below:
1.Commercial General Liability insurance shall be written on
ISO occurrence form CG 00 01 and shall cover liability
arising from premises, operations, independent contractors,
products-completed operations, personal injury and
advertising injury, and liability assumed under an insured
contract. The City shall be named as an insured under the
Contractor’s Commercial General Liability insurance policy
with respect to the work performed for the City using ISO
additional insured endorsement CG 20 10 11 85 or a
substitute endorsement providing equivalent coverage.
2.Automobile Liability insurance covering all owned, non-
owned, hired and leased vehicles. Coverage shall be written
on Insurance Services Office (ISO) form CA 00 01 or a
substitute form providing equivalent liability coverage. If
necessary, the policy shall be endorsed to provide
contractual liability coverage.
3.Workers’ Compensation coverage as required by the
Industrial Insurance laws of the State of Washington.
B. Minimum Amounts of Insurance
Contractor shall maintain the following insurance limits:
1.Commercial General Liability insurance shall be written with
limits no less than $1,000,000 each occurrence, $1,000,000
general aggregate and a $1,000,000 products-completed
operations aggregate limit.
2.Automobile Liability insurance with a minimum combined
single limit for bodily injury and property damage of
$1,000,000 per accident.
EXHIBIT B (Continued)
C. Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following
provisions for Automobile Liability and Commercial General Liability
insurance:
1.The Contractor’s insurance coverage shall be primary insurance as respect
the City. Any Insurance, self-insurance, or insurance pool coverage
maintained by the City shall be excess of the Contractor’s insurance and
shall not contribute with it.
2.The Contractor’s insurance shall be endorsed to state that coverage shall
not be cancelled by either party, except after thirty (30) days prior
written notice by certified mail, return receipt requested, has been given
to the City.
3. The City of Kent shall be named as an additional insured on all policies
(except Professional Liability) as respects work performed by or on behalf
of the contractor and a copy of the endorsement naming the City as
additional insured shall be attached to the Certificate of Insurance. The
City reserves the right to receive a certified copy of all required insurance
policies. The Contractor’s Commercial General Liability insurance shall
also contain a clause stating that coverage shall apply separately to each
insured against whom claim is made or suit is brought, except with
respects to the limits of the insurer’s liability.
D. Acceptability of Insurers
Insurance is to be placed with insurers with a current A.M. Best rating of not
less than A:VII.
E. Verification of Coverage
Contractor shall furnish the City with original certificates and a copy of the
amendatory endorsements, including but not necessarily limited to the
additional insured endorsement, evidencing the insurance requirements of
the Contractor before commencement of the work.
F. Subcontractors
Contractor shall include all subcontractors as insureds under its policies or
shall furnish separate certificates and endorsements for each subcontractor.
All coverages for subcontractors shall be subject to all of the same insurance
requirements as stated herein for the Contractor.
SKYCLTD-01 SOGDON
A�o,R'0 CERTIFICATE OF LIABILITY INSURANCE DATE 1
513121
D21
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW, THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.
if SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
PRODUCER NQMTACT Stephanie Voss
Alliant Insurance Services, Inc. PH ONE FAX
3977 Harbour Pointe Blvd SW AlC, No, Ext : (425) 740-5239 (AfC, Nu)
Mukilteo, WA 98275 oAIL
SS: Stephanie.Voss@alliant.com
INSURER A:Cuide0ne National Insurance Company 114167
INSURED ,NSURERB:Austin Mutual Insurance Company I1341.2
Skycorp LTD. INSURER c :
526 NW Ave Ste. 11 INSURER D :
Arlington, WA 98223
INSURER E
INSURER F :
r•n+r�o Ar_t=c rcoTrcrrnrr w u�rr2�o.
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
_
ILTR TYPE OF INSURANCE
ADDL SUBp
IN
POLICY NUMBER
POLICY EFF
YYY
POLICY EXp
M DD
LIMITS
A X 1 COMMERCIAL GENERAL LIABILITY
11000,000
CLAIMS -MADE ` X OCCUR
X
}(
FNV567001277-02
4/4/2021
4/4/2022
H OCCURRENCE $
RENTED 5a,00a
�PACEM:MA;IGETO
-
EI$ LEa o_ccurrenct3j,. , $
-
MEDEXP(Anyone person) $ 5000
PERSONAL & ADV INJURY 1,000,000
GEN'L AGGREGATE LIMIT APPLIES PER:
_$
GENERAL AGGREGATE 2,000,000
POLICY PECOT- LOG
_$
PRODUCTS - COMP/OP AGG_ $ 2,000,000
$
OTHER'
B AUTOMOBILE LIABILITY
COMBINED SINGLE LIMIT
Ea a iden)) $ 1,aao,00a
BpDILYINJURY Per ersonj $
j ANY AUTO
B1P7793M
414/2021
4/4/2022
OWNED SCHEDULED
AUTOS ONLY _ X AUTOS
60DILYINJURY(Peraccident); $
X HIRED X NONDpWNEO
AUTOS ONLY ,__—� AUTOS ONLY
PROPERTY DAMAGE
(Per accfden� _$
A X 1 UMBRELLA LIAB X OCCUR
, EACH OCCURRENCE $ 1'OQa,000
EXCESS LIAB CLAIMS -MADE
ENV562002773-01
41412021
4/4/2022
- 1,000,000
.—_.. ._-
DIED X RETENTION$ t9r000
AGGREGATE _ 5
A WORKERS
X
EMPLOYERS' LIABr Y i�
ANY PRO PRIETORIPARTNE RIEXECUTIVE Y!N
'ENV5620U1277-02
414l2021
4l412022
„LSTATU7-E_ , ERH _
E.L. EACH 1,000,000
OFFICER/MEMBER EXCLUDED? I�
(Mandatory in NH)
N 1 A
ACCIDENT S _
1,000,000
If yes, descr;he under
E.L. DISEASE - EA EMPLOYEE $ - ---
DESCRIPTIONOFOPERATIONSbelow
E.L. DISEASE - POUCYLIMIT S 1,000,000
A !POLLUTION LIABILITY
ENV562001277-02 4/4/2021
4/4/2022 !LIMIT
1,000,000
DESCRIPTION OF OPERATIONS f LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached If more space is required)
RE: Project# Millcreek Staircase Demo
City of Kent is Additional Insured with respect to the General Liability per forms attached. General Liability is Primary and Non -Contributory per forms
attached. Waiver of Subrogation applies to the Gone ral Liability per forms attached. Per Project Aggregate applies per form attached.
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
City of Kent THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
Parks, Recreation and Community Services
Parks Planning & Development Division
220 Fourth Avenue South AUTHORIZED REPRESENTATIVE
Kent, WA 98032
ACORD 25 (2a16103) O 1988-2015 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD
POLICY NUMBER:
COMMERCIAL GENERAL. LIABILITY
CG 20 10 07 04
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED - OWNERS, LESSEES OR
CONTRACTORS - SCHEDULED PERSON OR
ORGANIZATION
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE, PART
SCHEDULE
Name Of Additional Insured Person(s) Location(s) Of Covered Operations
Or Ur anization s
Any person or organization for whom you are performing In respect to any location where the named insured is
operations when you and such person or organization have performing "your work".
agreed in writing in a contract or agreement, effected prior
to the date your operations for that person or organization
commenced, that such person or organization be added as
an additional insured on your policy.
Information required to com late this Schedule, if not shown above, will be shown in the Declarations.
A Section 11 - Who Is An Insured is amended to B.
include as an additional insured the person(s) or
organization(s) shown in the Schedule, but only with
respect to liability for "bodily injury "properly
damage" or "personal and advertising inW' caused,
in whole or in part, by:
1. Your acts or omissions; or
Y. The acts or omissions of those acting on your
behalf;
in the performance of your ongoing operations for the
additional insured(s) at the location(s) designated
above.
With respect to the insurance afforded to these
additional insureds, the following additional exclu-
sions apply,
This insurance does not apply to "bodily injury" or
"property damage" occurring after:
1. All work, including materials, parts or equip-
ment furnished in connection with such work,
on the project (other than service,
maintenance or repairs) to be performed by or
on behalf of the additional insured(s) at the
location of the covered operations has been
completed; or
2. That portion of "your work" out of which the
injury or damage arises has been put to its in-
tended use by any person or organization
other than another contractor or subcontractor
engaged in performing operations for a
principal as a part of the same project.
0320109704 C 150 Properties, Inc., 2004. Page 1 of 1
POLICY NUMBER: ENV562001277-01
COMMERCIAL GENERAL LIABILITY
CG2D370704
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED - OWNERS, LESSEES OR
CONTRACTORS - COMPLETED OPERATIONS
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SCHEDULE
Name Of Additional lnsured Person(s) Location And Description Of Completed
Or Or anization s : Operations
Any person or organization for whom you are In respect to any location where the named insured is
performing operations when you and such person or performing "your work".
organization have agreed in writing in a contract or
agreement, effected prior to the date your operations
for that person or organization commenced, that such
person or organization be added as an additional
insured on your policy.
Information required to complete this Schedule, if not shown above, will be shown in the Declarations.
Section I — Who Is An Insured is amended to
include as an additional insured the person(s) or
organization(s) shown in the Schedule, but only with
respect to liability for "bodily injury" or "property
damage" caused, in whole or in part, by "your work"
at the location designated and described in the
schedule of this endorsement performed for that
additional insured and included in the "products -
completed operations hazard",
CO 20 37 07 04 O ISO Properties, Inc,, 2004 Page 1 of 1
POLICYNUMBER.
COMMERCIAL GENERAL. LIABILITY
CG 25 Eta 03 97
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
DESIGNATED CONSTRUCTION PROJECT(S)
GENERAL AGGREGATE LIMIT
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
Designated Construction Projects:
(if no entry appears above, information requ
as applicable to this endorsement,)
SCHEDULE
to complete this endorsement will be shown in the Declarations
A. For all sums which the insured becomes legally
obligated to pay as damages caused by
"occurrences" under COVERAGE A (SECTION
1), and for all medical expenses caused by acci-
dents under COVERAGE C (SECTION 1), which
can be attributed only to ongoing operations at a
single designated construction project shown in
the Schedule above.
i. A separate Designated Construction Project
General Aggregate Limit applies to each
designated construction project, and that limit
is equal to the amount of the General Aggre-
gate Limit shown in the Declarations.
2. The Designated Construction Project General
Aggregate Limit is the most we will pay for
the sure of all damages under COVERAGE
A, except damages because of "bodily injury"
or `property damage" included in the
'products -completed operations hazard", and
for medical expenses under COVERAGE C
regardless of the number of.
a. Insureds;
b, Claims made or suits" brought: or
G. Persons or organizations making claims
or bringing "suits".
3. Any payments made under COVERAGE A
for damages or under COVERAGE C for
medical expenses shall reduce the Desig-
nated Construction Project General Aggre-
gate Limit for that designated construction
project, Such payments shall not reduce the
General Aggregate Limit shown in the Decla-
rations nor shall they reduce any other Des-
ignated Construction Project General Aggre-
gate Limit for any other designated construc-
tion project shown in the Schedule above.
4. The limits shown in the Declarations for Each
Occurrence, Fire Damage and Medical Ex-
pense continue to apply. However, instead of
being subject to the General Aggregate Limit
shown in the Declarations, such limits will be
subject to the applicable Designated Con-
struction Project General Aggregate Limit.
B. For all sums which the insured becomes iegally
obligated to pay as damages caused by
`occurrences" under COVERAGE A (SECTION
1), and for all medical expenses caused by acci-
dents under COVERAGE C (SECTION 1), which
cannot be attributed only to ongoing operations
at a single designated construction project shown
in the Schedule above:
1. Any payments made under COVERAGE A
for damages or under COVERAGE C for
medical expenses shall reduce the amount
available under the General Aggregate Limit
or the Products -Completed Operations Ag-
gregate Limit. whichever is applicable and
2. Such payments shall not reduce any Desig-
nated Construction Protect General Aggre-
gate Limit.
C. When coverage for liability arising out of fhe
'products -completed operations hazard'' is pro-
vided, any payments for damages because of
"bodily injury" or 'property damage- included in
the `products -completed operations hazard' will
reduce the Products -Completed Operations Ag-
gregate Limit. and not reduce the General Ag-
gregate Limit nor the Designated Construction
Project General Aggregate Limit.
CG 25 133 03 97 Copyright Insurance Services Office Inc. 1995 Page 9 of 2 0
D. IF the applicable designated construction project
has been abandoned, delayed, or abandoned
and then restarted, or if the authorized contract-
ing parties deviate From plans.. blueprints, de-
signs, specifications or timetables. the project
will still be deemed to be the same construction
project.
E. The provisions of Limits Of Insurance (SECT10N
Ili) not otherwise modified by this endorsement
shall continue to apply as stipulated.
Page 2 of 2 Copyright. Insurance Services Office, tnc., 199E CG 25 03 V 97 0
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
PRIMARY/NON-CONTRIBUTORY COVERAGE
This endorsement mocfifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
PRIMARY/NON-CONTRIBUTORY — K required by written contract or agreement, effected prior th the date your operations
for that person or organization commenced and named below, such insurance as is afforded by this policy to any
additional insureds under this policy shall be primary insurance, and any insurance or self-insurance maintained by such
additional insured(s)shall not contribute to the insurance afforded to the named insured.
All other terms and conditions remain unchanged.
SCHEDULE
Any pemo n or organization that is
1. An owner or real or personal property on vA ich you are performing operations, but only at the specific written
request by that person or organization to you, and only tF
a That request is made prior fo the date your operations for that person or organization commenced; and
b► A Certificate or Insurance evidencing that request has been issued by your authorized insurance agent or
broker; or
2 A contractor on whose behatr you are performing operations, but only at the specfic written request by that
person or organization b you, and only i`:
a That request is made prior to the date your operaGuns fa that person or organization commenced; and
4 A CPr fficatP rf Insurance evidencing that request has been issued by your authorized insurance agent or
"er,
GO 0216-4YP 10-17 Includes Copyrighted Material of Insurance Services Office, Page i ofi
Inc. with its permission
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
AMENDED WAIVER OF SUBROGATION
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SCHEDULE
Name of Person or Organization,
Any person or organization that is:
1. An owner of real or personal property on which you are performing operations, but only at the specific
written request by that person or organization to you, and only if:
a. That requests made prior to the date your operations for that person or organization commenced; and
h A Certificate of Insurance evidencing that request has been issued by your authorized insurance agent
or broker; or
2 A contractor on whose behalf you are performing operations, but only at the specific written request by that
person or organization to you, and only if -
EL That request is made prior to the date your operations for that person or organization commenced; and
h, A Certificate of Insurance evidencing that request has been issued by your authorized insurance
agent or broker.
WAIVER OF SUBROGATION —If required by written contract or agreement, we waive any right of recovery we may have
against any entity that is an additional insured shown in the Schedule above per the terms of this endorsement because
of payments we make for injury or damage arising out of "your work" performed under a contract with that person or
organization.
All other terms and conditions remain unchanged.
GO o218— 4YA 10-17 Includes Copyrighted Material of Insurance Services Office, Inc. Page 1 of 1
with its permission
State of Washington
Department of Labor & Industries
Prevailing Wage Section - Telephone 360-902-5335
PO Box 44540, Olympia, WA 98504-4540
Washington State Prevailing Wage
The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, worker's wage and benefit rates must add to not less than this
total. A brief description of overtime calculation requirements are provided on the Benefit Code Key.
Journey Level Prevailing Wage Rates for the Effective Date: 5/26/2021
County
Trade
Job Classification
_WA ga
Holiday
Overtime
Note
`Risk Class
King
Asbestos Abatement Workers
Journey Level
$52.39
SD
1H
View
King
Boilermakers
Journey Level
$70.79
SN
1C
View
King
Brick Mason
Journey Level
$60.57
7E
1N
View
King
Brick Mason
Pointer -Caulker -Cleaner
$60.57
7E
I
View
King
Building Service Employees
Janitor
$26.28
5S
2F
View
King Building Service Emplgyees Traveling Waxer/Shampooer
King Building Service Employees Window Cleaner (Non-Scaffold)
King Building Service Employees Window Cleaner (Scaffold)
King Cabinet Makers (In Shop) Journey Level
$26.63
5S
2E
Y.i=
$29.98
SS
2F
View
$30.98
SS
2F
View
$22.74
1
View
King Carpenters Acoustical Worker
King Scdroenters Carpenter
King Carpenters Carpenters on Stationary Tools
King Carpenters Creosoted Material
$64.94
$64.94
$65.07
$65.07
7A
ZA
7A
7A
4C
4C
4C
View
Y.i=
View
View
King Carpenters Floor Finisher $64.94 7A 4C
King Carpenters Floor Layer _ $64.94 7A 4C
King LZIIgnters Scaffold Erector $64.94 jA
King Cement Masons Application of all Composition Mastic $64.84 7A 4U
King Cement Masons Application of all Epoxy Material $64.34 7A 4U
King Cement Masons Application of all Plastic Material $64.84 7A 4U
King Cement Masons Application of Sealing Compound $64.34 7A 41.1
King Cement Masons Application of Underlayment $64.84 7A 41.1
King Cement Masons Building General $64.341 ZA 9J
King Cement Masons Composition or Kalman Floors $64.84 7A 4U
King Cement Masons Concrete Paving $64.34 7A 4U
King Cement Masons Curb Et Gutter Machine $64.84 7A 41.1
King Cement Masons Curb It Gutter, Sidewalks $64.34 7A 41.1
King Cement Masons Curing Concrete W 34 ZA 9J
King Cement Masons Finish Colored Concrete $64.84 7A 4U
King Cement Masons Floor Grinding $64.84 7A 4U
King Cement Masons Floor Grinding/Polisher $64.34 7A 4U
King Cement Masons Green Concrete Saw, self -powered $64.841 7A 41.1
King Cement Masons Grouting of all Plates $64.34 ZA 9J
King Cement Masons Grouting of all Tilt -up Panels $64.34 7A 4U
King Cement Masons Gunite Nozzleman $64.84 7A 4U
King Cement Masons Hand Powered Grinder $64.84 7A 4U
King Cement Masons Journey Level $64.34 7A 41.1
King 1Cement Masons Patching Concrete $64.341 7A 41.1
King Cement Masons Pneumatic Power Tools $64.84 ZA 9k
View
View
yi=
View
View
View
View
View
Y.i=
View
View
View
View
Y.i=
View
View
View
View
yi=
View
View
View
View
View
yi=
King Cement Masons
Power Chipping rc Brushing
$64.84
7A 4U
View
King Cement Masons
Sand Blasting Architectural Finish
$64.84 7A 4U
View
View
King Cement Masons
King Cement Masons
King Cement Masons
King Cement Masons
King Cement Masons
King Divers a Tenders
King Divers Et Tenders
King Divers & Tenders
King Divers a Tenders
King Divers Ft Tenders
King Divers It Tenders
King Divers Et Tenders
King Divers Et Tenders
King Divers it Tenders
King Dredge Workers
King Dredge Workers
King Dredge Workers
King Dredge Workers
King 2=d9e Workers
King Dredge Workers
King Dredge Workers
King Drywall Applicator
King Drywall Tapers
King Electrical Fixture Maintenance Workers
Screed rc Rodding Machine
Spackling or Skim Coat Concrete
Troweling Machine Operator
Troweling Machine Operator on Colored Slabs
Tunnel Workers
Bell/Vehicle or Submersible Operator (Not Under Pressure)
Dive Supervisor/Master
Diver
Diver On Standby
Diver Tender
Manifold Operator
Manifold Operator Mixed Gas
Remote Operated Vehicle Operator/Technician
Remote Operated Vehicle Tender
Assistant Engineer
Assistant Mate (Deckhand)
Boatmen
Engineer Welder
Leverman, Hydraulic
Mates
Oiler
Journey Level
Journey Level
Journey Level
$64.84 7A 41.1
$64.34 7A 41.1
$64.84 ZA 9k
$64.84 7A 4U
$64.84 7A 4U
$118.80 7A 4C
$81.98 7A 4C
$118.80 ZA
$76.98 7A 4C
$69.91 7A 4C
$69.91 7A 4C
$74.91 7A 4C
$69.911 7A 4C
$65.19 ZA
$70.62 SD 3F
$70.07 5D 3F
$70.62 SO 3F
$71.97 SD 3F
$73.41 M )f
$70.62 SD 3F
$70.071 SD 3F
$64.94 SD 1 H
$65.31 5P 1 E
$31.99 51 ¢
View
yi=
View
View
View
View
@y
view
View
View
View
View
View
yi=
View
View
View
View
yi=
View
View
View
View
Yi=
King Electricians - Inside Cable Splicer $92.57 7C
King Electricians - Inside Cable Splicer (tunnel) $99.46 7C
King Electricians - Inside Certified Welder $89.44 7C
King IElectricians - Inside Certified Welder (tunnel) $96.02 7C
King Electricians - Inside Construction Stock Person $44.78 7C
King Electricians -Inside Journey Level $86.30 M
King Electricians -Inside Journey Level (tunnel) $92.57 7C
King Electricians - Motor Shop Journey Level $47.531 SA
King Electricians - Powerline Construction Cable Splicer $82.391 5A
King Electricians - Powerline Construction Certified Line Welder $75.641 5A
King Electricians - Powerline Construction Groundperson $49.17 5A
King Electricians - Powerline Construction Heavy Line Equipment Operator $75.64 SA
King Electricians - Powerline Construction Journey Level Lineperson $75.64 SA
King Electricians - Powerline Construction Line Equipment Operator $64.54 5A
King IElectricians - Powerline Construction ,Meter Installer $49.17 5A
4E
View
4E
View
4E
View
4E
View
4E
View
AL
View
View
4E
1B
View
4D
View
4D
View
}Q
view
4D
View
4D
View
4D
View
4D
8W
View
King Electricians - Powerline Construction
Pole Sprayer
$75.64
$56.49
5A
5A
4D
4D
View
View
King Electricians - Powerline Construction
King Electronic Technicians
King Elevator Constructors
King Elevator Constructors
King Fabricated Precast Concrete Products
Powderperson
Journey Level
$53.57
ZE
IE
Yi=
Mechanic
$100.51
7D
4A
View
Mechanic In Charge
$108.53
7D
4A
View
All Classifications - In -Factory Work Only
$18.25
$44.40
5B
7A
1 R
4V
8Y
$Y
8Y
flY
View
View
King Fence Erectors
King Fence Erectors
King Flaggers
King Glaziers
Fence Erector
Fence Laborer
$44.40
ZA
AY
Yi=
Journey Level
$44.40
7A
4V
View
Journey Level
$69.26 7L
$79.43 5J
$89.61 7F
$54.01 ZA
$13.69
$61.41 5B
$56.48 5B
$57.48 5B
1Y
4H
View
View
King Heat Ft Frost Insulators And Asbestos Workers
Journeyman
King Heating Equipment Mechanics
King Hod Carriers Ft Mason Tenders
King Industrial Power Vacuum Cleaner
King Inland Boatmen
Journey Level
1 E
View
Journey Level
4Y
view
Journey Level
1
View
Boat Operator
1K
View
King Inland Boatmen
Cook
1K
1K
View
View
King Inland Boatmen Deckhand
King Inland Boatmen _ Deckhand Engineer
King Inland Boatmen Launch Operator
King Inland Boatmen Nate
King Inspection/Cleaning/Sealing Of Sewer 6: Water Systems By Remote Cleaner Operator, Foamer Operator
Control
King Inspection/Cleaning/Sealing Of Sewer & Water Systems By Remote Grout Truck Operator
Control
King Inspection/Cleaning/Sealing Of Sewer Ft Water Systems By Remote I Head Operator
Control _
King iMoection/Cleaning/Sealing Of Sewer &Water 5vs1ms By Remote Technician
Control
King Lpection/Cleaning/Sealing Of Sewer &Water Systems By Remote Tv Truck Operator
Control
King Insulation Applicators Journey Level
King Ironworkers Journeyman
King Laborers Air, Gas Or Electric Vibrating Screed
King Laborers Airtrac Drill Operator
King Laborers Ballast Regular Machine
King Laborers Batch Weighman
King Laborers Brick Pavers
King Laborers Brush Cutter
King Laborers Brush Hog Feeder
King Burner
King Laborers Caisson Worker
King Laborers Carpenter Tender
King Laborers Cement Dumper -paving
King Laborers Cement Finisher Tender
King Laborers Change House Or Dry Shack
King Laborers Chipping Gun (30 Lbs. And Over)
King Laborers Chipping Gun (Under 30 Lbs.)
King Laborers Choker Setter
King Laborers Chuck Tender
King Laborers Clary Power Spreader
King Laborers Clean-up Laborer
$58.81
5B
1K
View
$58.89
M
it
Yi=
$57.31
5B
1K
View
$31.49
1
View
$13.69
1
View
$24.91
1
View
$19.33
1
view
View
$20.45
1
$64.94
7A
4C
View
$76.78
7N
10
View
$52.39
7A
4V
8Y
View
$54.01
ZA
7A
7A
7A
7A
7A
ZA
4Y
4V
4V
4V
4V
flY
view
$52.39
BY
View
$44.40
8Y
View
$52.39
8Y
View
$52.39
8Y
View
$52.39
4V
8Y
View
$52.39
4Y
a
Yi=
$54.01
7A
4V
BY
View
$52.39
7A
4V
8Y
View
$53.35
7A
4V
8Y
View
$52.39
7A
4V
8Y
View
$52.39
ZA
4Y
a
view
$53.35
7A
4V
BY
View
$52.39
7A
4V
8Y
View
$52.39
7A
4V
BY
View
$52.39
7A
4V
8Y
View
$53.35
ZA
4Y
flY
Yi=
$52.39
7A
4V
BY
View
King Laborers
Concrete Dumper/Chute Operator
$53.35
$52.39
7A
7A
4V
4V
8Y
8Y
View
View
King Laborers
Concrete Form Stripper
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
Concrete Placement Crew
Concrete Saw Operator/Core Driller
Crusher Feeder
Curing Laborer
Demolition, Wrecking 8. Moving (Ind. Charred Material)
Ditch Digger
Diver
Drill Operator (Hydraulic, Diamond)
$53.35
7A
4V
8Y
View
$53.35
7A
4V
8Y
View
$44.40
ZA
4Y
a
View
$52.39
7A
4V
BY
View
$52.39
7A
4V
8Y
View
$52.39
7A
4V
8Y
View
$54.01
7A
4V
8Y
View
$53.35
ZA
4Y
a
view
Dry Stack Walls
$52.39
7A
4V
BY
View
Dump Person
$52.39
7A
4V
8Y
View
Epoxy Technician
$52.39
7A
4V
BY
View
Erosion Control Worker
$52.391
7A
4V
8Y
View
Faller Ft Bucker Chain Saw
$53.35
ZA
4Y
flY
view
Fine Graders
$52.39
7A
4V
BY
View
Firewatch
Form Setter
Gabian Basket Builders
General Laborer
Grade Checker Fc Transit Person
Grinders
$44.40
7A
4V
8Y
View
$52.39
7A
4V
8Y
View
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
King Laborers
$52.39
7A
4V
8Y
View
$52.39
7A
4V
8Y
View
$54.01
ZA
4Y
a
Yi=
$52.39
7A
4V
BY
View
Grout Machine Tender
$52.39
7A
4V
8Y
View
Groutmen (Pressure) Including Post Tension Beams
$53.35
7A
4V
8Y
View
Guardrail Erector
$52.39
7A
4V
8Y
View
Hazardous Waste Worker (Level A)
$54.01
ZA
4Y
a
View
Hazardous Waste Worker (Level B)
$53.35
7A
4V
BY
View
Hazardous Waste Worker (Level C)
$52.39
7A
4V
8Y
View
High Scaler
$54.01
7A
4V
BY
View
Jackhammer
$53.351
7A
4V
8Y
View
Laserbeam Operator
$53.35
ZA
4Y
flY
View
Maintenance Person
$52.39
7A
4V
BY
View
Manhole Builder-Mudman
Material Yard Person
Motorman -Dinky Locomotive
$53.35
7A
4V
8Y
View
$52.39
7A
7A
7A
jA
7A
4V
8Y
View
$53.35
4V
8Y
View
King Laborers
Noaleman (Concrete Pump, Green Cutter When Using Combination
Of High Pressure Air Et Water On Concrete Fc Rock, Sandblast,
Gunite, Shotcrete, Water Blaster, Vacuum Blaster)
$53.35
4V
8Y
View
Yi=
View
View
View
View
View
King Laborers Pavement Breaker
King Laborers Pilot Car
King Laborers Pipe Layer Lead
King Laborers Pipe Layer/Tailor
King Laborers Pipe Pot Tender
King Laborers Pipe Reliner
$53.35
AY
a
$44.40
4V
BY
$54.01
7A
4V
8Y
$53.35
7A
4V
8Y
$53.35
7A
4V
4Y
8Y
a
$53.35
ZA
King Laborers Pipe Wrapper
King Laborers Pot Tender
King Laborers Powderman
King Laborers Powderman's Helper
King Laborers Power Jacks
King Laborers Railroad Spike Puller - Power
King Laborers Raker - Asphalt
King Laborers Re-timberman
King Laborers Remote Equipment Operator
$53.35
7A
4V
8y
View
$52.39
7A
4V
8Y
View
$54.01
ZA
4Y
a
Yi=
$52.39
7A
4V
By
View
$53.35
7A
4V
8Y
View
$53.35
7A
4V
8Y
View
$54.01
7A
4V
8Y
View
$54.01
ZA
4Y
a
Yi=
$53.35
7A
4V
By
View
King Laborers
Rigger/Signal Person
$53.35
7A
4V
8Y
View
King Laborers
Rip Rap Person
$52.39
7A
4V
BY
View
King Laborers
Rivet Buster
$53.35
7A
4V
8Y
View
King Laborers
Rodder
$53.35
ZA
4Y
flY
view
King Laborers
Scaffold Erector
$52.39
$52.391
7A
7A
4V
4V
BY
8Y
View
View
King Laborers
Scale Person
King Laborers Sloper(Over 20")
King Laborers Sloper Sprayer
King Laborers Spreader (Concrete)
King Laborers Stake Hopper
King Laborers Stock Piler
King Laborers Swinging Stage/Boatswain Chair
King Laborers Tamper Ft Similar Electric, Air Ft Gas Operated Tools
King Laborers Tamper (Multiple & Self-propelled)
King Laborers Timber Person - Sewer (Lagger, Shorer 8 Cribber)
King Laborers Toolroom Person (at Jobsite)
King Laborers Topper
King Laborers Track Laborer
King Laborers Track Liner (Power)
King Laborers Traffic Control Laborer
$53.35
7A
4V
8Y
View
$52.39
7A
4V
8Y
View
$53.35
7A
4V
8Y
View
$52.39
ZA
4Y
a
Yi=
$52.39
7A
4V
By
View
$44.40
7A
4V
8Y
View
$53.35
7A
4V
8Y
View
$53.351
7A
4V
8Y
View
$53.35
ZA
4Y
a
Yi=
$52.39
7A
4V
By
View
$52.39
7A
4V
8Y
View
$52.39
7A
4V
SY
View
$53.35
7A
4V
8Y
View
$47.48
ZA
4Y
9S
Yi=
King
Laborers
Traffic Control Supervisor
$50.31
7A
4V
9C
View
King
Laborers
Truck Spotter
$52.39
7A
4V
8Y
View
King
Laborers
Tugger Operator
$53.35
7A
4V
8Y
View
King
Laborers
Tunnel Work -Compressed Air Worker 0-30 psi
$129.67
7A
4V
9B
View
King Laborers
Tunnel Work -Compressed Air Worker 30.01-44.00 psi
$134.70
7A
4V
9B
View
_
King Laborers
Tunnel Work -Compressed Air Worker 44.01-54.00 psi
$138.38
ZA
4Y
9B
View
King Laborers
Tunnel Work -Compressed Air Worker 54.01-60.00 psi
$144.08
7A
4V
9B
View
King Laborers
Tunnel Work -Compressed Air Worker 60.01-64.00 psi
$146.20
7A
4V
9B
View
King Laborers
Tunnel Work -Compressed Air Worker 64.01-68.00 psi
$151.30
7A
4V
9B
View
King Laborers
Tunnel Work -Compressed Air Worker 68.01-70.00 psi
$153.20
7A
4V
9B
View
King Laborers Tunnel Work -Compressed Air Worker 70.01-72.00 psi
King Laborers Tunnel Work -Compressed Air Worker 72.01-74.00 psi
King Laborers Tunnel Work-Guage and Lock Tender
King Laborers Tunnel Work -Miner
King Laborers Vibrator
King Laborers Vinyl Seamer
King Laborers Watchman
King Laborers Welder
King Laborers Well Point Laborer
King Laborers Window Washer/Cleaner
King Laborers - Underground Sewer Ft Water General Laborer Ft Topman
King Laborers - Underground Sewer Ft Water Pipe Layer
King Landscape Construction Landscape Construction/Landscaping Or Planting Laborers
King Landscape Construction Landscape Operator
King Landscape Maintenance Groundskeeper
King Lathers Journey Level
King Marble Setters Journey Level
King Metal Fabrication (In Shop). Journey Level
King Millwright Journey Level
King Modular Buildings Cabinet Assembly
King Modular Buildings Electrician
King Modular Buildings Equipment Maintenance
King Modular Buildings Plumber
King Modular Buildings Production Worker
King Modular Buildings Tool Maintenance
King Modular Buildings Utility Person
King Modular Buildings Welder
King Painters Journey Level
King Pile Driver Crew Tender
King Pile Driver Crew Tender/Technician
King Pile Driver Hyperbaric Worker - Compressed Air Worker 0-30.00 PSI
$155.20
ZA
4Y
91
View
$157.20
7A
4V
9B
View
$54.11
7A
4V
8Y
View
$54.11
7A
7A
YA
7A
7A
7A
4V
SY
View
$53.351
4V
8Y
View
$52.39
4Y
flY
View
$40.36
4V
BY
View
$53.35
4V
8Y
View
$53.35
4V
8Y
View
$40.36
7A
4V
8Y
View
$52.39
7A
4V
8Y
View
$53.35
IA
4Y
a
Yi=
$40.36
7A
4V
By
View
$72.28
7A
3K
8X
View
1 $17.871
1
View
$64.94
SO
1H
View
$60.57
7F
1M
Yi=
$41.70
15F
11A
View
$66.44
7A
4C
View
$13.69
1
View
$13.69
1
View
$13.69
1
Yi=
$13.691
1
View
$13.69
1
View
$13.69
1
View
$13.69
1
View
$13.69
1
View
$45.40
a
2@
Yi=
$69.91
7A
4C
View
$69.91
7A
4C
View
$80.76
7A
4C
View
King
Pile Driver
Hyperbaric Worker - Compressed Air Worker 30.01 - 44.00 PSI
$85.76
$89.76
7A
ZA
4C
q1
View
Yi=
King
Pile Driver
Hyperbaric Worker - Compressed Air Worker 44.01 - 54.00 PSI
King
Pile Driver
Hyperbaric Worker - Compressed Air Worker 54.01 - 60.00 PSI
$94.76
$97.26
7A
7A
4C
4C
View
View
King
Pile Driver
Hyperbaric Worker - Compressed Air Worker 60.01 - 64.00 PSI
King
Pile Driver
Hyperbaric Worker - Compressed Air Worker 64.01 - 68.00 PSI
Hyperbaric Worker - Compressed Air Worker 68.01 - 70.00 PSI
$102.26
$104.26
7A
7A
ZA
7A
4C
4C
q1
4C
View
View
Yi=
View
King
Pile Driver
King Pile Driver
King Pile Driver
King Pile Driver
King Plasterers
King Playground 8 Park Equipment Installers
King Plumbers 8 Pipefitters
King Power EopjpmeDLQoerators
King Power Equipment Operators
King Power Equipment Operators
King Power Equipment Operators
King Power Equipment Operators
King Power Eogji2mentSnerators
King Power Equipment Operators
King Power Equipment Operators
King Power Equipment Operators
King Power Equipment Operators
King Power Eopji2ment Operators
Hyperbaric Worker - Compressed Air Worker 70.01 - 72.00 PSI
$106.261
Hyperbaric Worker - Compressed Air Worker 72.01 - 74.00 PSI
$108.26
Journey Level
$65.19
7A
4C
View
Journey Level
$61.67
ZQ
111
View
Journey Level
$13.69
1
View
Journey Level
$92.19
6Z 1G
ZA M
7A 3K
7A 3K
7A 3K
7A 3K
ZA 3K
7A 3K
7A 3K
7A 3K
View
Asphalt Plant Operators
$73.49
$Z
Yi=
Assistant Engineer
$69.12
BX
View
Barrier Machine (zipper) $72.84
Batch Plant Operator: concrete $72.84
Bobcat $69.12
8X
View
8X
View
8X
View
Brokk - Remote Demolition Equipment $69.12
Brooms $69.12
Bump Cutter $72.84
Cableways $73.49
Chipper $72.84
Compressor 569.12
BIX
view
BX
View
8X
View
8X
View
View
view
7A
3K
8X
jA
3K
$X
King
Power Equipment Operators
Concrete Finish Machine - Laser Screed
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Concrete Pump - Mounted Or Trailer High Pressure Line Pump,
$72.28
7A
3K
8X
View
Pump High Pressure
King
Power Eagjument Operators
Concrete Pump: Truck Haunt With Boom Attachment Over 42 M
$73.49
View
King
Power Equipment Operators
Concrete Pump: Truck Mount With Boom Attachment Up To 42m
$72.84
7A
3K
BX
View
King
(Power Equipment Operators
Conveyors
$72.28
7A
3K
8X
View
King
Power Equipment Operators
Cranes friction: 200 tons and over
$75.72
7A
3K
8X
View
King
Power Equipment Operators
Cranes: 100 tons through 199 tons, or 150' of boom (including jib
$74.22
7A
3K
8X
View
with attachments)
King
Power Eagjpment Operators
Cranes: 20 Tons Through 44 Tons With Attachments
$72.84
ZA
E
2Z
view
King
Power Equipment Operators
Cranes: 200 tons- 299 tom, or 25U of boom including jib with
$74.99
7A
3K
BX
View
attachments
King
Power Equipment Operators
Cranes: 300 tons and over or 300' of boom including jib with
$75.72
7A
3K
8X
View
attachments
King
Power Equipment Operators
Cranes: 45 Tons Through 99 Tons, Under 150' Of Boom (including Jib
$73.49
7A
3K
8X
View
With Attachments)
King
Power Equipment Operators
Cranes: A -frame - 10 Tons And Under
$69.12
7A
3K
8X
View
King
Power Eayjpment Operators
Cranes: Friction cranes through 199 tons
$74.991
view
King
Power Equipment Operators
Cranes: through 19 tons with attachments, A -frame over 10 tons
$72.28
7A
3K
BX
View
King
Power Equipment Operators
Crusher
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Deck Engineer/Deck Winches (power)
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Derricks, On Building Work
$73.491
7A
3K
8X
View
King
Power Equipment Operators
Dozers D-9 Ft Under
$72.28
7A
3K
8X
View
King
Power EaUjpment Operators
Drill Oilers: Auger Type, Truck Or Crane Mount
$72.28
ZA
M
BZ
Yi=
King
Power Equipment Operators
Drilling Machine
$74.22
7A
3K
BX
View
King
Power Equipment Operators
Elevator And Man -lift: Permanent And Shaft Type
$69.12
7A
1K
8X
View
King
Power Equipment Operators
Finishing Machine, Bidwell And Gamaco & Similar Equipment
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Forklift: 3000 Lbs And Over With Attachments
$72.28
7A
3K
8X
View
King
Power Esnumn€Dt-Operators
Forklifts: Under 3000 Lbs. With Attachments
$69.12
ZA
3K
M
View
King
Power Equipment Operators
Grade Engineer: Using Blue Prints, Cut Sheets, Etc
$72.84
7A
3K
BX
View
King
Power Equipment Operators
Gradechecker/Stakeman
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Guardrail Punch
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Hard Tail End Dump Articulating Off- Road Equipment 45 Yards. Et
$73.49
7A
3K
8X
View
Over
King
Power E9Uji2ment QD€LdL4CS
Hard Tail End Dump Articulating Off -road Equipment Under 45
$72.84
jg
3K
$iS
view
Yards
King
Power Equipment Operators
Horizontal/Directional Drill Locator
$72.28
7A
3K
BX
View
King
Power Equipment Operators
Horizontal/Directional Drill Operator
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Hydralifts/Boom Trucks Over 10 Tons
$72.28
7A
3K
8X
View
King
Power Equipment Operators
Hydralifts/Boom Trucks, 10 Tons And Under
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Loader, Overhead 8 Yards. F[ Over
$74.22
7A
3K
8X
View
King
Power E9Uji2me¢L4R€LdL4CS
Loader, Overhead, 6 Yards. But Not Including 8 Yards
$73.49
ZA
3K
BX
Yi=
King
Power Equipment Operators
Loaders, Overhead Under 6 Yards
$72.84
7A
3K
BX
View
King
Power Equipment Operators
Loaders, Plant Feed
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Loaders: Elevating Type Belt
$72.28
7A
3K
8X
View
King
Power Equipment Operators
Locomotives, All
$72.84
7A
3K
8X
View
King
Power ESIUji2meGS-4Perators
Material Transfer Device
$72.84
ZA
3K
BIX
Yi=
King
Power Equipment Operators
Mechanics, All (leadmen - $0.50 Per Hour Over Mechanic)
$74.22
7A
3K
BX
View
King
Power Equipment Operators
Motor Patrol Graders
$73.49
7A
3K
8X
View
King
Equipment Operators
Mucking Machine, Mole, Tunnel Drill, Boring, Road Header And/or
$73.49
7A
3K
8X
View
(Power
Shield
King
Power Equipment Operators
Oil Distributors, Blower Distribution & Mulch Seeding Operator
$69.12
7A
3K
8X
View
King
Power E9Uji2meIIL4D€LdL4CS
Outside Hoists (Elevators And Manlifts), Air Tuggers, Strato
$72.28
YA
3K
M
Yi=
King
Power Equipment Operators
Overhead, Bridge Type Crane: 20 Tons Through 44 Tons
$72.84
7A
3K
BX
View
King
Power Equipment Operators
Overhead, Bridge Type: 100 Tons And Over
$74.22
7A
3K
8X
View
King
Power Equipment Operators
Overhead, Bridge Type: 45 Tons Through 99 Tons
$73.49
7A
3K
8X
View
King
Power Equipment Operators
Pavement Breaker
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Pile Driver (other Than Crane Mount)
$72.84
7A
3K
8X
View
King
Power ESIUji2ment4perators
Plant Oiler - Asphalt, Crusher
$72.28
ZA
ali
BX
Yi=
King
Power Equipment Operators
Posthole Digger, Mechanical
$69.12
7A
3K
BX
View
King
Power Equipment Operators
Power Plant
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Pumps - Water
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Quad 9, Hd 41, D10 And Over
$73.49
7A
3K
8X
View
King
Power EUUji2ment4perators
Quick Tower - No Cab, Under 100 Feet In Height Based To Boom
$69.12
ZA
A
BIX
Yi=
King
Power Equipment Operators
Remote Control Operator On Rubber Tired Earth Moving Equipment
$73.49
7A
3K
8X
View
King
Power Equipment Operators
Rigger and Bellman
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Rigger/Signal Person, BeUman (Certified)
$72.28
7A
3K
8X
View
King
Power Equipment Operators
Rollagon
$73.49
7A
3K
8X
View
King
PJ�rtex-EsIUji2ment Operators
Roller, Other Than Plant Mix
$69.12
ZA
3K
M
view
King
Power Equipment Operators
Roller, Plant Mix Or Multi -lift Materials
$72.28
7A
3K
BX
View
King
Power Equipment Operators
Roto-mill, Roto-grinder
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Saws - Concrete
$72.28
7A
3K
8X
View
King
Power Equipment Operators
Scraper, Self Propelled Under 45 Yards
$72.84
7A
3K
8X
View
King
Power Equipment Operators
Scrapers - Concrete F[ Carry All
$72.28
7A
3K
8X
View
King
Power -EUUji2ment 0ReLslLotS
Scrapers, Self-propelled: 45 Yards And Over
$73.49
ZA
3K
BIX
Yi=
King
Power Equipment Operators
Service Engineers - Equipment
$72.28
7A
3K
BX
View
King
Power Equipment Operators
Shotcrete/Gunite Equipment
$69.12
7A
3K
8X
View
King
Power Equipment Operators
Shovel, Excavator, Backhoe, Tractors Under 15 Metric Tons
$72.28
7A
3K
8X
View
King
Power Equipment Operators
Shovel, Excavator, Backhoe: Over 30 Metric Tons To 50 Metric Tons
$73.49
7A
3K
8X
View
King
Power EpUji2me.DS-4Perators
Shovel, Excavator, Backhoes, Tractors: 15 To 30 Metric Tons
$72.84
ZA
3K
BIX
Yi=
King
Power Equipment Operators
Shovel, Excavator, Backhoes: Over 50 Metric Tom To 90 Metric Tons
$74.22
7A
3K
BX
View
King
Power Equipment Operators
Shovel, Excavator, Backhoes: Over 90 Metric Tom
$74.99
7A
3K
8X
View
King
Power Equipment Operators
Slipform Pavers
$73.49
7A
3K
8X
View
King
Power Equipment Operators
Spreader, Topsider F[ Screedman
$73.49
7A
3K
8X
View
King
Power EpUJ12ment-Operators
Subgrader Trimmer
$72.84
ZA
3K
BK
Yi=
King
Power Equipment Operators
Tower Bucket Elevators
$72.28
7A
3K
BX
View
King
Power Equipment Operators
Tower Crane Up To 175' In Height Base To Boom
$74.22
7A
3K
8X
View
King
Power Equipment Operators
Tower Crane: over 175through 259 in height, base to boom
$74.99
7A
3K
8X
View
King
Power Equipment Operators
Tower Cranes: over 25Y in height from base to boom
$75.72
7A
3K
8X
View
King
Power Equipment Operators
Transporters, All Track Or Truck Type
$73.49
7A
3K
8X
View
King
Power EpU1R113e.¢S-Operators
Trenching Machines
$72.28
ZA
3K
$iS
Y.i=
King
Power Equipment Operators
Truck Crane Oiler/driver - 100 Tons And Over
$72.84
7A
3K
BX
View
King
Power Equipment Operators
Truck Crane Oiler/Driver Under 100 Tons
$72.28
7A
3K
8X
View
King
Power Equipment Operators
Truck Mount Portable Conveyor
$72.84
7A
3K
8X
View
King
,Power Equipment Operators
Welder
$73.49
7A
3K
8X
View
King
King
King
King
Power Equipment Operators
Wheel Tractors, Farmall Type
_
Power Equipment Operators
Yo Yo Pay Dozer
_
Power Eagjument Ouerators- Underground Sewer & Water
Asphalt Plant Operators
Power Equipment Operators- Underground Sewer It Water
Assistant Engineer
Power Equipment Operators- Underground Sewer It Water
Barrier Machine (zipper)
Power Equipment Operators- Underground Sewer & Water
Batch Plant Operator, Concrete
Power Equipment Operators- Underground Sewer Et Water
Bobcat
Power EaUjument Ouerators-Underground Sewer 8 Water
Brokk - Remote Demolition Equipment
Power Equipment Operators- Underground Sewer Ft Water
Brooms
Power Equipment Operators- Underground Sewer It Water
Bump Cutter
Power Equipment Operators- Underground Sewer It Water
Cableways
Power Equipment Operators- Underground Sewer & Water
Chipper
Power EaUjument Ouerators- Underground Sewer 8 Water
Compressor
Power Equipment Operators- Underground Sewer Ft Water
Concrete Finish Machine - Laser Screed
Power Equipment Operators- Underground Sewer ft Water
Concrete Pump - Mounted Or Trailer High Pressure Line Pump,
Pump High Pressure
Power Equipment Operators- Underground Sewer & Water
Concrete Pump: Truck Mount With Boom Attachment Over 42 M
Power Equipment Operators- Underground Sewer & Water
Concrete Pump: Truck Mount With Boom Attachment Up To 42m
Power Equipment Operators- Underground Sewer & Water
Conveyors
Power EaUjument Ouerators- Underground Sewer & Water
Cranes friction: 200 tons and over
Power Equipment Operators- Underground Sewer & Water
Cranes: 100 tons through 199 tons, or 150' of boom (including jib
with attachments)
Power Equipment Operators- Underground Sewer It Water
Cranes: 20 Tons Through 44 Tons With Attachments
Power Equipment Operators- Underground Sewer & Water
Cranes: 200 tons- 299 tons, or 25Y of boom including jib with
attachments
Power Equipment Operators- Underground Sewer & Water
Cranes: 300 tons and over or 300' of boom including jib with
attachments
_
Power EaUjument Ouerators- Underground Sewer it Water
Cranes: 45 Tons Through 99 Tons, Under 150 Of Boom (including J
_
With Attachments)
Power Equipment Operators- Underground Sewer Ft Water
Cranes: A -frame - 10 Tons And Under
Power Equipment Operators- Underground Sewer It Water
Cranes: Friction cranes through 199 tons
Power Equipment Operators- Underground Sewer & Water
Cranes: through 19 tons with attachments, A -frame over 10 tons
Power Equipment Operators- Underground Sewer & Water
Crusher
Power EaUjument Ouerators- Underground Sewer 8 Water
Deck Engineer/Deck Winches (power)
Power Equipment Operators- Underground Sewer Ft Water
Derricks, On Building Work
Power Equipment Operators- Underground Sewer ft Water
Dozers D-9 & Under
Power Equipment Operators- Underground Sewer & Water
Drill Oilers: Auger Type, Truck Or Crane Mount
Power Equipment Operators- Underground Sewer & Water
Drilling Machine
Power Equipment Operators- Underground Sewer Et Water
Elevator And Man -lift: Permanent And Shaft Type
Power EaUjument Operators- Underground Sewer & Water
Finishing Machine, Bidwell And Gamaco 8 Similar Equipment
Power Equipment Operators- Underground Sewer ft Water
Forklift: 3000 Lbs And Over With Attachments
Power Equipment Operators- Underground Sewer It Water
Forklifts: Under 3000 Lbs. With Attachments
Power Equipment Operators- Underground Sewer & Water
Grade Engineer: Using Blue Prints, Cut Sheets, Etc
Power Equipment Operators- Underground Sewer & Water
Gradechecker/Stakeman
Power EaUjper ment Opators- Underground Sewer 8 Water
Guardrail Punch
Power Equipment Operators- Underground Sewer Ft Water
Hard Tail End Dump Articulating Off- Road Equipment 45 Yards. 8
Over
Power Equipment Operators- Underground Sewer & Water
Hard Tail End Dump Articulating Off -road Equipment Under 45
Yards
Power Equipment Operators- Underground Sewer Et Water
Horizontal/Directional Drill Locator
Power Equipment Operators- Underground Sewer & Water
Horizontal/Directional Drill Operator
Power EaUjpment Operators- Underground Sewer 8 Water
Hydralifts/Boom Trucks Over 10 Tons
Power Equipment Operators- Underground Sewer Ft Water
Hydralifts/Boom Trucks, 10 Tons And Under
Power Equipment Operators- Underground Sewer ft Water
Loader, Overhead 8 Yards. It Over
Power Equipment Operators- Underground Sewer & Water
Loader, Overhead, 6 Yards. But Not Including 8 Yards
Power Equipment Operators- Underground Sewer & Water
Loaders, Overhead Under 6 Yards
Power Equipment Operators- Underground Sewer Et
Loaders, Plant Feed
Power EaUjument Operators -Underground Sewer it Water
Loaders: Elevating Type Belt
Power Equipment Operators- Underground Sewer ft Water
Locomotives, All
Power Equipment Operators- Underground Sewer & Water
Material Transfer Device
Power Equipment Operators- Underground Sewer & Water
Mechanics, All (leadmen - $0.50 Per Hour Over Mechanic)
Power Equipment Operators- Underground Sewer & Water
Motor Patrol Graders
Power EaUjument Ouerators-Underground Sewer 8 Water
Mucking Machine, Mole, Tunnel Drill, Boring, Road Header And/or
Shield
_
Power Equipment Operators- Underground Sewer & Water
_
Oil Distributors, Blower Distribution & Mulch Seeding Operator
Power Equipment Operators- Underground Sewer Ft Water
Outside Hoists (Elevators And Manlifts), Air Tuggers, Strato
Power Equipment Operators- Underground Sewer & Water
Overhead, Bridge Type Crane: 20 Tons Through 44 Tons
Power Equipment Operators- Underground Sewer & Water
Overhead, Bridge Type: 100 Tons And Over
Power EoUjument Onerators-Underground Sewer 8 Water
Overhead, Bridge Type: 45 Tons Through 99 Tons
Power Equipment Operators- Underground Sewer it Water
Pavement Breaker
Power Equipment Operators- Underground Sewer 8: Water
Pile Driver (other Than Crane Mount)
Power Equipment Operators- Underground Sewer & Water
Plant Oiler - Asphalt, Crusher
Power Equipment Operators- Underground Sewer & Water
Posthole Digger, Mechanical
Power Equipment Operators- Underground Sewer & Water
Power Plant
Power EaUjument Ouerators-Underground Sewer &Water
Pumps - Water
Power Equipment Operators- Underground Sewer ft Water
Quad 9, Hd 41, D10 And Over
Power Equipment Operators- Underground Sewer Ft Water
Quick Tower - No Cab, Under 100 Feet In Height Based To Boom
Power Equipment Operators- Underground Sewer & Water
Remote Control Operator On Rubber Tired Earth Moving Equipment
Power Equipment Operators- Underground Sewer & Water
Rigger and Bellman
Power EaUjument Ouerators-Underground Sewer 8 Water
Rigger/Signal Person, Bellman (Certified)
Power Equipment Operators- Underground Sewer Ft Water
Rollagon
Power Equipment Operators- Underground Sewer It Water
Roller, Other Than Plant Mix
Power Equipment Operators- Underground Sewer & Water
Roller, Plant Mix Or Multi -lift Materials
Power Equipment Operators- Underground Sewer & Water
Roto-mill, Roto-grinder _
Power EaUjument Ouerators-Underground Sewer 8 Water
Saws - Concrete
Power Equipment Operators- Underground Sewer Ft Water
Scraper, Self Propelled Under 45 Yards
Power Equipment Operators- Underground Sewer ft Water
Scrapers - Concrete Ft Carry All
Power Equipment Operators- Underground Sewer & Water
Scrapers, Self-propelled: 45 Yards And Over
Power Equipment Operators- Underground Sewer & Water
Service Engineers - Equipment
Power Equipment Operators- Underground Sewer & Water
Shotcrete/Gunite Equipment
Power EaUjument Ouerators-Underground Sewer 8 Water
Shovel, Excavator, Backhoe, Tractors Under 15 Metric Tons
Power Equipment Operators- Underground Sewer & Water
Shovel, Excavator, Backhoe: Over 30 Metric Tons To 50 Metric Tons
Power Equipment Operators- Underground Sewer It Water
Shovel, Excavator, Backhoes, Tractors: 15 To 30 Metric Tons
Power Equipment Operators- Underground Sewer & Water
Shovel, Excavator, Backhoes: Over 50 Metric Toro To 90 Metric Tons
Power Equipment Operators- Underground Sewer & Water
Shovel, Excavator, Backhoes: Over 90 Metric Tons
$69.12
7A
3K
$72.84
7A
3K
$73.49
ZA
3K
$69.12
7A
3K
$72.84
7A
3K
$72.84
7A
3K
$69.12
7A
3K
$69.12
ZA
I 3K
$69.12
7A
3K
$72.84
7A
3K
$73.49
7A
3K
$72.84
7A
3K
$69.12
ZA
3K
$69.12
7A
3K
$72.28
7A
3K
$73.49
7A
3K
$72.84
7A
3K
$72.28
7A
3K
$75.72
ZA
3K
$74.22
7A
3K
$72.84
7A
3K
$74.99
7A
3K
$75.72
7A
3K
$73.49
ZA
3K
$69.12
7A
3K
$74.99
7A
3K
$72.28
7A
3K
$72.84 7A 3K
$72.84 ZA 3K
$73.49 7A 3K
$72.28 7A 3K
$72.28 7A 3K
$74.22 7A 3K
$69.12 7A 3K
$72.84 ZA 3K
$72.28 7A 3K
$69.12 7A 3K
$72.84 7A 3K
$69.12 7A 3K
$72.84 ZA 3K
$73.49 7A 3K
$72.84 7A 3K
$72.28
7A
3K
$72.84
7A
3K
$72.28
ZA
3K
$69.121
7A
3K
BX I View
BX I View
BX
8X
8X
8X
8X
$if
BX
8X
8X
8X
BX
8X
8X
8X
View
View
View
View
View
View
View
View
View
View
view
View
View
View
View
8X iView
8X View
8X
8X
8X
$X
BX
8X
8X
8X
$72.84
7A
3K 8X
3K M
3K 8X
3K 8X
3K 8X
3K 8X
3K n
3K 8X
3K 8X
$72.28
ZA
$72.84
7A
$72.84
7A
$74.22
7A
$73.49
7A
$73.49
ZA
$69.12
7A
$72.28
7A
$72.841
7A
3K
1 8X
$72.84
7A 3K
7A 3K
8X
$72.28
8X
$69.12
7A
3K
8X
$69.12
7A
3K
8X
$69.12
ZA
3K
BX
$73.49
7A
3K
8X
$69.12
7A
3K
8X
$73.49
7A
3K
8X
$69.12
7A
3K
8X
$72.28
ZA
3K
BLS
$73.49
7A
3K
BX
$69.12
7A
3K
8X
$72.84 7A
$72.28 7A
$73.49 7A
$72.28 7A
$69.12 7A
$72.28 ZA
3K
3K
3K
3K
3K
3K
BX
8X
8X
8X
8X
BX
View
View
View
view
View
View
View
View
view
View
View
View
View
View
view
view
View
View
View
View
view
View
View
View
View
View
View
View
View
View
View
view
View
View
View
View
view
View
View
View
View
View
View
King Power Equipment Operators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer Et
King Power Eag.12ment OWcLators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer It Water
King Power Equipment Operators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer & Water
King Power Eagji2ment OWCLators- Underground Sewer 8 Water
King Power Equipment Operators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer & Water
King Power Eayjplp�pt-Querators-Underground Sewer &Water
King Power Equipment Operators- Underground Sewer & Water
King Power Equipment Operators- Underground Sewer & Water
King Power Line Clearance Tree Trimmers
King Power Line Clearance Tree Trimmers
King Power Line Clearance Tree Trimmers
King Power Line Clearance Tree Trimmers
King Power Line Clearance Tree Trimmers
King Refrigeration & Air Conditioning Mechanics
King Residential Brick Mason
King Residential Carpenters
King Residential Cement Masons
King Residential Drywall Applicators
King Residential Drywall Tapers
King Residential Electricians
King Residential Glaziers
King Residential Insulation Applicators
King Residential Laborers
King Residential Marble Setters
King Residential Painters
King Residential Plumbers & Pipefitters
King _ Residential Refrigeration Etni Air Conditiong Mechanics
King Residential sheet Metal Workers
King Residential Soft Floor Layers
King Residential Sprinkler Fitters (Fire Protection)
King Residential Stone Masons
King Residential Terrauo Workers
King Residential Terrazzo/Tile Finishers
King Residential Tile Setters
King Roofers
Slipform Pavers
Spreader, Topsider Ft Screedman
$73.49
$73.49
7A 3K
7A 3K
ZA M
7A 3K
7A 3K
7A 3K
7A 3K
ZA 2K
7A 3K
7A 3K
7A 3K
8X
8X
ii
BX
8X
8X
8X
BX
BX
8X
8X
View
View
yj�sy
View
View
View
View
Yi=
View
View
View
Subgrader Trimmer
$72.84
Tower Bucket Elevators
$72.28
Tower Crane Up To 175' In Height Base To Boom
Tower Crane: over 175 through 250' in height, base to boom
$74.22
$74.99
Tower Cranes: over 25Y in height from base to boom
Transporters, All Track Or Truck Type
Trenching Machines
Truck Crane Oiler/driver - 100 Tons And Over
Truck Crane Oiler/Driver Under 100 Tons
Truck Mount Portable Conveyor
Welder
$75.72
$73.49
$72.28
$72.84
$72.28
$72.84
$73.49
7A
3K
8X
View
ZA
2K
M
view
Wheel Tractors, Farmall Type
$69.12
7A
3K
BX
View
Yo Yo Pay Dozer
$72.84
7A 3K 8X View
SA 4A View
5A 4A View
5A 4A View
5A 4A Yi=
SA 4A View
6Z 1 G View
7E 1N View
1 View
1 Yi=
7A 4C View
1 View
1 View
1 View
J. View
1 View
1 View
1 View
6Z 1G view
6Z 1 G View
7F 1L View
5A 3J View
SC ZR View
7E I view
7E I View
1 View
1 View
Journey Level In Charge
$55.03
Spray Person
$52.24
Tree Equipment Operator
$55.03
Tree Trimmer
$49.21
Tree Trimmer Groundperson
$37.47
Journey Level
$87.01
Journey Level
$60.57
Journey Level
$36.44
Journey Level
$46.64
Journey Level
Journey Level
Journey Level
Journey Level
$64.94
$36.36
$48.80
$28.93
Journey Level
$28.18
Journey Level
$29.73
Journey Level
$27.38
Journey Level
$23.47
Journey Level
$92.19
Journey Level
$87.01
Journey Level
$89.61
Journey Level
$51.91
Journey Level
$53.04
Journey Level
$60.57
Journey Level
$55.71
Journey Level
$24.39
Journey Level
$21.04
Journey Level
$57.30
5A
3H
View
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
King
Roofers
Sheet Metal Workers
Shjpbujl4jpg_L.$lljp$epAK
Shipbuilding fc Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding EL Ship Repair
Shipbuilding Et Ship Repair
5h i2bultdi gS42Wp$epp1L
Shipbuilding Ft Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding EL Ship Repair
Shipbuilding Et Repair
5hjpbultdi gS45hp &Wk
Shipbuilding fc Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding EL Ship Repair
&Wbu ildi gSi2jp$epAk
Shipbuilding fc Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding Ft Ship Repair
5.Wpbumidi0gS45JJP-&PAk
Shipbuilding Ft Ship Repair
Shipbuilding Ft Ship Repair
Shipbuilding Et Ship Repair
Shipbuilding &Ship Repair
Sh1pbUKSa1041t.51liRBCpp1I
Shipbuilding fc Ship Repair
Sign Makers Ft Installers (Electrical),
Sign Makers Ft Installers (Non -Electrical)
Using Irritable Bituminous Materials
Journey Level (Field or Shop)
New Construction Boilermaker
New Construction Carpenter
New Construction Crane Operator
New Construction Electrician
New Construction Heat & Frost Insulator
New Construction Laborer
New Construction Machinist
New Construction Operating Engineer
New Construction Painter
New Construction Pipefitter
New Construction Rigger
New Construction Sheet Metal
New Construction Shipfitter
New Construction Warehouse/Teamster
New Construction Welder / Burner
Ship Repair Boilermaker
Ship Repair Carpenter
Ship Repair Crane Operator
Ship Repair Electrician
Ship Repair Heat Ft Frost Insulator
Ship Repair Laborer
Ship Repair Machinist
Ship Repair Operating Engineer
Ship Repair Painter
Ship Repair Pipefitter
Ship Repair Rigger
Ship Repair Sheet Metal
Ship Repair Shipwright
Ship Repair Warehouse / Teamster
Journey Level
Journey Level
$60.30
$89.61
$38.54
$38.54
$38.54
$38.54
$79.43
$38.54
$38.54
$38.54
$38.54
$38.54
$38.54
1 $38.541
$38.54
$38.54
$38.54
$47.35
$47.35
$45.06
$47.42
$79.43
$47.35
$47.35
$45.06
$47.35
$47.35
$47.35
$47.35
$47.35
$45.06
$51.56
$33.20
5A
7F
ZY
N
N
7V
5J
N
N-
7V
N
7V
7V
ZY
N
N
7V
7X
7%
7Y
7X
5J
7X
7X
ZY
7X
7X
7X
7X
71l
7Y
0
0
3H
View
1 E
View
1
1
1
1
4H
1
Yi=
View
View
View
view
View
1
View
1
View
1
View
1
View
1
View
1
Yi=
1
View
1
View
1
View
4J
View
41
Yi=
4K
View
4J
View
4H
View
4J
View
4J
View
4K
Yi=
4J
View
4J
View
4J
View
4J
View
41
Yi=
4K
View
1
View
1
View
King
King
King
King
Soft Floor Layers
Solar Controls For Windows
Sprinkler Fitters (Fire Protection),
Stage Rigging Mechanics (Non Structural).
Journey Level
$51.91
5A
3.1
View
Journey Level
$13.69
1
Yi=
Journey Level
$85.89
SC
1X
View
Journey Level
$13.69
1
View
King
King
Stone Masons
Street And Parking Lot Sweeper Workers
Journey Level
$60.57
7E
1N
View
Journey Level
$19.09
1
View
King
King
King
King
Surveyors _
.5u=y4Ci _
Surveyors
Telecommunication Technicians
Assistant Construction Site Surveyor
$72.28
7A
3K
8X
View
Chainman
$69.12
ZA
M
3K
1E
2Z
Yi=
Construction Site Surveyor
$73.49
7A
BX
View
Journey Level
$53.571
7E
View
King
King
King
King
King
King
Telephone Line Construction - Outside
Telephone Line Construction - Outside
Ipleohone Line Construction -Outride
Telephone Line Construction - Outride
Terrazzo Workers
Tile Setters
Cable Splicer
$37.40
5A
2B
2B
View
Hole Digger/Ground Person
Telephone Equipment Operator (Light)
Telephone Lineperson
Journey Level
Journey Level
Finisher
$25.04
5A
View
Yi=
View
$31.22
SA
ZE
$35.34
$55.71
$55.71
SA
2B
7E
1N
View
7E
1N
View
King
King
Tile, Marble Fc Terrazzo Finishers
Traffic Control 5tripM
$46.54
$49.131
7E
ZA
1 N
1K
View
view
Journey Level
King
Truck Drivers
King
Truck Drivers
King
_
Truck Drivers
King
Truck Drivers
King
Truck Drivers
King
Truck Drivers - Ready Mix
King
Well Drillers & Irrigation Pump Installers
King
Well Drillers FtIrrigation Pumn Installers
King
Well Drillers it Irrigation Pump Installers
Asphalt Mix Over 16 Yards
Asphalt Mix To 16 Yards
Dump Truck
Dump Truck & Trailer
Other Trucks
Transit Mix
Irrigation Pump Installer
Oiler
Well Driller
$64.55
5D
4Y
8L
View
$63.71
5D
4Y
8L
view
$63.71
52
4y
L
View
$64.55
5D
4Y
8L
View
$64.55
5D
4Y
8L
View
$64.55
5D
4Y
8L
view
$17.71
1
view
513.69
1
view
$18.00
1
View
Signature: Terry JuPrgm an (May 16, 2117:21 PDT)
Email: tjungman@kentwa.gov
Signature: L�-
Email: rlashley@kentwa.gov
Signature:
Brian Levenha e n(J Lin 3, 202116:29 PDT)
Email: bjlevenhagen@kentwa.gov
E-TRANSMITTAL: Agmt. for Earthworks Park
Staircase Demolition
Final Audit Report
Created: 2021-05-26
By: Lynn Osborn (losborn@kentwa.gov)
Status: Signed
Transaction ID: CBJCHBCAABAAYomdYT17Lygfp6Ygm_PbcaBmhSy1nmOQ
2021-06-10
"E-TRANSMITTAL: Agmt. for Earthworks Park Staircase Demol
ition" History
Document created by Lynn Osborn (losborn@kentwa.gov)
2021-05-26 - 5:51:20 PM GMT- IP address: 146.129.252.126
Document emailed to Terry Jungman (tjungman@kentwa.gov) for signature
2021-05-26 - 5:56:17 PM GMT
Email viewed by Terry Jungman (tjungman@kentwa.gov)
2021-05-27 - 0:21:17 AM GMT- IP address: 73.118.200.115
'a Document e-signed by Terry Jungman (tjungman@kentwa.gov)
Signature Date: 2021-05-27 - 0:21:58 AM GMT - Time Source: server- IP address: 73.118.200.115
Document emailed to Ronald Lashley (rlashley@kentwa.gov) for signature
2021-05-27 - 0:22:01 AM GMT
Email viewed by Ronald Lashley (rlashley@kentwa.gov)
2021-05-27 - 9:34:11 PM GMT- IP address: 146.129.252.126
'a Document e-signed by Ronald Lashley (rlashley@kentwa.gov)
Signature Date: 2021-05-27 - 10:56:06 PM GMT - Time Source: server- IP address: 146.129.252.126
Document emailed to Brian Levenhagen (bjlevenhagen@kentwa.gov) for signature
2021-05-27 - 10:56:09 PM GMT
Email viewed by Brian Levenhagen (bjlevenhagen@kentwa.gov)
2021-06-03 - 11:28:48 PM GMT- IP address: 146.129.252.126
Document e-signed by Brian Levenhagen (bjlevenhagen@kentwa.gov)
Signature Date: 2021-06-03 - 11:29:35 PM GMT - Time Source: server- IP address: 146.129.252.126
a Adobe Sign
Document emailed to skyler waldal (skycorpltd@yahoo.com) for signature
2021-06-03 - 11:29:38 PM GMT
Email viewed by skyler waldal (skycorpltd@yahoo.com)
2021-06-04 - 2:08:18 AM GMT- IP address: 67.170.69.239
. Document e-signed by skyler waldal (skycorpltd@yahoo.com)
Signature Date: 2021-06-10 - 5:29:27 PM GMT - Time Source: server- IP address: 67.170.69.239
Agreement completed.
2021-06-10 - 5:29:27 PM GMT
a Adobe Sign