Loading...
HomeMy WebLinkAboutCAG2021-208 - Original - Mocon Fence Contractors - Holding Pond Fence & Gate Repair - 04/22/2021ApprovalOriginator:Department: Date Sent:Date Required: Authorized to Sign: Director or Designee Mayor Date of Council Approval: Grant? Yes No Type:Review/Signatures/RoutingDate Received by City Attorney: Comments: Date Routed to the Mayor’s Office: Date Routed to the City Clerk’s Office:Agreement InformationVendor Name:Category: Vendor Number:Sub-Category: Project Name: Project Details: Agreement Amount: Start Date: Basis for Selection of Contractor: Termination Date: Local Business? Yes No* Business License Verification: Yes In-Process Exempt (KCC 5.01.045) If meets requirements per KCC 3.70.100, please complete “Vendor Purchase-Local Exceptions” form on Cityspace. Notice required prior to disclosure? Yes No Contract Number: Agreement Routing Form For Approvals, Signatures and Records Management This form combines & replaces the Request for Mayor’s Signature and Contract Cover Sheet forms. (Print on pink or cherry colored paper) Visit Documents.KentWA.gov to obtain copies of all agreementsadccW22373_1_20 Budget Account Number: Budget? Yes No Dir Asst: Sup/Mgr: Dir/Dep: rev. 200821 FOR CITY OF KENT OFFICIAL USE ONLY (Optional) * Memo to Mayor must be attached CAG2021-208 PUBLIC WORKS AGREEMENT - 1 ($20K or Less and No Performance Bond) PUBLIC WORKS AGREEMENT between City of Kent and Moriarty Enterprises, LLC D.B.A. Mocon Fence Contractors THIS AGREEMENT is made by and between the City of Kent, a Washington municipal corporation (hereinafter the "City"), and Moriarty Enterprises, LLC D.B.A. Mocon Fence Contractors organized under the laws of the State of Washington, located and doing business at 12510 SE Petrovitsky Road, Renton, WA 98058-6706, Phone: (425) 228-2296, Contact: Michael Moriarty (hereinafter the "Contractor"). AGREEMENT The parties agree as follows: I. DESCRIPTION OF WORK. The Contractor shall perform the following services for the City in accordance with the following described plans and/or specifications: The Contractor shall repair holding pond fencing and gate which is located on the west side of 14233 SE 272nd Street. For a description, see the Scope of Work and Contractor's proposal which is attached as Exhibit A and incorporated by this reference. The Contractor further represents that the services furnished under this Agreement will be performed in accordance with generally accepted professional practices within the Puget Sound region in effect at the time such services are performed. II. TIME OF COMPLETION. The parties agree that work will begin on the tasks described in Section I above within 5 business days after the City issues its Notice to Proceed. Upon the effective date of this Agreement, all physical work shall thereafter be completed within 30 days. The term of this Agreement shall continue until all work has been completed, final acceptance has occurred, and all Contractor obligations have been fulfilled. III. COMPENSATION. The City shall pay the Contractor a total amount not to exceed Two Thousand, Nine Hundred Sixteen Dollars and Fifty Five Cents ($2,916.55), including any applicable Washington State Sales Tax, for the work and services contemplated in this Agreement. The City shall pay the Contractor eighty-five percent (85%) of the Contract amount upon completion and acceptance of the work by the City, or at such earlier time as the City may determine is appropriate. The City will pay the remaining Contract amount upon fulfillment of the conditions listed below and throughout this Agreement. Card Payment Program. The Contractor may elect to participate in automated credit card payments provided for by the City and its financial institution. This Program is provided as an alternative to payment by check and is available for the convenience of the Contractor. If the Contractor voluntarily participates in this Program, the Contractor will be solely responsible for any fees imposed by financial institutions or credit card companies. The Contractor shall not charge those fees back to the City. PUBLIC WORKS AGREEMENT - 2 ($20K or Less and No Performance Bond) A. No Payment and Performance Bond. Because this contract, including applicable sales tax, is $150,000 or less, and pursuant to Chapter 39.08 RCW, the Contractor, in lieu of providing the City a payment and performance bond, has elected to have the City retain the final ten percent (10%) of the Contract amount for a period of thirty (30) days after the date of final acceptance, or until receipt of all necessary releases from the State Department of Revenue, the State Department of Labor & Industries, and the State Employment Security Department, and until settlement of any liens filed under Chapter 60.28 RCW, whichever is later. B. Retainage. The City shall also hold back a retainage in the amount of five percent (5%) of any and all payments made to the Contractor for a period of sixty (60) days after the date of final acceptance, or until receipt of all necessary releases from the State Department of Revenue, the State Department of Labor & Industries, and the State Employment Security Department, and until settlement of any liens filed under Chapter 60.28 RCW, whichever is later. The amount retained shall be placed in a fund by the City pursuant to RCW 60.28.011(4)(a), unless otherwise instructed by the Contractor within fourteen (14) calendar days of the Contractor’s signature on the Agreement. C. Defective or Unauthorized Work. The City reserves its right to withhold payment from the Contractor for any defective or unauthorized work. Defective or unauthorized work includes, without limitation: work and materials that do not conform to the requirements of this Agreement; and extra work and materials furnished without the City’s written approval. If the Contractor is unable, for any reason, to satisfactorily complete any portion of the work, the City may complete the work by contract or otherwise, and the Contractor shall be liable to the City for any additional costs incurred by the City. “Additional costs” shall mean all reasonable costs, including legal costs and attorney fees, incurred by the City beyond the maximum Contract price specified above. The City further reserves its right to deduct the cost to complete the Contract work, including any Additional Costs, from any and all amounts due or to become due the Contractor. D. Final Payment: Waiver of Claims. THE CONTRACTOR’S ACCEPTANCE OF FINAL PAYMENT (EXCLUDING WITHHELD RETAINAGE) SHALL CONSTITUTE A WAIVER OF CONTRACTOR’S CLAIMS, EXCEPT THOSE PREVIOUSLY AND PROPERLY MADE AND IDENTIFIED BY CONTRACTOR AS UNSETTLED AT THE TIME FINAL PAYMENT IS MADE AND ACCEPTED. IV. INDEPENDENT CONTRACTOR. The parties intend that an Independent Contractor- Employer Relationship will be created by this Agreement. By their execution of this Agreement, and in accordance with Ch. 51.08 RCW, the parties make the following representations: A. The Contractor has the ability to control and direct the performance and details of its work, the City being interested only in the results obtained under this Agreement. B. The Contractor maintains and pays for its own place of business from which the Contractor’s services under this Agreement will be performed. C. The Contractor has an established and independent business that is eligible for a business deduction for federal income tax purposes that existed before the City retained the Contractor’s services and is a service other than that furnished by the City, or the Contractor is engaged in an independently established trade, occupation, profession, or business of the same nature as that involved under this Agreement. D. The Contractor is responsible for filing as they become due all necessary tax documents with appropriate federal and state agencies, including the Internal Revenue Service and the state Department of Revenue. PUBLIC WORKS AGREEMENT - 3 ($20K or Less and No Performance Bond) E. The Contractor has registered its business and established an account with the state Department of Revenue and other state agencies as may be required by the Contractor’s business, and has obtained a Unified Business Identifier (UBI) number from the State of Washington. F. The Contractor has a valid contractor registration pursuant to Ch. 18.27 RCW or an electrical contractor license pursuant to Ch. 19.28 RCW. G. The Contractor maintains a set of books dedicated to the expenses and earnings of its business. V. TERMINATION. The City may terminate this Agreement for good cause. “Good cause” shall include, without limitation, any one or more of the following events: A. The Contractor’s refusal or failure to supply a sufficient number of properly skilled workers or proper materials for completion of the Contract work. B. The Contractor’s failure to complete the work within the time specified in this Agreement. C. The Contractor’s failure to make full and prompt payment to subcontractors or for material or labor. D. The Contractor’s persistent disregard of federal, state or local laws, rules or regulations. E. The Contractor’s filing for bankruptcy or becoming adjudged bankrupt. F. The Contractor’s breach of any portion of this Agreement. If the City terminates this Agreement for good cause, the Contractor shall not receive any further money due under this Agreement until the Contract work is completed. After termination, the City may take possession of all records and data within the Contractor’s possession pertaining to this project which may be used by the City without restriction. VI. PREVAILING WAGES. The Contractor shall file a “Statement of Intent to Pay Prevailing Wages,” with the State of Washington Department of Labor & Industries prior to commencing the Contract work. The Contractor shall pay prevailing wages in effect on the date the bid is accepted or executed by the Contractor, and comply with Chapter 39.12 of the Revised Code of Washington, as well as any other applicable prevailing wage rate provisions. The latest prevailing wage rate revision issued by the Department of Labor and Industries is attached. VII. CHANGES. The City may issue a written change order for any change in the Contract work during the performance of this Agreement. If the Contractor determines, for any reason, that a change order is necessary, the Contractor must submit a written change order request to the person listed in the notice provision section of this Agreement, Section XVI(D), within fourteen (14) calendar days of the date the Contractor knew or should have known of the facts and events giving rise to the requested change. If the City determines that the change increases or decreases the Contractor's costs or time for performance, the City will make an equitable adjustment. The City will attempt, in good faith, to reach agreement with the Contractor on all equitable adjustments. However, if the parties are unable to agree, the City will determine the equitable adjustment as it deems appropriate. The Contractor shall proceed with the change order work upon receiving either a written change order from the City or an oral order from the City before actually receiving the written change order. If the Contractor fails to require a change order within the time specified in this paragraph, the Contractor waives its right to make any claim or submit subsequent change order requests for that portion of the contract work. If the Contractor disagrees with the equitable adjustment, the Contractor must complete the change order work; however, PUBLIC WORKS AGREEMENT - 4 ($20K or Less and No Performance Bond) the Contractor may elect to protest the adjustment as provided in subsections A through E of Section IX, Claims, below. The Contractor accepts all requirements of a change order by: (1) endorsing it, (2) writing a separate acceptance, or (3) not protesting in the way this section provides. A change order that is accepted by the Contractor as provided in this section shall constitute full payment and final settlement of all claims for contract time and for direct, indirect and consequential costs, including costs of delays related to any work, either covered or affected by the change. VIII. FORCE MAJEURE. Neither party shall be liable to the other for breach due to delay or failure in performance resulting from acts of God, acts of war or of the public enemy, riots, pandemic, fire, flood, or other natural disaster or acts of government (“force majeure event”). Performance that is prevented or delayed due to a force majeure event shall not result in liability to the delayed party. Both parties represent to the other that at the time of signing this Agreement, they are able to perform as required and their performance will not be prevented, hindered, or delayed by the current COVID-19 pandemic, any existing state or national declarations of emergency, or any current social distancing restrictions or personal protective equipment requirements that may be required under federal, state, or local law in response to the current pandemic. If any future performance is prevented or delayed by a force majeure event, the party whose performance is prevented or delayed shall promptly notify the other party of the existence and nature of the force majeure event causing the prevention or delay in performance. Any excuse from liability shall be effective only to the extent and duration of the force majeure event causing the prevention or delay in performance and, provided, that the party prevented or delayed has not caused such event to occur and continues to use diligent, good faith efforts to avoid the effects of such event and to perform the obligation. Notwithstanding other provisions of this section, the Contractor shall not be entitled to, and the City shall not be liable for, the payment of any part of the contract price during a force majeure event, or any costs, losses, expenses, damages, or delay costs incurred by the Contractor due to a force majeure event. Performance that is more costly due to a force majeure event is not included within the scope of this Force Majeure provision. If a force majeure event occurs, the City may direct the Contractor to restart any work or performance that may have ceased, to change the work, or to take other action to secure the work or the project site during the force majeure event. The cost to restart, change, or secure the work or project site arising from a direction by the City under this clause will be dealt with as a change order, except to the extent that the loss or damage has been caused or exacerbated by the failure of the Contractor to fulfill its obligations under this Agreement. Except as expressly contemplated by this section, all other costs will be borne by the Contractor. IX. CLAIMS. If the Contractor disagrees with anything required by a change order, another written order, or an oral order from the City, including any direction, instruction, interpretation, or determination by the City, the Contractor may file a claim as provided in this section. The Contractor shall give written notice to the City of all claims within fourteen (14) calendar days of the occurrence of the events giving rise to the claims, or within fourteen (14) calendar days of the date the Contractor knew or should have known of the facts or events giving rise to the claim, whichever occurs first . Any claim for damages, additional payment for any reason, or extension of time, whether under this Agreement or otherwise, shall be conclusively deemed to have been waived by the Contractor unless a timely written claim is made in strict accordance with the applicable provisions of this Agreement. At a minimum, a Contractor's written claim shall include the information set forth in subsections A, items 1 through 5 below. FAILURE TO PROVIDE A COMPLETE, WRITTEN NOTIFICATION OF CLAIM WITHIN THE TIME ALLOWED SHALL BE AN ABSOLUTE WAIVER OF ANY CLAIMS ARISING IN ANY WAY FROM THE FACTS OR EVENTS SURROUNDING THAT CLAIM OR CAUSED BY THAT DELAY. PUBLIC WORKS AGREEMENT - 5 ($20K or Less and No Performance Bond) A. Notice of Claim. Provide a signed written notice of claim that provides the following information: 1. The date of the Contractor's claim; 2. The nature and circumstances that caused the claim; 3. The provisions in this Agreement that support the claim; 4. The estimated dollar cost, if any, of the claimed work and how that estimate was determined; and 5. An analysis of the progress schedule showing the schedule change or disruption if the Contractor is asserting a schedule change or disruption. B. Records. The Contractor shall keep complete records of extra costs and time incurred as a result of the asserted events giving rise to the claim. The City shall have access to any of the Contractor's records needed for evaluating the protest. The City will evaluate all claims, provided the procedures in this section are followed. If the City determines that a claim is valid, the City will adjust payment for work or time by an equitable adjustment. No adjustment will be made for an invalid protest. C. Contractor's Duty to Complete Protested Work. In spite of any claim, the Contractor shall proceed promptly to provide the goods, materials and services required by the City under this Agreement. D. Failure to Protest Constitutes Waiver. By not protesting as this section provides, the Contractor also waives any additional entitlement and accepts from the City any written or oral order (including directions, instructions, interpretations, and determination). E. Failure to Follow Procedures Constitutes Waiver. By failing to follow the procedures of this section, the Contractor completely waives any claims for protested work and accepts from the City any written or oral order (including directions, instructions, interpretations, and determination). X. LIMITATION OF ACTIONS. CONTRACTOR MUST, IN ANY EVENT, FILE ANY LAWSUIT ARISING FROM OR CONNECTED WITH THIS AGREEMENT WITHIN 120 CALENDAR DAYS FROM THE DATE THE CONTRACT WORK IS COMPLETE OR CONTRACTOR’S ABILITY TO FILE THAT CLAIM OR SUIT SHALL BE FOREVER BARRED. THIS SECTION FURTHER LIMITS ANY APPLICABLE STATUTORY LIMITATIONS PERIOD. XI. WARRANTY. The Contractor warrants that it will faithfully and satisfactorily perform all work provided under this Agreement in accordance with the provisions of this Agreement. The Contractor shall promptly correct all defects in workmanship and materials: (1) when the Contractor knows or should have known of the defect, or (2) upon the Contractor’s receipt of notification from the City of the existence or discovery of the defect. In the event any parts are repaired or replaced, only original replacement parts shall be used—rebuilt or used parts will not be acceptable. When defects are corrected, the warranty for that portion of the work shall extend for an additional year beyond the original warranty period applicable to the overall work. The Contractor shall begin to correct any defects within seven (7) calendar days of its receipt of notice from the City of the defect. If the Contractor does not accomplish the corrections within a reasonable time as determined by the City, the City may complete the corrections and the Contractor shall pay all costs incurred by the City in order to accomplish the correction. XII. DISCRIMINATION. In the hiring of employees for the performance of work under this Agreement or any sub-contract, the Contractor, its sub-contractors, or any person acting on behalf of the Contractor or sub-contractor shall not, by reason of race, religion, color, sex, age, sexual orientation, national origin, or the presence of any sensory, mental, or physical disability, discriminate against any person who is qualified and available to perform the work to which the employment relates. PUBLIC WORKS AGREEMENT - 6 ($20K or Less and No Performance Bond) The Contractor shall execute the attached City of Kent Equal Employment Opportunity Policy Declaration, Comply with City Administrative Policy 1.2, and upon completion of the contract work, file the attached Compliance Statement. XIII. INDEMNIFICATION. The Contractor shall defend, indemnify and hold the City, its officers, officials, employees, agents and volunteers harmless from any and all claims, injuries, damages, losses or suits, including all legal costs and attorney fees, arising out of or in connection with the Contractor's performance of this Agreement, except for that portion of the injuries and damages caused by the City's negligence. The City's inspection or acceptance of any of the Contractor's work when completed shall not be grounds to avoid any of these covenants of indemnification. Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Contractor and the City, its officers, officials, employees, agents and volunteers, the Contractor's duty to defend, indemnify, and hold the City harmless, and the Contractor’s liability accruing from that obligation shall be only to the extent of the Contractor's negligence. IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THE INDEMNIFICATION PROVIDED HEREIN CONSTITUTES THE CONTRACTOR'S WAIVER OF IMMUNITY UNDER INDUSTRIAL INSURANCE, TITLE 51 RCW, SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PARTIES FURTHER ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER. In the event the Contractor refuses tender of defense in any suit or any claim, if that tender was made pursuant to this indemnification clause, and if that refusal is subsequently determined by a court having jurisdiction (or other agreed tribunal) to have been a wrongful refusal on the Contractor’s part, then the Contractor shall pay all the City’s costs for defense, including all reasonable expert witness fees and reasonable attorneys’ fees, plus the City’s legal costs and fees incurred because there was a wrongful refusal on the Contractor’s part. The provisions of this section shall survive the expiration or termination of this Agreement. XIV. INSURANCE. The Contractor shall procure and maintain for the duration of the Agreement, insurance of the types and in the amounts described in Exhibit B attached and incorporated by this reference. XV. WORK PERFORMED AT CONTRACTOR'S RISK. The Contractor shall take all necessary precautions and shall be responsible for the safety of its employees, agents, and subcontractors in the performance of the contract work and shall utilize all protection necessary for that purpose. All work shall be done at the Contractor's own risk, and the Contractor shall be responsible for any loss of or damage to materials, tools, or other articles used or held for use in connection with the work. XVI. MISCELLANEOUS PROVISIONS. A. Recyclable Materials. Pursuant to Chapter 3.80 of the Kent City Code, the City requires its contractors and consultants to use recycled and recyclable products whenever practicable. A price preference may be available for any designated recycled product. B. Non-Waiver of Breach. The failure of the City to insist upon strict performance of any of the covenants and agreements contained in this Agreement, or to exercise any option conferred by this Agreement in one or more instances shall not be construed to be a waiver or relinquishment of those covenants, agreements or options, and the same shall be and remain in full force and effect. C. Resolution of Disputes and Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of Washington. If the parties are unable to settle any dispute, difference or claim arising from the parties’ performance of this Agreement, the exclusive means PUBLIC WORKS AGREEMENT - 7 ($20K or Less and No Performance Bond) of resolving that dispute, difference or claim, shall only be by filing suit exclusively under the venue, rules and jurisdiction of the King County Superior Court, King County, Washington, unless the parties agree in writing to an alternative dispute resolution process. In any claim or lawsuit for damages arising from the parties' performance of this Agreement, each party shall pay all its legal costs and attorney's fees incurred in defending or bringing such claim or lawsuit, including all appeals, in addition to any other recovery or award provided by law; provided, however, nothing in this paragraph shall be construed to limit the City's right to indemnification under Section XIII of this Agreement. D. Written Notice. All communications regarding this Agreement shall be sent to the parties at the addresses listed on the signature page of the Agreement, unless notified to the contrary. Any written notice hereunder shall become effective three (3) business days after the date of mailing by registered or certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated in this Agreement or such other address as may be hereafter specified in writing. E. Assignment. Any assignment of this Agreement by either party without the written consent of the non-assigning party shall be void. If the non-assigning party gives its consent to any assignment, the terms of this Agreement shall continue in full force and effect and no further assignment shall be made without additional written consent. F. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of the City and the Contractor. G. Entire Agreement. The written provisions and terms of this Agreement, together with any Exhibits attached hereto, shall supersede all prior verbal statements of any officer or other representative of the City, and such statements shall not be effective or be construed as entering into or forming a part of or altering in any manner this Agreement. All of the above documents are hereby made a part of this Agreement. However, should any language in any of the Exhibits to this Agreement conflict with any language contained in this Agreement, the terms of this Agreement shall prevail. H. Compliance with Laws. The Contractor agrees to comply with all federal, state, and municipal laws, rules, and regulations that are now effective or in the future become applicable to the Contractor's business, equipment, and personnel engaged in operations covered by this Agreement or accruing out of the performance of those operations. I. Public Records Act. The Contractor acknowledges that the City is a public agency subject to the Public Records Act codified in Chapter 42.56 of the Revised Code of Washington and documents, notes, emails, and other records prepared or gathered by the Contractor in its performance of this Agreement may be subject to public review and disclosure, even if those records are not produced to or possessed by the City of Kent. As such, the Contractor agrees to cooperate fully with the City in satisfying the City’s duties and obligations under the Public Records Act. J. City Business License Required. Prior to commencing the tasks described in Section I, the Contractor agrees to provide proof of a current city of Kent business license pursuant to Chapter 5.01 of the Kent City Code. K. Counterparts and Signatures by Fax or Email. This Agreement may be executed in any number of counterparts, each of which shall constitute an original, and all of which will together constitute this one Agreement. Further, upon executing this Agreement, either party may deliver the signature page to the other by fax or email and that signature shall have the same force and effect as if the Agreement bearing the original signature was received in person. IN WITNESS, the parties below execute this Agreement, which shall become effective on the last date entered below. All acts consistent with the authority of this Agreement and prior to its effective date are ratified and affirmed, and the terms of the Agreement shall be deemed to have applied. CONTRACTOR: By: 2t t Print Name: Michael C Moriarty Its Owner/Man DATE: 4/22/21 NOTICES TO BE SENT TO: CONTRACTOR: Michael Moriarty Moriarty Enterprises, LLC D.B.A. Mocon Fence Contractors 12510 SE Petrovitsky Rd. Renton, WA 98058-6706 (425) 228-2296 (telephone) (425) 228-9969 (facsimile) Mocon - 272nd Holding Pond/Codiga CITY OF KENT: By: Digitally signed by David A. Brock David A. Brock DNcn=DavidABrock il-dbcckKent,ou=Public Works Operations, email=dbrock@kentwa.gov, c=US Date: 2021.04.22 10:09:09-07'00' Print Name: David A. Brock, P.E. Its: Deputy Director Operations Manager DATE: NOTICES TO BE SENT TO: CITY OF KENT: Chad Bieren, P.E. City of Kent 220 Fourth Avenue South Kent, WA 98032 (253) 856-5500 (telephone) (253) 856-6500 (facsimile) ATTEST: L� klcwh Kent City Clerk PUBLIC WORKS AGREEMENT - 8 ($20K or Less and No Performance Bond) EEO COMPLIANCE DOCUMENTS - 1 DECLARATION CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY POLICY The City of Kent is committed to conform to Federal and State laws regarding equal opportunity. As such all contractors, subcontractors and suppliers who perform work with relation to this Agreement shall comply with the regulations of the City’s equal employment opportunity policies. The following questions specifically identify the requirements the City deems necessary for any contractor, subcontractor or supplier on this specific Agreement to adhere to. An affirmative response is required on all of the following questions for this Agreement to be valid and binding. If any contractor, subcontractor or supplier willfully misrepresents themselves with regard to the directives outlines, it will be considered a breach of contract and it will be at the City’s sole determination regarding suspension or termination for all or part of the Agreement; The questions are as follows: 1. I have read the attached City of Kent administrative policy number 1.2. 2. During the time of this Agreement I will not discriminate in employment on the basis of sex, race, color, national origin, age, or the presence of all sensory, mental or physical disability. 3. During the time of this Agreement the prime contractor will provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 4. During the time of the Agreement I, the prime contractor, will actively consider hiring and promotion of women and minorities. 5. Before acceptance of this Agreement, an adherence statement will be signed by me, the Prime Contractor, that the Prime Contractor complied with the requirements as set forth above. By signing below, I agree to fulfill the five requirements referenced above. By: ___________________________________________ For: __________________________________________ Title: _________________________________________ Date: _________________________________________ MOCON Fence Contactors Owner/Manager 4/22/21 EEO COMPLIANCE DOCUMENTS - 2 CITY OF KENT ADMINISTRATIVE POLICY NUMBER: 1.2 EFFECTIVE DATE: January 1, 1998 SUBJECT: MINORITY AND WOMEN SUPERSEDES: April 1, 1996 CONTRACTORS APPROVED BY Jim White, Mayor POLICY: Equal employment opportunity requirements for the City of Kent will conform to federal and state laws. All contractors, subcontractors, consultants and suppliers of the City must guarantee equal employment opportunity within their organization and, if holding Agreements with the City amounting to $10,000 or more within any given year, must take the following affirmative steps: 1. Provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 2. Actively consider for promotion and advancement available minorities and women. Any contractor, subcontractor, consultant or supplier who willfully disregards the City’s nondiscrimination and equal opportunity requirements shall be considered in breach of contract and subject to suspension or termination for all or part of the Agreement. Contract Compliance Officers will be appointed by the Directors of Planning, Parks, and Public Works Departments to assume the following duties for their respective departments. 1. Ensuring that contractors, subcontractors, consultants, and suppliers subject to these regulations are familiar with the regulations and the City’s equal employment opportunity policy. 2. Monitoring to assure adherence to federal, state and local laws, policies and guidelines. EEO COMPLIANCE DOCUMENTS - 3 CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE STATEMENT This form shall be filled out AFTER COMPLETION of this project by the Contractor awarded the Agreement. I, the undersigned, a duly represented agent of Company, hereby acknowledge and declare that the before-mentioned company was the prime contractor for the Agreement known as that was entered into on the (date), between the firm I represent and the City of Kent. I declare that I complied fully with all of the requirements and obligations as outlined in the City of Kent Administrative Policy 1.2 and the Declaration City of Kent Equal Employment Opportunity Policy that was part of the before-mentioned Agreement. By: ___________________________________________ For: __________________________________________ Title: _________________________________________ Date: _________________________________________ BIDDER RESPONSIBILITY CRITERIA - 1 BIDDER RESPONSIBILITY CRITERIA Certification of Compliance with Wage Payment Statutes This certification is required by state law (RCW 39.04.350(2)) to be submitted to the City before the contract can be awarded. The bidder hereby certifies that, within the three-year period immediately preceding the bid solicitation date (March 31, 2021), the bidder is not a “willful” violator, as defined in RCW 49.48.082, of any provision of chapters 49.46, 49.48, or 49.52 RCW, as determined by a final and binding citation and notice of assessment issued by the Department of Labor and Industries or through a civil judgment entered by a court of limited or general jurisdiction. I certify under penalty of perjury under the laws of the State of Washington that the foregoing is true and correct. Moriarty Enterprises, LLC D.B.A. Mocon Fence Contractors By: ___________________________________________ Signature of Authorized Official* Printed Name: __________________________________ Title: _________________________________________ Date: _________________________________________ City and State: _________________________________ *If a corporation, proposal must be executed in the corporate name by the president or vice- president (or any other corporate officer accompanied by evidence of authority to sign). If a co- partnership, proposal must be executed by a partner. Michael C Moriarty Owner/Manager 4/22/21 Renton, WA Citv of Kent Fence lnstall/Repair Scope of Work1. Contractor must pay prevailing wage.2. Contractor must use appropriate flagging control whenneeded for safety.3. Proof of insurance and bonding required.4. Contractor responsible for locates if underground wiresor pipes are in the area.Site location-Holding pond located on the west side of 14233 SE 272ndSt. (Kent Kangley) Please repair the gate and section withsame materials as remaining fence, posts and hardware.Please contact Joe Codiga at 253-856-5674, or HeatherMclntosh at 253-740-0436 with any questions you have onthis project. Please send bid to hmcintosh@kentwa.qov#032921EXHIBIT A r{.0MOCONFENCE COHTRACTORS12510 S. E. Petrovitsky Rd.Renton, WA 98058-6706P: @25) 228-2296 F: (425) 228-9969e-mail : mike@moconfence.comI nternet: www.moconfence.comTo:Attention:No. of pages:From:Project Name:Subject:PROPOSALCity of KentHeather Mcintosh1Michael MoriartyKent Pond Fence Repair -14233 SF.272d St (Kent Kangley)6' high all galvanized chain link fence and gateDate: 3l3Il202Ihmcintosh@kentwa.govWe propose to remove and replace as required to put the 50 LF section of fence plus replace the 15' double swinggate with new. We will reuse the eastern most 4" gate support posts, install new double swing gate with new drop rodassembly and install a new 4" od gate support post. Also includes replacing up to 50 LF of new fabric and}4-lineposts as required along Kent Kangley, and fix the brace rail off the corner in the eastern run of fence as required to putfence back into good working order.LUMP SUM S 2.649.00 Plus Local Sales TaxTERMS: Balance is due immediately upon completion with no retainer withheld.STANDARD EXCLUSIONS: Clearing, grading, stakingAocating of fence line, locating of tnderground utility, traffic control, electrical grounding, sleeves,block outs, asphalt patch, core drilling, sonotubes, padlocks, any locking devices, saw cutting, backfill, extra mobilizations, removal ofexisting fence, postpulling, mow strips, curbs, bollards, hazardous waste training and removal of, wood or plastic slats, pipe gates, painting, vinyl or powder coating, temporaryfence, guardrail, wire mesh, liquidated damages, sales tax, engineering, performance bonds, bid bonds, permits and union fees (non-union quote). All costsincurred for drug testing, performance bonds and OCIP programs (no credit will be issued for any OCIP). Warranty's more than one year.QUALIFY: Survey and grade hubs supplied by others prior to us mobilizing. We must have access to fence line with digging equipment and concrete truck.Please allow minimum 2 weeks for powdercoated or vinyl coated finished materials. WA Contractor Lic # MORIAELO27R3INSURANCE: Insurance coverage of $ I ,000,000 each occurrence ($2,000,000 General Aggregate) included. Insurance certifications include CG2033 at noadditional charge (requirements beyond CG2033 will result in additional charges). Waivers of subrogation endorsements add $ 150.00 per named entity.This proposal expires 7 days from proposal date due to unstable steel market and all prices will need to be confirmed at time of contracVinstallation.Date accepted:Company:(Sign and Print Name of Authorized Officer)By: EXHIBIT B INSURANCE REQUIREMENTS FOR SERVICE CONTRACTS Insurance The Contractor shall procure and maintain for the duration of the Agreement, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees or subcontractors. A. Minimum Scope of Insurance Contractor shall obtain insurance of the types described below: 1. Commercial General Liability insurance shall be written on ISO occurrence form CG 00 01 and shall cover liability arising from premises, operations, independent contractors, products-completed operations, personal injury and advertising injury, and liability assumed under an insured contract. The City shall be named as an insured under the Contractor’s Commercial General Liability insurance policy with respect to the work performed for the City using ISO additional insured endorsement CG 20 10 11 85 or a substitute endorsement providing equivalent coverage. 2. Automobile Liability insurance covering all owned, non-owned, hired and leased vehicles. Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. 3. Workers’ Compensation coverage as required by the Industrial Insurance laws of the State of Washington. B. Minimum Amounts of Insurance Contractor shall maintain the following insurance limits: 1. Commercial General Liability insurance shall be written with limits no less than $2,000,000 each occurrence, $2,000,000 general aggregate and a $2,000,000 products-completed operations aggregate limit. 2. Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $2,000,000 per accident. EXHIBIT B (Continued) C. Other Insurance Provisions The insurance policies are to contain, or be endorsed to contain, the following provisions for Automobile Liability and Commercial General Liability insurance: 1. The Contractor’s insurance coverage shall be primary insurance as respect the City. Any Insurance, self-insurance, or insurance pool coverage maintained by the City shall be excess of the Contractor’s insurance and shall not contribute with it. 2. The Contractor’s insurance shall be endorsed to state that coverage shall not be cancelled by either party, except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City. 3. The City of Kent shall be named as an additional insured on all policies (except Professional Liability) as respects work performed by or on behalf of the contractor and a copy of the endorsement naming the City as additional insured shall be attached to the Certificate of Insurance. The City reserves the right to receive a certified copy of all required insurance policies. The Contractor’s Commercial General Liability insurance shall also contain a clause stating that coverage shall apply separately to each insured against whom claim is made or suit is brought, except with respects to the limits of the insurer’s liability. D. Acceptability of Insurers Insurance is to be placed with insurers with a current A.M. Best rating of not less than A:VII. E. Verification of Coverage Contractor shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the insurance requirements of the Contractor before commencement of the work. F. Subcontractors Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor. All coverages for subcontractors shall be subject to all of the same insurance requirements as stated herein for the Contractor. 01/11/2021 Conover Insurance 155 108th Avenue NE, Suite 725 P.O. Box 90007 Bellevue WA 98004 Tanya Myers, ACSR, CISR (509) 972-7442 (425) 454-5550 tanyam@conoverinsurance.com Moriarty Enterprises, LLC, DBA: MOCON 12510 SE Petrovitsky Rd. Renton WA 98058-6706 American Fire & Casualty 24066 Ohio Security Ins Co 24082 Ohio Casualty Ins Co.24074 Master 20-21 A Y BKA55548617 05/15/2020 05/15/2021 1,000,000 1,000,000 15,000 1,000,000 2,000,000 2,000,000 Stopgap 1,000,000 B Y Y BAS61328694 05/15/2020 05/15/2021 1,000,000 Hired Non-owned auto liability 1,000,000 C 10,000 USO55548617 05/15/2020 05/15/2021 5,000,000 5,000,000 A BKA55548617 05/15/2020 05/15/2021 WA Stopgap 1,000,000 1,000,000 1,000,000 A Installation Floater BKA55548617 05/15/2020 05/15/2021 Limit $25,000 Deductible $500 RE: Remove existing fencing fabric and install new fence. City of Kent is Additional Insured. Completed Operations applies. Coverage is Primary & Non-Contributory. Waiver of Subrogation applies. Per Project Aggregate applies. Forms attached: CG9043 0812, CG9044 0812, CG8870 1208, AC8501 0618 Business Auto Enhancement Endorsement, CU6002 0697, CU8840 0210 and CU6495 1207. City of Kent 220 Fourth Avenue South Kent WA 98032 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME: CONTACT (A/C, No): FAX E-MAIL ADDRESS: PRODUCER (A/C, No, Ext): PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT ER OTH- STATUTE PER LIMITS(MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) POLICY EFF POLICY NUMBERTYPE OF INSURANCELTR INSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO- JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY Y Y General Endorsement POLICY NUMBER BKA (21 ) 55 54 8617 Policy Period: From 05/15/2020 To 05/1512021 12:01 am Standard Time at Insured Mailing Location This Endorsement Changes The Policy, Please Read it Carefully. BLANKET CG9043: ANY PERSON OR ORGANIZATION, WHERE REQUIRED IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT, FOR "YOUR" ONGOING OPERATIONS THAT IS THE SUBJECT OF THE CONTRACT OR AGREEMENT. BLANKET CG9044: ANY PERSON OR ORGANIZATION, WHERE REQUIRED IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT, FOR "YOUR WORK" THAT IS THE SUBJECT OF THE CONTRACT OR AGREEMENT. To report a claim, call your Agent or CG70 02 01 01 Page 1 of 2 General Endorsement POLICY NUMBER BKA (21) 55 54 8617 Policy Period: From 05/15/2020 To 05/15/2021 12:01 am Standard Time at Insured Mailing Location To report a claim, call your Agent or CG 70 02 01 01 Page 2 of 2 POLICY NUMBER: COMMERCIAL GENERAL LIABILITY CG 90 43 08 12 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED -OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION - INCLUDING PRIMARY / NON- CONTRIBUTORY AND WAIVER OF SUBROGATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): BLANKET CG9044 & CG9043 SEE CG7002 0101 attached Location(s) Of Covered Operations PER JOB Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. To the extent permitted by law, Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" arising out of your ongoing operations at the location(s) designated above. B. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: 1. All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the addi- tional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as apart of the same project. C. PRIMARY AND NON-CONTRIBUTORY Condition 4. Other Insurance of SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS is amended as follows: This provision applies to any person or organization who is named in the schedule of this endorsement as an additional insured or scheduled as an additional insured under any other form or endorsement under this policy. © 2012 Liberty Mutual Insurance CG 90 43 08 12 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 1 of 2 1. The following is added to paragraph a. Primary Insurance: To the extent permitted by law, this insurance is primary insurance as respects to our coverage to an additional insured person or organization, where the written contract or written agreement requires that this insurance be primary and non-contributory. In that event, we will not seek con- tribution from any other any other insurance policy available to the additional insured on which the additional insured person or organization is a Named Insured. 2. The following is added to paragraph b. Excess Insurance: When a written contract or written agreement does not require this insurance to be primary or primary and non-contributory, this insurance is excess over any other insurance for which the additional insured is designated a Named Insured. Regardless of the written contract or written agreement, this insurance is excess over any other insurance whether primary, excess, contingent or on any other basis for which the additional insured has been added as an additional insured on other policies. D. WAIVER OF SUBROGATION To the extent permitted by law, we waive any rights of recovery we may have against the persons or organizations shown in the Schedule above because of payments we make for 'bodily injury" or "property damage" arising out of your ongoing operations, when required in a written contract or agreement. This waiver applies only to the persons or organizations shown in the Schedule above. © 2012 Liberty Mutual Insurance CG 90 43 08 12 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 2 of 2 POLICY NUMBER: COMMERCIAL GENERAL LIABILITY CG 90 44 08 12 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED -OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS - INCLUDING PRIMARY AND NON-CONTRIBUTORY AND WAIVER OF SUBROGATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Person(s) Or Organization(s): BLANKET CG9044 & CG9043 SEE CG7002 0101 Attached Location And Description Of Completed Operations: PER JOB PER JOB Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. To the extent permitted by law, Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" arising out of "your work" at the location designated and de- scribed in the schedule of this endorsement performed for that additional insured and included in the "products -completed operations hazard". B. Primary and Non -Contributory Condition 4. Other Insurance of SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS is amended as follows: This provision applies to any person or organization who is named in the schedule of this endorsement as an additional insured or scheduled as an additional insured under any other form or endorsement under this policy. 1. The following is added to paragraph a. Primary Insurance: To the extent permitted by law, this insurance is primary insurance as respects to our coverage to an additional insured person or organization, where the written contract or written agreement requires that this insurance be primary and non-contributory. In that event, we will not seek con- tribution from any other insurance policy available to the additional insured on which the additional insured person or organization is a Named Insured. © 2012 Liberty Mutual Insurance CG 90 44 08 12 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 1 of 2 2. The following is added to paragraph b. Excess Insurance: When a written contract or written agreement does not require this insurance to be primary or primary and non-contributory, this insurance is excess over any other insurance for which the additional insured is designated a Named Insured. Regardless of the written contract or written agreement, this insurance is excess over any other insur- ance whether primary, excess, contingent or on any other basis for which the additional insured has been added as an additional insured on other policies. C. WAIVER OF SUBROGATION To the extent permitted by law, we waive any rights of recovery we may have against the persons or organizations shown in the Schedule above because of payments we make for "bodily injury" or "property damage" arising out of your completed operations, where required in a written contract or agreement. This waiver applies only to the persons or organizations shown in the Schedule above. © 2012 Liberty Mutual Insurance CG 90 44 08 12 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 2 of 2 BKA55548617 COMMERCIAL GENERAL LIABILITY CG 88 70 12 08 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CONSTRUCTION PROJECT(S) - GENERAL AGGREGATE LIMIT (PER PROJECT) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under Section I - Coverage A - Bodily Injury And Property Damage Liability, and for all medical ex- penses caused by accidents under Section I - Coverage C Medical Payments, which can be attributed only to ongoing operations at a single construction project away from premises owned by or rented to you: 1. A separate Construction Project General Aggregate Limit applies to each construction project, and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations . 2. The Construction Project General Aggregate Limit is the most we will pay for the sum of all damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products -completed operations hazard", and for medical expenses under Cov- erage C regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 3. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the Construction Project General Aggregate Limit for that construction project. Such payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Construction Project General Aggregate Limit for any other construction project. 4. The limits shown in the Declarations for Each Occurrence, Fire Damage and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, such limits will be subject to the applicable Construction Project General Aggregate Limit. B. For all sums which the insured becomes legally obligated to pay as damages caused by 'occurrences" under Section I - Coverage A - Bodily Injury And Property Damage Liability, and for all medical ex- penses caused by accidents under Section I - Coverage C Medical Payments, which cannot be attrib- uted only to ongoing operations at a single construction project away from premises owned by or rented to you: 1. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the amount available under the General Aggregate Limit or the Products -Completed Operations Aggregate Limit, whichever is applicable; and 2. Such payments shall not reduce any Construction Project General Aggregate Limit. C. When coverage for liability arising out of the "products -completed operations hazard" is provided, any payments for damages because of "bodily injury" or "property damage" included in the "products - completed operations hazard" will reduce the Products -Completed Operations Aggregate Limit, and not reduce the General Aggregate Limit nor the Construction Project General Aggregate Limit. D. If the applicable construction project has been abandoned, delayed, or abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints, designs, specifications or timetables, the project will still be deemed to be the same construction project. E. The provisions of Section III - Limits Of Insurance not otherwise modified by this endorsement shall continue to apply. CG 88 70 12 08 Includes copyrighted material of ISO Properties, Inc., with its permission. Page 1 of 1 Policy #BAS61328694 COMMERCIAL AUTO AC 85 01 06 18 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BUSINESS AUTO COVERAGE ENHANCEMENT ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM With respect to coverage afforded by this endorsement, the provisions of the policy apply unless modified by the endorsement. If the policy to which this endorsement is attached also contains a Business Auto Coverage Enhancement Endorsement with a specific state named in the title, this endorsement does not apply to vehicles garaged in that specified state. COVERAGEINDEX SUBJECT PROVISION NUMBER ACCIDENTAL AIRBAG DEPLOYMENT 13 ADDITIONAL INSURED BY CONTRACT, AGREEMENT OR PERMIT 4 AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS 21 AMENDED FELLOW EMPLOYEE EXCLUSION 6 AUDIO, VISUAL AND DATA ELECTRONIC EQUIPMENT COVERAGE 15 BODILY INJURY REDEFINED 25 EMPLOYEES AS INSUREDS (Including Employee Hired Auto) 3 EXTRA EXPENSE -BROADENED COVERAGE 11 GLASS REPAIR - WAIVER OF DEDUCTIBLE 17 HIRED AUTO COVERAGE TERRITORY 23 HIRED AUTO PHYSICAL DAMAGE (Including Employee Hired Auto) 7 LOAN / LEASE GAP (Coverage Not Available In New York) 16 NEWLY FORMED OR ACQUIRED SUBSIDIARIES 2 PARKED AUTO COLLISION COVERAGE (WAIVER OF DEDUCTIBLE) 18 PERSONAL EFFECTSCOVERAGE 12 PHYSICAL DAMAGE - ADDITIONAL TRANSPORTATION EXPENSE COVERAGE 9 PHYSICAL DAMAGE DEDUCTIBLE - VEHICLE TRACKING SYSTEM 14 PRIMARY AND NON-CONTRIBUTORY -WRITTEN CONTRACT OR WRITTEN AGREEMENT 24 RENTAL REIMBURSEMENT 10 SUPPLEMENTARY PAYMENTS 5 TOWING AND LABOR 8 TRAILERS - INCREASED LOAD CAPACITY 1 TWO OR MORE DEDUCTIBLES 19 UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS 20 WAIVER OF TRANSFER OF RIGHTS OF RECOVERYAGAINST OTHERS TO US 22 SECTION I - COVERED AUTOS is amended as follows: 1. TRAILERS - INCREASED LOAD CAPACITY The following replaces Paragraph C.1. Certain Trailers, Mobile Equipment And Temporary Substitute Autos of SECTION I - COVERED AUTOS: "Trailers" with a load capacity of 3,000 pounds or less designed primarily for travel on public roads. © 2017 Liberty Mutual Insurance AC 85 01 06 18 Includes copyrighted material of Insurance Services Office Inc., with its Permission. Page 1 of 7 SECTION II - LIABILITY COVERAGE is amended as follows: 2. NEWLY FORMED OR ACQUIRED SUBSIDIARIES SECTION II - LIABILITY COVERAGE, Paragraph A.1. - Who Is An Insured is amended to include the following as an "insured": d. Any legally incorporated subsidiary of which you own more than 50 percent interest during the policy period. Coverage is afforded only for 90 days from the date of acquisition or formation. However, "insured" does not include any organization that: (1) Is a partnership or joint venture; or (2) Is an "insured" under any other automobile policy except a policy written specificall y to apply in excess of this policy; or (3) Has exhausted its Limit of Insurance or had its policy terminated under any other automobile policy. Coverage under this provision d. does not apply to "bodily injury" or "property damage" that occurred before you acquired or formed the organization. 3. EMPLOYEES AS INSUREDS SECTION II - LIABILITY COVERAGE, Paragraph A.I. Who Is An Insured is amended to include the following as an "insured": e. Any "employee" of yours while using a covered "auto" you do not own, hire or borrow but only for acts within the scope of their employment by you. Insurance provided by this endorsement is excess over any other insurance available to any "employee". f. Any "employee" of yours while operating an "auto" hired or borrowed under a written contract or agreement in that "employee's" name, with your permission, while performing duties related to the conduct of your business and within the scope of their employment. Insurance provided by this endorsement is excess over any other insurance available to the "employee". 4. ADDITIONAL INSURED BY CONTRACT, AGREEMENT OR PERMIT SECTION II - LIABILITY COVERAGE, Paragraph A.1. Who Is An Insured is amended to include the following as an "insured": g. Any person or organization with respect to the operation, maintenance or use of a covered "auto", provided that you and such person or organization have agreed in a written contract, written agreement, or permit issued to you by governmental or public authority, to add such person, or organization, or governmental or public authority to this policy as an "insured". However, such person or organization is an "insured": (1) Only with respect to the operation, maintenance or use of acovered "auto"; (2) Only for "bodily injury" or "property damage" caused by an "accident" which takes place after you executed the written contract or written agreement, or the permit has been issued to you; and (3) Only for the duration of that contract, agreement or permit. The "insured" is required to submit a claim to any other insurer to which coverage could apply for defense and indemnity. Unless the "insured" has agreed in writing to primary noncontributory wording per enhancement number 24, this policy is excess over any other collectible insurance. 5. SUPPLEMENTARY PAYMENTS SECTION II - LIABILITY COVERAGE, Coverage Extensions, 2.a. Supplementary Payments, Paragraphs (2) and (4) are replaced by the following: (2) Up to $3,000 for cost of bail bonds (including bonds for related traffic violations ) required because of an "accident" we cover. We do not have to furnish these bonds. (4) All reasonable expenses incurred by the "insured" at our request, including actual loss of earnings up to $500 a day because of time off from work. © 2017 Liberty Mutual Insurance AC 85 01 06 18 Includes copyrighted material of Insurance Services Office Inc., with its Permission. Page 2 of 7 6. AMENDED FELLOW EMPLOYEE EXCLUSION In those jurisdictions where, by law, fellow "employees" are not entitled to the protection afforded to the employer by the workers compensation exclusivity rule, or similar protection, the following provi- sion is added: SECTION II - LIABILITY, Exclusion B.5. Fellow Employee does not apply if the "bodily injury" results from the use of a covered "auto" you awn or hire if you have workers compensation insurance in force for all of your "employees" at the time of "loss". This coverage is excess over any other collectible insurance. SECTION III - PHYSICAL DAMAGE COVERAGE is amended as follows: 7. HIRED AUTO PHYSICAL DAMAGE Paragraph A.4. Coverage Extensions of SECTION III - PHYSICAL DAMAGE COVERAGE, is amended by adding the following: If hired "autos" are covered "autos" for Liability Coverage, and if Comprehensive, Specified Causes of Loss or Collision coverage are provided under the Business Auto Coverage Form for any "auto" you own, then the Physical Damage coverages provided are extended to "autos": a. You hire, rent or borrow; or b. Your "employee" hires or rents under a written contract or agreement in that "employee's" name, but only if the damage occurs while the vehicle is being used in the conduct of your business, subject to the following limit and deductible: a. The most we will pay for "loss" in any one "accident" or "loss" is the smallest of: (1) $50,000; or (2) The actual cash value of the damaged or stolen property as of the time of the "loss"; or (3) The cost of repairing or replacing the damaged or stolen property with other property of like N kind and quality, minus a deductible. b. The deductible will be equal to the largest deductible applicable to any owned "auto" for that coverage. c. Subject to the limit, deductible and excess provisions described in this provision, we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own. d. Subject to a maximum of $1,000 per "accident", we will also cover the actual loss of use of the hired "auto" if it results from an "accident", you are legally liable and the lessor incurs an actual financial loss. e. This coverage extension does not apply to: (1) Any "auto" that is hired, rented or borrowed with a driver; or (2) Any "auto" that is hired, rented or borrowed from your "employee" or any member of your "employee's" household. Coverage provided under this extension is excess over any other collectible insurance available at the time of "loss". 8. TOWING AND LABOR M SECTION III - PHYSICAL DAMAGE COVERAGE, Paragraph A.2. Towing, is amended by the addition of the following: We will pay towing and labor costs incurred, up to the limits shown below, each time a covered "auto" classified and rated as a private passenger type, "light truck" or "medium truck" is disabled: a. For private passenger type vehicles, we will pay up to $75 per disablement. b. For "light trucks", we will pay up to $75 per disablement. "Light trucks" are trucks that have a gross vehicle weight (GVW) of 10,000 pounds or less. c. For "medium trucks" , we will pay up to $150 per disablement. "Medium trucks" are trucks that have a gross vehicle weight (GVW) of 10,001 - 20,000 pounds. However, the labor must be performed at the place of disablement. © 2017 Liberty Mutual Insurance AC 85 01 06 18 Includes copyrighted material of Insurance Services Office Inc., with its Permission. Page 3 of 7 9. PHYSICAL DAMAGE - ADDITIONAL TRANSPORTATION EXPENSE COVERAGE Paragraph AA.a. Coverage Extensions, Transportation Expenses of SECTION III - PHYSICAL DAMAGE COVERAGE, is amended to provide a limit of $50 per day and a maximum limit of $1,500. 10. RENTAL REIMBURSEMENT SECTION III - PHYSICAL DAMAGE COVERAGE, A. Coverage, is amended by adding the following: a. We will pay up to $75 per day for rental reimbursement expenses incurred by you for the rental of an "auto" because of "accident" or "loss", to an "auto" for which we also pay a "loss" under Comprehensive, Specified Causes of Loss or Collision Coverages. We will pay only for those ex- penses incurred after the first 24 hours following the "accident" or "loss" to the covered "auto." b. Rental Reimbursement requires the rental of a comparable or lessor vehicle, which in many cases may be substantially less than $75 per day, and will only be allowed for the period of time it should take to repair or replace the vehicle with reasonable speed and similar quality, up to a maximum of 30 days. c. We will also pay up to $500 for reasonable and necessary expenses incurred by you to remove and replace your tools and equipment from the covered "auto". This limit is excess over any other collectible insurance. d. This coverage does not apply unless you have a business necessity that other "autos" available for your use and operation cannot fill. e. If "loss" results from the total theft of a covered "auto" of the private passenger type, we will pay under this coverage only that amount of your rental reimbursement expenses which is not already provided under Paragraph 4. Coverage Extension. f. No deductible applies to this coverage. g. The insurance provided under this extension is excess over any other collectible insurance. If this policy also provides Rental Reimbursement Coverage you purchased, the coverage provided by this Enhancement Endorsement is in addition to the coverage you purchased. For the purposes of this endorsement provision, materials and equipment do not include "personal effects" as defined in provision 12.B. 11. EXTRA EXPENSE - BROADENED COVERAGE Under SECTION III - PHYSICAL DAMAGE COVERAGE, A. Coverage, we will pay for the expense of returning a stolen covered "auto" to you. The maximum amount we will pay is $1,000. 12. PERSONAL EFFECTS COVERAGE A. SECTION III - PHYSICAL DAMAGE COVERAGE, A. Coverage, is amended by adding the following: If you have purchased Comprehensive Coverage on this policy for an "auto" you own and that "auto" is stolen, we will pay, without application of a deductible, up to $600 for "personal effects" stolen with the "auto." The insurance provided under this provision is excess over any other collectible insurance. B. SECTION V -DEFINITIONS is amended by adding the fallowing: For the purposes of this provision, "personal effects" mean tangible property that is worn or carried by an "insured." "Personal effects" does not include tools, equipment, jewelry, money or securi- ties. 13. ACCIDENTAL AIRBAG DEPLOYMENT SECTION III - PHYSICAL DAMAGE COVERAGE, B. Exclusions is amended by adding the following: If you have purchased Comprehensive or Collision Coverage under this policy, the exclusion for "loss" relating to mechanical breakdown does not apply to the accidental discharge of an airbag. Any insurance we provide shall be excess over any other collectible insurance or reimbursement by manufacturer's warranty. However, we agree to pay any deductible applicable to the other coverage or warranty. © 2017 Liberty Mutual Insurance AC 85 01 06 18 Includes copyrighted material of Insurance Services Office Inc., with its Permission. Page 4 of 7 14. PHYSICAL DAMAGE DEDUCTIBLE - VEHICLE TRACKING SYSTEM SECTION III - PHYSICAL DAMAGE COVERAGE, D. Deductible, is amended by adding the following: Any Comprehensive Deductible shown in the Declarations will be reduced by 50% for any "loss" caused by theft if the vehicle is equipped with a vehicle tracking device such as a radio tracking device or a global position device and that device was the method of recovery of the vehicle. 15. AUDIO, VISUAL AND DATA ELECTRONIC EQUIPMENT COVERAGE SECTION III - PHYSICAL DAMAGE COVERAGE, B. Exclusions, Paragraph a. of the exception to exclu- sions 4.c. and 4.d. is deleted and replaced with the following: Exclusions 4.c. and 4.d. do not apply to: a. Electronic equipment that receives or transmits audio, visual or data signals, whether or not de- signed solely for the reproduction of sound, if the equipment is: (1) Permanently installed in the covered "auto" at the time of the "loss" or removable from a housing unit that is permanently installed in the covered "auto"; and (2) Designed to be solely operated by use from the power from the "auto's" electrical system; and (3) Physical damage coverages are provided for the covered "auto". If the "loss" occurs solely to audio, visual or data electronic equipment or accessories used with this equipment, then our obligation to pay for, repair, return or replace damaged or stolen property will be reduced by a $100 deductible. 16. LOAN/ LEASE GAP COVERAGE (Not Applicable In New York) A. Paragraph C. Limit Of Insurance of SECTION III - PHYSICAL DAMAGE COVERAGE is amended by adding the following: The most we will pay for a "total loss" to a covered "auto" owned by or leased to you in any one "accident" is the greater of the: N 1. Balance due under the terms of the loan or lease to which the damaged covered "auto" is subject at the time of the "loss" less the amount of: a. Overdue payments and financial penalties associated with those payments as of the date of the "loss"; b. Financial penalties imposed under a lease due to high mileage, excessive use or abnormal wear and tear; c. Costs for extended warranties, Credit Life Insurance, Health, Accident or Disability Insur- ance purchased with the loan or lease; d. Transfer or rollover balances from previous loans or leases; e. Final payment due under a "Balloon Loan"; f. The dollar amount of any unrepaired damage which occurred prior to the "total loss" of a covered "auto"; g. Security deposits not refunded by a lessor; h. All refunds payable or paid to you as a result of the early termination of a lease agreement or as a result of the early termination of any warranty or extended service agreement on a covered "auto"; M I. Any amount representing taxes; j. Loan or lease termination fees; or 2. The actual cash value of the damage or stolen property as of the time of the "loss". An adjustment for depreciation and physical condition will be made in determining the actual cash value at the time of the "loss". This adjustment is not applicable in Texas. B. Additional Conditions This coverage applies only to the original loan for which the covered "auto" that incurred the "loss" serves as collateral, or lease written on the covered "auto" that incurred the "loss". © 2017 Liberty Mutual Insurance AC 85 01 06 18 Includes copyrighted material of Insurance Services Office Inc., with its Permission. Page 5 of 7 C. SECTION V - DEFINITIONS is changed by adding the following: As used in this endorsement provision, the following definitions apply: "Total loss" means a "loss" in which the cost of repairs plus the salvage value exceeds the actual cash value. A "balloon loan" is one with periodic payments that are insufficient to repay the balance over the term of the loan, thereby requiring a large final payment. 17. GLASS REPAIR - WAIVER OF DEDUCTIBLE Paragraph D. Deductible of SECTION III - PHYSICAL DAMAGE COVERAGE is amended by the addition of the following: No deductible applies to glass damage if the glass is repaired rather than replaced. 18. PARKED AUTO COLLISION COVERAGE (WAIVER OF DEDUCTIBLE) Paragraph D. Deductible of SECTION III - PHYSICAL DAMAGE COVERAGE is amended by the addition of the following: The deductible does not apply to "loss" caused by collision to such covered "auto" of the private passenger type or light weight truck with a gross vehicle weight of 10,000 lbs. or less as defined by the manufacturer as maximum loaded weight the "auto" is designed to carry while it is: a. In the charge of an "insured"; b. Legally parked; and c. Unoccupied. The 'loss" must be reported to the police authorities within 24 hours of known damage. The total amount of the damage to the covered "auto" must exceed the deductible shown in the Declarations. This provision does not apply to any 'loss" if the covered "auto" is in the charge of any person or organization engaged in the automobile business. 19. TWO OR MORE DEDUCTIBLES Under SECTION III - PHYSICAL DAMAGE COVERAGE, if two or more company policies or coverage forms apply to the same "accident', the following applies to Paragraph D. Deductible: a. If the applicable Business Auto deductible is the smaller (or smallest) deductible, it will be waived; or b. If the applicable Business Auto deductible is not the smaller (or smallest) deductible , it will be reduced by the amount of the smaller (or smallest) deductible; or c. If the "loss" involves two or more Business Auto coverage forms or policies, the smaller (or smallest) deductible will be waived. For the purpose of this endorsement, company means any company that is part of the Liberty Mutual Group. SECTION IV - BUSINESS AUTO CONDITIONS is amended as follows: 20. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS SECTION IV- BUSINESS AUTO CONDITIONS, Paragraph B.2. is amended by adding the following: If you unintentionally fail to disclose any hazards, exposures or material facts existing as of the incep- tion date or renewal date of the Business Auto Coverage Form, the coverage afforded by this policy will not be prejudiced. However, you must report the undisclosed hazard of exposure as soon as practicable after its discovery, and we have the right to collect additional premium for any such hazard or exposure. © 2017 Liberty Mutual Insurance AC 85 01 06 18 Includes copyrighted material of Insurance Services Office Inc., with its Permission. Page 6 of 7 21. AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT, OR LOSS SECTION IV - BUSINESS AUTO CONDITIONS, Paragraph A.2.a. is replaced in its entirety by the follow- ing: a. In the event of "accident", claim, "suit" or "loss", you must promptly notify us when it is known to: (1) You, if you are an individual; (2) A partner, if you are a partnership; (3) Member, if you are a limited liability company; (4) An executive officer or the "employee" designated by the Named Insured to give such notice, if you are a corporation. To the extent possible, notice to us should include: (a) How, when and where the "accident" or "loss" took place; (b) The "insureds" name and address; and (c) The names and addresses of any injured persons and witnesses. 22. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US SECTION IV - BUSINESS AUTO CONDITIONS, Paragraph A.5. Transfer Of Rights Of Recovery Against Others To Us, is amended by the addition of the following: If the person or organization has in a written agreement waived those rights before an "accident" or "loss", our rights are waived also. 23. HIRED AUTO COVERAGE TERRITORY SECTION IV - BUSINESS AUTO CONDITIONS, Paragraph B.7. Policy Period, Coverage Territory, is amended by the addition of the following: f. For "autos" hired 30 days or less, the coverage territory is anywhere in the world, provided that the "insured's" responsibility to pay for damages is determined in a "suit", on the merits, in the United " States, the territories and possessions of the United States of America, Puerto Rico or Canada or in a settlement we agree to. This extension of coverage does not apply to an "auto" hired, leased, rented or borrowed with a driver. 24. PRIMARY AND NON-CONTRIBUTING IF REQUIRED BY WRITTEN CONTRACT OR WRITTEN AGREE- MENT The following is added to SECTION IV - BUSINESS AUTO CONDITIONS, General Conditions, B.5. Other Insurance and supersedes any provision to the contrary: This Coverage Form's Covered Autos Liability Coverage is primary to and will not seek contribution from any other insurance available to an "insured" under your policy provided that: 1. Such "insured" is a Named Insured under such other insurance; and 2. You have agreed in a written contract or written agreement that this insurance would be primary and would not seek contribution from any other insurance available to such "insured". SECTION V - DEFINITIONS is amended as follows: 25. BODILY INJURY REDEFINED Under SECTION V - DEFINITIONS, Definition C. is replaced by the following: "Bodily injury" means physical injury, sickness or disease sustained by a person, including mental anguish, mental injury, shock, fright or death resulting from any of these at any time. © 2017 Liberty Mutual Insurance AC 85 01 06 18 Includes copyrighted material of Insurance Services Office Inc., with its Permission. Page 7 of 7 US055548617 COMMERCIAL UMBRELLA CU 88 40 02 10 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. AMENDMENT OF OTHER INSURANCE -DESIGNATED PERSONS OR ORGANIZATIONS This endorsement modifies insurance provided under the following: COMMERCIAL UMBRELLA COVERAGE PART SCHEDULE Name of Person or Organization: AS REQUIRED BY WRITTEN CONTRACT The following is added to Condition J. Other Insurance under SECTION VI. CONDITIONS: However, with respect to a person or organization shown in the Schedule, that qualifies as an additional "Insured" under paragraph F.5. of SECTION V. DEFINITIONS, if a written contract in which you have " agreed to provide insurance for that person or organization expressly requires that this insurance applies on a primary or a primary and non-contributory basis, this insurance will apply as if other insurance available to that person or organization which designates that person or organization as a Named Insured does not exist, and we will not share with that other insurance. Regardless of the written contract between you and the person or organization shown in the Schedule, this insurance is still excess over any other valid and collectible insurance available to that person or organization, whether such insurance is primary, contributing, excess, contingent or otherwise, as respects "autos" or when that person or organization is an additional insured under such other insurance. This endorsement does not change any other provision of the policy. ©2010 Liberty Mutual Insurance Company. All rights reserved. CU 88 40 02 10 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Page 1 of 1 CU 60 02 06 97 COMMERCIAL UMBRELLA COVERAGE FORM There are provisions in this policy that restrict Insuring Agreement, V. DEFINITIONS. Words and coverage. Read the entire policy carefully to deter- phrases that appear in quotation marks have spe- mine rights, duties and what is and is not cov- cial meaning and can be found in the DEFINITION ered. Section or the specific policy provision where they appear. Throughout this policy, the words "you" and "your" refer to the Named Insured as defined in Insuring Agreement, V. DEFINITIONS. The words "we," "us" and 'bur" refer to the Company pro- viding this insurance. The word "Insured" means any person or organization qualifying as such in I. COVERAGE In consideration of the payment of the premium and in reliance upon the statements in the Dec- larations we agree with you to provide coverage as follows: INSURING AGREEMENTS We will pay on behalf of the "Insured" those sums in excess of the "Retained Limit' that the "Insured" becomes legally obligated to pay by reason of liability imposed by law or assumed by the "Insured" under an "insured contract' because of "bodily injury," "property damage," "personal injury," or "advertising injury" that takes place during the Policy Pe- riod and is caused by an 'occurrence" hap- pening anywhere. The amount we will pay for damages is limited as described below in the Insuring Agreement Section II. LIMITS OF IN- SURANCE. 11. LIMITS OF INSURANCE A. The Limits of Insurance shown in Item 4. of the Declarations and the rules below state the most we will pay regardless of the number of: M 1. "Insureds"; 2. "claims" made or "suits" brought; or 3. persons or organizations making "claims" or bringing "suits." CU 60 02 06 97 (Page 1 of 15) B. The General Aggregate Limit is the most we will pay for all damages covered under the Insuring Agreement in Section I., ex- cept: 1. damages included in the "products - completed operations hazard'; and 2. coverages included in the policies list- ed in the Schedule of Underlying Insur- ance to which no underlying aggregate limit applies. The amount stated on the Declarations as the General Aggregate Limit is the most we will pay for all damages arising out of any "bodily injury," "property damage," "personal injury," or "advertising injury" subject to an aggregate limit in the "un- derlying insurance." The General Aggre- gate Limit applies separately and in the same manner as the aggregate limits in the "underlying insurance." C. The Products -Completed Operations Ag- gregate Limit is the most we will pay for all damages included in the "products - completed operations hazard." D. Subject to B. or C. in Section II. LIMITS OF INSURANCE, whichever applies, the Each Occurrence Limit is the most we will pay for "bodily injury," "property damage," "personal injury," or "advertising injury" covered under the Insuring Agreement in Section I. because of all "bodily injury," "property damage," "personal injury," or "advertising injury" arising out of any one "occurrence." E. If the applicable Limits of Insurance of the policies listed in the Schedule of Under- lying Insurance or of other insurance pro- viding coverage to the "Insured" are re- duced or exhausted by actual payment of one or more "claims," subject to the terms and conditions of this policy, we will: 1. in the event of reduction, pay in excess of the reduced underlying Limits of In- surance, or; 2. in the event of exhaustion, continue in force as "underlying insurance," but for no broader coverage than is avail- able under this policy. F. The Limits of Insurance of this policy ap- ply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the begin- ning of the policy period shown in the Declarations, unless the policy period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the last preceding period for pur- poses of determining the Limits of Insur- ance. G. Retained Limit We will be liable only for that portion of damages, subject to the Each Occurrence Limit stated in the Declarations, in excess of the "retained limit," which is the great- er of: 1. the total amounts stated as the ap- plicable limits of the underlying poli- cies listed in the Schedule of Under- lying Insurance and the applicable lim- its of any other insurance providing coverage to the "Insured" during the Policy Period; or 2. the amount stated in the Declarations as Self -Insured Retention as a result of any one "occurrence" not covered by the underlying policies listed in the Schedule of Underlying Insurance nor by any other insurance providing cov- erage to the "Insured" during the Poli- cy Period; and then up to an amount not exceeding the Each Occurrence Limit as stated in the Declarations. Once the Self -Insured Retention has been exhausted by actual payment of "claims" in full by the "Insured," the Self -Insured Retention will not be reapplied or again payable by the "Insured" for said Policy Period, III. DEFENSE CU 60 02 06 97 (Page 2 of 15) A. We will have the right and duty to investi- gate any "claim" and defend any "suit" seeking damages covered by the terms and conditions of this policy when: the applicable Limits of Insurance of the underlying policies listed in the Schedule of Underlying Insurance and the Limits of Insurance of any other insurance providing coverage to the "Insured" have been exhausted by ac- tual payment of "claims" for any "oc- currence" to which this policy applies; or 2. damages are sought for any "occur- rence" which is covered by this policy but not covered by any underlying policies listed in the Schedule of Un- derlying Insurance or any other insur- ance providing coverage to the "In- sured." B. When we assume the defense of any "claim" or "suit": We will investigate any "claim" and defend any "suit" against the "In- sured" seeking damages on account of any "occurrence" covered by this poli- cy. We have the right to investigate, defend and settle the "claim" or "suit" as we deem expedient. 2. All expenses we incur in the investiga- tion of any "claim" or defense of any "suit" are in addition to our Limits of Insurance. 3. We will pay the following as expenses, to the extent that they are not included in the coverage in the underlying poli- cies listed in the Schedule of Under- lying Insurance or in any other insur- ance providing coverage to the "In- sured": a. premiums on bonds to release at- tachments, which bond amounts will not exceed our Limits of In- surance, but we are not obligated to apply for or furnish any such bond; b. premiums on appeal bonds, which bond amounts will not ex- ceed our policy limits, required by law to appeal any "claim" or "suit" we defend, but we are not obligated to apply for or furnish any such bond; c. all costs taxed against the "In- sured" in any "claim" or "suit" we defend; d. pre -judgment interest awarded against the "Insured" on that part of the judgment we pay that is within our applicable Limits of In- surance. If we make an offer to pay the applicable Limits of Insur- ance, we will not pay any pre- judgment interest based on the period of time after the offer; e. all interest that accrues after entry of judgment and before we have paid, offered to pay or deposited in court the part of the judgment that is within our applicable Limit of Insurance; f. the "Insured's" actual and reason- able expenses incurred at our re- quest. C. We will not investigate any "claim" or de- fend any "suit" after our applicable Limits of Insurance have been exhausted by pay- ment of judgments or settlements. D. In all other instances except Subsection A. in Section III. DEFENSE, we will not be obligated to assume charge of the inves- tigation, settlement or defense of any "claim" or "suit" against the "Insured." We will, however, have the right and will be given the opportunity to participate in the settlement, defense and trial of any "claim" or "suit" relative to any "occur- rence" which, in our opinion, may create liability on our part under the terms of this policy. If we exercise such right, we will do so at our own expense. IV. EXCLUSIONS This insurance does not apply to: CU 60 02 06 97 (Page 3 of 15) A. "Bodily injury" or "property damage" ex- pected or intended from the standpoint of the "Insured." This exclusion does not ap- ply to "bodily injury" resulting from the use of reasonable force to protect persons or property. B. Any obligation of the "Insured" under a Workers Compensation, Unemployment Compensation or Disability Benefits Law, or under any similar law, regulation or ordinance. C. Any obligation of the "Insured" under the Employee Retirement Income Security Act of 1974 or any amendments to that act, or under any similar law, regulation or ordi- nance. D. Any obligation of the "Insured" under a No Fault, Uninsured Motorist or Underin- sured Motorist law, or under any similar law, regulation or ordinance. E. "Property damage" to "impaired property" or property that has not been physically injured, arising out of: 1. a defect, deficiency, inadequacy or dangerous condition in "your product" or "your work"; or 2. a delay or failure by you or anyone acting on your behalf to perform a con- tract or agreement in accordance with its terms. This exclusion does not apply to the loss of use of other property arising out of sudden and accidental physical injury to "your product" or "your work" after it has been put to its intended use. F. "Property damage" to "your product" aris- ing out of it or any part of it. G. "Property damage" to "your work" arising out of it or any part of it and included in the "products -completed operations haz- ard." This exclusion does not apply if the damaged work or the work out of which the damage arises was performed on your behalf by a subcontractor. H. Damages claimed for any loss, cost or ex- pense incurred by you or others for the loss of use, withdrawal, recall, inspection, repair, replacement, adjustment, removal or disposal of: 1. "your product"; damages that the "Insured" would have in the absence of the contract or agreement. K. "Advertising injury" arising out of: 1. breach of contract, other than misap- propriation of advertising ideas under an implied contract; 2. the failure of goods, products or ser- vices to conform with advertised qual- ity or performance; 3. the wrong description of the price of goods, products or services; or 4. an offense committed by an "Insured" whose business is advertising, broad- casting, publishing or telecasting. 2. "your work"; or L. Any liability, including but not limited to settlements, judgments, costs, charges, ex- 3. "impaired property" penses, costs of investigations, or the fees of attorneys, experts, or consultants, aris- if such product, work or property is with- ing out of or in any way related to: drawn or recalled from the market or from use by any person or organization because 1. The actual, alleged or threatened pres- of a known or suspected defect, deficiency, ence, discharge, dispersal, seepage, inadequacy or dangerous condition in it. migration, release, or escape of "pollu- tants," however caused. I. "Property damage" to property owned by the "Insured." 2. Any request, demand or order that any "Insured" or others test for, monitor, J. "Personal injury" or "advertising injury": clean-up, remove, contain, treat, de- l. arising out of oral, written, televised, toxify, neutralize or in any way re - videotaped, or electronic publication of spond to or assess the effects of "pol- material, if done by or at the direction lutants." This includes demands, direc- "suits," of the "Insured" with knowledge of its tives, complaints, orders or re - falsity; quests brought by any governmental entity or by any person or group of 2. arising out of oral, written, televised, persons. videotaped, or electronic publication of 3• Steps taken or amounts incurred by a ° material whose first publication took governmental unit or any other person place before the beginning of the poli- or organization to test for, monitor, cy period; clean-up, remove, contain, treat, de- 3. arising out of the willful violation of a toxify or neutralize or assess the ef- penal statute or ordinance committed fects of "pollutants." by or with consent of the "lnsured"; or This exclusion will apply to any liability, 4. for which the "Insured" has assumed costs, charges, or expenses, or any judg- liability in a contract or agreement. ments or settlements, arising directly or This exclusion does not apply to liabil- indirectly out of pollution whether or not ity for the pollution was sudden, accidental, grad- ual, intended, expected, unexpected, pre- ventable or not preventable. CU 60 02 06 97 (Page 4 of 15) As used in this exclusion "pollutants" 3. coercion, demotion, evaluation, reas- means any solid, liquid, gaseous, or ther- signment, discipline, defamation, ha- mal irritant or contaminant, including, but rassment, molestation, humiliation, not limited to smoke, vapor, soot, fumes, discrimination or other employment re - acids, alkalis, chemicals and waste ma- lated practices, policies, acts or omis- terial. Waste material includes materials sions; or which are intended to be or have been recycled, reconditioned or reclaimed. 4. consequential "bodily injury," "proper- ty damage," "personal injury" or "ad- M. "Bodily injury" or "property damage" due vertising injury" as a result of 0.1. to war, whether or not declared, or any act through 0.3. or condition incident to war. War includes civil war, insurrection, rebellion or revoiu- This exclusion applies whether the "In- tion. This exclusion applies only to liability sured" may be held liable as an employer assumed under a contract or agreement. or in any other capacity and to any obliga- tion to share damages with or to repay N. Any liability, including, but not limited to someone else who must pay damages be - settlements, judgments, costs, charges, ex- cause of "bodily injury," "property dam- penses, costs of investigations, or the fees age," "personal injury" or "advertising in - of attorneys, experts, or consultants aris- jury." ing out of or related in any way, either o directly or indirectly, to: P. 'Bodily injury," "property damage," "per- sonal injury" or "advertising injury" ex- 1. asbestos, asbestos products, asbestos- eluded by the Nuclear Energy Liability Ex - containing materials or products, as- elusion attached to this Policy. bestos fibers or asbestos dust, includ- ing, but not limited to, manufacture, 0. The following Items 1. through 4., except mining, use, sale, installation, removal, to the extent that such insurance is pro - or distribution activities; vided by a policy listed in the Schedule of Underlying Insurance, and for no broader 2. exposure to testing for, monitoring of, coverage than is provided by such policy: cleaning up, removing, containing or treating of asbestos, asbestos pro- 1. Liability of any employee with respect ducts, asbestos -containing materials or to "bodily injury," "property damage," products, asbestos fibers or asbestos "personal injury" or "advertising In- dust; or jury" to you or to another employee of the same employer injured in the 3. any obligation to investigate, settle or course of such employment. defend, or indemnify any person against any "claim" or "suit" arising 2. "Bodily injury" or "property damage" out of, or related in any way, either arising out of the ownership, mainten- directly or indirectly, to asbestos, as- ance, operation, use, "loading" or "un- bestos products, asbestos -containing loading" of any watercraft, if such ° materials or products, asbestos fibers watercraft is owned, or chartered with - or asbestos dust. out crew, by or on behalf of any "In- sured." This exclusion will not apply to O. "Bodily injury," "property damage," "per- watercraft while ashore on any prem- sonal injury" or "advertising injury" aris- ises owned by, rented to, or controlled ing out of any: by you. I. refusal to employ or promote; 2. termination of employment; CU 60 02 06 97 (Page 5 of 15) 3. "Bodily injury" or "property damage" arising out of the ownership, mainten- ance, operation, use, "loading" or "un- loading" of any aircraft, if such aircraft is owned, or hired without pilot or crew, by or on behalf of any "Insured." 4. "Bodily injury" to: a. an employee of any "Insured" arising out of and in the course of: i. employment by any "In- sured"; or Ii. performing duties related to the conduct of any 1n- sured's" business; or b. the spouse, child, parent, brother or sister of that employee as a consequence of Paragraph 4.a. This exclusion applies: a. whether any "Insured" may be liable as an employer or in any other capacity; and b. to any obligation to share dam- ages with or repay someone else who must pay damages because of the injury. V. DEFINITIONS A. "Advertising injury" means injury arising solely out of advertising activities of any "Insured" as a result of one or more of the following offenses during the policy pe- riod: 1. oral, written, televised, videotaped, or electronic publication of material that slanders or libels a person or organiza- tion or disparages a person's or or- ganization's goods, products or ser- vices; 2. oral, written, televised, videotaped, or electronic publication of material that violates a person's right of privacy; 3. misappropriation of advertising ideas or style of doing business; 4. infringement of copyright, title or slo- gan; or 5. mental injury, mental anguish, humili- ation, or shock, if directly resulting from Items A.1. through AA CU 60 02 06 97 (Page 6 of 15) B. "Auto" means a land motor vehicle, trailer or semitrailer designed for travel on public roads, including any attached machinery or equipment. "Auto" does not include "mo- bile equipment." C. "Bodily injury" means physical injury, sick- ness, or disease, including death of a per- son. "Bodily injury" also means mental injury, mental anguish, humiliation, or shock if directly resulting from physical injury, sickness, or disease to that person. D. "Claim" means any demand for monetary damages upon an "insured" resulting from a covered "occurrence." E. "Impaired property" means tangible prop- erty, other than "your product" or "your work," that cannot be used or is less use- ful because: 1. it incorporates "your product' or "your work" that is known or thought to be defective, deficient, inadequate or dan- gerous; or 2. you have failed to fulfill the terms of a contract or agreement; if such property can be restored to use by: 1. the repair, replacement, adjustment or removal of "your product' or "your work'; or 2. your fulfilling the terms of the contract or agreement. F. "Insured" means each of the following, to the extent set forth: 1. The Named Insured meaning: a. Any person or organization listed in Item 1. of the Declarations, and any Company of which you own more than 50%, as of the effective date of this policy. b. Any organization you newly ac- quire or form, other than a part- nership, joint venture or limited liability company, and over which you maintain ownership or major- ity interest, will qualify to be a Named Insured. However: (1) coverage under this provi- "unloading" of any "autos," aircraft or sion is afforded only until the watercraft unless such coverage is in- 90th day after you acquire or cluded under the policies listed in the form the organization or the Schedule of Underlying Insurance and end of the policy period, for no broader coverage than is pro - whichever is earlier; vided under such underlying policies. (2) coverage does not apply to Employees include "leased workers" "bodily injury," "property but not "temporary workers." "Leased damage," "personal injury" workers" are leased to you by a labor or "advertising injury" that leasing firm under an agreement be - occurred before you acquired tween you and the labor leasing firm or formed the organization; to perform related duties to the con - and duct of your business. "Leased work- ers" are not "temporary workers." (3) coverage applies only if the "Temporary workers" are persons fur- organization is included un- nished to you to substitute for perma- der the coverage provided by nent employees on leave or to meet the policies listed in the seasonal or short-term workload condi- Schedule of Underlying In- tions. surance and then for no o broader coverage than is 7. Any person, other than one of your provided under such under- employees, or organization while act - lying policies. ing as your real estate manager. 2. If you are an individual, you and your 8. Any person (other than your partners, spouse, but only with respect to the executive officers, directors, stockhol- conduct of a business of which you are ders or employees) or organizations the sole owner as of the effective date with respect to any "auto" owned by of this policy. you, loaned to you or hired by you or on your behalf and used with your per- 3. If you are a partnership or joint ven mission. ture, the partners or members and their spouses but only as respects the However, the coverage granted by this conduct of your business. Provision B. does not apply to any per- son using an "auto" while working in a 4. If you are a limited liability company, business that sells, services, repairs or the members or managers but only as parks "autos" unless you are in that respects the conduct of your business. business. 5. Any person or organization, other than 9. No person or organization is an "In - the Named Insured, included as an ad- sured" with respect to the conduct of ditional "Insured" by virtue of an "in- any current or past partnership or joint sured contract," and to which coverage venture that is not shown as a Named is provided by the "underlying insur- Insured in the Declarations. ance," and for no broader coverage than is provided by the "underlying G. "Insured contract" means any oral or writ - insurance" to such additional "In- ten contract or agreement entered into by sured." you and pertaining to your business under which you assume the "tort liability" of 6. Any of your partners, executive offi- another party to pay for "bodily injury" or cers, directors, or employees but only "property damage" to a third person or while acting within the scope of their organization, provided that the "bodily in - duties. jury" or "property damage" occurs subse- However, the coverage granted by this quent to the execution of the contract or Provision 6. does not apply to the own- ership, maintenance, use, "loading" or CU 60 02 06 97 (Page 7 of 15) agreement. "Tort liability" means a civil liability that would be imposed by law in the absence of any contract or agreement. H. "Loading" or "unloading" means the han- dling of property: 1. after it is removed from the place where it is accepted for movement into or onto an aircraft, watercraft or "auto"; 2. while it is in or on an aircraft, water- craft or "auto"; 3. while it is being moved from an air- craft, watercraft or "auto" to the place where it is finally delivered. However, 'loading" or "unloading" does not include the movement of property by means of a mechanical device, other than a hand truck, that is not attached to the aircraft, watercraft or "auto." I. "Mobile equipment' means any of the fol- lowing types of land vehicles, including any attached machinery or equipment: 1. bulldozers, farm machinery, forklifts and other vehicles designed for use principally off public roads; 2. vehicles maintained for use solely on or next to premises you own or rent; 3. vehicles that travel on crawler treads; 4. vehicles, whether self-propelled or not, maintained primarily to provide mobil- ity to permanently mounted: a. power cranes, shovels, loaders, diggers or drills; or b. road construction or resurfacing equipment such as graders, scrap- ers or rollers; 5. vehicles not described in 1., 2.5 3., or 4. above that are not self-propelled and are maintained primarily to provide mobility to permanently attached equipment of the following types: CU 60 02 06 97 (Page 8 of 15) a. air compressors, pumps and gen- erators, including spraying, weld- ing, building cleaning, geophysi- cal exploration, lighting and well servicing equipment or b. cherry pickers and similar devices used to raise or lower workers; 6. vehicles not described in 1., 2., 3., or 4. above maintained primarily for pur- poses other than the transportation of persons or cargo. However, self-propelled vehicles with the following types of permanently at- tached equipment are not "mobile equipment' but will be considered "autos": a. equipment designed primarily for: (1) snow removal; (2) road maintenance, but not construction or resurfacing; or (3) street cleaning; b. cherry pickers and similar devices mounted on auto or truck chassis and used to raise or lower work- ers; and c. air compressors, pumps and gen- erators, including spraying, weld- ing, building cleaning, geophysi- cal exploration, lighting and well servicing equipment. J. "Occurrence" means: 1. as respects "bodily injury" or "prop- erty damage," an accident, including continuous or repeated exposure to substantially the same general harmful conditions; 2. as respects "personal injury," an of- fense arising out of the business of any 'Insured" that results in "personal injury." All damages that arise from the same or related injurious material or acts will be considered as arising out of one 'occurrence," regardless of the frequency or repetition thereof, the number and kind of media used and the number of claimants; 3. as respects "advertising injury," an of- fense committed in the course of ad- vertising your goods, products and ser- vices that results in "advertising in- jury." All damages that arise from the same or related injurious material or acts will be considered as arising out of one "occurrence," regardless of the frequency or repetition thereof, the number and kind of media used and the number of claimants. K. "Personal injury" means injury other than "bodily injury" or "advertising injury" aris- ing out of one or more of the following offenses during the policy period: I. false arrest, detention or imprison- ment; 2. malicious prosecution; 3. the wrongful eviction from, wrongful entry into, or invasion of the right of private occupancy of a room, dwelling or premises that a person occupies by or on behalf of its owner, landlord or lessor; 4. oral, written, televised, videotaped, or electronic publication of material that slanders or libels a person or organiza- tion or disparages a person's or or- ganization's goods, products or ser- vices; 5. oral, written, televised, videotaped, or electronic publication of material that violates a person's right of privacy; or 6. mental injury, mental anguish, humili- ation, or shock, if directly resulting from Items K.1. through 5. L. 1. "Products -completed operations haz- ard" means all "bodily injury" and "property damage" from an "occur- rence" taking place away from prem- ises you own or rent and arising out of "your product" or "your work" except: a. products that are still in your physical possession; or b, work that has not yet been com- pleted or abandoned. 2. "Your work" will be deemed complet- ed at the earliest of the following times: a. When all of the work called for in your contract has been complet- ed. b. When all of the work to be done at the site has been completed if your contract calls for work at more than one site. c. When that part of the work done at a job site has been put to its intended use by any person or or- ganization other than another con- tractor or subcontractor working on the same project. Work that may need service, mainten- ance, correction, repair or replacement, but which is otherwise complete, will be treated as completed. 3. This "products -completed operations hazard" does not include "bodily in- jury" or "property damage" arising out of: a. the transportation of property, un- less the injury or damage arises out of a condition in or on a ve- hicle created by the "loading" or "unloading" of it; b. the existence of tools, uninstalled equipment or abandoned or un- used materials. M. "Property damage" means: CU 60 02 06 97 (Page 9 of 15) 1. physical injury to tangible property, in- cluding all resulting loss of use of that property. All such loss of use will be deemed to occur at the time of the physical injury that caused it; or 2. loss of use of tangible property that is not physically injured. All such loss will be deemed to occur at the time of the "occurrence" that caused it. N. "Suit" means a civil proceeding which seeks monetary damages because of "bod- ily injury," "property damage," "per- sonal injury," or "advertising injury" to which this insurance applies. "Suit" in- cludes: 1. an arbitration proceeding in which such damages are claimed and to which you must submit or do submit with our consent; or 2. any other alternative dispute resolution proceeding in which such damages are claimed and to which you submit with our consent. O. "Underlying insurance" means the insur- ance coverage provided under policies shown in the Schedule of Underlying In- surance, or any additional policies agreed to by us in writing. It includes any policies issued to replace those policies during the term of this insurance that provide: 1. at least the same policy limits; and 2. insurance for the same hazards, except as to any modifications which are agreed to by us in writing. P. "Your product" means: 1. Any goods or products, other than real property, manufactured, sold, handled, distributed or disposed of by: a. you; b. others trading under your name; or c. a person or organization whose business or assets you have ac- quired; and Z9 2. Containers (other than vehicles) materi- als, parts or equipment furnished in connection with such goods or pro- ducts. "Your product" includes: 1. warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your product"; and 2. the providing of or failure to provide warnings or instructions. "Your product" does not include vending machines or other property rented to or located for the use of others but not sold. 0. "Your work" means: 1. work or operations performed by you or on your behalf; and 2. materials, parts or equipment fur- nished in connection with such work or operations. "Your work" includes: 1. warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your work"; and 2. the providing of or failure to provide warnings or instructions. VI. Conditions A. Appeals If the "Insured" or an "Insured's" under- lying insurers do not appeal a judgment in excess of the "retained limit," we have the right to make such an appeal. If we elect to appeal, our liability on such an award or judgment will not exceed our Limits of Insurance as stated in Item 4. of the Dec- larations plus the cost and expense of such appeal. B. Audit We may audit and examine your books and records as they relate to this policy at any time during the period of this policy and for up to three years after the expira- tion or termination of this policy. C. Bankruptcy or Insolvency CU 60 02 06 97 (Page 10 of 15) The bankruptcy, insolvency or inability to pay of any "Insured" or the bankruptcy, insolvency or inability to pay of any of the Underlying Insurers will not relieve us from the payment of any "claim" or "suit" covered by this policy. Under no circum- stances will such bankruptcy, insolvency or inability to pay require us to drop down and replace the "retained limit" or assume any obligation with the "retained limit." D. Cancellation 1. You may cancel this policy. You must mail or deliver advance written notice to us stating when the cancellation is to take effect. 2. We may cancel this policy. If we cancel because of nonpayment of premium, we must mail or deliver to you not less than ten (10) days advance written no- tice stating when the cancellation is to take effect. If we cancel for any other reason, we must mail or deliver to you not less than thirty (30) days advance written notice stating when the can- cellation is to take effect. Mailing that notice to you at your mailing address shown in Item 1. of the Declarations will be sufficient to prove notice. 3. The policy period will end on the day and hour stated in the cancellation no- tice. 4. If we cancel, final premium will be cal- culated pro rata based on the time this policy was in force. Final premium will not be less than the Minimum Pre- mium as shown in Item 3. of the Dec- larations. 5. If you cancel, final premium will be more than pro rata; it will be based on the time this policy was in force and increased by our short rate cancellation table and procedure. Final premium will not be less than the Minimum Pre- mium as shown in Item 3. of the Dec- larations. 6. Premium adjustment may be made at the time of cancellation or as soon as practicable thereafter but the cancella- tion will be effective even if we have not made or offered any refund due you. Our check or our representative's check, mailed or delivered, will be suf- ficient tender of any refund due you. 7. The first Named Insured in Item 1. of the Declarations will act on behalf of all other "Insured's" with respect to the giving and receiving of notice of can- cellation and the receipt of any refund that may become payable under this policy. 8. Any of these provisions that conflict with a law that controls the cancella- tion of the insurance in this policy is changed by this statement to comply with the law. E. Changes CU 60 02 06 97 (Page 11 of 15) Notice to any agent or knowledge pos- sessed by any agent or any other person will not effect a waiver or a change in any part of this policy. This policy can only be changed by a written endorsement that becomes a part of this policy and that is signed by one of our authorized repre- sentatives. F. Duties in The Event of An Occurrence, Claim Or Suit 1. You must see to it that we are notified as soon as practicable of an "occur- rence" which may result in a "claim" or "suit" under this policy. To the ex- tent possible, notice will include: a. how, when and where the "occur- rence" took place; b. the names and addresses of any injured person and witnesses; c. the nature and location of any in- jury or damage arising out of the "occurrence." 2. If a "claim" or "suit" against any "In- sured" is reasonably likely to involve this policy you must notify us in writ- ing as soon as practicable. 3. You and any other involved "Insured" must: a. immediately send us copies of any demands, notices, summons- es or legal papers received in con- nection with the "claim" or "suit"; b. authorize us to obtain records and other information; c. cooperate with us in the inves- 1. to keep the policies listed in the Sched- tigation, settlement or defense of ule of Underlying Insurance in full the "claim" or "suit"; and force and effect; d. assist us, upon our request, in the 2. that any renewals or replacements of enforcement of any right against the policies listed in the Schedule of any person or organization which Underlying Insurance will not be more may be liable to the "Insured" be- restrictive in coverage; cause of injury or damage to which this insurance may also ap- 3. that the Limits of Insurance of the poli- ply. cies listed in the Schedule of Under- lying Insurance will be maintained ex- 4. The "Insured's" will not, except at cept for any reduction or exhaustion of their own cost, voluntarily make a pay- aggregate limits by payment of ment, assume any obligation, or incur "claims" or "suits" for "occurrences" any expense, other than for first aid, covered by "underlying insurance"; without our consent. and G. Inspection We have the right, but are not obligated, to inspect the premises and operations of any "Insured" at any time. Our inspections are not safety inspections. They relate only to the insurability of the premises and op- erations of any "Insured" and the premi- ums to be charged. We may give you re- ports on the conditions we find. We may also recommend changes. While they may help reduce losses, we do not undertake to perform the duty of any person or organi- zation to provide for the health or safety of any employees or the public. We do not warrant that the premises or operations of any "Insured" are safe or healthful or that they comply with laws, regulations, codes or standards. H. Legal Actions Against Us There will be no right of action against us under this insurance unless: 1. you have complied with all the terms of this policy; and 2. the amount you owe has been deter- mined by settlement with our consent or by actual trial and final judgment; This insurance does not give anyone the right to add us as a party in an action against you to determine your liability. I. Maintenance of Underlying Insurance During the period of this policy, you agree: CU 60 02 06 97 4. that the terms, conditions and endorse- ments of the policies listed in the Schedule of Underlying Insurance will not change during the period of this policy such as to increase the coverage afforded under this policy. If you fail to comply with these require- ments, we will only be liable to the same extent that we would have been had you fully complied with these requirements. J. Other Insurance If other insurance applies to a loss that is also covered by this policy, this policy will apply excess of the other insurance. Noth- ing herein will be construed to make this policy subject to the terms, conditions and limitations of such other insurance. How- ever, this provision will not apply if the other insurance is specifically written to be excess of this policy. K. Premium (Page 12 of 15) The first Named Insured designated in Item 1. of the Declarations will be respon- sible for payment of all premiums when due. The premium for this policy will be com- puted on the basis set forth in Item 3. of the Declarations. At the beginning of the policy period, you must pay us the Ad- vance Premium shown in Item 3. of the Declarations. When this policy expires or if it is can- celed, we will compute the earned pre- mium for the time this policy was in force. If this policy is subject to audit adjust - ment, the actual exposure basis will be used to compute the earned premium. If the earned premium is greater than the Advance Premium, you will promptly pay us the difference. If the earned premium is less than the Advance Premium, we will return the difference to you_ But in any event we will retain the Minimum Pre- mium as shown in Item 3. of the Declara- tions for each twelve months of our policy period. L. Separation of Insureds Except with respect to our Limits of Insur- ance and any rights or duties specifically assigned to the first Named Insured des- ignated in Item 1. of the Declarations, this insurance applies: 1. as if each Named Insured were the only Named Insured; and 2. separately to each "Insured" against whom "claim" is made or "suit" brought. M. Transfer of Rights of Recovery Against Others to Us If any "Insured" has rights to recover all or part of any payment we have made under this policy, those rights are transferred to us. The "Insured" must do nothing after loss to impair those rights and must help us enforce them. Any recoveries will be applied as follows: 1. any interests, including the "Insured," that have paid an amount in excess of our payment under this policy will be reimbursed tirst; 2. we then will be reimbursed up to the amount we have paid; and 3. lastly, any interests, including the "In- sured," over which our insurance is excess, are entitled to claim the resi- due. Expenses incurred in the exercise of rights of recovery will be apportioned between the interests, including the "Insured," in the ratio of their respective recoveries as finally settled. N. Terms Conformed to Statute The terms of this Policy which are in con- flict with the statutes of the state where this Policy is issued are amended to con- form to such statutes. If we are prevented by law or statute from paying on behalf of an "Insured," then we will, where permitted by law or statute, indemnify the "Insured" for those sums in excess of the "retained limit." O. Transfer of Your Rights And Duties Your rights and duties under this policy may not be transferred without our written consent. If you die or are legally declared bankrupt, your rights and duties will be transferred to your legal representative but only while acting within the scope of duties as your legal representative. However, notice of cancellation sent to the first Named In- sured designated in Item 1. of the Declara- tions and mailed to the address shown in this policy will be sufficient notice to effect cancellation of this policy. P. When Loss Is Payable CU 60 02 06 97 (Page 13 of 15) Coverage under this policy will not apply unless and until any "Insured" or an "In- sured's" underlying insurer is obligated to pay the "retained limit." When the amount of loss has finally been determined, we will promptly pay on be- half of the "Insured" the amount of loss failing within the terms of this policy. You will promptly reimburse us for any amount within the Self -Insured Retention advanced by us at our discretion on behalf of any "Insured." NUCLEAR ENERGY LIABILITY EXCLUSION This policy does not apply to: Canada, this Exclusion 2.c. applies only to "nuclear property damage" to such "nu- 1. Any liability, injury or damage: clear facility" and any property therein. a. with respect to which any "Insured" under the policy is also an "Insured" under a nuclear energy liability policy issued by Nuclear Energy Liability Insurance Associ- ation, Mutual Atomic Energy Liability Un- derwriters, Nuclear Insurance Association of Canada or any of their successors, or would be an "Insured" under any such policy but for its termination upon exhaus- tion of its Limits of Insurance; or b. resulting from the "hazardous properties" of "nuclear material" and with respect to which (a) a person or organization is re- quired to maintain financial protection pur- suant to the Atomic Energy Act of 1954, or any law amendatory thereof, or (b) any "Insured" is, or had this policy not been issued would be, entitled to indemnity from the United States of America, or any agency thereof, under any agreement en- tered into by the United States of America, or any agency thereof, with any person or organization. 2. Any injury or "nuclear property damage" re- sulting from the "hazardous properties" of "nuclear material," if: a. the "nuclear material" (a) is at any "nu- clear facility" owned by, or operated by or on behalf of, any "Insured" or (b) has been discharged or dispersed therefrom; b. the "nuclear material" is contained in "spent fuel" or "nuclear waste" at any time possessed, handled, used, processed, stored, transported or disposed of by or on behalf of any "Insured"; or c. the injury or "nuclear property damage" arises out of the furnishing by any "In- sured" of services, materials, parts or equipment in connection with the plan- ning, construction, maintenance, operation or use of any "nuclear facility," but if such facility is located within the United States of America, its territories or possessions or 3. As used in this exclusion: a. "Hazardous properties" includes radioac- tive, toxic or explosive properties. b. "Nuclear facility" means: I. any "nuclear reactor"; li. any equipment or device designed or used for (1) separating the isotopes of urani- um or plutonium, (2) processing or utilizing "spent fuel" or (3) handling, processing or packaging "nuclear waste"; iii. any equipment or device used for the processing, fabricating or alloying of "special nuclear material" if at any time the total amount of such material in the custody of any "Insured" at the premises where such equipment or de- vice is located consists of or contains more than 25 grams of plutonium or uranium 233 or any combination there- of, or more than 250 grams of uranium 235; iv. any structure, basin, excavation, prem- ises or place prepared or used for the storage or disposal of, "nuclear waste," and includes the site on which any of the foregoing is located, all op- erations considered on such site and all premises used for such operations. c. "Nuclear material" means "source mate- rial," "special nuclear material" or by- product material, d. "Nuclear property damage" includes all forms of radioactive contamination of property. CU 60 02 06 97 (Page 14 of 15) e. "Nuclear reactor" means any apparatus designed or used to sustain nuclear fission in a self-supporting chain reaction or to contain a critical mass of fissionable ma- terial. "Nuclear waste" means any nuclear waste material (a) containing "by-product mate- rial' other than the tailings of nuclear waste produced by the extraction or con- centration of uranium or thorium from any ore processed primarily for its "source ma- terial' content, and (b) resulting from the operation by any person or organization of any "nuclear facility" included within the definition of "nuclear facility" under Para- graph 3.b.i. or 3.b.ili. g. "Source material," "special nuclear mate- rial," and "by-product material' have the meanings given them in the Atomic En- ergy Act of 1954 or in any law amendatory thereof. h. "Spent fuel" means any fuel element or fuel component, solid or liquid, which has been used or exposed to radiation in a "nuclear reactor." This endorsement does not change any other pro- vision of the policy. In Witness Whereof, we have caused this policy to be executed and attested, but this policy will not be valid unless countersigned by one of our duly authorized representatives, where required by law. CU 60 02 06 97 (Page 15 of 15) US055548617 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CU 64 95 12 07 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against any person or organization for whom you perform work under a written contract that requires you to obtain this agreement from us to the extent that such insurance is provided by a policy listed in the Schedule of Underlying Insurance, and for no broader coverage than is provided by such policy. This endorsement does not change any other provisions of the policy. CU 64 95 12 07 State of Washington Department of Labor & Industries Prevailing Wage Section - Telephone 360-902-5335 PO Box 44540, Olympia, WA 98504-4540 Washington State Prevailing Wage The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, worker's wage and benefit rates must add to not less than this total. A brief description of overtime calculation requirements are provided on the Benefit Code Key. Journey Level Prevailing Wage Rates for the Effective Date: 4/22/2021 County_ Trade Job Classification Wage Holiday Overtime Note King King King King King King King King King King King King King King King King King Asbestos Abatement Workers Boilermakers Brick Mason Brick Mason Building Service Employees Building Service Employees Building Service Employees Building Service Employees Cabinet Makers (In Shop). Carpenters Carpenters Carpenters Carpenters Carpenters Carpenters Carpenters Cement Masons King Cement Masons King Cement Masons King Cement Masons King King King King King King King Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Journey Level Journey Level Journey Level Pointer -Caulker -Cleaner Janitor Traveling Waxer/Shampooer Window Cleaner (Non -Scaffold) Window Cleaner (Scaffold) Journey Level Acoustical Worker Carpenter Carpenters on Stationary Tools Creosoted Material Floor Finisher Floor Layer Scaffold Erector Application of all Composition Mastic Application of all Epoxy Material Application of all Plastic Material Application of Sealing Compound Application of Underlayment Building General Composition or Kalman Floors Concrete Paving Curb Et Gutter Machine Curb Et Gutter, Sidewalks Curing Concrete $52.39 $70.79 $60.57 $60.57 $26.28 $26.63 $29.98 $30.98 $22.74 $64.94 $64.94 $65.07 $65.07 $64.94 $64.94 $64.94 $64.84 5D 5N 7E 7E 5S 5S 5S 5S 7A 7A 7A 7A 7A 7A 7A 7A $64.34 7A $64.84 7A $64.34 7A 1H 1C 1N 1N 2F 2F 2F 2F 1 4C 4C 4C 4C 4C 4C 4C 4U *Risk Class View View View View View View View View View View View View View View View View View 4U View 4U View 4U View $64.84 7A 41J View $64.34 7A 41J View $64.84 7A 41J View $64.34 7A 41J View $64.84 7A 41J View $64.34 7A 41J View $64.34 7A 41J View King King King King King King King King King King King King King Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons Cement Masons King Cement Masons King Cement Masons King Cement Masons King Cement Masons King King King King King King King King King King King King King King King King King King King King King King King Cement Masons Divers Et Tenders Divers Et Tenders Divers Et Tenders Divers Et Tenders Divers Et Tenders Divers Et Tenders Divers Et Tenders Divers Et Tenders Divers Et Tenders Dredge Workers Dredge Workers Dredge Workers Dredge Workers Dredge Workers Dredge Workers Dredge Workers Drywall Applicator Drywall Tapers Electrical Fixture Maintenance Workers Electricians - Inside Electricians - Inside Electricians - Inside Finish Colored Concrete Floor Grinding Floor Grinding/Polisher Green Concrete Saw, self - powered Grouting of all Plates Grouting of all Tilt -up Panels Gunite Nozzleman Hand Powered Grinder Journey Level Patching Concrete Pneumatic Power Tools Power Chipping Et Brushing Sand Blasting Architectural Finish Screed Et Rodding Machine Spackling or Skim Coat Concrete Troweling Machine Operator Troweling Machine Operator on Colored Slabs Tunnel Workers Bell/Vehicle or Submersible Operator (Not Under Pressure) Dive Supervisor/Master Diver Diver On Standby Diver Tender Manifold Operator Manifold Operator Mixed Gas Remote Operated Vehicle Operator/Technician Remote Operated Vehicle Tender Assistant Engineer Assistant Mate (Deckhand) Boatmen Engineer Welder Leverman, Hydraulic Mates Oiler Journey Level Journey Level Journey Level $64.84 7A 4U View $64.84 7A 4U View $64.34 7A 4U View $64.84 7A 4U View $64.34 7A 4U View $64.34 7A 4U View $64.84 7A 4U View $64.84 7A 4U View $64.34 7A 4U View $64.34 7A 4U View $64.84 7A 4U View $64.84 7A 4U View $64.84 7A 4U View $64.84 7A 4U View $64.34 7A 4U View $64.84 7A 4U View $64.84 7A 4U View $64.84 7A 4U View $118.80 7A 4C View $81.98 7A 4C View $118.80 7A 4C 8V View $76.98 7A 4C View $69.91 7A 4C View $69.91 7A 4C View $74.91 7A 4C View $69.91 7A 4C View $65.19 7A 4C View $70.62 5D 3F View $70.07 5D 3F View $70.62 5D 3F View $71.97 5D 3F View $73.41 5D 3F View $70.62 5D 3F View $70.07 5D 3F View $64.94 5D 1 H View $65.31 5P 1 E View $31.99 5L 1 E View Cable Splicer $92.57 7C 4E View Cable Splicer (tunnel) $99.46 7C 4E View Certified Welder $89.44 7C 4E View King Electricians - Inside Certified Welder (tunnel) $96.02 7C 4E View King Electricians - Inside Construction Stock Person $44.78 7C 4E View King Electricians - Inside Journey Level $86.30 7C 4E View King Electricians - Inside Journey Level (tunnel) $92.57 7C 4E View King Electricians - Motor Shop Journey Level $47.53 5A 1 B View King Electricians - Powerline Cable Splicer $82.39 5A 4D View Construction King Electricians - Powerline Certified Line Welder $75.64 5A 4D View Construction King Electricians - Powerline Groundperson $49.17 5A 4D View Construction King Electricians - Powerline Heavy Line Equipment $75.64 5A 4D View Construction Operator King Electricians - Powerline Journey Level Lineperson $75.64 5A 4D View Construction King Electricians - Powerline Line Equipment Operator $64.54 5A 4D View Construction King Electricians - Powerline Meter Installer $49.17 5A 4D 8W View Construction King Electricians - Powerline Pole Sprayer $75.64 5A 4D View Construction King Electricians - Powerline Powderperson $56.49 5A 4D View Construction King Electronic Technicians Journey Level $53.57 7E 1 E View King Elevator Constructors Mechanic $100.51 7D 4A View King Elevator Constructors Mechanic In Charge $108.53 7D 4A View King Fabricated Precast Concrete All Classifications - In -Factory $18.25 5B 1 R View Products Work Only King Fence Erectors Fence Erector $44.40 7A 4V 8Y View King Fence Erectors Fence Laborer $44.40 7A 4V 8Y View King Flaggers Journey Level $44.40 7A 4V 8Y View King Glaziers Journey Level $69.26 7L 1Y View King Heat Et Frost Insulators And Journeyman $79.43 5J 4H View Asbestos Workers King Heating Equipment Mechanics Journey Level $89.61 7F 1 E View King Hod Carriers Et Mason Tenders Journey Level $54.01 7A 4V 8Y View King Industrial Power Vacuum Journey Level $13.69 1 View Cleaner King Inland Boatmen Boat Operator $61.41 5B 1 K View King Inland Boatmen Cook $56.48 5B 1 K View King Inland Boatmen Deckhand $57.48 5B 1 K View King Inland Boatmen Deckhand Engineer $58.81 5B 1 K View King Inland Boatmen Launch Operator $58.89 5B 1 K View King Inland Boatmen Mate $57.31 5B 1 K View King Inspection/Cleaning/Sealing Of Cleaner Operator, Foamer $31.49 1 View Sewer Et Water Systems By Operator Remote Control King Inspection/Cleaning/Sealing Of Grout Truck Operator $13.69 1 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Head Operator $24.91 1 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Technician $19.33 1 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Tv Truck Operator $20.45 1 View Sewer Et Water Systems By Remote Control King Insulation Applicators Journey Level $64.94 7A 4C T View King Ironworkers Journeyman $76.78 7N 10 View King Laborers Air, Gas Or Electric Vibrating $52.39 7A 4V 8Y View Screed King Laborers Airtrac Drill Operator $54.01 7A 4V 8Y View King Laborers Ballast Regular Machine $52.39 7A 4V 8Y View King Laborers Batch Weighman $44.40 7A 4V 8Y View King Laborers Brick Pavers $52.39 7A 4V 8Y View King Laborers Brush Cutter $52.39 7A 4V 8Y View King Laborers Brush Hog Feeder $52.39 7A 4V 8Y View King Laborers Burner $52.39 7A 4V 8Y View King Laborers Caisson Worker $54.01 7A 4V 8Y View King Laborers Carpenter Tender $52.39 7A 4V 8Y View King Laborers Cement Dumper -paving $53.35 7A 4V 8Y View King Laborers Cement Finisher Tender $52.39 7A 4V 8Y View King Laborers Change House Or Dry Shack $52.39 7A 4V 8Y View King Laborers Chipping Gun (30 Lbs. And $53.35 7A 4V 8Y View Over) King Laborers Chipping Gun (Under 30 Lbs.) $52.39 7A 4V 8Y View King Laborers Choker Setter $52.39 7A 4V 8Y View King Laborers Chuck Tender $52.39 7A 4V 8Y View King Laborers Clary Power Spreader $53.35 7A 4V 8Y View King Laborers Clean-up Laborer $52.39 7A 4V 8Y View King Laborers Concrete Dumper/Chute $53.35 7A 4V 8Y View Operator King Laborers Concrete Form Stripper $52.39 7A 4V 8Y View King Laborers Concrete Placement Crew $53.35 7A 4V 8Y View King Laborers Concrete Saw Operator/Core $53.35 7A 4V 8Y View Driller King Laborers Crusher Feeder $44.40 7A 4V 8Y View King Laborers Curing Laborer $52.39 7A 4V 8Y View King Laborers Demolition: Wrecking Et Moving $52.39 7A 4V 8Y View (Incl. Charred Material) King Laborers Ditch Digger $52.39 7A 4V 8Y View King Laborers Diver $54.01 7A 4V 8Y View King Laborers Drill Operator (Hydraulic, $53.35 7A 4V 8Y View Diamond) King Laborers Dry Stack Walls $52.39 7A 4V 8Y View King Laborers Dump Person $52.39 7A 4V 8Y View King Laborers Epoxy Technician $52.39 7A 4V 8Y View King Laborers Erosion Control Worker $52.39 7A 4V 8Y View King Laborers Faller Et Bucker Chain Saw $53.35 7A 4V 8Y View King Laborers Fine Graders $52.39 7A 4V 8Y View King Laborers Firewatch $44.40 7A 4V 8Y View King Laborers Form Setter $52.39 7A 4V 8Y View King Laborers Gabian Basket Builders $52.39 7A 4V 8Y View King Laborers General Laborer $52.39 7A 4V 8Y View King Laborers Grade Checker Et Transit Person $54.01 7A 4V 8Y View King Laborers Grinders $52.39 7A 4V 8Y View King Laborers Grout Machine Tender $52.39 7A 4V 8Y View King Laborers Groutmen (Pressure) Including $53.35 7A 4V 8Y View Post Tension Beams King Laborers Guardrail Erector $52.39 7A 4V 8Y View King Laborers Hazardous Waste Worker (Level $54.01 7A 4V 8Y View A) King Laborers Hazardous Waste Worker (Level $53.35 7A 4V 8Y View B) King Laborers Hazardous Waste Worker (Level $52.39 7A 4V 8Y View C) King Laborers High Scaler $54.01 7A 4V 8Y View King Laborers Jackhammer $53.35 7A 4V 8Y View King Laborers Laserbeam Operator $53.35 7A 4V 8Y View King Laborers Maintenance Person $52.39 7A 4V 8Y View King Laborers Manhole Builder-Mudman $53.35 7A 4V 8Y View King Laborers Material Yard Person $52.39 7A 4V 8Y View King Laborers Motorman -Dinky Locomotive $53.35 7A 4V 8Y View King Laborers Nozzleman (Concrete Pump, $53.35 7A 4V 8Y View Green Cutter When Using Combination Of High Pressure Air Et Water On Concrete Et Rock, Sandblast, Gunite, Shotcrete, Water Blaster, Vacuum Blaster) King Laborers Pavement Breaker $53.35 7A 4V 8Y View King Laborers Pilot Car $44.40 7A 4V 8Y View King Laborers Pipe Layer Lead $54.01 7A 4V 8Y View King Laborers Pipe Layer/Tailor $53.35 7A 4V 8Y View King Laborers Pipe Pot Tender $53.35 7A 4V 8Y View King Laborers Pipe Reliner $53.35 7A 4V 8Y View King Laborers Pipe Wrapper $53.35 7A 4V 8Y View King Laborers Pot Tender $52.39 7A 4V 8Y View King Laborers Powderman $54.01 7A 4V 8Y View King Laborers Powderman's Helper $52.39 7A 4V 8Y View King Laborers Power Jacks $53.35 7A 4V 8Y View King Laborers Railroad Spike Puller - Power $53.35 7A 4V 8Y View King Laborers Raker - Asphalt $54.01 7A 4V 8Y View King Laborers Re-timberman $54.01 7A 4V 8Y View King Laborers Remote Equipment Operator $53.35 7A 4V 8Y View King Laborers Rigger/Signal Person $53.35 7A 4V 8Y View King Laborers Rip Rap Person $52.39 7A 4V 8Y View King Laborers Rivet Buster $53.35 7A 4V 8Y View King Laborers Rodder $53.35 7A 4V 8Y View King Laborers Scaffold Erector $52.39 7A 4V 8Y View King Laborers Scale Person $52.39 7A 4V 8Y View King Laborers Sloper (Over 20") $53.35 7A 4V 8Y View King Laborers Sloper Sprayer $52.39 7A 4V 8Y View King Laborers Spreader (Concrete) $53.35 7A 4V 8Y View King Laborers Stake Hopper $52.39 7A 4V 8Y View King Laborers Stock Piler $52.39 7A 4V 8Y View King Laborers Swinging Stage/Boatswain $44.40 7A 4V 8Y View Chair King Laborers Tamper Et Similar Electric, Air $53.35 7A 4V 8Y View Et Gas Operated Tools King Laborers Tamper (Multiple Et Self- $53.35 7A 4V 8Y View propelled) King Laborers Timber Person - Sewer (Lagger, $53.35 7A 4V 8Y View Shorer Et Cribber) King Laborers Toolroom Person (at Jobsite) $52.39 7A 4V 8Y View King Laborers Topper $52.39 7A 4V 8Y View King Laborers Track Laborer $52.39 7A 4V 8Y View King Laborers Track Liner (Power) $53.35 7A 4V 8Y View King Laborers Traffic Control Laborer $47.48 7A 4V 9C View King Laborers Traffic Control Supervisor $50.31 7A 4V 9C View King Laborers Truck Spotter $52.39 7A 4V 8Y View King Laborers Tugger Operator $53.35 7A 4V 8Y View King Laborers Tunnel Work -Compressed Air $129.67 7A 4V 9B View Worker 0-30 psi King Laborers Tunnel Work -Compressed Air $134.70 7A 4V 9B View Worker 30.01-44.00 psi King Laborers Tunnel Work -Compressed Air $138.38 7A 4V 9B View Worker 44.01-54.00 psi King Laborers Tunnel Work -Compressed Air $144.08 7A 4V 9B View Worker 54.01-60.00 psi King Laborers Tunnel Work -Compressed Air $146.20 7A 4V 9B View Worker 60.01-64.00 psi King Laborers Tunnel Work -Compressed Air $151.30 7A 4V 9B View Worker 64.01-68.00 psi King Laborers Tunnel Work -Compressed Air $153.20 7A 4V 9B View Worker 68.01-70.00 psi King Laborers Tunnel Work -Compressed Air $155.20 7A 4V 9B View Worker 70.01-72.00 psi King Laborers Tunnel Work -Compressed Air $157.20 7A 4V 9B View Worker 72.01-74.00 psi King Laborers Tunnel Work-Guage and Lock $54.11 7A 4V 8Y View Tender King Laborers Tunnel Work -Miner $54.11 7A 4V 8Y View King Laborers Vibrator $53.35 7A 4V 8Y View King Laborers Vinyl Seamer $52.39 7A 4V 8Y View King Laborers Watchman $40.36 7A 4V 8Y View King Laborers Welder $53.35 7A 4V 8Y View King Laborers Well Point Laborer $53.35 7A 4V 8Y View King Laborers Window Washer/Cleaner $40.36 7A 4V 8Y View King Laborers - Underground Sewer General Laborer Et Topman $52.39 7A 4V 8Y View Et Water King Laborers - Underground Sewer Pipe Layer $53.35 7A 4V 8Y View Et Water King Landscape Construction Landscape $40.36 7A 4V 8Y View Construction/Landscaping Or Planting Laborers King Landscape Construction Landscape Operator $72.28 7A 3K 8X View King Landscape Maintenance Groundskeeper $17.87 1 View King Lathers Journey Level $64.94 5D 1 H View King Marble Setters Journey Level $60.57 7E 1 N View King Metal Fabrication (In Shop). Journey Level $41.70 15F 11A View King Millwright Journey Level $66.44 7A 4C View King Modular Buildings Cabinet Assembly $13.69 1 View King Modular Buildings Electrician $13.69 1 View King Modular Buildings Equipment Maintenance $13.69 1 View King Modular Buildings Plumber $13.69 1 View King Modular Buildings Production Worker $13.69 1 View King Modular Buildings Tool Maintenance $13.69 1 View King Modular Buildings Utility Person $13.69 1 View King Modular Buildings Welder $13.69 1 View King Painters Journey Level $45.40 6Z 2B View King Pile Driver Crew Tender $69.91 7A 4C View King Pile Driver Crew Tender/Technician $69.91 7A 4C View King Pile Driver Hyperbaric Worker - $80.76 7A 4C View Compressed Air Worker 0-30.00 PSI King Pile Driver Hyperbaric Worker - $85.76 7A 4C View Compressed Air Worker 30.01 44.00 PSI King Pile Driver Hyperbaric Worker - $89.76 7A 4C View Compressed Air Worker 44.01 - 54.00 PSI King Pile Driver Hyperbaric Worker - $94.76 7A 4C View Compressed Air Worker 54.01 60.00 PSI King Pile Driver Hyperbaric Worker - $97.26 7A 4C View Compressed Air Worker 60.01 - 64.00 PSI King Pile Driver Hyperbaric Worker - $102.26 7A 4C View Compressed Air Worker 64.01 68.00 PSI King Pile Driver Hyperbaric Worker - $104.26 7A 4C View Compressed Air Worker 68.01 70.00 PSI King Pile Driver Hyperbaric Worker - $106.26 7A 4C View Compressed Air Worker 70.01 - 72.00 PSI King Pile Driver Hyperbaric Worker - $108.26 7A 4C View Compressed Air Worker 72.01 74.00 PSI King Pile Driver Journey Level $65.19 7A 4C View King Plasterers Journey Level $61.67 M 1 R View King Playground Et Park Equipment Journey Level $13.69 1 View Installers King Plumbers & Pipefitters Journey Level $92.19 6Z 1G View King Power Equipment Operators Asphalt Plant Operators $73.49 7A 3K 8X View King Power Equipment Operators Assistant Engineer $69.12 7A 3K 8X View King Power Equipment Operators Barrier Machine (zipper) $72.84 7A 3K 8X View King Power Equipment Operators Batch Plant Operator: concrete $72.84 7A 3K 8X View King Power Equipment Operators Bobcat $69.12 7A 3K 8X View King Power Equipment Operators Brokk - Remote Demolition $69.12 7A 3K 8X View Equipment King Power Equipment Operators Brooms $69.12 7A 3K 8X View King Power Equipment Operators Bump Cutter $72.84 7A 3K 8X View King Power Equipment Operators Cableways $73.49 7A 3K 8X View King Power Equipment Operators Chipper $72.84 7A 3K 8X View King Power Equipment Operators Compressor $69.12 7A 3K 8X View King Power Equipment Operators Concrete Finish Machine - $69.12 7A 3K 8X View Laser Screed King Power Equipment Operators Concrete Pump - Mounted Or $72.28 7A 3K 8X View Trailer High Pressure Line Pump, Pump High Pressure King Power Equipment Operators Concrete Pump: Truck Mount $73.49 7A 3K 8X View With Boom Attachment Over 42 M King Power Equipment Operators Concrete Pump: Truck Mount $72.84 7A 3K 8X View With Boom Attachment Up To 42m King Power Equipment Operators Conveyors $72.28 7A 3K 8X View King Power Equipment Operators Cranes friction: 200 tons and $75.72 7A 3K 8X View over King Power Equipment Operators Cranes: 100 tons through 199 $74.22 7A 3K 8X View tons, or 150' of boom (including jib with attachments) King Power Equipment Operators Cranes: 20 Tons Through 44 $72.84 7A 3K 8X View Tons With Attachments King Power Equipment Operators Cranes: 200 tons- 299 tons, or $74.99 7A 3K 8X View 250' of boom including jib with attachments King Power Equipment Operators Cranes: 300 tons and over or $75.72 7A 3K 8X View 300' of boom including jib with attachments King Power Equipment Operators Cranes: 45 Tons Through 99 $73.49 7A 3K 8X View Tons, Under 150' Of Boom (including Jib With Attachments) King Power Equipment Operators Cranes: A -frame - 10 Tons And $69.12 7A 3K 8X View Under King Power Equipment Operators Cranes: Friction cranes through $74.99 7A 3K 8X View 199 tons King Power Equipment Operators Cranes: through 19 tons with $72.28 7A 3K 8X View attachments, A -frame over 10 tons King Power Equipment Operators Crusher $72.84 7A 3K 8X View King Power Equipment Operators Deck Engineer/Deck Winches $72.84 7A 3K 8X View (power) King Power Equipment Operators Derricks, On Building Work $73.49 7A 3K 8X View King Power Equipment Operators Dozers D-9 Ft Under $72.28 7A 3K 8X View King Power Equipment Operators Drill Oilers: Auger Type, Truck $72.28 7A 3K 8X View Or Crane Mount King Power Equipment Operators Drilling Machine $74.22 7A 3K 8X View King Power Equipment Operators Elevator And Man -lift: $69.12 7A 3K 8X View Permanent And Shaft Type King Power Equipment Operators Finishing Machine, Bidwell And $72.84 7A 3K 8X View Gamaco Et Similar Equipment King Power Equipment Operators Forklift: 3000 Lbs And Over $72.28 7A 3K 8X View With Attachments King Power Equipment Operators Forklifts: Under 3000 Lbs. With $69.12 7A 3K 8X View Attachments King Power Equipment Operators Grade Engineer: Using Blue $72.84 7A 3K 8X View Prints, Cut Sheets, Etc King Power Equipment Operators Gradechecker/Stakeman $69.12 7A 3K 8X View King Power Equipment Operators Guardrail Punch $72.84 7A 3K 8X View King Power Equipment Operators Hard Tail End Dump $73.49 7A 3K 8X View Articulating Off- Road Equipment 45 Yards. &t Over King Power Equipment Operators Hard Tail End Dump $72.84 7A 3K 8X View Articulating Off -road Equipment Under 45 Yards King Power Equipment Operators Horizontal/Directional Drill $72.28 7A 3K 8X View Locator King Power Equipment Operators Horizontal/Directional Drill $72.84 7A 3K 8X View Operator King Power Equipment Operators Hydralifts/Boom Trucks Over $72.28 7A 3K 8X View 10 Tons King Power Equipment Operators Hydralifts/Boom Trucks, 10 $69.12 7A 3K 8X View Tons And Under King Power Equipment Operators Loader, Overhead 8 Yards. Ft $74.22 7A 3K 8X View Over King Power Equipment Operators Loader, Overhead, 6 Yards. But $73.49 7A 3K 8X View Not Including 8 Yards King Power Equipment Operators Loaders, Overhead Under 6 $72.84 7A 3K 8X View Yards King Power Equipment Operators Loaders, Plant Feed $72.84 7A 3K 8X View King Power Equipment Operators Loaders: Elevating Type Belt $72.28 7A 3K 8X View King Power Equipment Operators Locomotives, All $72.84 7A 3K 8X View King Power Equipment Operators Material Transfer Device $72.84 7A 3K 8X View King Power Equipment Operators Mechanics, All (leadmen - $74.22 7A 3K 8X View $0.50 Per Hour Over Mechanic) King Power Equipment Operators Motor Patrol Graders $73.49 7A 3K 8X View King Power Equipment Operators Mucking Machine, Mole, Tunnel $73.49 7A 3K 8X View Drill, Boring, Road Header And/or Shield King Power Equipment Operators Oil Distributors, Blower $69.12 7A 3K 8X View Distribution E. Mulch Seeding Operator King Power Equipment Operators Outside Hoists (Elevators And $72.28 7A 3K 8X View Manlifts), Air Tuggers, Strato King Power Equipment Operators Overhead, Bridge Type Crane: $72.84 7A 3K 8X View 20 Tons Through 44 Tons King Power Equipment Operators Overhead, Bridge Type: 100 $74.22 7A 3K 8X View Tons And Over King Power Equipment Operators Overhead, Bridge Type: 45 Tons $73.49 7A 3K 8X View Through 99 Tons King Power Equipment Operators Pavement Breaker $69.12 7A 3K 8X View King Power Equipment Operators Pile Driver (other Than Crane $72.84 7A 3K 8X View Mount) King Power Equipment Operators Plant Oiler - Asphalt, Crusher $72.28 7A 3K 8X View King Power Equipment Operators Posthole Digger, Mechanical $69.12 7A 3K 8X View King Power Equipment Operators Power Plant $69.12 7A 3K 8X View King Power Equipment Operators Pumps - Water $69.12 7A 3K 8X View King Power Equipment Operators Quad 9, Hd 41, D10 And Over $73.49 7A 3K 8X View King Power Equipment Operators Quick Tower - No Cab, Under $69.12 7A 3K 8X View 100 Feet In Height Based To Boom King Power Equipment Operators Remote Control Operator On $73.49 7A 3K 8X View Rubber Tired Earth Moving Equipment King Power Equipment Operators Rigger and Bellman $69.12 7A 3K 8X View King Power Equipment Operators Rigger/Signal Person, Bellman $72.28 7A 3K 8X View (Certified) King Power Equipment Operators Rollagon $73.49 7A 3K 8X View King Power Equipment Operators Roller, Other Than Plant Mix $69.12 7A 3K 8X View King Power Equipment Operators Roller, Plant Mix Or Multi -lift $72.28 7A 3K 8X View Materials King Power Equipment Operators Roto-mill, Roto-grinder $72.84 7A 3K 8X View King Power Equipment Operators Saws - Concrete $72.28 7A 3K 8X View King Power Equipment Operators Scraper, Self Propelled Under $72.84 7A 3K 8X View 45 Yards King Power Equipment Operators Scrapers - Concrete Et Carry All $72.28 7A 3K 8X View King Power Equipment Operators Scrapers, Self-propelled: 45 $73.49 7A 3K 8X View Yards And Over King Power Equipment Operators Service Engineers - Equipment $72.28 7A 3K 8X View King Power Equipment Operators Shotcrete/Gunite Equipment $69.12 7A 3K 8X View King Power Equipment Operators Shovel, Excavator, Backhoe, $72.28 7A 3K 8X View Tractors Under 15 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoe: $73.49 7A 3K 8X View Over 30 Metric Tons To 50 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes, $72.84 7A 3K 8X View Tractors: 15 To 30 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes: $74.22 7A 3K 8X View Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes: $74.99 7A 3K 8X View Over 90 Metric Tons King Power Equipment Operators Slipform Pavers $73.49 7A 3K 8X View King Power Equipment Operators Spreader, Topsider Et $73.49 7A 3K 8X View Screedman King Power Equipment Operators Subgrader Trimmer $72.84 7A 3K 8X View King Power Equipment Operators Tower Bucket Elevators $72.28 7A 3K 8X View King Power Equipment Operators Tower Crane Up To 175' In $74.22 7A 3K 8X View Height Base To Boom King Power Equipment Operators Tower Crane: over 175' through $74.99 7A 3K 8X View 250' in height, base to boom King Power Equipment Operators Tower Cranes: over 250' in $75.72 7A 3K 8X View height from base to boom King Power Equipment Operators Transporters, All Track Or Truck $73.49 7A 3K 8X View Type King Power Equipment Operators Trenching Machines $72.28 7A 3K 8X View King Power Equipment Operators Truck Crane Oiler/driver - 100 $72.84 7A 3K 8X View Tons And Over King Power Equipment Operators Truck Crane Oiler/Driver Under $72.28 7A 3K 8X View 100 Tons King Power Equipment Operators Truck Mount Portable Conveyor $72.84 7A 3K 8X View King Power Equipment Operators Welder $73.49 7A 3K 8X View King Power Equipment Operators Wheel Tractors, Farman Type $69.12 7A 3K 8X View King Power Equipment Operators Yo Yo Pay Dozer $72.84 7A 3K 8X View King Power Equipment Operators- Asphalt Plant Operators $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Assistant Engineer $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Barrier Machine (zipper) $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Batch Plant Operator, Concrete $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Bobcat $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Brokk - Remote Demolition $69.12 7A 3K 8X View Underground Sewer Et Water Equipment King Power Equipment Operators- Brooms $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Bump Cutter $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Cableways $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Chipper $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Compressor $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Concrete Finish Machine - $69.12 7A 3K 8X View Underground Sewer Et Water Laser Screed King Power Equipment Operators- Concrete Pump - Mounted Or $72.28 7A 3K 8X View Underground Sewer Et Water Trailer High Pressure Line Pump, Pump High Pressure King Power Equipment Operators- Concrete Pump: Truck Mount $73.49 7A 3K 8X View Underground Sewer Et Water With Boom Attachment Over 42 M King Power Equipment Operators- Concrete Pump: Truck Mount $72.84 7A 3K 8X View Underground Sewer Et Water With Boom Attachment Up To 42m King Power Equipment Operators- Conveyors $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Cranes friction: 200 tons and $75.72 7A 3K 8X View Underground Sewer Et Water over King Power Equipment Operators- Cranes: 100 tons through 199 $74.22 7A 3K 8X View Underground Sewer Et Water tons, or 150' of boom (including jib with attachments) King Power Equipment Operators- Cranes: 20 Tons Through 44 $72.84 7A 3K 8X View Underground Sewer Et Water Tons With Attachments King Power Equipment Operators- Cranes: 200 tons- 299 tons, or $74.99 7A 3K 8X View Underground Sewer Et Water 250' of boom including jib with attachments King Power Equipment Operators- Cranes: 300 tons and over or $75.72 7A 3K 8X View Underground Sewer Et Water 300' of boom including jib with attachments King Power Equipment Operators- Cranes: 45 Tons Through 99 $73.49 7A 3K 8X I View Underground Sewer Et Water Tons, Under 150' Of Boom (including Jib With Attachments) King Power Equipment Operators- Cranes: A -frame - 10 Tons And $69.12 7A 3K 8X View Underground Sewer Et Water Under King Power Equipment Operators- Cranes: Friction cranes through $74.99 7A 3K 8X View Underground Sewer Et Water 199 tons King Power Equipment Operators- Cranes: through 19 tons with $72.28 7A 3K 8X View Underground Sewer Et Water attachments, A -frame over 10 I tons King Power Equipment Operators- Crusher $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Deck Engineer/Deck Winches $72.84 7A 3K 8X View Underground Sewer Et Water (power) King Power Equipment Operators- Derricks, On Building Work $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Dozers D-9 Et Under $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Drill Oilers: Auger Type, Truck $72.28 7A 3K 8X View Underground Sewer Et Water Or Crane Mount King Power Equipment Operators- Drilling Machine $74.22 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Elevator And Man -lift: $69.12 7A 3K 8X View Underground Sewer Et Water Permanent And Shaft Type King Power Equipment Operators- Finishing Machine, Bidwell And $72.84 7A 3K 8X View Underground Sewer Et Water Gamaco Et Similar Equipment King Power Equipment Operators- Forklift: 3000 Lbs And Over $72.28 7A 3K 8X View Underground Sewer Et Water With Attachments King Power Equipment Operators- Forklifts: Under 3000 Lbs. With $69.12 7A 3K 8X View Underground Sewer Et Water Attachments King Power Equipment Operators- Grade Engineer: Using Blue $72.84 7A 3K 8X View Underground Sewer Et Water Prints, Cut Sheets, Etc King Power Equipment Operators- Gradechecker/Stakeman $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Guardrail Punch $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Hard Tail End Dump $73.49 7A 3K 8X View Underground Sewer Et Water Articulating Off- Road Equipment 45 Yards. Et Over King Power Equipment Operators- Hard Tail End Dump $72.84 7A 3K 8X View Underground Sewer Et Water Articulating Off -road Equipment Under 45 Yards King Power Equipment Operators- Horizontal/Directional Drill $72.28 7A 3K 8X View Underground Sewer Et Water Locator King Power Equipment Operators- Horizontal/Directional Drill $72.84 7A 3K 8X View Underground Sewer Et Water Operator King Power Equipment Operators- Hydralifts/Boom Trucks Over $72.28 7A 3K 8X View Underground Sewer Et Water 10 Tons King Power Equipment Operators- Hydralifts/Boom Trucks, 10 $69.12 7A 3K 8X View Underground Sewer Et Water Tons And Under King Power Equipment Operators- Loader, Overhead 8 Yards. Et $74.22 7A 3K 8X View Underground Sewer Et Water Over King Power Equipment Operators- Loader, Overhead, 6 Yards. But $73.49 7A 3K 8X View Underground Sewer Et Water Not Including 8 Yards King Power Equipment Operators- Loaders, Overhead Under 6 $72.84 7A 3K 8X View Underground Sewer Et Water Yards King Power Equipment Operators- Loaders, Plant Feed $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Loaders: Elevating Type Belt $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Locomotives, All $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Material Transfer Device $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Mechanics, All (leadmen - $74.22 7A 3K 8X View Underground Sewer Et Water $0.50 Per Hour Over Mechanic) King Power Equipment Operators- Motor Patrol Graders $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Mucking Machine, Mole, Tunnel $73.49 7A 3K 8X View Underground Sewer Et Water Drill, Boring, Road Header And/or Shield King Power Equipment Operators- Oil Distributors, Blower $69.12 7A 3K 8X View Underground Sewer Et Water Distribution Et Mulch Seeding Operator King Power Equipment Operators- Outside Hoists (Elevators And $72.28 7A 3K 8X View Underground Sewer Et Water Manlifts), Air Tuggers, Strato King Power Equipment Operators- Overhead, Bridge Type Crane: $72.84 7A 3K 8X View Underground Sewer Et Water 20 Tons Through 44 Tons King Power Equipment Operators- Overhead, Bridge Type: 100 $74.22 7A 3K 8X View Underground Sewer Et Water Tons And Over King Power Equipment Operators- Overhead, Bridge Type: 45 Tons $73.49 7A 3K 8X View Underground Sewer Et Water Through 99 Tons King Power Equipment Operators- Pavement Breaker $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Pile Driver (other Than Crane $72.84 7A 3K 8X View Underground Sewer Et Water Mount) King Power Equipment Operators- Plant Oiler - Asphalt, Crusher $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Posthole Digger, Mechanical $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Power Plant $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Pumps - Water $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Quad 9, Hd 41, D10 And Over $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Quick Tower - No Cab, Under $69.12 7A 3K 8X View Underground Sewer Et Water 100 Feet In Height Based To Boom King Power Equipment Operators- Remote Control Operator On $73.49 7A 3K 8X View Underground Sewer Et Water Rubber Tired Earth Moving Equipment King Power Equipment Operators- Rigger and Bellman $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Rigger/Signal Person, Bellman $72.28 7A 3K 8X View Underground Sewer Et Water (Certified) King Power Equipment Operators- Rollagon $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Roller, Other Than Plant Mix $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Roller, Plant Mix Or Multi -lift $72.28 7A 3K 8X View Underground Sewer Et Water Materials King Power Equipment Operators- Roto-mill, Roto-grinder $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Saws - Concrete $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Scraper, Self Propelled Under $72.84 7A 3K 8X View Underground Sewer Et Water 45 Yards King Power Equipment Operators- Scrapers - Concrete Et Carry All $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Scrapers, Self-propelled: 45 $73.49 7A 3K 8X View Underground Sewer Et Water Yards And Over King Power Equipment Operators- Service Engineers - Equipment $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Shotcrete/Gunite Equipment $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Shovel, Excavator, Backhoe, $72.28 7A 3K 8X View Underground Sewer Et Water Tractors Under 15 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoe: $73.49 7A 3K 8X View Underground Sewer Et Water Over 30 Metric Tons To 50 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes, $72.84 7A 3K 8X View Underground Sewer Et Water Tractors: 15 To 30 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes: $74.22 7A 3K 8X View Underground Sewer Et Water Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes: $74.99 7A 3K 8X View Underground Sewer Et Water Over 90 Metric Tons King Power Equipment Operators- Slipform Pavers $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Spreader, Topsider Et $73.49 7A 3K 8X View Underground Sewer Et Water Screedman King Power Equipment Operators- Subgrader Trimmer $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Tower Bucket Elevators $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Tower Crane Up To 175' In $74.22 7A 3K 8X View Underground Sewer Et Water Height Base To Boom King Power Equipment Operators- Tower Crane: over 175through $74.99 7A 3K 8X View Underground Sewer Et Water 250' in height, base to boom King Power Equipment Operators- Tower Cranes: over 250' in $75.72 7A 3K 8X View Underground Sewer Et Water height from base to boom King Power Equipment Operators- Transporters, All Track Or Truck $73.49 7A 3K 8X View Underground Sewer Et Water Type King Power Equipment Operators- Trenching Machines $72.28 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Truck Crane Oiler/driver - 100 $72.84 7A 3K 8X View Underground Sewer Et Water Tons And Over King Power Equipment Operators- Truck Crane Oiler/Driver Under $72.28 7A 3K 8X View Underground Sewer Et Water 100 Tons King Power Equipment Operators- Truck Mount Portable Conveyor $72.84 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Welder $73.49 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Wheel Tractors, Farmall Type $69.12 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Yo Yo Pay Dozer $72.84 7A 3K 8X View Underground Sewer Et Water King Power Line Clearance Tree Journey Level In Charge $55.03 5A 4A View Trimmers King Power Line Clearance Tree Spray Person $52.24 5A 4A View Trimmers King Power Line Clearance Tree Tree Equipment Operator $55.03 5A 4A View Trimmers King Power Line Clearance Tree Tree Trimmer $49.21 5A 4A View Trimmers King Power Line Clearance Tree Tree Trimmer Groundperson $37.47 5A 4A View Trimmers King Refrigeration Et Air Journey Level $87.01 6Z 1G View Conditioning Mechanics King Residential Brick Mason Journey Level $60.57 7E 1 N View King Residential Carpenters Journey Level $36.44 1 View King Residential Cement Masons Journey Level $46.64 1 View King Residential Drywall Applicators Journey Level $64.94 7A 4C View King Residential Drywall Tapers Journey Level $36.36 1 View King Residential Electricians Journey Level $48.80 1 View King Residential Glaziers Journey Level $28.93 1 View King Residential Insulation Journey Level $28.18 1 View Applicators King Residential Laborers Journey Level $29.73 1 View King Residential Marble Setters Journey Level $27.38 1 View King Residential Painters Journey Level $23.47 1 View King Residential Plumbers Et Journey Level $92.19 6Z 1G View Pipefitters King Residential Refrigeration Et Air Journey Level $87.01 6Z 1G View Conditioning Mechanics King Residential Sheet Metal Journey Level $89.61 7F 1 E View Workers King Residential Soft Floor Layers Journey Level $51.91 5A 3J View King Residential Sprinkler Fitters Journey Level $53.04 5C 2R View .(Fire Protection), King Residential Stone Masons Journey Level $60.57 7E 1 N View King Residential Terrazzo Workers Journey Level $55.71 7E 1 N View King Residential Terrazzo/Tile Journey Level $24.39 1 View Finishers King Residential Tile Setters Journey Level $21.04 1 View King Roofers Journey Level $57.30 5A 3H View King Roofers Using Irritable Bituminous $60.30 5A 3H View Materials King Sheet Metal Workers Journey Level (Field or Shop) $89.61 7F 1 E View King Shipbuilding Et Ship Repair New Construction Boilermaker $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Carpenter $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Crane $38.54 7V 1 View Operator King Shipbuilding Et Ship Repair New Construction Electrician $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Heat Et Frost $79.43 5.1 4H View Insulator King Shipbuilding Et Ship Repair New Construction Laborer $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Machinist $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Operating $38.54 7V 1 View Engineer King Shipbuilding Et Ship Repair New Construction Painter $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Pipefitter $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Rigger $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Sheet Metal $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction Shipfitter $38.54 7V 1 View King Shipbuilding Et Ship Repair New Construction $38.54 7V 1 View Warehouse/Teamster King Shipbuilding Et Ship Repair New Construction Welder / $38.54 7V 1 View Burner King Shipbuilding Et Ship Repair Ship Repair Boilermaker $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Carpenter $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Crane Operator $45.06 7Y 4K View King Shipbuilding Et Ship Repair Ship Repair Electrician $47.42 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Heat Et Frost $79.43 5J 4H View Insulator King Shipbuilding Et Ship Repair Ship Repair Laborer $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Machinist $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Operating Engineer $45.06 7Y 4K View King Shipbuilding Et Ship Repair Ship Repair Painter $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Pipefitter $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Rigger $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Sheet Metal $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Shipwright $47.35 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Warehouse / $45.06 7Y 4K View Teamster King Sign Makers Et Installers Journey Level $51.56 0 1 View _(Electrical) King Sign Makers Et Installers (Non- Journey Level $33.20 0 1 View Electrical). King Soft Floor Layers Journey Level $51.91 5A 3J View King Solar Controls For Windows Journey Level $13.69 1 View King Sprinkler Fitters (Fire Journey Level $85.89 5C 1X View Protection) King Stage Rigging Mechanics (Non Journey Level $13.69 1 View Structural), King Stone Masons Journey Level $60.57 7E 1N View King Street And Parking Lot Sweeper Journey Level $19.09 1 View Workers King Surveyors Assistant Construction Site $72.28 7A 3K 8X View Surveyor King Surveyors Chainman $69.12 7A 3K 8X View King Surveyors Construction Site Surveyor $73.49 7A 3K 8X View King Telecommunication Technicians Journey Level $53.57 7E 1 E View King Telephone Line Construction - Cable Splicer $37.40 5A 2B View Outside King Telephone Line Construction - Hole Digger/Ground Person $25.04 5A 2B View Outside King Telephone Line Construction - Telephone Equipment Operator $31.22 5A 2B View Outside (Light) King Telephone Line Construction - Telephone Lineperson $35.34 5A 2B View Outside King Terrazzo Workers Journey Level $55.71 7E 1N View King Tile Setters Journey Level $55.71 7E 1N View King Tile, Marble Et Terrazzo Finisher $46.54 7E 1N View Finishers King Traffic Control Stripers Journey Level $49.13 7A 1 K View King Truck Drivers Asphalt Mix Over 16 Yards $64.55 5D 4Y 8L View King Truck Drivers Asphalt Mix To 16 Yards $63.71 5D 4Y 8L View King Truck Drivers Dump Truck $63.71 5D 4Y 8L View King Truck Drivers Dump Truck Et Trailer $64.55 5D 4Y 8L View King Truck Drivers Other Trucks $64.55 5D 4Y 8L View King Truck Drivers - Ready Mix Transit Mix $64.55 5D 4Y 8L View King Well Drillers Et Irrigation Pump Irrigation Pump Installer $17.71 1 View Installers King Well Drillers Et Irrigation Pump Oiler $13.69 1 View King Installers Well Drillers it Irrigation Pump Installers Well Driller $18.00 i View Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Overtime Codes Overtime calculations are based on the hourly rate actually paid to the worker. On public works projects, the hourly rate must be not less than the prevailing rate of wage minus the hourly rate of the cost of fringe benefits actually provided for the worker. ALL HOURS WORKED IN EXCESS OF EIGHT (8) HOURS PER DAY OR FORTY (40) HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. B. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. C. The first two (2) hours after eight (8) regular hours Monday through Friday and the first ten (10) hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. D. The first two (2) hours before or after a five -eight (8) hour workweek day or a four -ten (10) hour workweek day and the first eight (8) hours worked the next day after either workweek shall be paid at one and one-half times the hourly rate of wage. All additional hours worked and all worked on Sundays and holidays shall be paid at double the hourly rate of wage. E. The first two (2) hours after eight (8) regular hours Monday through Friday and the first eight (8) hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. F. The first two (2) hours after eight (8) regular hours Monday through Friday and the first ten (10) hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours worked, except Labor Day, shall be paid at double the hourly rate of wage. All hours worked on Labor Day shall be paid at three times the hourly rate of wage. G. The first ten (10) hours worked on Saturdays and the first ten (10) hours worked on a fifth calendar weekday in a four - ten hour schedule, shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of ten (10) hours per day Monday through Saturday and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. H. All hours worked on Saturdays (except makeup days if work is lost due to inclement weather conditions or equipment breakdown) shall be paid at one and one-half times the hourly rate of wage. All hours worked Monday through Saturday over twelve (12) hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. I. All hours worked on Sundays and holidays shall also be paid at double the hourly rate of wage. The first two (2) hours after eight (8) regular hours Monday through Friday and the first ten (10) hours on Saturday shall be paid atone and one-half times the hourly rate of wage. All hours worked over ten (10) hours Monday through Saturday, Sundays and holidays shall be paid at double the hourly rate of wage. K. All hours worked on Saturdays and Sundays shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays shall be paid at double the hourly rate of wage. M. All hours worked on Saturdays (except makeup days if work is lost due to inclement weather conditions) shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. N. All hours worked on Saturdays (except makeup days) shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. 1of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Overtime Codes Continued O. The first ten (10) hours worked on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays, holidays and after twelve (12) hours, Monday through Friday and after ten (10) hours on Saturday shall be paid at double the hourly rate of wage. P. All hours worked on Saturdays (except makeup days if circumstances warrant) and Sundays shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays shall be paid at double the hourly rate of wage. Q. The first two (2) hours after eight (8) regular hours Monday through Friday and up to ten (10) hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of ten (10) hours per day Monday through Saturday and all hours worked on Sundays and holidays (except Christmas day) shall be paid at double the hourly rate of wage. All hours worked on Christmas day shall be paid at two and one-half times the hourly rate of wage. R. All hours worked on Sundays and holidays shall be paid at two times the hourly rate of wage. U. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays (except Labor Day) shall be paid at two times the hourly rate of wage. All hours worked on Labor Day shall be paid at three times the hourly rate of wage. V. All hours worked on Sundays and holidays (except Thanksgiving Day and Christmas day) shall be paid at one and one-half times the hourly rate of wage. All hours worked on Thanksgiving Day and Christmas day shall be paid at double the hourly rate of wage. W. All hours worked on Saturdays and Sundays (except make-up days due to conditions beyond the control of the employer)) shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays shall be paid at double the hourly rate of wage. X. The first four (4) hours after eight (8) regular hours Monday through Friday and the first twelve (12) hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked over twelve (12) hours Monday through Saturday, Sundays and holidays shall be paid at double the hourly rate of wage. When holiday falls on Saturday or Sunday, the day before Saturday, Friday, and the day after Sunday, Monday, shall be considered the holiday and all work performed shall be paid at double the hourly rate of wage. Y. All hours worked outside the hours of 5:00 am and 5:00 pm (or such other hours as may be agreed upon by any employer and the employee) and all hours worked in excess of eight (8) hours per day (10 hours per day for a 4 x 10 workweek) and on Saturdays and holidays (except labor day) shall be paid at one and one-half times the hourly rate of wage. (except for employees who are absent from work without prior approval on a scheduled workday during the workweek shall be paid at the straight -time rate until they have worked 8 hours in a day (10 in a 4 x 10 workweek) or 40 hours during that workweek.) All hours worked Monday through Saturday over twelve (12) hours and all hours worked on Sundays and Labor Day shall be paid at double the hourly rate of wage. Z. All hours worked on Saturdays and Sundays shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays shall be paid the straight time rate of pay in addition to holiday pay. 2of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Overtime Codes Continued 2. ALL HOURS WORKED IN EXCESS OF EIGHT (8) HOURS PER DAY OR FORTY (40) HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. B. All hours worked on holidays shall be paid at one and one-half times the hourly rate of wage. F. The first eight (8) hours worked on holidays shall be paid at the straight hourly rate of wage in addition to the holiday pay. All hours worked in excess of eight (8) hours on holidays shall be paid at double the hourly rate of wage. M. This code appears to be missing. All hours worked on Saturdays, Sundays and holidays shall be paid at double the hourly rate of wage. O. All hours worked on Sundays and holidays shall be paid at one and one-half times the hourly rate of wage. R. All hours worked on Sundays and holidays and all hours worked over sixty (60) in one week shall be paid at double the hourly rate of wage. U. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked over 12 hours in a day or on Sundays and holidays shall be paid at double the hourly rate of wage. ALL HOURS WORKED IN EXCESS OF EIGHT (8) HOURS PER DAY OR FORTY (40) HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. F. All hours worked on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sunday shall be paid at two times the hourly rate of wage. All hours worked on paid holidays shall be paid at two and one-half times the hourly rate of wage including holiday pay. H. All work performed on Sundays between March 16th and October 14th and all Holidays shall be compensated for at two (2) times the regular rate of pay. Work performed on Sundays between October 15th and March 15th shall be compensated at one and one half (1-1/2) times the regular rate of pay. All hours worked between the hours of 10:00 pm and 5:00 am, Monday through Friday, and all hours worked on Saturdays shall be paid at a one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. K. Work performed in excess of eight (8) hours of straight time per day, or ten (10) hours of straight time per day when four ten (10) hour shifts are established, or forty (40) hours of straight time per week, Monday through Friday, or outside the normal 5 am to 6pm shift, and all work on Saturdays shall be paid at one and one-half times the hourly rate of wage. All work performed after 6:00 pm Saturday to 5:00 am Monday and Holidays, and all hours worked in excess of twelve (12) hours in a single shift shall be paid at double the hourly rate of wage. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight (8) hours or more. When an employee returns to work without at least eight (8) hours time off since their previous shift, all such time shall be a continuation of shift and paid at the applicable overtime rate until he/she shall have the eight (8) hours rest period. 4. ALL HOURS WORKED IN EXCESS OF EIGHT (8) HOURS PER DAY OR FORTY (40) HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. A. All hours worked in excess of eight (8) hours per day or forty (40) hours per week shall be paid at double the hourly rate of wage. All hours worked on Saturdays, Sundays and holidays shall be paid at double the hourly rate of wage. 3of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Overtime Codes Continued 4. C. On Monday through Friday, the first four (4) hours of overtime after eight (8) hours of straight time work shall be paid at one and one half (1-1/2) times the straight time rate of pay, unless a four (4) day ten (10) hour workweek has been established. On a four (4) day ten (10) hour workweek scheduled Monday through Thursday, or Tuesday through Friday, the first two (2) hours of overtime after ten (10) hours of straight time work shall be paid at one and one half (1-1/2) times the straight time rate of pay. On Saturday, the first twelve (12) hours of work shall be paid at one and one half (1-1/2) times the straight time rate of pay, except that if the job is down on Monday through Friday due to weather conditions or other conditions outside the control of the employer, the first ten (10) hours on Saturday may be worked at the straight time rate of pay. All hours worked over twelve (12) hours in a day and all hours worked on Sunday and Holidays shall be paid at two (2) times the straight time rate of pay. D. All hours worked in excess of eight (8) hours per day or forty (40) hours per week shall be paid at double the hourly rate of wage. All hours worked on Saturday, Sundays and holidays shall be paid at double the hourly rate of pay. Rates include all members of the assigned crew. EXCEPTION: On all multipole structures and steel transmission lines, switching stations, regulating, capacitor stations, generating plants, industrial plants, associated installations and substations, except those substations whose primary function is to feed a distribution system, will be paid overtime under the following rates: The first two (2) hours after eight (8) regular hours Monday through Friday of overtime on a regular workday, shall be paid at one and one-half times the hourly rate of wage. All hours in excess of ten (10) hours will be at two (2) times the hourly rate of wage. The first eight (8) hours worked on Saturday will be paid at one and one-half (1-1/2) times the hourly rate of wage. All hours worked in excess of eight (8) hours on Saturday, and all hours worked on Sundays and holidays will be at the double the hourly rate of wage. All overtime eligible hours performed on the above described work that is energized, shall be paid at the double the hourly rate of wage. E. The first two (2) hours after eight (8) regular hours Monday through Friday and the first eight (8) hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. On a four -day, ten-hour weekly schedule, either Monday thru Thursday or Tuesday thru Friday schedule, all hours worked after ten shall be paid at double the hourly rate of wage. The Monday or Friday not utilized in the normal four - day, ten hour work week, and Saturday shall be paid at one and one half (1'h) times the regular shift rate for the first eight (8) hours. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. G. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked Monday through Saturday over twelve (12) hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. H. The first two (2) hours after eight (8) regular hours Monday through Friday and the first eight (8) hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours worked, except Labor Day, and all hours on Sunday shall be paid at double the hourly rate of wage. All hours worked on Labor Day shall be paid at three times the hourly rate of wage. I. The First eight (8) hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of eight (8) per day on Saturdays shall be paid at double the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. 4of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Overtime Codes Continued 4. J. The first eight (8) hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of eight (8) hours on a Saturday shall be paid at double the hourly rate of wage. All hours worked over twelve (12) in a day, and all hours worked on Sundays and Holidays shall be paid at double the hourly rate of wage. K. All hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage, so long as Saturday is the sixth consecutive day worked. All hours worked over twelve (12) in a day Monday through Saturday, and all hours worked on Sundays and Holidays shall be paid at double the hourly rate of wage. L. The first twelve (12) hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked on a Saturday in excess of twelve (12) hours shall be paid at double the hourly rate of pay. All hours worked over twelve (12) in a day Monday through Friday, and all hours worked on Sundays shall be paid at double the hourly rate of wage. All hours worked on a holiday shall be paid at one and one-half times the hourly rate of wage, except that all hours worked on Labor Day shall be paid at double the hourly rate of pay. U. The first four (4) hours after eight (8) regular hours Monday through Friday and the first twelve (12) hours on Saturday shall be paid at one and one-half times the hourly rate of wage. (Except on makeup days if work is lost due to inclement weather, then the first eight (8) hours on Saturday may be paid the regular rate.) All hours worked over twelve (12) hours Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. V. Work performed in excess of ten (10) hours of straight time per day when four ten (10) hour shifts are established or outside the normal shift (5 am to 6pm), and all work on Saturdays, except for make-up days shall be paid at time and one-half (1 ''/2) the straight time rate. In the event the job is down due to weather conditions, then Saturday may, be worked as a voluntary make-up day at the straight time rate. However, Saturday shall not be utilized as a make-up day when a holiday falls on Friday. All work performed on Sundays and holidays and work in excess of twelve (12) hours per day shall be paid at double (2x) the straight time rate of pay. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight (8) hours. When an employee returns to work without a break of eight (8) hours since their previous shift, all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight (8) hours. W. All hours worked on Saturdays (except makeup days if work is lost due to inclement weather conditions) shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. When an employee returns to work without at least eight (8) hours time off since their previous shift, all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight (8) hours. 5of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Overtime Codes Continued 4. X. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. Work performed outside the normal shift of 6 am to 6pm shall be paid at one and one-half the straight time rate, (except for special shifts or three shift operations). All work performed on Sundays and holidays shall be paid at double the hourly rate of wage. Shifts may be established when considered necessary by the Employer. The Employer may establish shifts consisting of eight (8) or ten (10) hours of work (subject to WAC 296-127-022), that shall constitute a normal forty (40) hour work week. The Employer can change from a 5-eight to a 4-ten hour schedule or back to the other. All hours of work on these shifts shall be paid for at the straight time hourly rate. Work performed in excess of eight hours (or ten hours per day (subject to WAC 296-127-022) shall be paid atone and one- half the straight time rate. When due to conditions beyond the control of the Employer, or when contract specifications require that work can only be performed outside the regular day shift, then by mutual agreement a special shift may be worked at the straight time rate, eight (8) hours work for eight (8) hours pay. The starting time shall be arranged to fit such conditions of work. When an employee returns to work without at a break of eight (8) hours since their previous shift, all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight (8) hours. Y. Work performed in excess of eight (8) hours of straight time per day, or ten (10) hours of straight time per day when four ten (10) hour shifts are established, or forty (40) hours of straight time per week, Monday through Friday, or outside the normal shift, and all work on Saturdays shall be paid at time and one-half the straight time rate. All work performed after 6:00 pm Saturday to 6:00 am Monday and holidays shall be paid at double the straight time rate of pay. Any shift starting between the hours of 6:00 pm and midnight shall receive an additional one dollar ($1.00) per hour for all hours worked that shift. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight (8) hours or more. Z. All hours worked between the hours of 6:00 pm and 6:00 am, Monday through Saturday, shall be paid at a premium rate of 20% over the hourly rate of wage. Work performed on Sundays may be paid at double time. All hours worked on holidays shall be paid at double the hourly rate of wage. 11. ALL HOURS WORKED IN EXCESS OF EIGHT (8) HOURS PER DAY OR FORTY (40) HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. A. The first ten (10) hours worked on Saturday and all hours worked on holidays shall be paid at one and one-half times the hourly rate of wage. All hours worked over twelve (12) hours Monday through Saturday, and all hours worked on Sundays shall be paid at double the hourly rate of wage. After an employee has worked eight (8) hours, all additional hours worked shall be paid at the applicable overtime rate until such time as the employee has had a break of eight (8) hours or more. 6of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Holiday Codes A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, and Christmas Day (7). B. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, the day before Christmas, and Christmas Day (8). C. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (8). D. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day, And Christmas Day (8). H. Holidays: New Year's Day, Memorial Day, Independence Day, Thanksgiving Day, the Day after Thanksgiving Day, And Christmas (6). I. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day (6). Holidays: New Year's Day, Memorial Day, Independence Day, Thanksgiving Day, Friday after Thanksgiving Day, Christmas Eve Day, And Christmas Day (7). K. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday After Thanksgiving Day, The Day Before Christmas, And Christmas Day (9). L. Holidays: New Year's Day, Martin Luther King Jr. Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, And Christmas Day (8). N. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, The Friday After Thanksgiving Day, And Christmas Day (9). P. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday And Saturday After Thanksgiving Day, The Day Before Christmas, And Christmas Day (9). If A Holiday Falls On Sunday, The Following Monday Shall Be Considered As A Holiday. Q. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day (6). R. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Day After Thanksgiving Day, One -Half Day Before Christmas Day, And Christmas Day. (7 1/2). S. Paid Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, And Christmas Day (7). Z. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans Day, Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (8). 6. G. Paid Holidays: New Year's Day, Martin Luther King Jr. Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and Christmas Eve Day (11). H. Paid Holidays: New Year's Day, New Year's Eve Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday After Thanksgiving Day, Christmas Day, The Day After Christmas, And A Floating Holiday (10). 7of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Holiday Codes Continued T. Paid Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, The Friday After Thanksgiving Day, The Last Working Day Before Christmas Day, And Christmas Day (9). Z. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, And Christmas Day (7). If a holiday falls on Saturday, the preceding Friday shall be considered as the holiday. If a holiday falls on Sunday, the following Monday shall be considered as the holiday. A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day, And Christmas Day (8). Any Holiday Which Falls On A Sunday Shall Be Observed As A Holiday On The Following Monday. If any of the listed holidays falls on a Saturday, the preceding Friday shall be a regular work day. B. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day, And Christmas Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. C. Holidays: New Year's Day, Martin Luther King Jr. Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. D. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Veteran's Day, Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (8). Unpaid Holidays: President's Day. Any paid holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any paid holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. E. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. F. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, the last working day before Christmas day and Christmas day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. G. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day (6). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. H. Holidays: New Year's Day, Martin Luther King Jr. Day, Independence Day, Memorial Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, the Last Working Day before Christmas Day and Christmas Day (9). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. I. Holidays: New Year's Day, President's Day, Independence Day, Memorial Day, Labor Day, Thanksgiving Day, The Friday After Thanksgiving Day, The Day Before Christmas Day And Christmas Day (9). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. 8of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Holiday Codes Continued Holidays: New Year's Day, Independence Day, Memorial Day, Labor Day, Thanksgiving Day and Christmas Day (6). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. K. Holidays: New Year's Day, Memorial Day, Independence Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day, And Christmas Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. L. Holidays: New Year's Day, Memorial Day, Labor Day, Independence Day, Thanksgiving Day, the Last Work Day before Christmas Day, And Christmas Day (7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. N. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. When Christmas falls on a Saturday, the preceding Friday shall be observed as a holiday. P. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, And Christmas Day (7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Q. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, the Last Working Day before Christmas Day and Christmas Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. If any of the listed holidays falls on a Saturday, the preceding Friday shall be a regular work day. S. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, Christmas Day, the Day after Christmas, and A Floating Holiday (9). If any of the listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. V. Holidays: New Year's Day, President's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, the day before or after Christmas, and the day before or after New Year's Day. If any of the above listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. W. Holidays: New Year's Day, Day After New Year's, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Eve Day, Christmas Day, the day after Christmas, the day before New Year's Day, and a Floating Holiday. X. Holidays: New Year's Day, Day before or after New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and the day before or after Christmas day. If a holiday falls on a Saturday or on a Friday that is the normal day off, then the holiday will be taken on the last normal workday. If the holiday falls on a Monday that is the normal day off or on a Sunday, then the holiday will be taken on the next normal workday. Y. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, and Christmas Day. (8) If the holiday falls on a Sunday, then the day observed by the federal government shall be considered a holiday and compensated accordingly. 9of14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Holiday Codes Continued G. New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, The Friday After Thanksgiving Day, the last scheduled workday before Christmas, and Christmas Day (9). If any of the listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. H. Holidays: New Year's Day, Martin Luther King Jr. Day, Independence Day, Memorial Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, the Last Working Day before Christmas Day and Christmas Day (9). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. I. Holidays: New Year's Day, President's Day, Independence Day, Memorial Day, Labor Day, Thanksgiving Day, The Friday After Thanksgiving Day, The Day Before Christmas Day And Christmas Day (9). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. Holidays: New Year's Day, Independence Day, Memorial Day, Labor Day, Thanksgiving Day and Christmas Day (6). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. K. Holidays: New Year's Day, Memorial Day, Independence Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day, And Christmas Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. L. Holidays: New Year's Day, Memorial Day, Labor Day, Independence Day, Thanksgiving Day, the Last Work Day before Christmas Day, And Christmas Day (7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. N. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. When Christmas falls on a Saturday, the preceding Friday shall be observed as a holiday. P. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, And Christmas Day (7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Q. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, the Last Working Day before Christmas Day and Christmas Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. If any of the listed holidays falls on a Saturday, the preceding Friday shall be a regular work day. S. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, Christmas Day, the Day after Christmas, and A Floating Holiday (9). If any of the listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. V. Holidays: New Year's Day, President's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, the day before or after Christmas, and the day before or after New Year's Day. If any of the above listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. 10 of 14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Holiday Codes Continued 7. W. Holidays: New Year's Day, Day After New Year's, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Eve Day, Christmas Day, the day after Christmas, the day before New Year's Day, and a Floating Holiday. X. Holidays: New Year's Day, Day before or after New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and the day before or after Christmas day. If a holiday falls on a Saturday or on a Friday that is the normal day off, then the holiday will be taken on the last normal workday. If the holiday falls on a Monday that is the normal day off or on a Sunday, then the holiday will be taken on the next normal workday. Y. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, and Christmas Day. (8) If the holiday falls on a Sunday, then the day observed by the federal government shall be considered a holiday and compensated accordingly. 15. F. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, the last scheduled workday before Christmas, and Christmas Day (8). If any of the listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. G. New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, The Friday After Thanksgiving Day, the last scheduled workday before Christmas, and Christmas Day (9). If any of the listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. Note Codes 8. D. Workers working with supplied air on hazmat projects receive an additional $1.00 per hour. L. Workers on hazmat projects receive additional hourly premiums as follows -Level A: $0.75, Level B: $0.50, And Level C: $0.25. M. Workers on hazmat projects receive additional hourly premiums as follows: Levels A & B: $1.00, Levels C & D: $0.50. N. Workers on hazmat projects receive additional hourly premiums as follows -Level A: $1.00, Level B: $0.75, Level C: $0.50, And Level D: $0.25. S. Effective August 31, 2012 —A Traffic Control Supervisor shall be present on the project whenever flagging or spotting or other traffic control labor is being utilized. Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer. All flaggers and spotters shall possess a current flagging card issued by the State of Washington, Oregon, Montana, or Idaho. This classification is only effective on or after August 31, 2012. 11 of 14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Note Codes Continued 8. T. Effective August 31, 2012 — A Traffic Control Laborer performs the setup, maintenance and removal of all temporary traffic control devices and construction signs necessary to control vehicular, bicycle, and pedestrian traffic during construction operations. Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer. All flaggers and spotters shall possess a current flagging card issued by the State of Washington, Oregon, Montana, or Idaho. This classification is only effective on or after August 31, 2012. U. Workers on hazmat projects receive additional hourly premiums as follows — Class A Suit: $2.00, Class B Suit: $1.50, And Class C Suit: $1.00. Workers performing underground work receive an additional $0.40 per hour for any and all work performed underground, including operating, servicing and repairing of equipment. The premium for underground work shall be paid for the entire shift worked. Workers who work suspended by a rope or cable receive an additional $0.50 per hour. The premium for work suspended shall be paid for the entire shift worked. Workers who do "pioneer" work (break open a cut, build road, etc.) more than one hundred fifty (150) feet above grade elevation receive an additional $0.50 per hour. V. In addition to the hourly wage and fringe benefits, the following depth and enclosure premiums shall be paid. The premiums are to be calculated for the maximum depth and distance into an enclosure that a diver reaches in a day. The premiums are to be paid one time for the day and are not used in calculating overtime pay. Depth premiums apply to depths of fifty feet or more. Over 50' to 100' - $2.00 per foot for each foot over 50 feet. Over 10l' to 150' - $3.00 per foot for each foot over 101 feet. Over 15l' to 220' - $4.00 per foot for each foot over 220 feet. Over 22 F - $5.00 per foot for each foot over 221 feet. Enclosure premiums apply when divers enter enclosures (such as pipes or tunnels) where there is no vertical ascent and is measured by the distance travelled from the entrance. 25' to 300' - $1.00 per foot from entrance. 300' to 600' - $1.50 per foot beginning at 300'. Over 600' - $2.00 per foot beginning at 600'. W. Meter Installers work on single phase 120/240V self-contained residential meters. The Lineman/Groundmen rates would apply to meters not fitting this description. X. Workers on hazmat projects receive additional hourly premiums as follows - Class A Suit: $2.00, Class B Suit: $1.50, Class C Suit: $1.00, and Class D Suit: $0.50. Special Shift Premium: Basic hourly rate plus $2.00 per hour. When due to conditions beyond the control of the Employer or when an owner (not acting as the contractor), a government agency or the contract specifications requires that work can only be performed outside the normal 5 am to 6pm shift, then the special shift premium will be applied to the basic hourly rate. When an employee works on a special shift, they shall be paid a special shift premium for each hour worked unless they are in OT or Double-time status. (For example, the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) Y. Tide Work: When employees are called out between the hours of 6:00 p.m. and 6:00 a.m. to work on tide work (work located in the tide plane) all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair: Employees working on a swinging state or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents ($0.75) per hour above the classification rate. 12 of 14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Note Codes Continued 8. Z. Workers working with supplied air on hazmat projects receive an additional $1.00 per hour. Special Shift Premium: Basic hourly rate plus $2.00 per hour. When due to conditions beyond the control of the Employer or when an owner (not acting as a contractor), a government agency or the contract specifications require that more than (4) hours of a special shift can only be performed outside the normal 6 am to 6pm shift, then the special shift premium will be applied to the basic straight time for the entire shift. When an employee works on a special shift, they will be paid a special shift premium for each hour worked unless they are in overtime or double- time status. (For example, the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) A. Workers working with supplied air on hazmat projects receive an additional $1.00 per hour. Special Shift Premium: Basic hourly rate plus $2.00 per hour. When due to conditions beyond the control of the Employer or when an owner (not acting as the contractor), a government agency or the contract specifications require that more than four (4) hours of a special shift can only be performed outside the normal 6 am to 6pm shift, then the special shift premium will be applied to the basic straight time for the entire shift. When an employee works on a special shift, they shall be paid a special shift premium for each hour worked unless they are in overtime or double- time status. (For example, the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) Certified Crane Operator Premium: Crane operators requiring certifications shall be paid $0.50 per hour above their classification rate. Boom Pay Premium: All cranes including tower shall be paid as follows based on boom length: (A) — 130' to 199' — $0.50 per hour over their classification rate. (B) — 200' to 299' — $0.80 per hour over their classification rate. (C) — 300' and over — $1.00 per hour over their classification rate. B. The highest pressure registered on the gauge for an accumulated time of more than fifteen (15) minutes during the shift shall be used in determining the scale paid. Tide Work: When employees are called out between the hours of 6:00 p.m. and 6:00 a.m. to work on tide work (work located in the tide plane) all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair: Employees working on a swinging stage or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents ($0.75) per hour above the classification rate. C. Tide Work: When employees are called out between the hours of 6:00 p.m. and 6:00 a.m. to work on tide work (work located in the tide plane) all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair: Employees working on a swinging stage or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents ($0.75) per hour above the classification rate. Effective August 31, 2012 — A Traffic Control Supervisor shall be present on the project whenever flagging or spotting or other traffic control labor is being utilized. A Traffic Control Laborer performs the setup, maintenance and removal of all temporary traffic control devices and construction signs necessary to control vehicular, bicycle, and pedestrian traffic during construction operations. Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer. All flaggers and spotters shall possess a current flagging card issued by the State of Washington, Oregon, Montana, or Idaho. These classifications are only effective on or after August 31, 2012. 13 of 14 Benefit Code Key — Effective 3/3/2021 thru 8/31/2021 Note Codes Continued D. Industrial Painter wages are required for painting within industrial facilities such as treatment plants, pipelines, towers, dams, bridges, power generation facilities and manufacturing facilities such as chemical plants, etc., or anywhere abrasive blasting is necessary to prepare surfaces, or hazardous materials encapsulation is required. E. Heavy Construction includes construction, repair, alteration or additions to the production, fabrication or manufacturing portions of industrial or manufacturing plants, hydroelectric or nuclear power plants and atomic reactor construction. Workers on hazmat projects receive additional hourly premiums as follows -Level A: $1.00, Level B: $0.75, Level C: $0.50, And Level D: $0.25. F. Industrial Painter wages are required for painting within industrial facilities such as treatment plants, pipelines, towers, dams, power generation facilities and manufacturing facilities such as chemical plants, etc., or anywhere abrasive blasting is necessary to prepare surfaces, or hazardous materials encapsulation is required. 14 of 14