Loading...
HomeMy WebLinkAboutPW12-088 - Original - WA State Recreation & Conservation Office - Downey Farmstead Final Design - 03/12/2012 " - -K Records M-,��,- _ emen ..ENT WASHINGTOH Document rvt Y�v _ CONTRACT COVER SHEET This is to be completed by the Contract Manager prior to submission to City Clerks Office. All portions are to be completed. If you have questions, please contact City Clerk's Office. Vendor Name: WA State Recreation and Conservation Office (RCO) Vendor Number: JD Edwards Number Contract Number: pW 1a- a 89 This is assigned by City Clerk's Office Project Name: Downey Farmstead Final Design Description: ❑ Interlocal Agreement ❑ Change Order/Amendment ❑ Public Works Agreement ❑ Goods & Services ❑ Consultant Services ❑ Public Works ® Other: PSAR Project Agreement Contract Effective Date: 2/29/2012 Termination Date: 12/31/2013 Contract Renewal Notice (Days): Number of days required notice for termination or renewal or amendment Contract Manager: A Murillo Department: Public Works Engineering Detail: (i.e. address, location, parcel number, tax id, etc.): CM2/21/2012 Project Number 11-1219P S Public\RecordsManagement\Forms\ContractCover\adcc7832 1 11/08 'y WASHINGTON STATE Recreation and Conservation Office PSAR Project Agreement Salmon Funding Accounts Project Sponsor. City of Kent Project Number,11-1219P Project Title Downey Farmstead Final Design Approval Date 12/9/2011 A. PARTIES OF THE AGREEMENT This project grant Agreement(Agreement)is entered into between the State of Washington by and through the Salmon Recovery Funding Board(SRFB)and the Recreation and Conservation Office,P O Box 40917,Olympia, Washington 98504-0917 and City of Kent(sponsor),220 Fourth Ave S,Kent,WA 98032-5895 and shall be binding on the agents and all persons acting by or through the parties B. PURPOSE OF AGREEMENT This Agreement sets out the terms and conditions by which a grant is made from the Salmon Funding Accounts of the State of Washington The grant is administered by the Recreation and Conservation Office(RCO)to the sponsor for the project named above C DESCRIPTION OF PROJECT City of Kent will complete final design and permitting of the Downey Farmstead Restoration project to realign and setback Frager Road from the Green River in order to reconnect the floodplain and create off-channel reanng and refuge habitat,primarily forjuvenile Chinook salmon A secondary goal of the project is to create additional flood storage to help alleviate flood damage to nearby urban and agricultural areas The project site is located in King County along the left(south)bank of the Green River between river mile 21 5 and 22 3 on 21 8 acres of property owned by City of Kent and purchased with 2002 SRFB funding(02-1601) The downstream edge of the site coincides with the confluence of Mullen Slough with the Green River A feasibility study and 30%design document for the Downey Farmstead was successfully completed with 2008 SRFB funding(08-1659) D. PERIOD OF PERFORMANCE The project reimbursement period shall begin on December 8,2011 and end on December 31,2013 No expenditure made before or after this period is eligible for reimbursement unless incorporated by written amendment into this Agreement or specifically provided for by RCFB and/or SRFB policy or WAC Requests for time extensions are to be made at least 60 days before the Agreement end date If the request is made after the Agreement end date,the time extension will be denied The sponsor has obligations beyond this penod of performance as described in Section E i E. ON-GOING OBLIGATION � The Project Sponsor's on-going obligation for the project shall be the same as the Period of Performance period identified in Section D F. PROJECT FUNDING The total grant award provided by the funding board for this project shall not exceed$253,581 00 The funding board shall not pay any amount beyond that approved for grant funding of the project and within the funding board's j percentage as identified below The sponsor shall be responsible for all total project costs that exceed this amount { The contribution by the sponsor toward work on this project at a minimum shall be as indicated below Percentage DollarAmount SRFB-Puget Sound Acq &Restoration 84 53% $253,581 00 Project Sponsor 15 47% $46,419 00 Total Project Cost 100 00% $300,000 00 PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 1 of 16 PROJAGR RPT G RIGHTS AND OBLIGATIONS All rights and obligations of the parties to this Agreement are subject to this Agreement and its attachments,as now existing or hereafter amended,including the sponsor's application,eligible scope activities,project milestones,and the Standard Terms and Conditions of the project Agreement,all of which are incorporated herein Except as provided herein,no amendment/deletions of any of the terms or conditions of this Agreement will be effective unless provided in wnting All such amendment/deletions must be signed by both parties except the RCO director may unilaterally make amendments to extend the period of performance Period of performance extensions need only be signed by RCO's director or designee N. COMPLIANCE WITH APPLICABLE STATUTES,RULES,AND RCFB-SRFB POLICIES This agreement is governed by,and the sponsor shall comply with,all applicable state and federal laws and regulations,including Chapter 77 85 RCW,Chapter 420 WAG,and published agency policies,which are incorporated herein by this reference as if fully set forth I SPECIAL CONDITIONS a Cultural Resources Consultation This project is subject to the National Historic Preservation Act, Section 106, and therefore appears to be exempt from Governor's Executive Order 05-05 Archaeological and Cultural Resources (EO 05-05)as described in Section 9 of this project agreement In order for this project to be exempt from EO 05-05, the Section 106 Area of Potential Effect(APE)must include all ground-disturbing activities subject to this project agreement, including the restoration staging area The sponsor is encouraged to work with the federal permitting agency to align the Section 106 APE with the scope of work subject to this project agreement If the APE does not include all ground-disturbing activities subject to this project agreement, promptly notify the RCO grant manager, as this will require RCO to initiate cultural resources consultation following EO 05-05 for those activities not included in the federal APE Completion of this consultation and a Notice to Proceed from RCO will be required before these ground-disturbing activities can begin b Design Deliverables The project will meet the standards for Design and Restoration Project Deliverables described in Manual 18(2012)Appendix D"Final Design Deliverables" J FEDERAL FUND INFORMATION (none) K PROJECT GRANT AGREEMENT REPRESENTATIVE All written communications and notices under this Agreement will be addressed and sent to at least the mail address or the email address listed below if not both Project Contact SRFB Name Alex Murillo Recreation and Conservation Office Title ENVIRONMENTAL ENGINEERING SUPE Natural Resources Building Address 220 Fourth Ave S PO Box 40917 Kent,WA 98032 Olympia,Washington 98504-0917 Email amunllo@ci kent wa us These addresses shall be effective until receipt by one party from the other of a wntten notice of any change L ENTIRE AGREEMENT This Agreement,with all amendments and attachments,constitutes the entire Agreement of the parties No other understandings,oral or otherwise,regarding this Agreement shall exist or bind any of the parties M. EFFECTIVE DATE This Agreement,for project 11-1219P,shall be subject to the written approval of the RCO's authonzed representative and shall not be effective and binding until executed by both the Sponsor and the RCO Reimbursements for eligible and allowable costs incurred within the period of performance identified in Section D above are allowed only when this Agreement is fully executed and an original is received by RCO PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 2 of 16 PROJAGR RPT The sponsor/s has read,fully understands,and agrees to be bound by all terms and conditions as set forth in this Agreement,The signators listed below represent and warrant their authority to bind the parties to this Agreement City of Kent By. C Date Nam (printed) T— I r State of Washington On behalf oAaleen Recove Fu ding Board(SRFB) By Date )12 Cott Director, Recreation and Conservation Office Pre-approved as to form By: is/ Date June 27, 2011 Assistant Attorney General RECEIVED MAR — 97n17 RECREATION AND CONSERVATION OFFICE PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page s of 16 PROJAGR RPT Standard Terms and Conditions of the Project Agreement Table of Contents Page SECTION 1. CITATIONS,HEADINGS AND DEFINITIONS .. ............. ... ............ . 6 SECTION 2 PERFORMANCE BY THE SPONSOR .... .... . „ 7 . . . . . ... ......... . .. . . SECTION 3. ASSIGNMENT. .................. ... .............................. .................................I ...... 7 SECTION 4 RESPONSIBILITY FOR PROJECT. . . .. . . . . . ... . . .. .. 7 SECTION 5 INDEMNIFICATION . .... .. .. .. . .. . ............. . . .. ..... 7 SECTION 6 INDEPENDENT CAPAPCITY OF THE SPONSOR. . ....... .... . ... ... ...... ... 7 SECTION 7. CONFLICT OF INTEREST . . .. . .. . ..... .. . ....... .. ........... . . . 7 SECTION 8 ACKNOWLEDGMENT AND SIGNS ... .................. ........ ... . . 7 SECTION 9 COMPLIANCE WITH APPLICABLE LAW... .. ... .. .... . . .. 8 SECTION 10. HAZARDOUS SUBSTANCES . .... .. .... .... ......... . ....... 9 SECTION 11 RECORDS......... .... ......... .... . . . .. .......... .................I... . ............. 9 SECTION 12. TREATMENT OF ASSETS. ................................... ..... . ... ....... . ........ 9 SECTION 13 RIGHT OF INSPECTION .. .. .. . . .. .. ........... .... ......... ...... 9 SECTION 14. STEWARDSHIP AND MONITORING...... ......... ........ .. . .... .. . .... . .. 9 SECTION 15. DEBARMENT CERTIFICATION . . . . ......... . .. . . ...... 10 SECTION 16. PROJECT FUNDING . . . ... . .. ..... . .. ....... . .. ..... .. .. . ... .... , 10 SECTION17 PROJECT REIMBURSEMENTS. ......... ........ . . ........... ..... . . . .. .. 10 SECTION 18. ADVANCE PAYMENTS . .. .. .. ......... . .. . . . . 10 SECTION 19 RECOVERY OF PAYMENTS . ...... . ... 11 SECTION 20 CONVENANT AGAINST CONTINGENT FEES ... ..... ........ 11 SECTION 21. PROVISIONS APPLYING TO DEVELOPMENT, RENOVATION AND RESTORATION PROJECTS . . . . .. ... . . .. 11 SECTION 22. PROVISIONS APPLYING TO ACQUISITION PROJECTS.. ...... ......... . . .. . 11 SECTION 23 RESTRICTION ON CONVERSION OF REAL PROPERTY AND/OR FACILITIES TO OTHER USES . .. .... .. .. . .. . . .. 12 SECTION 24 CONSTRUCTION,OPERATION,USE AND MAINTENANCE OF ASSISTED PROJECTS .. . . . . . . .. ............... ..... 12 SECTION 25 INCOME AND INCOME USE ..... . 13 SECTION 26 PREFERENCES FOR RESIDENTS . . .. 13 PSAR Protect Agreement-RCO#11-12191P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 4 of is PROJAGR RPT SECTION 27. PROVISIONS RELATED TO CORPORATE(INCLUDING NONPROFIT) SPONSORS .. . ........ ........... 13 SECTION 28 LIBAILITY INSURANCE REQUIRMENTS FOR FIREARMS AND ARCHERY RANGE SPONSORS ... . . . . .. ..... .. . .. .... ....... 13 SECTION 29 REQUIRMENTS OF THE NATIONAL PARK SERVICE. .. ........... . . . ....... ... . 14 SECTION 30 FARMLAND PRESERVATION ACCOUNT. ... . .. ... ........ .. .. . . .. .......... 14 SECTION 31 ORDER OF PRECEDENCE. ... ... . . .............. ........ .......... ... ..... ........... 14 SECTION 32 AMENDMENTS. .. . . . .. . . .. . ................. . .. .. . ... ......... . . . 14 SECTION 33 LIMITATION OF AUTHORITY. .. . .... . ..... . . . . ... .......................... . . .. . 14 SECTION 34 WAIVER OF DEFAULT. . ....................... ...... ......... ...... ... ..... ....... 14 SECTION 35 APPLICATION REPRESENTATIONS-MISREPRESENTATIONS OR INACCURACY OR BREACH 14 SECTION 36 SPECIFIC PERFORMANCE . .. ... . . . ...... .. . ... ........ . ...... 15 SECTION 37 TERMINATION . ..... .. . ....................... . .. . . ............ .. ...... . .. ... 15 SECTION 38 DISPUTE HEARING . . . . . . ... ........... ............... ........................ . ... ...... 15 SECTION 39. ATTORNEYS'FEES .. . . .... .. . .. ....... ......... ....... .. . .. 15 SECTION 40 GOVERNING LAW/VENUE . ....... .. .. .. . . .. ...... .. ... .. . . .. 16 SECTION 41 SEVERABILITY .. . . .......... ......... . ........ ...... .... .......... .............. .... 16 PSAR Protect Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 5 of 16 PROJAGR RPT y WASHINGTON STATE • Recreation and ram Conservation Office Standard Terms and Conditions of the Project Agreement Project Sponsor: City of Kent Project Number 11-1219P Project Title: Downey Farmstead Final Design Approval Date 1 2/912 0 1 1 SECTION 1 CITATIONS,HEADINGS AND DEFINITIONS A Any citations referencing specific documents refer to the current version at the date of protect Agreement and/or any revisions in the future B Headings used in this Agreement are for reference purposes only and shall not be considered a substantive part of this Agreement C Definitions As used throughout this Agreement,the following terns shall have the meaning set forth below- acquisition-The purchase of fee or less than fee Interests in real property These Interests Include,but are not limited to, options,right of first refusal,conservation easements,access/trail easements,covenants,water rights,leases,and mineral rights Agreement-The accord accepted by all parties to the present transaction,this Agreement,any supplemental Agreements,any amendments to this Agreement and any Intergovernmental Agreements applicant-Any agency or organization that meets the qualifying standards,including deadlines,for submission of an application soliciting a grant of funds from the funding Board application-The documents and other materials that an applicant submits to the RCO to support the applicant's request for grant funds,this Includes materials required for the"Application"in the RCO's automated project Information system,and other documents as noted on the application checklist Including but not limited to legal opinions,evaluation presentations and scripts asset-Equipment purchased by the sponsor or acquired or transferred to the sponsor for the purpose of this Agreement This definition is restricted to non-fixed assets,including but not limited to vehicles,computers or machinery cognizant or oversight agency-Federal agency responsible for ensuring compliance with federal audit requirements contractor-Shall mean one not in the employment of the sponsor who is performing all or part of the eligible activities for this project under a separate Agreement with the sponsor The term"contractor"and"contractors"means contractor(s)in any tier secondary sponsor-one of two or more eligible organizations that sponsors a grant-funded project Of these two sponsors, only one-the primary sponsor-may be the fiscal agent development-The construction of or work resulting in new elements,including but not limited to structures,facilities,and/or materials to enhance outdoor recreation,salmon recovery or habitat conservation resources director-The chief executive officer of the Recreation and Conservation Office or that person's designee elements,items and worktypes-Components of the funded project as provided in the project description funding board-The board that authorized the funds in this Agreement,either the Recreation and Conservation Funding Board (RCFB)created under chapter 79A 25 110 RCW,or the Salmon Recovery Funding Board (SRFB)created under chapter 77 85 110 RCW grantee-The organizational entity or individual to which a grant(or cooperative agreement)is awarded and signatory to the Agreement which is responsible and accountable both for the use of the funds provided and for the performance of the grant-supported project or activities landowner agreement-A landowner agreement is required between a SRFB project sponsor and landowner for projects located on land not owned,or otherwise controlled,by the sponsor lower tier participant-refers to any sponsor receiving a federal grant through RCO Lower tier participants also refer to any grantee,subgrantee,or contractor of any grantee or subgrantee from the original sponsor funded by RCO milestone-An important event with a defined deadline for an activity related to implementation of a funded project period of performance-The time period specified in the Agreement,under Section D,period of performance project-The undertaking that is the subject of this Agreement and that is,or may be,funded in whole or in part with funds administered by RCO on behalf of the funding board RCO-Recreation and Conservation Office-The state office that provides administrative support to the Recreation and Conservation Funding Board and Salmon Recovery Funding Board RCO includes the director and staff created by Chapters 79A 25 110 and 79A 25 150 RCW and charged with administering this Agreement by Chapters 77 85 110 and 79A 25 240 RCW reimbursement-Payment of eligible and allowable costs that have already been paid by the sponsor per the terms of the Agreement renovation- The activities intended to improve an existing site or structure in order to increase its service life or functions This does not include maintenance activities restoration-Bringing a site back to its original function as part of a natural ecosystem or improving the ecological functionality of a site sponsor-The eligible applicant who has been awarded a grant of funds and is bound by this executed Agreement, includes its officers,employees,agents and successors subgrantee-The term subgrantee means the government or other legal entity to which a subgrant is awarded and which is accountable to the grantee for the use of the funds provided PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page s of 16 PROJAGR RPT SECTION 2 PERFORMANCE BY THE SPONSOR The sponsor and secondary sponsor where applicable,shall undertake the project as described in this Agreement,post evaluation summary,the sponsors application,and in accordance with the sponsor's proposed goals and objectives described in the application or documents submitted with the application,all as finally approved by the funding board All submitted documents are incorporated by this reference as if fully set forth herein The Order of Precedence is covered in Section 31 Timely completion of the project and submission of required documents,including progress and final reports,is Important Failure to meet critical milestones or complete the project,as set out in this Agreement,is a material breach of the Agreement SECTION 3 ASSIGNMENT Neither this Agreement,nor any claim arising under this Agreement,shall be transferred or assigned by the sponsor without prior written consent of the Recreation and Conservation Office SECTION 4 RESPONSIBILITY FOR PROJECT h n r with the project b providing a rant pursuant to this Agreement,reement the project While the funding board undertakes to assist the spo so p j y p g g p 9 � P 1 itself remains the sole responsibility of the sponsor The funding board undertakes no responsibilities to the sponsor,a secondary sponsor,or to any third party, other than as is expressly set out in this Agreement The responsibility for the implementation of the project is solely that of the sponsor, as is the responsibility for any claim or suit of any nature by any third party related in any way to the project When a project is sponsored by more than one entity,any and all sponsors are equally responsible for the project and all post-completion stewardship responsibilities SECTION 5 INDEMNIFICATION To the fullest extent permitted by the law,the sponsor expressly agrees to and shall Indemnify,defend and hold harmless the State and its agencies,officials,agents and employees from and against all claims actions,costs,damages,or expenses of any nature arising out of or Incident to the sponsor's or any contractor's performance or failure to perform the Agreement Sponsor's obligation to Indemnify,defend and hold harmless also includes any claim by sponsor's agents,employees,representatives or any contractor or its employees Sponsor's obligation to defend Includes payment of any costs or attorneys'fees Sponsor's obligation shall not include such claims that may be caused by the sole negligence of RCO,its officials,agents,and employees If the claims or damages are caused by or result from the concurrent negligence of(a)RCO,Its agents or employees and (b)the sponsor,Its contractors, agents or employees,this Indemnity provision shall be valid and enforceable only to the extent of the negligence of the sponsor or its contractors,agents,or employees The sponsor expressly agrees to waive his/her immunity under Title 51 RCW(as to the State,and its agencies but not as to any employee,worker or third party)to the extent required to indemnify, defend,and hold harmless the State and its agencies,officials,agents or employees SECTION 6. INDEPENDENT CAPACITY OF THE SPONSOR The sponsor and its employees or agents performing under this Agreement are not officers,employees or agents of the funding board or RCO The sponsor will not hold itself out as nor claim to be an officer,employee or agent of RCO,a funding board or of the state of Washington,nor will the sponsor make any claim of right,privilege or benefit which would accrue to an employee under Chapters 41 06 or 28B RCW The sponsor is responsible for withholding and/or paying employment taxes,insurance,or deductions of any kind required by federal, state,and/or local laws SECTION 7 CONFLICT OF INTEREST Notwithstanding any determination by the Executive Ethics Board or other tribunal,RCO may,in its sole discretion,by written notice to the sponsor terminate this Agreement if it is found after due notice and examination by RCO that there is a violation of the Ethics in Public Service Act,Chapter 42 52 RCW,or any similar statute involving the sponsor in the procurement of,or performance under,this Agreement In the event this Agreement is terminated as provided above,RCO shall be entitled to pursue the same remedies against the sponsor as it could pursue in the event of a breach of the Agreement by the sponsor The rights and remedies of RCO provided for in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law SECTION 8 ACKNOWLEDGMENT AND SIGNS A Publications The sponsor shall include language which acknowledges the funding contribution of the applicable grant program to this project in any release or other publication developed or modified for,or referring to,the project during the project period and in the future B Signs The sponsor also shall post signs or other appropriate media during the project period and in the future at project entrances and other locations on the project which acknowledge the applicable grant program's funding contribution,unless exempted in funding board policy or waived by the director C Ceremonies The sponsor shall notify RCO no later than two weeks before a dedication ceremony for this project The sponsor shall verbally acknowledge the applicable grant program's funding contribution at all dedication ceremonies PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 7 of 16 PROJAGR RPT x D Federally Funded Projects When issuing statements,press releases,requests for proposals,bid solicitations,and other documents describing a protect funded in whole or in part with federal money provided for in this grant,sponsors shall clearly stale 1 The percentage of the total costs of the protect that Is financed with federal money, 2 The dollar amount of federal funds for the protect,and 3 The percentage and dollar amount of the total costs of the protect that is financed by nongovernmental sources SECTION 9 COMPLIANCE WITH APPLICABLE LAW The sponsor will implement the Agreement in accordance with applicable federal,state,and local laws,regulations and RCO and funding board policies regardless of whether the sponsor is a public or non-public organization The sponsor shall comply with,and RCO is not responsible for determining compliance with,any and all applicable federal,state,and local laws,regulations,and/or policies,including,but not limited to State Environmental Policy Act,Industrial Insurance Coverage, Architectural Barriers Act,permits(shoreline Hydraulics Protect Approval,demolition),land use regulations(critical areas ordinances, Growth Management Act),federal and state safety and health regulations(Occupational Safety and Health Administration/Washington Industrial Safety and Health Act),and Buy American Act Endangered Species For habitat restoration protects funded in part or whole with federal funds administered by the SRFB the sponsor shall not commence with clearing of riparian trees or in-water work unless either the sponsor has complied with 50 CFR 223 203(b)(8),limit 8 or until an Endangered Species Act consultation is finalized in writing by the National Oceanic and Atmospheric Administration Violation of this requirement may be grounds for terminating this protect Agreement This section shall not be the basis for any enforcement responsibility by RCO Nondiscrimination Laws The sponsor shall comply with all applicable federal,state,and local nondiscrimination laws and/or policies, including but not limited to the Americans with Disabilities Act Civil Rights Act,and the Age Discrimination Act In the event of the sponsor's noncompliance or refusal to comply with any nondiscrimination law or policy,the Agreement may be rescinded,cancelled,or terminated in whole or in part,and the sponsor may be declared ineligible for further grant awards from the funding board The sponsor is responsible for any and all costs or liability arising from the sponsor's failure to so comply with applicable law Wages and Job Safety The sponsor agrees to comply with all applicable laws,regulations,and policies of the United States and the State of Washington which affect wages and job safely The sponsor agrees to pay the prevailing wage rate to all workers,laborers,or mechanics employed in the performance of any part of this contract if state law applies to the lands in question and the prevailing wage law applies to the work being performed The Washington State Department of Labor and Industries should be consulted to determine whether prevailing wage laws apply Further the sponsor agrees to comply with the provisions of the Davis-Bacon Act as required, and any other applicable federal laws Archaeological and Cultural Resources The sponsor must comply with Executive Order 05-05 or the National Historic Preservation Act before initiating ground disturbing activity The funding board requires documented compliance with Executive Order 05-05 or Section 106 of the National Historic Preservation Act,whichever is applicable to the project If a federal agency declines to consult,the sponsor shall comply with the requirements of Executive Order 05-05 In the event that archaeological or historic materials are discovered during project activities, work in the location of discovery and immediate vicinity must stop instantly,the area must be secured,and notification must be provided to the following concerned Tribes'cultural staff and cultural committees,RCO,and the State Department of Archaeology and Historic Preservation If human remains are discovered during project activity work in the location of discovery and immediate vicinity must stop instantly,the area must be secured,and notification provided to the concerned Tribe's cultural staff and cultural committee,RCO,State Department of Archaeology,the coroner and local law enforcement in the most expeditious manner possible according to RCW 68 50 Restrictions on Grant Use No part of any funds provided under this grant shall be used,other than for normal and recognized executive-legislative relationships, for publicity or propaganda purposes,or for the preparation,distribution,or use of any kit,pamphlet booklet,publication,radio, television,or video presentation designed to support or defeat legislation pending before the U S Congress or any state legislature No part of any funds provided under this grant shall be used to pay the salary or expenses of any sponsor,or agent acting for such sponsor,related to any activity designed to influence legislation or appropriations pending before the U S Congress or any state legislature PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 8 of 16 PROJAGR RPT SECTION 10. HAZARDOUS SUBSTANCES A Certification The sponsor shall inspect, investigate,and conduct an environmental audit of the proposed acquisition site for the presence of hazardous substances,as defined in Chapter 70 105D 020(11)RCW,and certify 1 No hazardous substances were found on the site,or 2 Any hazardous substances found have been treated and/or disposed of in compliance with applicable state and federal laws,and the site deemed"clean" B Responsibility Nothing in this provision alters the sponsor's duties and liabilities regarding hazardous substances as set forth in Chapter 70 105D RCW C Hold Harmless The sponsor will defend,protect and hold harmless RCO and any and all of its employees and/or agents,from and against any and all liability,cost(including but not limited to all costs of defense and attomeys'fees)and any and all loss of any nature from any and all claims or suits resulting from the presence of,or the release or threatened release of,hazardous substances on the property the sponsor is acquiring SECTION 11 RECORDS A Maintenance The sponsor shall maintain books,records,documents,data and other evidence relating to this Agreement and performance of the services described herein,including but not limited to accounting procedures and practices which sufficiently and properly reflect all direct and indirect costs of any nature expended in the performance of this Agreement Sponsor shall retain such records for a period of six years from the date RCO deems the project complete,as defined in Section 17(C)below If any litigation,claim or audit is started before the expiration of the six(6)year period,the records shall be retained until all litigation,claims,or audit findings involving the records have been resolved B Access to records and data At no additional cost,the records relating to the Agreement,including materials generated under the Agreement,shall be subject at all reasonable times to inspection,review or audit by RCO,personnel duly authorized by RCO,the Office of the State Auditor,and federal and state officials so authorized by law,regulation or Agreement This includes access to all information that supports the costs submitted for payment under the grant and all findings,conclusions,and recommendations of the sponsor's reports,including computer models and methodology for those models C Public Records Sponsor acknowledges that the funding board is subject to chapter 42 56 RCW and that this Agreement and any records sponsor submits or has submitted to the Stale shall be a public record as defined in chapter 42 56 RCW Additionally,in compliance with RCW 77 85 130(8),sponsor agrees to disclose any information in regards to expenditure of any funding received from the SRFB By submitting any record to the state sponsor understands that the State may be requested to disclose or copy that record under the state public records law,currently codified at RCW 42 56 The sponsor warrants that it possesses such Iegai rights as are necessary to permit the State to disclose and copy such document to respond to a request under state public records laws The Sponsor hereby agrees to release the State from any claims arising out of allowing such review or copying pursuant to a public records act request and to indemnify against any claims arising from allowing such review or copying and pay the reasonable cost of state's defense of such claims SECTION 12 TREATMENT OF ASSETS A Assets shall remain in the possession of the sponsor for the duration of the project or applicable grant program When the sponsor discontinues use of the asset(s)for the purpose for which it was funded,RCO will require the sponsor to deliver the asset(s)to RCO,dispose of the asset according to RCO policies,or return the fair market value of the asset(s)to RCO Assets shall be used only for the purpose of this Agreement,unless otherwise provided herein or approved by RCO in writing B The sponsor shall be responsible for any loss or damage to assets which results from the negligence of the sponsor or which results from the failure on the part of the sponsor to maintain and administer that asset in accordance with sound management practices SECTION 13 RIGHT OF INSPECTION The sponsor shall provide right of access to the project to RCO,or any of its officers,or to any other authorized agent or official of the state of Washington or the federal government,at all reasonable times,in order to monitor and evaluate performance,compliance, and/or quality assurance under this Agreement If a landowner Agreement or other form of control and tenure has been executed,it will further stipulate and define the funding board and RCO's right to inspect and access lands acquired or developed with funding board assistance SECTION 14 STEWARDSHIP AND MONITORING Sponsor agrees to perform monitoring and stewardship functions as stated in policy documents approved by the funding boards or RCO Sponsor further agrees to utilize,where applicable and financially feasible,any monitoring protocols recommended by the funding board PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 9 of 16 PROJAGR RPT SECTION 15 DEBARMENT CERTIFICATION A For Federally Funded Projects By signing the Agreement with RCO,the sponsor certifies that neither it nor Its principals nor any other lower tier participant are presently debarred,suspended,proposed for debarment,declared ineligible or voluntarily excluded from participation in this transaction by any Federal department or agency Further,the sponsor agrees not to enter into any arrangements or contracts related to this Agreement with any party that is on the"General Services Administration's Excluded from Federal Procurement or Non-procurement Programs at http 11www epls gov, The sponsor(prospective lower tier participant)shall provide immediate written notice to RCO if at any time the prospective lower tier participant learns that the above certification was not correct when submitted or has become erroneous by reason of changed circumstances B For State Funded Protects By signing the Agreement with RCO,the sponsor certifies that neither it nor its principals nor any other lower tier participant are presently debarred,suspended,proposed for debarment,declared ineligible or voluntarily excluded from participation in this transaction by Washington State Labor and Industries Further,the sponsor agrees not to enter into any arrangements or contracts related to this Agreement with any party that is on the"Contractors not Allowed to Bid on Public Works Protects"list at http llwww Im wa gov/TradesLicensing/PrevWage/AwardmgAgencies/DebarredContractors/ SECTION 16 PROJECT FUNDING A Additional Amounts The funding board shall not be obligated to pay any amount beyond the dollar amount as identified in this Agreement,unless an additional amount has been approved in advance by the funding board or director and incorporated by written amendment into this Agreement B Before the Agreement No expenditure made,or obligation incurred,by the sponsor before the project start dale shall be eligible for grant funds in whole or in part, unless specifically provided for by funding board policy,such as a waiver of retroactivity or program specific eligible pre-Agreement costs For reimbursements of such costs,this Agreement must be fully executed and an original received by RCO The dollar amounts identified in this Agreement may be reduced as necessary to exclude any such expenditure from reimbursement C After the period of performance No expenditure made,or obligation incurred,following the period of performance shall be eligible,in whole or in part,for grant funds hereunder In addition to any remedy the funding board may have under this Agreement,the grant amounts identified in this Agreement shall be reduced to exclude any such expenditure from participation SECTION 17 PROJECT REIMBURSEMENTS A This contract is administered on a reimbursement basis The sponsors may only request reimbursement after eligible and allowable costs have already been paid by the sponsor and remitted to their vendors RCO will then reimburse the sponsor for those costs based upon RCO's percentage as defined in Section F of the Protect Agreement of the amount billed to RCO RCO does not reimburse for donations which the sponsor may use as part of its percentage All reimbursement requests must include proper documentation of expenditures as required by RCO B Compliance and Payment The obligation of RCO to pay any amount(s)under this Agreement is expressly conditioned on strict compliance with the terms of this Agreement by the sponsor C Compliance and Retainage RCO reserves the right to withhold disbursement of up to the final ten percent(10%)of the total amount of the grant to the sponsor until the project has been completed A project is considered"complete"when 1 All approved or required activities outlined in the Agreement are done, 2 On-site signs are in place(if applicable), 3 A final project report is submitted to and accepted by RCO, 4 Any other required documents are complete and submitted to RCO, 5 A final reimbursement request is submitted to RCO, 6 The completed project has been accepted by RCO, 7 Final amendments have been processed,and 8 Fiscal transactions are complete 9 RCO has accepted a final boundary map,if required for the project,for which the Agreement terms will apply in the future D Reimbursement Request Frequency Sponsors are encouraged to send RCO a reimbursement request at least quarterly Sponsors are required to submit a reimbursement request to RCO,at a minimum for each project at least once a year for reimbursable activities occurring between July 1 and June 30 Sponsors must refer to the most recently published/adopted RCO policies and procedures regarding reimbursement requirements SECTION 18 ADVANCE PAYMENTS Advance payments of or in anticipation of goods or services to be provided under this Agreement are limited to grants approved by the SRFB and must comply with SRFB policy See WAC 420-12-060(5) PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW, Chapter 420 WAC Page 10 of 16 PROJAGR RPT SECTION 19 RECOVERY OF PAYMENTS In the event that the sponsor fails to expend funds under this Agreement in accordance with state and federal laws,and/or the provisions of the Agreement,or meet its percentage of the project total,RCO reserves the right to recover grant award funds in the amount equivalent to the extent of noncompliance in addition to any other remedies available at law or in equity The sponsor shall reimburse RCO for any overpayment or erroneous payments made under the Agreement Repayment by the sponsor of such funds under this recovery provision shall occur within 30 days of demand by RCO Interest shall accrue at the rate of twelve percent(12%)per annum from the time that payment becomes due and owing SECTION 20. COVENANT AGAINST CONTINGENT FEES The sponsor warrants that no person or selling agent has been employed or retained to solicit or secure this Agreement on an Agreement or understanding for a commission,percentage,brokerage or contingent fee,excepting bona fide employees or bona fide established agents maintained by the sponsor for the purpose of securing business RCO shall have the right,in the event of breach of this clause by the sponsor,to terminate this Agreement without liability or, in its discretion,to deduct from the Agreement grant amount or consideration or recover by other means the full amount of such commission,percentage, brokerage or contingent fee SECTION 21 PROVISIONS APPLYING TO DEVELOPMENT,RENOVATION AND RESTORATION PROJECTS The following provisions shall be in force only if the project described in this Agreement is for development,renovation and restoration of land or facilities for outdoor recreation,habitat conservation,or salmon recovery A Document Review and Approval The sponsor agrees to submit one copy of all development,renovation,restoration or construction plans and specifications to RCO for review prior to implementation Review and approval by RCO will be for compliance with the terms of this Agreement B Contracts for Development,Renovation or Restoration Sponsors must follow any applicable stale and/or required federal procurement procedures If such procedures do not apply,Sponsor must follow these minimum procedures (1)publish a notice to the public requesting bids/proposals for the project(2)specify in the notice the date for submittal of bids/proposals(3)speGfy in the notice the general procedure and criteria for selection,and (4)comply with the same legal standards regarding unlawful discrimination based upon race,ethnicity,sex,or sex-onentation that are applicable to stale agencies in selecting a bidder or proposer This procedure creates no rights for the benefit of third parties, including any proposers,and may not be enforced or subject to review of any kind or manner by any other entity other than the RCO Sponsors maybe required to certify to the RCO they have followed any applicable state and/or federal procedures or the minimum procedure where the former procedures do not apply C Contract Change Order Only change orders that impact the amount of funding or changes to the scope of the project as described to and approved by the funding board or RCO must receive pnorwntten approval D Control and Tenure The sponsor must provide documentation that shows appropriate tenure(land ownerAgreement,long term lease Agreement easement,or fee simple ownership)for the land proposed for development,renovation or restoration The documentation must meet current RCO requirements E Nondiscrimination Except where a nondiscrimination clause required by a federal funding agency is used,the sponsor shall insert the following nondiscrimination clause in each contract for construction of this project 'During the performance of this contract, the contractor agrees to comply with all federal and state nondiscrimination laws,regulations and policies" F Use of Best Management Practices Project sponsors are encouraged to use best management practices developed as part of the Washington State Aquatic Habitat Guidelines(AHG)Program The best management practices are described in three documents "Stream Habitat Restoration Guidelines Final Draft",2004,"Design of Road Culverts for Fish Passage' 2003,and "Integrated Streambank Protection Guidelines",2002 These documents and other information can be found on the AHG website SECTION 22 PROVISIONS APPLYING TO ACQUISITION PROJECTS The following provisions shall be in force only if the project described in this Agreement is for the acquisition of interest in real property (including easements)for outdoor recreation,habitat conservation,salmon recovery purposes,or farmland preservation A Evidence of Land Value Before disbursement of funds by RCO as provided under this Agreement the sponsor agrees to supply documentation acceptable to RCO that the cost of the property rights acquired has been established according to funding board policy B Evidence of Title The sponsor agrees to provide documentation that shows the type of ownership interest for the properly that has been acquired This shall be done before any payment of financial assistance C Legal Descnplion of Real Property Rights Acquired The legal description of the real property rights purchased with funding assistance provided through this project Agreement(and protected by a recorded conveyance of rights to the State of Washington)shall be incorporated into the Agreement before final payment PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 11 of 16 PROJAGR RPT D Conveyance of Rights to the State of Washington Document securing long-term rights for the State of Washington When real property rights(both fee simple and lesser interests)are acquired,the sponsor agrees to execute an appropriate document conveying certain rights and responsibilities to RCO,on behalf of the State of Washington These documents include a Deed of Right,Assignment of Rights Easements and/or Leases The sponsor agrees to use document language provided by RCO,to record the executed document in the County where the real property lies,and to provide a copy of the recorded document to RCO The document required will vary depending on the project type,the real property rights being acquired and whether or not those nghts are being acquired in perpetuity 1 Deed of Right The Deed of Right conveys to the people of the state of Washington the right to preserve,protect,and/or use the property for public purposes consistent with the fund source Sponsors shall use this document when acquiring real property rights that include the underlying land This document may also be applicable for those easements where the sponsor has acquired a perpetual easement for public purposes 2 Assignment of Rights The Assignment of Rights document transfers certain rights such as access and enforcement to RCO Sponsors shall use this document when an easement or lease is being acquired for habitat conservation or salmon recovery purposes The Assignment of Rights requires the signature of the underlying landowner and must be incorporated by reference in the easement document 3 Easements and Leases The sponsor may incorporate required language from the Deed of Right or Assignment of Rights directly into the easement or lease document,thereby eliminating the requirement for a separate document Language will depend on the situation,sponsor must obtain RCO approval on the draft language prior to executing the easement or lease E Real Property Acquisition and Relocation Assistance 1 When federal funds are part of this Agreement,the Sponsor agrees to comply with the terms and conditions of the Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970,84 Stat 1894(1970)—Public Law 91-646,as amended by the Surface Transportation and Uniform Relocation Assistance Act, PL 100-17-1987,and applicable regulations and procedures of the federal agency implementing that Act 2 When state funds are part of this Agreement,the sponsor agrees to comply with the terms and conditions of the Uniform Relocation Assistance and Real Property Acquisition Policy of the State of Washington Chapter 8 26 010 RCW,and Chapter 468-100 WAC 3 Housing and Relocation In the event that housing and relocation costs,as required by federal law set out in subsection(1) above and/or state law set out in subsection(2)above,are involved in the execution of this project,the sponsor agrees to provide any housing and relocation assistance required F Buildings and Structures In general,grant funds are to be used for outdoor recreation,habitat conservation,or salmon recovery Sponsors agree to remove or demolish ineligible structures Sponsors must consult RCO regarding compliance with section 9- Archaeological and Cultural Resources before structures are removed or demolished G Archaeological and Cultural Resources The sponsor agrees that any real property interests acquired under this Agreement,if to be subject to land disturbing activities in the future,is subject to Governor's Executive Order 05-05 or the National Preservation HistoncAct(S 106) The sponsor further agrees that ground disturbing activity will not occur until RCO has been notified and determines if a cultural resources review is needed SECTION 23 RESTRICTION ON CONVERSION OF REAL PROPERTYANDIOR FACILITIES TO OTHER USES The sponsor shall not at any time convert any real property or facility acquired,developed,and/or restored pursuant to this Agreement to uses other than those purposes for which funds were approved without prior approval of the funding board in compliance with applicable statutes,rules,and funding board policies It is the intent of the funding board's conversion policy,current or as amended in the future,that all real property or facilities acquired,developed and/or restored with funding assistance remain in the public domain in perpetuity unless otherwise identified in the Agreement or as approved by the funding board Determination of whether a conversion has occurred shall be based upon applicable law and RCFB/SRFB policies When a conversion has been determined to have occurred,the sponsor is required to remedy the conversion per established funding board policies SECTION 24 CONSTRUCTION,OPERATION,USE AND MAINTENANCE OF ASSISTED PROJECTS For acquisition,development, renovation and restoration projects,sponsors must ensure that properties or facilities assisted with funding board funds,including undeveloped sites,are built,operated,used,and maintained A According to applicable federal,state,and local laws and regulations,including public health standards and building codes B In a reasonably safe condition for the project's intended use C Throughout its estimated life so as to prevent undue deterioration D In compliance with all federal and state nondiscrimination laws,regulations and policies PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW Chapter 420 WAC Page 12 of 16 PROJAGR RPT For acquisition,development,renovation and restoration projects,facilities open and accessible to the general public must E Be constructed and maintained to meet or exceed the minimum requirements of the most current local or stale codes,Uniform Federal Accessibility Standards,guidelines,or rules,including but not limited to the Intemational Building Code,the Americans with Disabilities Act,and the Architectural Barriers Act,as updated F Appear attractive and inviting to the public except for brief installation,construction,or maintenance periods G Be available for use by the general public without reservation at reasonable hours and times of the year,according to the type of u area or facility SECTION 25 INCOME AND INCOME USE A Income 1 Compatible source The source of any income generated in a funded project or project area must be compatible with the funding source and the Agreement 2 Fees User and/or other fees maybe charged in connection with land acquired or facilities developed with funding board grants if the fees are consistent with the (a) Value of any service(s)furnished, (b) Value of any opportunities furnished,and (c) Prevailing range of public fees in the state for the activity involved Excepted are Firearms and Archery Range Recreation Program safety classes(firearm and/or hunter)for which a facility/range fee must not be charged(Chapter 79A 25 210 RCW) B Income use Regardless of whether income or fees in a project work site(including entrance, utility corridor permit,cattle grazing, timber harvesting,farming,etc)are gained during or after the reimbursement penod cited in the Agreement,unless precluded by state or federal law,the revenue may only be used to offset 1 The sponsor's matching funds, 2 The project's total cost, 3 The expense of operation,maintenance,stewardship,monitoring,and/or repair of the facility or program assisted by the funding board grant, 4 The expense of operation,maintenance,stewardship,monitoring,and/or repair of other similar units in the sponsor's system,and/or 5 Capital expenses for similar acquisition and/or development SECTION 26 PREFERENCES FOR RESIDENTS Sponsors shall not express a preference for users of grant assisted projects on the basis of residence(including preferential reservation, membership,and/or permit systems)except that reasonable differences in admission and other fees may be maintained on the basis of residence Even so,the funding board discourages the imposition of differential fees Fees for nonresidents must not exceed twice the fee imposed on residents Where there is no fee for residents but a fee is charged to nonresidents,the nonresident fee shall not exceed the amount that would be imposed on residents at comparable state or local public facilities SECTION 27. PROVISIONS RELATED TO CORPORATE(INCLUDING NONPROFIT)SPONSORS •corporate sponsor,including any nonprofit sponsor,shall A Maintain corporate status with the slate,including registering with the Washington Secretary of State's office,throughout the sponsor's obligation to the project as identified in the Agreement B Notify RCO prior to corporate dissolution Within 30 days of dissolution the sponsor shall name a qualified successor that will agree in writing to assume any on-going project responsibilities A qualified successor is any party eligible to apply for funds in the subject grant program and capable of complying with the terms and conditions of this Agreement RCO will process an amendment transferring the sponsors obligation to the qualified successor if requirements are met C Sites or facilities open to the public may not require exclusive use,(e g ,members only) SECTION 28. LIABILITY INSURANCE REQUIREMENTS FOR FIREARMS AND ARCHERY RANGE SPONSORS A The sponsor of a firearms or archery range recreation project shall procure an endorsement,or other addition,to liability insurance it may currently carry,or Shall procure a new policy of habil,ty insurance,-n a total coverage amount the sponsor deems adequate to ensure it will have resources to pay successful claims of persons who may be killed or injured,or suffer damage to property,while present at the range facility to which this grant is related,or by reason of being in the vicinity of that facility provided that the coverage shall be at least one million dollars($1,000,000)for the death of,or injury to each person B The liability insurance policy,including any endorsement or addition,shall name Washington Slate,the funding board,and RCO as additional insured and shall be in a form approved by the funding board or director PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 13 of 16 PROJAGR RPT C The policy,endorsement or other addition,or a similar liability insurance policy meeting the requirements of this section,shall be kept in force throughout the sponsor's obligation to the project as identified in this Agreement D The policy,as modified by any endorsement or other addition,shall provide that the issuing company shall give written notice to RCO not less than thirty(30)calendar days in advance of any cancellation of the policy by the insurer,and within ten(10) calendar days following any termination of the policy by the sponsor E The requirement of Subsection A through D above shall not apply if the sponsor is a federal,state,or municipal government which has established a program of self-insurance or a policy of self-insurance with respect to claims arising from its facilities or activities generally,including such facilities as firearms or archery ranges,when the applicant declares and describes that program or policy as a part of its application to the funding board F By this requirement,the funding board and RCO does not assume any duty to any individual person with respect to death,Injury, or damage to property which that person may suffer while present at,or in the vicinity of,the facility to which this grant relates Any such person,or any other person making claims based on such death,injury,or damage,must look to the sponsor,or others,for any and all remedies that may be available by law SECTION 29 REQUIREMENTS OF THE NATIONAL PARK SERVICE If the project has been approved by the National Park Service,US Department of the Interior,for funding assistance from the federal Land and Water Conservation Fund(LWCF),the`Project Agreement General Provisions"in the LWCF State Assistance Program Federal Financial Assistance Manual are also made part of this Agreement The sponsor shall abide by these LWCF General Provisions, in addition to this Agreement,as they now exist or are hereafter amended Further,the sponsor agrees to provide RCO with reports or documents needed to meet the requirements of the LWCF General Provisions SECTION 30 FARMLAND PRESERVATION ACCOUNT For projects funded through the Washington Wildlife and Recreation Program Farmland Preservation Account,the following sections will not apply if covered separately in a recorded RCO approved Agricultural Conservation Easement Section 8-Acknowledgement and Signs, Section 10-Hazardous Substances, Section 14-Stewardship and Monitoring Section 22-Provisions Applying to Acquisition Projects,Sub-sections F and G Section 23-Restriction on Conversion of Real Property and/or Facilities to Other Uses,and Section 24-Construction,Operation,Use and Maintenance of Assisted Projects,Sub-sections E, F,and G Section 25-Income and Income Use SECTION 31 ORDER OF PRECEDENCE This Agreement is entered into,pursuant to,and under the authority granted by applicable federal and state laws The provisions of the Agreement shall be construed to conform to those laws In the event of an inconsistency in the terms of this Agreement,or between its terms and any applicable statute,rule or policy or procedure,the inconsistency shall be resolved by giving precedence in the following order A Applicable federal and/or state statutes,regulations,policies and procedures including RCO/funding board policies and procedures,applicable federal Office of Management and Budget(OMB)circulars and federal and state executive orders, B Project agreement including attachments, C Special Conditions, D Standard Terms and Conditions of the Project Agreement SECTION 32. AMENDMENTS Amendments to this Agreement shall be binding only if in writing and signed by personnel authorized to bind each of the parties except period of performance extensions and minor scope adjustments need only be signed by RCO's director or designee SECTION 33 LIMITATION OF AUTHORITY Only RCO or RCO's delegate by writing(delegation to be made prior to action)shall have the express,implied,or apparent authority to alter,amend,modify,or waive any clause or condition of this Agreement Furthermore, any alteration,amendment,modification,or waiver of any clause or condition of this Agreement is not effective or binding unless made in writing and signed by RCO SECTION 34 WAIVER OF DEFAULT Waiver of any default shall not be deemed to be a waiver of any subsequent default Waiver or breach of any provision of the Agreement shall not be deemed to be a waiver of any other or subsequent breach and shall not be construed to be a modification of the terms of the Agreement unless stated to be such in writing,signed by the director,or the director's designee,and attached to the original Agreement SECTION 35 APPLICATION REPRESENTATIONS--MISREPRESENTATIONS OR INACCURACY OR BREACH The funding board and RCO rely on the sponsor's application in making its determinations as to eligibility for,selection for,and scope of,funding grants Any misrepresentation,error or inaccuracy in any part of the application may be deemed a breach of this Agreement PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter420 WAC Page 14 of 16 PROJAGR RPT SECTION 36. SPECIFIC PERFORMANCE The funding board and RCO may enforce this Agreement by the remedy of specific performance,which usually will mean completion of the protect as described in this Agreement However,the remedy of specific performance shall not be the sole or exclusive remedy available to RCO No remedy available to the funding board or RCO shall be deemed exclusive The funding board or RCO may elect to exercise any,a combination of,or all of the remedies available to it under this Agreement,or under any provision of law,common law,or equity SECTION 37 TERMINATION The funding board and RCO will require strict compliance by the sponsor with all the terms of this Agreement including, but not limited to,the requirements of the applicable statutes,rules and all funding board and RCO policies,and with the representations of the sponsor in its application for a grant as finally approved by the funding board A For Cause The funding board or the director may suspend or terminate the obligation to provide funding to the sponsor under this Agreement i In the event of any breach by the sponsor of any of the sponsor's obligations under this Agreement,or u If the sponsor fails to make progress satisfactory to the funding board or director toward completion of the protect by the completion date set out in this Agreement Included in progress is adherence to milestones and other defined deadlines In the event this Agreement is terminated by the funding board or director,under this section or any other section after any portion of the grant amount has been paid to the sponsor under this Agreement the funding board or director may require that any amount paid be repaid to RCO for redeposit into the account from which the funds were derived B Non Availability of Funds The obligation of the RCO to make payments is contingent on the availability of state and federal funds through legislative appropriation and stale allotment If amounts sufficient to fund the grant made under this Agreement are not appropriated to RCO for expenditure for this Agreement in any biennial fiscal penod,RCO shall not be obligated to pay any remaining unpaid portion of this grant unless and until the necessary action by the Legislature or the Office of Financial Management occurs If RCO participation is suspended under this section for a continuous period of one year,RCO's obligation to provide any future funding under this Agreement shall terminate Termination of the Agreement under this section is not subject to appeal by the sponsor C For Convenience Except as otherwise provided in this Agreement, RCO may, by ten(10)days written notice,beginning on the second day after the mailing,terminate this Agreement,in whole or in part If this Agreement is so terminated, RCO shall be liable only for payment required under the terms of this Agreement for services rendered or goods delivered pnor to the effective date of termination SECTION 38 DISPUTE HEARING Except as may otherwise be provided in this Agreement,when a dispute arises between the sponsor and the funding board,which cannot be resolved,either party may request a dispute hearing according to the process set out in this section Either party's request for a dispute hearing must be in writing and clearly stale A The disputed issues B The relative positions of the parties, C The sponsor's name,address,project title,and the assigned project number In order for this section to apply to the resolution of any specific dispute or disputes,the other party must agree in writing that the procedure under this section shall be used to resolve those specific issues The dispute shall be heard by a panel of three persons consisting of one person chosen by the sponsor, one person chosen by the director,and a third person chosen by the two persons initially appointed If a third person cannot be agreed on,the third person shall be chosen by the funding board's chair Any hearing under this section shall be informal,with the specific processes to be determined by the disputes panel according to the nature and complexity of the issues involved The process may be solely based on written material if the parties so agree The disputes panel shall be governed by the provisions of this Agreement in deciding the disputes The parties shall be bound by the decision of the disputes panel,unless the remedy directed by that panel shall be without the authority of either or both parties to perform,as necessary,or is otherwise unlawful Request for a disputes hearing under this section by either party shall be delivered or mailed to the other party The request shall be delivered or mailed within thirty(30)days of the date the requesting party has received notice of the action or position of the other party which it wishes to dispute The written Agreement to use the process under this section for resolution of those issues shall be delivered or mailed by the receiving party to the requesting party within thirty(30)days of receipt by the receiving party of the request All costs associated with the implementation of this process shall be shared equally by the parties SECTION 39 ATTORNEYS'FEES In the event of litigation or other action brought to enforce contract terms,each party agrees to bear its own attorney fees and costs PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW,Chapter 420 WAC Page 15 of 16 PROJAGR RPT SECTION 40 GOVERNING LAW/VENUE This Agreement shall be construed and interpreted in accordance with the laws of the State of Washington In the event of a lawsuit involving this Agreement,venue shall be in Thurston County Superior Court if legally proper,otherwise venue shall be in a county where the project is situated The sponsor,by execution of this Agreement acknowledges the jurisdiction of the courts of the State of Washington In the cases where this Agreement is between the funding board and a federally recognized Indian Tribe,the following governing law/venue applies A Notwithstanding the above venue provision,if the State of Washington intends to initiate a lawsuit against a federally recognized Indian tribe relating to the performance,breach or enforcement of this Agreement, it shall so notify the Tribe If the Tribe believes that a good faith basis exists for subject matter jurisdiction of such a lawsuit in federal court,the Tribe shall so notify the State within five days of receipt of such notice and state the basis for such jurisdiction If the Tribe so notifies the State,the State shall bring such lawsuit in federal court,otherwise the State may sue the Tribe in the Thurston County Superior Court Interpretation of the Agreement shall be according to applicable State law except to the extent preempted by federal or tribal law In the event suit is brought in federal court and the federal court determines that it lacks subject matter jurisdiction to resolve the dispute between the Stale and Tribal Party,then the parties agree to venue in Thurston County Superior Court B Any judicial award,determination,order,decree or other relief,whether in law or equity or otherwise,resulting from such a lawsuit shall be binding and enforceable on the parties Any money judgment or award against a Tribe,tribal officers and members,or the State of Washington and its officers and employees may exceed the amount provided for in Section F-Project Funding of the Agreement in order to satisfy the judgment C The Tribe hereby waives its sovereign immunity to legal actions as may be brought pursuant to this section,and to the enforcement of any judgment from such legal actions This waiver is not for the benefit of any third party and shall not be enforceable by any third party or by any assignee of the parties In any enforcement action,the parties shall bear their own enforcement costs,including attorneys'fees SECTION 41 SEVERABILITY The provisions of this Agreement are intended to be severable If any term or provision is illegal or invalid for any reason whatsoever, such illegality or invalidity shall not affect the validity of the remainder of the Agreement PSAR Project Agreement-RCO#11-1219P Salmon Funding Accounts Chapter 77 85 RCW, Chapter 420 WAC Page 16 of 16 PROJAGR RPT Eligible Scope Activities Protect Sponsor: City of Kent Protect Number: 11-1219 Protect Title: Downey Farmstead Final Design Project Type: Planning Program: Puget Sound Acq & Restoration Approval 12/9/2011 Planning Metrics Worksite#1, Downey Farmstead Property Targeted salmonid ESU/DPS Chinook Salmon-Puget Sound ESU, Chum Salmon-Puget Sound/Strait of Georgia ESU, Coho Salmon-Puget Sound/Strait of Georgia ESU, Pink Salmon-unidentified ESU, Steelhead-Puget Sound DPS *Chinook-Primary species Targeted species(non-ESU species) Bull Trout, Cutthroat Area Encompassed(acres) 218 Design for Salmon restoration Final design and permitting Name of Plan Preliminary Design Report Downey Farmstead Restoration March 23, 2011 Herrera Environmental Consultants 2200 Sixth Ave, Suite 1100 Seattle, WA 98121 ELIGREIM RPT January 24,2012 Page 1 Eligible Scope Activities Description of Plan The report describes preliminary design analyses performed for the Downey Farmstead Restoration Protect, key features of the preliminary protect design, and additional work needed to support final design and permitting for the protect as presented The protect preliminary design included a comprehensive assessment of existing site conditions and potential restoration scenarios The preliminary design seeks to maximize juvenile salmonid rearing and refuge habitat within the available site area while balancing the need to maintain vehicular traffic on Frager Road through the site The report includes an overview of the protect that describes the history and goals of protect development to date, discussion of existing site conditions, discussion of habitat restoration plan development including alternatives that were analyzed and used as a basis for selecting the prefered alternative for detailed design, a summary of technical analyses performed to support design development and establish important information needed for project permitting and collaboration with regulatory agencies and the Muckleshoot Indian Tribe, a description of key aspects of the preliminary design plans, and additional design analyses needed to finish the design, a discussion of the regulatory permits and approvals needed to begin project construction Cultural Resources Cultural resources ELIGREIM RPT January 24,2012 Page 2 Milestone Report By Project Project Number: 11-1219 P Project Name: Downey Farmstead Final Design Sponsor Kent City of Project Manager: Elizabeth Butler X Milestone Target Date Comments/Description X i Preliminary Design to RCO 04/12/2011 Completed with 08-1659 funding Project Start 1 210 8/2 0 1 1 Eligible pre-ageement expenses per Manual 18(2011) page 65 Data Gathering Started 01/1 5120 1 2 City of Kent project engineer assigned Progress Report Submitted 06/30/2012 Annual Protect Billing 0713 1/2 0 1 2 Required by this date Applied for Permits 08/31/2012 Cultural Resources Complete 08/31/2012 Complete Survey Progress Report Submitted 12/31/2012 Draft Design to RCO 12/31/2012 Draft Final Design deliverables as described in Appendix D Manual 18 (2012) r Final Design to RCO 04/30/2013 Final Design deliverables as described in Appendix D Manual 18(2012) i Progress Report Submitted 06/30/2013 i Annual Project Billing 07/31/2013 Permits Complete 10/31/2013 Special Conditions Met 1 013 1/20 1 3 Section 106-confirm APE matches grant scope Final Report in PRISM 12/31/2013 PROJECT CLOSING All expenditures must be prior to this date i Agreement End Date 12/31/2013 Final Billing to RCO 02/28/2014 Provide your final invoice and report within 60 days of Agreement End Date X=Milestone Complete i=Critical Milestone 1MILESTO RPT January 24,2012 Page 1 Press Release Template City of Kent offered grant to develop a plan or assessment for salmon recovery. (Kent)-City of Kent was awarded a grant of$253,581 00 from the Puget Sound Acquisition & Restoration The grant was awarded by the Salmon Recovery Funding Board(SRFB), and will be used for the following The City of Kent will use this grant to complete the design and get permits for a project to realign Frager Road to allow creation of a side channel network and expanded floodplarn at the Downey farmstead on the south bank of the Green River The goal of the project is to create habitat for Chinook salmon to rear, rest and hide from predators A secondary goal is to create additional flood storage to help alleviate flooding in urban and agricultural areas The road alignment will provide a greater buffer from the river and will continue to be open to vehicular, bicycle and pedestrian access adjacent to river Kent will contribute $46,419 from a local grant There were thuty-nine applications submitted for consideration in the Puget Sound Acquisition & Restoration Each project went through an evaluation process prior to being recommended for funding The SRFB Board approved funding for projects on Friday, December 9, 2011 Funding for the Puget Sound Acquisition & Restoration comes(new) City of Kent will leverage local contributions totaling$46,419 00 with grant monies to implement the project Total estimated project cost is$300,000 00 SRFB is the state's administrator of the grant program Contact Alex Munllo, (253)856-5528(sponsor project manager) Elizabeth Butler, (360)725-3944, elizabeth butler@rco wa gov(SRFB project manager) I REQUEST FOR MAYOR'S SIGNATURE ,,7 .A�a KEN T Please Fill in All Applicable Boxes W.SHINGTON Routing Information (ALL REQUESTS MUST FIRST BE ROUTED THROUGH THE LAW DEPARTMENT) Originator Kob n- �Gn �r�eQr2tn Phone (Originator}: e,,+ 10549 Date Sent z_ Date Required. Z-Zcj'- ' -?_ Return Signed Document CONTRACT TERMINATION DATE: VENDOR NAME:�q�l�� �4 �-� DATE OF COUNCIL APPROVAL: -we - e se+-ila�►►e,� o i'u Brief Explanation of Document: �' A O-O jC c A^reQ AAevc �vr �,�r�Qx n i►� ,2 d/vto uv� p� Z�3,S� 1 All Contracts Must Be Routed Through the Law Department (This Area to be Completed By the Law Department) Received: RECENED Approval of Law Dept.: FEB 2 2 Law Dept Comments: �� ;.=a •`yt; KENT LAW DEPT• Date Forwarded to Mayor Shaded Areas to Be Completed by Administration Staff Received: Recommendations & Comments: Disposition: 2/Z 9F/Z L::1111 741;UXth � ERn Date Returned: lage58M • 3(05 RECEIVED (* CITY Natural Resources Budding (360)902-3000 1111 Washington St S E MAR 14 2012 TTY(360)902-1996 Olympia,WA 98501 Fax (360)902-3026 PO Box 40917 OF KENT infoC�rco wa gov STATE OF WASHING Olympia,WA98504-0917 GINEERING DEPT.E-mailbsite wwwrcowagov RECREATION AND CONSERVATION OFFICE March 13, 2012 TO: Alex Murillo City of Kent FROM: Brian Abbott, Salmon Section Manager RE Downey Farmstead Final Design, RCO #11-1219P Attached is a signed copy of your project agreement for your files You may visit our website at http //www rco wa gov/rcfb/docs htm#proq manuals to download copies of our manuals and reimbursement forms Please pay attention to the project milestones and contact us immediately if you are having any difficulty meeting your deadlines We wish you success and look forward to seeing the completed project! If you have any questions, please contact your grant manager, Elizabeth Butler, at (360) 725-3944 or elizabeth butler(&rco wa.gov. Thank you for your support and participation in our grant programs. Enclosure Recreation and Conservation Funding Board•Salmon Recovery Funding Board Washington Invasive Species Council•Governor's Salmon Recovery Office �r •°0111W" Habitat and Recreation Lands Coordinating Group `1�