The URL can be used to link to this page

Home My WebLink AboutCAG2019-473 - Original - Colvico, Inc. - Pump Station 3 Electrical System Improvements - 11/20/2019 Agreement RoutingForm KEN T For Approvals,Signatures and Records Management W A S Y I N G T O N This form combines&replaces the Request for Mayor's Signature and Contract Cover Sheet forms. (Print on pink or cherry colored paper) Originator. Nancy for Joe Araucto Department: Public Works Date Sent: 11/20/19 Date Required: 11/26/19 > Authorized Director or Designee Date of CL to Sign: ✓ Council 11/5/19 QMayor Approval: Budget W20032 Grant? ❑ Yes No Account Number. Type: N/A Vendor Name: Colvico Inc. Category: Contract = Vendor 747093 Sub-Category a Number: a Project E Name: Pump Station No. 3 Electrical System Improvements 0 C� Project Details: Installation of new electrical components. c £ Agreement Basis for $345,186.60 do Amount: Selection of B i d Contractor: Start Date: Mayor's signature Termination Date: 40 Working days Notice required prior to Yes No Contract Number: disclosure? ❑ ❑ 7 +7 3 Date Received by City Attorney: Comments: RECEIVED � t o 56�L— cc N a i RECEIVED _ M Date Route to the ayor's ice:' N 1 Date Routed to the City Clerk's Office: a� 1! I City of Kent Date Sent to Originator: Office of t1he IVICIyor Visit Documents.KentWA.gov to obtain copies of all agreements adccW22373_6_19 CITY OF KENT KING COUNTY, WASH I NGTON KENT SPEC I AL PROV I S I ONS FOR Pump Station No. 3 Electrical System Improvements Project Number: 17-7999.6 B 1 DS ACCEPTED UNT I L BID OPENING October 29, 2019 October 29, 2019 10:45 A.M. 11 :00 A.M. DELIVER TO CITY OF KENT, CITY HALL 220 4th Avenue S., Kent, WA 98032-5895 TIMOTHY J. LAPORTE, P.E. PUBLIC WORKS DIRECTOR • KENT' WAS HI NGTON I NDEX Section 1 Bidder's Package Section 2 Payment and Performance Bond and Contract Section 3 Table of Contents Section 4 Kent Special Provisions Section 5 Technical Specifications Section 6 Site and Equipment Photos Section 7 Prevailing Wage Rates CITY OF KENT KING COUNTY, WASHINGTON KENT SPECIAL PROVISIONS FOR Pump Station No. 3 Electrical System Improvements Project Number: 17-7999 . 6 BIDS ACCEPTED UNTIL BID OPENING October 29, 2019 October 29, 2019 10:45 A.M. 11 :00 A.M. DELIVER TO CITY OF KENT, CITY HALL 220 4th Avenue S., Kent, WA 98032-5895 N S. TIMOTHY J. LAPORTE, P.E. PUBLIC WORKS DIRECTOR /) . �10/8/2019 Q 38748 FG/STIE �s`S7�NA L Except for Technical Specifications KENT W A S H I N G T O N BIDDER'S NAME Colvico Inc . CITY OF KENT KING COUNTY, WASHINGTON KENT SPECIAL PROVISIONS FOR Pump Station No. 3 Electrical r v e S Project Number: 7-7 99.6 BIDS ACCEPTED UNTIL BID OPENING October 29, 2019 October 29, 2019 10:45 A.M. 11:00 A.M. DELIVER TO CITY OF KENT, CITY HALL 220 4th Avenue S., Kent, WA 98032-5895 TIMOTHY J. LAPORTE, P.E. PUBLIC WORKS DIRECTOR KEN• T W A 5 H I N G T 0 N ORDER OF CONTENTS Invitation to Bid Contractor Compliance Statement Declaration — City of Kent Equal Employment Opportunity Policy Administrative Policy 1 .2 — Minority and Women Contractors City of Kent Equal Employment Opportunity Compliance Statement Proposal City of Kent Subcontractor List (over $100K) Subcontractor List (over $1 million) Contractor's Qualification Statement Statement that Bidder Has Not Been Disqualified Certification of Compliance with Wage Payment Statutes Proposal Signature Page Bid Bond Form Combined Declaration Form Non-Collusion, Minimum Wage Change Order Bidder's Checklist Payment and Performance Bond Contract Table of Contents Kent Special Provisions Technical Specifications Site and Equipment Photos Prevailing Wage Rates INVITATION TO BID Notice is hereby given that the City of Kent, Washington, will receive sealed bids at the City Clerk's office through October 29, 2019 up to 10:45 a.m. as shown on the clock on the east wall of the City Clerk's Office on the first floor of City Hall, 220 4th Avenue South, Kent, Washington. All bids must be properly marked and sealed in accordance with this "Invitation to Bid." Bids must be delivered and received at the City Clerk's office by the above-stated time, regardless of delivery method, including U.S. Mail. All bids will be opened and read publicly aloud at 11:00 a.m. for the City of Kent project named as follows: Pump Station No. 3 Electrical System Improvements Project Number: 17-7999.6 The project consists removing existing electrical components and installation of new electrical components and other work all in accordance with the Contract Plans, Kent Special Provisions, and the WSDOT Standard Specifications; for the City of Kent's for the water Pump Station no. 3 site located at 25000 Lake Fenwick Road, Kent Washington 98032. The City will make the sites open to contractors interested on bidding the project on October 22, 2019 from 9:00 a.m. to 11:00 a.m. located at 25000 Lake Fenwick Road, Kent Washington 98032. City staff will be present only to provide access to the site and building; not to answer questions or provide information. The Engineer's estimated range for this project is approximately $300,000 to 350,000. Bid documents may be obtained by contacting City of Kent Engineering Department, Nancy Yoshitake at 253-856-5508. For technical questions, please call Joseph Araucto at 253-856- 5664. Bids must be clearly marked "Bid" with the name of the project on the outside of the envelope, addressed to the City Clerk, 220 4th Avenue South, Kent, WA 98032-5895. Only sealed bids will be accepted. No facsimiles or electronic submittals will be considered. Each bid shall be in accordance with the plans and specifications and other contract documents now on file in the office of the City Engineer, City of Kent, Washington. Plans and specifications can also be downloaded at no charge at KentWA.gov/doing- business/bids-procurement. Copies of the WSDOT Standard Specifications are available for perusal only. Apprentice Utilization Requirements are mandatory for all public works estimated to cost one million dollars or more, in which case no less than 15% of the labor hours must be performed by apprentices. KCC 6.01.030. A cashier's check, cash or surety bond in the amount of 5% of the bid must be included with the bid. The City of Kent reserves the right to reject any and all bids on any or all schedules or alternates or to waive any informalities in the bidding and shall determine which bid or bidders is the most responsive, satisfactory and responsible bidder and shall be the sole judge thereof. No plea of mistake in the bid shall be available to the bidder for the recovery of his/her deposit or as a defense to any action based upon the neglect or refusal to execute a contract. No bidder may withdraw his/her bid for a period of sixty (60) days after the day of bid opening. Dated this loth day of October, 2019. BY: Kimberley A. Komoto, City Clerk Published in Daily Journal of Commerce on October 15 and 22, 2019. CONTRACTOR COMPLIANCE STATEMENT (President's Executive Order #11246) Date October 28, 2019 This statement relates to a proposed contract with the City of Kent named Pump Station No. 3 Electrical System Improvements Project Number: 17-7999.6 I am the undersigned bidder or prospective contractor. I represent that - 1. I X have, have not, participated in a previous contract or subcontract subject to the President's Executive Order #11246 (regarding equal employment opportunity) or a preceding similar Executive Order. Colvico Inc . NAME OF I ER BY: SIG -A URE/TITLE Jesse Dragoo, Vice President 2812 N Pittsburg Street Spokane, WA 99207 ADDRESS (Note to Bidders: The information required in this Compliance Statement is informational only) PS 3 Electrical System Improvements/Araucto 1 October 10, 2019 Project Number: 17-7999.6 DECLARATION CITY OF (CENT EQUAL EMPLOYMENT OPPORTUNITY POLICY The City of Kent is committed to conform to Federal and State laws regarding equal opportunity. As such, all contractors, subcontractors and suppliers who perform work with relation to this contract shall comply with the regulations of the City's equal employment opportunity policies. The following questions specifically identify the requirements the City deems necessary for any contractor, subcontractor or supplier on this specific contract to adhere to. An affirmative response is required on all of the following questions for this contract to be valid and binding. If any contractor, subcontractor or supplier willfully misrepresents themselves with regard to the directives outlined, it will be considered a breach of contract and it will be at the City's sole determination regarding suspension or termination for all or part of the contract; The questions are as follows: 1. I have read the attached City of Kent administrative policy number 1.2. 2. During the time of this contract, I will not discriminate in employment on the basis of sex, race, color, national origin, age, or the presence of all sensory, mental or physical disability. 3. During the time of this contract, the prime contractor will provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 4. During the time of the contract I, the prime contractor, will actively consider hiring and promotion of women and minorities. 5. Before acceptance of this contract, an adherence statement will be signed by me, the Prime Contractor, that the Prime Contractor complied with the requirements as set forth above. By signing belo , gree to fulfill the five requirements referenced above. By: Jesse Dragoo For: Colvico Inc . Title: Vice President Date: October 28, 2019 PS 3 Electrical System Improvements/Araucto 2 October 10, 2019 Project Number: 17-7999.6 CITY OF KENT ADMINISTRATIVE POLICY NUMBER: 1.2 EFFECTIVE DATE: January 1, 1998 SUBJECT: MINORITY AND WOMEN SUPERSEDES: April 1, 1996 CONTRACTORS APPROVED BY Jim White, Mayor POLICY: Equal employment opportunity requirements for the City of Kent will conform to federal and state laws. All contractors, subcontractors, consultants and suppliers of the City must guarantee equal employment opportunity within their organization and, if holding contracts with the City amounting to $10,000 or more within any given year, must take the following affirmative steps: 1. Provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 2. Actively consider for promotion and advancement available minorities and women. Any contractor, subcontractor, consultant or supplier who willfully disregards the City's nondiscrimination and equal opportunity requirements shall be considered in breach of contract and subject to suspension or termination for all or part of the contract. Contract Compliance Officers will be appointed by the Directors of Planning, Parks, and Public Works Departments to assume the following duties for their respective departments. 1. Ensuring that contractors, subcontractors, consultants, and suppliers subject to these regulations are familiar with the regulations and the City's equal employment opportunity policy. 2. Monitoring to assure adherence to federal, state and local laws, policies and guidelines. PS 3 Electrical System Improvements/Araucto 3 October 10, 2019 Project Number: 17-7999.6 CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE STATEMENT This form shall be filled out AFTER COMPLETION of this project by the Contractor awarded the contract. I, the undersigned, a duly represented agent of Company, hereby acknowledge and declare that the before- mentioned company was the prime contractor for the contract known as Pump Station No. 3 Electrical System Improvements/Project Number: 17-7999.6 that was entered into on the (Date) , between the firm I represent and the City of Kent. I declare that I complied fully with all of the requirements and obligations as outlined in the City of Kent Administrative Policy 1.2 and the Declaration City of Kent Equal Employment Opportunity Policy that was part of the before-mentioned contract. By: For: Title: Date: PS 3 Electrical System Improvements/Araucto 4 October 10, 2019 Project Number: 17-7999.6 PROPOSAL To the City Clerk City Hall Kent, Washington 98032 The undersigned hereby certifies that Colvico Inc . has examined the job site and construction details of the work as outlined on the plans and described in the specifications for the project named Pump Station No. 3 Electrical System Improvements/Project Number: 17-7999.6 for the City of Kent, Washington, and has read and thoroughly understands the plans and specifications and contract governing the work embraced in this improvement and the method by which payment will be made for that work and hereby proposes to undertake and complete the work embraced in this improvement in accordance with the bid and contract, and at the following schedule of rates and prices: NOTE TO BIDDERS: 1) All bid items are described in the Kent Special Provisions (KSP) or the Standard Specifications (WSDOT). Reference the Section No. listed in this proposal, where the bid item is described. 2) Proposal items are numbered in sequence but are non-continuous. 3) Unit prices for all items, all extensions, and total amount of bid must be shown. 4) Should bid items with identically worded bid item descriptions, marked with asterisk (*), appear in more than one schedule of the proposal, the bidder must bid the same unit price on corresponding items for each schedule. If the Contractor enters different unit prices on these items, the City will unilaterally revise the bid amounts to the lowest unit price on each corresponding item and recalculate the Contractor's total bid amount. The corrected total bid amount will be used by the City for award purposes and fix the amount of the contract bond. EXAMPLE SCHEDULE I - STREET ITEM SECTION APPROX. ITEM UNIT TOTAL NO. NO. QUANTITY PRICE AMOUNT 1006 2-03.5 100 Roadway Excavation, $14.00 $1,400.00 WSDOT CU YDS Including Haul Per CY Any bids not filled out properly may be considered non-responsive. PS 3 Electrical System Improvements/Araucto 5 October 10, 2019 Project Number: 17-7999.6 ITEM SECTION APPROX. ITEM UNIT TOTAL NO. NO. QUANTITY PRICE AMOUNT 1 1-09.7 1 Mobilization $ 9, 480 . 00 $ 9, 480 . 00 WSDOT LUMP SUM Per LS 2 Technical 1 Temporary Operations $ 24, 7 0 8 . 0 0$ 24, 708 . 00 Specification 01200 LUMP SUM Per LS 3 Technical 1 Demolition $ 5, 7 8 4 . 0 0 $ 5, 7 8 4 0 0 Specification 01200 LUMP SUM Per LS 4 Technical 1 Electrical Equipment $ 4 5, 7 3 9 . 0 0 $ 4 5, 7 3 9 . 0 0 Specification 01200 LUMP SUM Per LS 5 Technical 1 Controls Equipment $170, 798 .00 $ Specification170, 798 . 00 01200 LUMP SUM Per LS 6 Technical 1 Raceways, Wire & Installation $15, 7 0 6 . 0 0 $ 15, 7 0 6 . 0 0 Specification 01200 LUMP SUM Per LS 7 Technical 1 Lighting, Receptacles, HVAC & Specification $ 18, 991 . 03 18, 991 . 00 01200 LUMP SUM Misc. Electrical Per LS 8 Technical 1 Programming Services $ 4, 760 - 00 $ 4, 7 6 0 00 Specification 01200 LUMP SUM Per LS 9 1-07.15(1) 1 SPCC Plan $2, 840 . 00 $ 2, 840 00 WSDOT LUMP SUM Per LS 10 8-01.5 1 Erosion/Water Pollution $10,000.00* $10,000.00 WSDOT FORCE Control Per FA ACCOUNT *Common price to all bidders PS 3 Electrical System Improvements/Araucto 6 October 10, 2019 Project Number: 17-7999.6 ITEM SECTION APPROX. ITEM UNIT TOTAL NO. NO. 2UANTITY PRICE AMOUNT 11 1-04.4(1) 1 Minor Changes $5,000.00* $5,000.00 WSDOT CALC Per CALL *Common price to all bidders Sub Total $ 313, 806 . 00 10% WA State Sales Tax $ 31 , 380 . 60 Total $ 345, 186 . 60 PS 3 Electrical System Improvements/Araucto 7 October 10, 2019 Project Number: 17-7999.6 CITY OF KENT SUBCONTRACTOR LIST (Contracts over $100,000) List each subcontractor, from any tier of subcontractors, that shall perform subcontract work amounting to more than 10% of the total bid contract price. List each bid item to be performed by each designated subcontractor in numerical sequence. If no subcontractors will be performing 10% or more of the work, indicate this by writing "None" and signing this form at the bottom of the page. Failure to submit a fully completed and signed subcontractor list after the time set for bid opening may disqualify your bid. Project Name: Pump Station No. 3 Electrical System Improvements Project Number: 17-7999.6 Subcontractor Name N/A Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers CONTRACTOR'S SIGNATURE PS 3 Electrical System Improvements/Araucto 8 October 10, 2019 Project Number: 17-7999.6 i CITY OF KENT SUBCONTRACTOR LIST (Contracts over $100,000) i List each subcontractor, from any tier of subcontractors, that shall perform subcontract work amounting to more than 10% of the total bid contract price. List each bid item to be performed by each designated subcontractor in numerical sequence. If no subcontractors will be performing 10% or more of the work, indicate this by writing "None" and signing this form at the bottom of the page. Failure to submit a fully completed and signed subcontractor list after the time set for bid opening may disqualify your bid. Project Name: Pump Station No. 3 Electrical System Improvements Project Number: 17-7999.6 I � Subcontractor Name N/A Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers Subcontractor Name Item Numbers CONTRACTOR'S SIGNATURE PS 3 Electrical System Improvements/Araucto 8 October 10,2019 Project Number: 17-7999.6 SUBCONTRACTOR LIST (Contracts over 1 million dollars) Name of Bidder: Colvico, Inc . Project Name: Pump Station No. 3 Electrical System Improvement s Project Number: 17-7999.6 Pursuant to RCW 39.30.060, Bidder shall list the names of the subcontractors with whom the Bidder, if awarded the contract, will subcontract for performance of the work of heating, ventilation, and air conditioning; plumbing; and electrical, or to name itself for the work. Failure of the Bidder to submit, as part of the Bid, the names of such subcontractors or to name itself to perform such work or the naming of two or more subcontractors to perform the same work shall render the Bidder's Bid non-responsive and, therefore, void. Heating, Ventilation, and Air Conditioning Subcontractor Name: N/A Plumbing Subcontractor Name: N/A Electrical Subcontractor Name: Colvico Inc . (Self Perform) rhOctober 28, 2019 Sign r Bidder Date PS 3 Electrical System Improvements/Araucto 9 October 10, 2019 Project Number: 17-7999.6 CONTRACTOR'S QUALIFICATION STATEMENT (RCW 39.04.350) THE CITY WILL REVIEW THE CONTRACTOR'S RESPONSES TO THIS FORM TO DETERMINE WHETHER THE BIDDING CONTRACTOR IS RESPONSIBLE TO PERFORM THE CONTRACT WORK. THIS FORM INCLUDES CRITERIA ESTABLISHED BY STATE LAW THAT MUST BE MET TO BE CONSIDERED A RESPONSIBLE BIDDER AND QUALIFIED TO BE AWARDED THIS PUBLIC WORKS PROJECT AS WELL AS SUPPLEMENTAL CRITERIA ESTABLISHED BY THE CITY THAT ARE APPLICABLE TO THIS PUBLIC WORKS PROJECT. THE BIDDER SHOULD READ AND RESPOND TO THIS FORM CAREFULLY. Indicia of contractor's responsibility inherently involve subjective determinations as to the contractor's ability to perform and complete the contract work responsibly and to the owner city's satisfaction. The city has an obligation and a duty to its citizens and its taxpayers to administer its budgets and complete its projects in a businesslike manner. Accordingly, it has a duty to exercise the type of inquiry and discretion a business would conduct when selecting a contractor who will be responsible to perform the contract work. The city's supplemental criteria are based, in large part, on the qualification statement form used by the American Institute of Architects. The city provides these criteria so as to provide the most objective framework possible within which the city will make its decision regarding the bidder's ability to be responsible to perform the contract work. These criteria, taken together, will form the basis for the city's decision that a bidder is or is not responsible to perform the contract work. Any bidder may make a formal written request to the city to modify the criteria set forth in this qualification statement, but that request may only be made within 48 hours of the date and time that the bidder first obtains the bid documents or three (3) business days prior to the scheduled bid opening date, whichever occurs first. If the city receives a modification request, it will consider any information submitted in the request and will respond before the bid submittal deadline. If the city's evaluation results in changed criteria, the city will issue an addendum establishing the new or modified criteria. If the city determines that, based on the criteria established in this statement, a bidder is not responsible to perform the contract work, the city will provide written notice of its determination that will include the city's reason for its decision. The bidder has 24 hours from the time the city delivers written notice to the bidder that the bidder is not responsible to perform the contract work to appeal the city's determination. No appeals will be received after the expiration of this 24 hour appeal period. The city may deliver this notice by hand delivery, email, facsimile, or regular mail. In the event the city uses regular mail, the delivery will be deemed complete three days after being placed in the U.S. Mail. The bidder's right to appeal is limited to the single remedy of providing the city with additional information to be considered before the city issues a final determination. Bidder acknowledges and understands that, as provided by RCW 39.04.350, no other appeal is allowed and no other remedy of any kind or nature is available to the bidding contractor if the City determines that the bidder is not responsible to perform the contract work. PS 3 Electrical System Improvements/Araucto 10 October 10, 2019 Project Number: 17-7999.6 If the bidder fails to request a modification within the time allowed, or fails to appeal a determination that the bidder is not responsible within the time allowed, the city will make its determination of bidder responsibility based on the information submitted. COMPLETE AND SIGN THIS FORM AS PART OF YOUR BID. FAILURE TO PROPERLY COMPLETE THIS FORM MAY ALSO RESULT IN A DETERMINATION THAT YOUR BID IS NON-RESPONSIVE AND THEREFORE VOID. THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES: CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION. The undersigned certifies under oath that the information provided herein is true and sufficiently complete so as not to be misleading. SUBMITTED BY: Colvico Inc . NAME: Jesse Dragoo ADDRESS: 2812 N Pittsburg Street Spokane, WA 99207 PRINCIPAL OFFICE: Colvico Inc . ADDRESS: 2812 N Pittsburg Street Spokane, WA 99207 PHONE: 509-536-1875 FAX: 509-534-3551 STATUTORY REQUIREMENTS - Per state law a bidder must meet the following responsibility criteria Please see attached 1. Required Responsibility Criteria 1.1 Provide a copy of your Department of Labor and Industries certificate of registration in compliance with chapter 18.27 RCW. 1.2 Provide your current state unified business identifier number. 1.3 Provide proof of applicable industrial insurance coverage for your employees working in Washington as required in Title 51 RCW, together with an employment security department number as required in Title 50 RCW, and a state excise tax registration number as required in Title 82 RCW. Providing a copy of a state of Washington "Master License Service Registration and Licenses" form is typically sufficient evidence of the requirements of this subsection. 1.4 Provide a statement, signed by a person with authority to act and speak for your company, that your company, including any subsidiary companies or affiliated companies under majority ownership or under PS 3 Electrical System Improvements/Araucto 11 October 10, 2019 Project Number: 17-7999.6 control by the owners of the bidder's company, are not and have not been in the past three (3) years, disqualified from bidding on any public works contract under RCW 39.06.010 or 39.12.065 (3). 1.5 Provide a signed statement, signed under penalty of perjury by a person with authority to act and speak for your company, that within the three- year period immediately preceding the bid solicitation date, your company is not a "willful" violator as defined in RCW 49.48.082, of any provisions of chapters 49.46, 49.48, or 49.52 RCW, as determined by a final and binding citation and notice of assessment issued by the Department of Labor and Industries or through a civil judgment entered by a court of limited or general jurisdiction. 1.6 Provide proof that a designated person or persons with your company has either received training from the department of labor and industries or an approved training provider on the requirements related to public works and prevailing wages under chapter 39.04 RCW and 39.12 RCW or provide proof that your company has completed three or more public works projects and have had a valid business license in Washington for three or more years and are exempt from this training requirement. SUPPLEMENTAL CRITERIA — Established by the City to determine bidder responsibility 2. ORGANIZATION 2.1 How many years has your organization been in business as a Contractor? 2.2 How many years has your organization been in business under its present business name? 2.2.1 Under what other or former names has your organization operated? 2.3 If your organization is a corporation, answer the following: 2.3.1 Date of incorporation: 2.3.2 State of incorporation: 2.3.3 President's name: 2.3.4 Vice-president's name(s): 2.3.5 Secretary's name: 2.3.6 Treasurer's name: 2.4 If your organization is a partnership, answer the following: 2.4.1 Date of organization: 2.4.2 Type of partnership (if applicable): 2.4.3 Name(s) of general partner(s): 2.5 If your organization is individually owned, answer the following: 2.5.1 Date of organization: 2.5.2 Name of owner: PS 3 Electrical System Improvements/Araucto 12 October 10, 2019 Project Number: 17-7999.6 2.6 If the form of your organization is other than those listed above, describe it and name the principals: 3. LICENSING 3.1 List jurisdictions and trade categories in which your organization is legally qualified to do business, and indicate license numbers, if applicable. 3.2 List jurisdictions in which your organization's partnership or trade name is filed. 4. EXPERIENCE 4.1 List the categories of work that your organization normally performs with its own forces. 4.2 Claims and Suits. (If the answer to any of the questions below is yes, please attach details.) 4.2.1 Has your organization ever failed to complete any work awarded to it? 4.2.2 Are there any judgments, claims, arbitration proceedings or suits pending or outstanding against your organization or its officers? 4.2.3 Has your organization filed any law suits or requested arbitration with regard to construction contracts within the last five years? 4.3 Within the last five years, has any officer or principal of your organization ever been an officer or principal of another organization when it failed to complete a construction contract? (If the answer is yes, please attach details.) 4.4 On a separate sheet, list major construction projects your organization has in progress, giving the name of project, owner, architect or design engineer, contract amount, percent complete and scheduled completion date. 4.4.1 State total worth of work in progress and under contract: 4.5 On a separate sheet, list the major projects your organization has completed in the past five years, giving the name of project, owner, architect or design engineer, contract amount, date of completion and percentage of the cost of the work performed with your own forces. 4.5.1 State average annual amount of construction work performed during the past five years: 4.6 On a separate sheet, list the construction experience and present commitments of the key individuals of your organization. 4.7 On a separate sheet, list your major equipment. PS 3 Electrical System Improvements/Araucto 13 October 10, 2019 Project Number: 17-7999.6 5. REFERENCES 5.1 Trade References: 5.2 Bank References: 5.3 Surety: 5.3.1 Name of bonding company: 5.3.2 Name and address of agent: 6. FINANCING 6.1 Financial Statement. After bid opening, the City may require the following financial information from any of the three apparent low bidders. If so required, the selected bidder(s) must respond with this financial information within 24 hours of the City's request for that information. The City's request for this information shall not be construed as an award or as an intent to award the contract. A bidder's failure or refusal to provide this information may result in rejection of that bidder's bid. 6.1.1 Attach a financial statement, preferably audited, including your organization's latest balance sheet and income statement showing the following items: Current Assets (e.g., cash, joint venture accounts, accounts receivable, notes receivable, accrued income, deposits, materials inventory and prepaid expenses); Net Fixed Assets; Other Assets; Current Liabilities (e.g., accounts payable, notes payable, accrued expenses, provision for income taxes, advances, accrued salaries and accrued payroll taxes); Other Liabilities (e.g., capital, capital stock, authorized and outstanding shares par values, earned surplus and retained earnings). 6.1.2 Name and address of firm preparing attached financial statement, and date thereof: 6.1.3 Is the attached financial statement for the identical organization named on page one? 6.1.4 If not, explain the relationship and financial responsibility of the organization whose financial statement is provided (e.g., parent- subsidiary). 6.2 Will the organization whose financial statement is attached act as guarantor of the contract for construction? PS 3 Electrical System Improvements/Araucto 14 October 10, 2019 Project Number: 17-7999.6 7. SIGNATURE 7.1 Dated at this 28 day of October , 2019. Name of Organization: Colvico Inc By: Title: Jesse Dragoo, Vice President 7.2 -Jf S S e J tZ a DQ , being duly sworn, deposes and says that the information provided herein is true and sufficiently complete so as not to be misleading. Subscribed and sworn before me this day of 1 lrA eC- , 2019. I ` Notary Public: My Commission Expires: �nunulunnnnllnouuuteolnunl0 Notary Public State of Washington ANGELA E GILBERT MY COMMISSION EXPIRES DECEMBER 07,2020 DI111111III I I I III Itl 11 l 11 llll lltllll lllll llllla PS 3 Electrical System Improvements/Araucto 15 October 10, 2019 Project Number: 17-7999.6 coy 1C0 Contractor's Qualification Statement P: 509.536.1875 PO. Box 2682 F: 509.534.3551 Spokane, WA 99ZZ0 1 Required Responsibility Criteria: 1.1 Please see attached 1.2 Please see attached. UBI#601009 703 1.3 Please see attached 1.4 Please see attached "Unanimous Consent Resolutions of the Board of Directors of Colvico Inc. 1.5 Please see attached 1.6 Please see attached Business License and completed project list 2. Organization: 2.1 32 years 2.2 32 years 2.3.1 3/4/1987 2.3.2 Washington 2.3.3 Cory Colvin 2.3.4 Jesse Dragoo 2.3.5 Cory Colvin 2.3.6 Cory Colvin 3. Licensing: 3.1 Washington General Contractor and Electrical Contractor: COLVII*072JH and COLVII*134D6 Idaho Electrical Contractor: ELE-C-4858 Oregon Commercial Specialty Contractor: 114114 4. Experience: 4.1 Electrical work 4.2 N/A 4.3 No 4.4 Please see attached current project list 4.4.1 $20,000,000.00 4.5 Please see attached completed project list 4.6 Please see attached Organizational Chart 4.7 Please see attached equipment list 5. References: 5.1 Please see attached completed project list 5.2 Washington Trust Bank—Confidential information please contact Cory Colvin 5.3.1 Travelers Casualty&Surety Company of America 5.3.2 Alliant Insurance Services Inc. 818 W Riverside Avenue,Suite 800 Spokane,WA 99201 6. Financing: Provided if requested after bid opening xtd � b� b °° O c p � > N a c" ° tl o �n t a N o o � C� � 6 pd o 0 +1 t (D O N 00 cc tr1 trJ ^ CD o � C ° o CD .. r O cu n ("D n (� CDCD ; n C c, o O CD t � W Or � polo 10/28/2019 Verify Workers'Comp Premium Status-Employer Liability Certificate Washington State Department of S-TAT�. Employer Liability Labor and Industries Certificate e 141, Department of Labor and Industries Employer Liability Certificate Date: 10/28/2019 UBI #: 601 009 703 Legal Business Name: COLUICO INC Account#: 535,104-02 'Doing Business As'Name: COLUICO INC Estimated Workers Reported: Quarter 2 of Year 2019 "51 to 75 Workers" (See Description Below) Workers' Comp Premium Status: Account is current. Firm has voluntarily reported and paid their premiums. Licensed Contractor? Yes License: Multiple Active Licenses Account Representative: TO/KRISTINE HATHAWAY (360)902-4811 - Email: HATK235@lni.wa.gov What does "Estimated Workers Reported" mean? Estimated workers reported represents the number of full time position requiring at least 480 hours of work per calendar quarter. A single 480 hour position may be filled by one person, or several part time workers. Industrial Insurance Information Employers report and pay premiums each quarter based on hours of employee work already performed, and are liable for premiums found later to be due. Industrial insurance accounts have no policy periods, cancellation dates, limitations of coverage or waiver of subrogation (See RCW 51.12.050 and 51.16.190 ). https://fortress.wa.gov/Ini/crpsi/AcctlnfoPrint.aspx?Accountld=53510402&AccountManager=TO+%2f+KRI STI N E+HATHAWAY+(360)902-4811+-+Ema il... 1/1 z 6349-1 COLVICO, INC. PO BOX 2682 SPOKANE WA 99220-2682 DETACH BEFORE POSTING STATE Y 6 BUSINESS LICENSE 1889 STATE OF f°5 WASHINGTON Issue Date: Jun 14, 2019 4 Unified Business ID #: 601009703 Profit Corporation Business ID#: 001 Location: 0002 COLVICO, INC. Expires: Mar 31, 2020 2812 N PITTSBURG ST 'fz SPOKANE, WA 99207-4854 <1. rj G` UNEMPLOYMENT INSURANCE -ACTIVE INDUSTRIAL INSURANCE -ACTIVE a i< =1, TAX REGISTRATION -ACTIVE k= CITY ENDORSEMENTS: =;ii j' ELLENSBURG GENERAL BUSINESS - NON-RESIDENT-ACTIVE G LAKEWOOD GENERAL BUSINESS - NON-RESIDENT#BL18-00474 -ACTIVE LACEY GENERAL BUSINESS - NON-RESIDENT#27383 -ACTIVE t SPOKANE VALLEY GENERAL BUSINESS - NON-RESIDENT#02016-ACTIVE f SPOKANE GENERAL BUSINESS - NON-RESIDENT#T1 1 102804BUS -ACTIVE .; 1= SEATAC GENERAL BUSINESS - NON-RESIDENT -ACTIVE -r t t; ?' �1 y; LICENSING RESTRICTIONS: yy k a �-1 Not licensed to hire minors without a Minor Work Permit. �y k- `a j> I* E to { J. f� 1 �r rah Lnamed ument lists the registrations,endorsements,and licenses authorized for the businessbove.By accepting this document,the licensee certifies the information on the application plete,true,and accurate to the best of his or her knowledge,and that business will bei-Med in compliance with all applicable Washington state,county,and city regulations. Director,Department of Revenue k UNANIMOUS CONSENT RESOLUTIONS OF THE BOARD OF DIRECTORS OF COLVICO, INC. SPECIAL MEETING OF DIRECTORS March 4, 2019 The undersigned, being all of the directors of COLVICO, INC., a Washington Corporation (the "Corporation"), by this instrument in lieu of a special meeting of the Board of Directors of the Corporation , hereby take the following actions and adopt the following resolutions pursuant to the provisions of the Washington Business Corporation Act: ELECTION OF OFFICERS RESOLVED, that the following individuals are unanimously elected to the corporate office or position set forth opposite their name, to serve as such until the next annual meeting of the Corporation and the elections and qualifications of their successors: CORY S. COLVIN President JESSE DRAGOO Vice President CORY S. COLVIN Secretary CORY S. COLVIN Treasurer OMNIBUS RESOLUTION RESOLVED, that the appropriate officers of the Corporation are authorized and directed to do all other acts, take all actions and prepare all papers, instruments and documents in connection therewith which they, in their sole discretion, deem proper in order to accomplish and carry out the intent of the foregoing resolutions and all such actions are, ratified, confirmed, approved and adopted as the official acts and deeds of the Corporation. IN WITNESS WHEREOF, this Unanimous Consent Resolution Of The Board Of Directors of the Company was executed effective as of the date first above written. Cory S. Colvin, Director PROJECT NAME PM AMOUNT GENERAL/OWNER Complete Date Percent Com. 9619 Walla Walla Txwy A Reconstruction Cory Colvin 1,400,000 Selland Construction Inc. 9/1/2019 90% 9642 Pullman Fast EV Charger Clint Reid 50,000 Avista 4/1/2019 99% 9644 Paine Field Txwy B and N.Ramp Recon. Terry DenBoer 670,000 Interwest Construction 9/1/2019 99% 9702 ESH-Well 2R Pumphouse Terry DenBoer 375,000 POW Contracting,Inc. 7/1/2019 99% 9708 1 Browns Point Generator Replacement Clint Reid 238,000 Pierce County 7/1/2019 95% 9711 Ellensburg Wastewater Treatment Facility PI Clint Reid 1,325,000 City of Ellensburg 7/30/2019 95% 9724 Riverside Extension Phase 2B Tom Baldwin 387,000 L&L Cargile Inc. 7/20/2019 99% 9728 E Appleway Ave&N Signal Drive Traffic Sign Tom Baldwin 300,000 City of Liberty Lake 7/20/2019 99% 9755 Kent Springs Pump Station#4 Electrical Upgy Clint Reid 1,150,000 City of Kent 7/30/2019 95% 9765 SIA Surface Parking Lot Expansion Cory Colvin 1,100,000 NA Degerstrom 1/15/2019 99% 9766 SIA Runway 725 Taxiway C Cory Colvin 1,700,000 Shamrock Paving 4/1/2019 99% 9776 Sunset Blvd Royal to Lineke Tom Baldwin 125,000 DW Excavating,Inc. 8/3/2019 99% 9787 Felts Field New Bulk Storage Hangar Clint Reid 338,000 Graham Construction 8/1/2019 90% 9788 Wallula UPRR Cold Connect Intermodal Fac Cory Colvin 840,000 Knife River 4/1/2019 99% 9792 Boundary Dam Entrance Realignment Clint Reid 93,000 N&N Excavation 7/30/2019 99% 9794 NE Campus Med Voltage Improvements Jesse Dragoo 425,000 CWU 6/1/2019 99% 9800 Felts Field Fuel Facility Terry DenBoer 105,000 Granite Petroleum 7/20/2019 99% 9805 Pullman Runway 2018 Jesse Dragoo 785,000 MA DeAtley 6/1/2019 90% 9806 Buckley Emergency Generator Installation Terry DenBoer 125,000 State of Washington Military De 8/1/2019 99% 9807 Sedro Woolley Emergency Generator Installz Troy Diederichs 121,000 State of Washington Military Del 12/20/2018 99% 9814 Fairchild Taxiway Signs Jesse Dragoo 345,000 MJ Takisaki 9/20/2019 45% 9817 VA Medical Boiler Plant Clint Reid 3,000,000 Burton Construction 8/1/2020 50% 9819 Fairchild Switch Replacement Jesse Dragoo 3,250,000 MJ Takisaki 7/30/2019 95% 9822 Curlew Mine Substation Upgrade Troy Diederichs 171,000 Echo Bay Minerals 12/20/2018 99% 9826 Avista EV-Maint/Repair Clint Reid service Avista 95% 9828 Odessa Airport Runway 2-20 Rehab Jesse Dragoo 105,000 CR Contracting 9/1/2019 99% 9829 PDX Terminal Balancing Con E-Extension Jesse Dragoo 325,000 Kodiak Pacific Construction 8/1/2019 99% 9832 PDX-Term Building Con E-Extension Jesse Dragoo 65,000 Skanska USA 7/1/2019 99% 9833 Riverfront Site Lighting-Locust Lane Terry DenBoer 25,000 City of Spokane 5/10/2019 99% 9834 Bowerman Airport Drainage Improvements Terry DenBoer 310,000 Rognlin's Inc. 11/1/2019 5% 9838 LV Elect Infrastructure Phase 2 Terry DenBoer 3,200,000 State of Wash Dept of Enterpris 2/1/2020 35% 9840 VAMC Boiler-Fuel Control Wiring Clint Reid 86,000 Granite Petroleum 8/1/2020 50% 9843 Redmond Airport Terminal Apron Expansion Jesse Dragoo 650,000 K&E Excavating,Inc. 10/2/2019 80% 9845 Indian Trail Road Widening Tom Baldwin 45,000 Inland Asphalt 8/3/2019 95% 9848 LV North Cottages-Nurse Call System Terry DenBoer 365,000 Dept of Enterprise Services 8/6/2019 75% 9855 SB 13.8 to MWDA Connection Cory Colvin 7,000 NA Degerstrom 5/1/2019 90% 9856 US 97 South of Blewett Pass Paving Troy Diederichs 28,000 Central Washington Asphalt 8/1/2019 95% 9859 KCIA S End Security Infrastrucure Terry DenBoer 870,000 King County 8/6/2019 65% 9860 PDX Taxiway K Lighting Rehab Jesse Dragoo 365,000 Tapani,Inc. 10/1/2019 15% 9861 Hillsboro Airport Runway 13R/13L Rehab Ph Jesse Dragoo 675,000 Kodiak Pacific Construction 10/2/2019 65% 9863 Methow Valley Airport II Jesse Dragoo 345,000 Selland Construction Inc. 10/2/2019 85% 9864 Hamblin/Logan Emergency Generator Clint Reid 135,000 Spokane Public Schools 7/30/2019 15% 9865 S&L Rentals LLC-Ev Charger Clint Reid service S&L Rentals/Avista 99% 9867 Project Rose-RRFB Clint Reid 23,000 Piersol Construction 7/30/2019 50% 9868 Lakota Med Voltage Switchgrear Doors Upgr Jesse Dragoo 650,000 Lakehaven Water/Sewer Dist 11/1/2019 50% 9871 Pacific Mobile Structures Relighting LED Troy Diederichs 7,000 Pacific Mobile Structures 2/1/2019 95% 9874 SIA Fuel Control Facility Rehab Tom Baldwin 15,000 Spokane Intl Airport 6/1/2019 100% 9875 Whitworth Energized EV Charger Jesse Dragoo 35,000 Whitworth University 8/1/2019 75% 9876 Auburn School District Portable Classrooms Troy Diederichs 200,000 Auburn School Diostrict 9/1/2019 25% 9878 Habitat for Humanity Troy Diederichs 14,000 Habitat for Humanit 5/1/2019 99% 9879 Lone Wolf -EV Charger Clint Reid 30,000 Lone Wolf/Seven Oaks Mtr 7/30/2019 99% 9882 Green River Pump Station Clint Reid 248,000 City Of Auburn 10/1/2019 90% 9883 Inland Asphalt Perry Pit Tom Baldwin 25,000 Central Premix 8/1/2019 99% 9884 Pullman RW 05 NAVAIDS Cory Colvin 1,450,000 Burton Construction,Inc. 9/1/2019 55% 9885 Elect Serv.Spokane County Avista Staduim Troy Diederichs 4,000 Spokane County 4/1/2019 99% 9886 Bremerton National Airport Lighting Terry DenBoer 2,100,000 Bremerton National Airport ?? 5% 9888 Spokane Falls Station Troy Diederichs 345,000 NNAC 8/1/2019 55% 9889 Lynnwood Link Extension Jesse Dragoo 265,000 Scarcella Bros,Inc. 9/1/2019 75% 9890 Sprague Ave Rebuild 2 A Tom Baldwin 388,000 LaRiviere,Inc. 11/1/2019 75% 9891 Lake Lenore Pump Plants#1 and#2 Clint Reid 283,000 Quincy-Columbia Basin Irr Dist 11/19/2019 85% 9892 Gonzaga Fast Charger Clint Reid 65,000 Avista Corp. 7/30/2019 95% 9894 University Road Preservation Project Tom Baldwin 26,000 N.A.Dergerstrom 9/1/2019 65% 9895 E.Appleway&N Madson St Traffic Signal ITom Baldwin 390,000 City of Liberty Lake 11/1/2019 75% 9896 lEvergreen Rd Preservation ITom Baldwin 1 20,000 linland Asphalt Company 7/25/2019 55% Page 1 PROJECT NAME PM AMOUNT GENERAL/OWNER Complete Date Percent Com. 9897 Whitworth EV-Charger Clint Reid 8,000 Whitworth University 7/30/2019 75% 9900 Spokane Indians-Extend Circuts Troy Diederichs 2,000 Spokane Indians 5/1/2019 90% 9901 2019 Airport Improvement Project Jesse Dragoo 248,000 Scarsella Bros 10/2/2019 10% 9902 Whitworth-Cowles Auditorium Stage Jesse Dragoo 100,000 Merit Electric 9/25/2019 25% 9903 Scarsella Fire Alarm Troy Diederichs 1,000 Scarsella Bros 5/1/2019 50% 9905 VA Replace Garage Door B-3 Clint Reid T&M Burton Constrution,Inc. 5% 9906 Spokane Airport Ramp Lighting Terry Den Boer 66,000 Ameresco,Inc 12/20/2019 5% 9908 Scappoose Sign Fix Jesse Dragoo 65,000 Scappoose Airport 9/1/2019 5% 9909 SIA Windows Troy Diederichs 125,000 Spokane International Airport 3/1/2020 5% 9910 Monroe-Regal Line,Phase 1 Tom Baldwin 45,000 Bacon Concrete,Inc. 9/1/2019 5% 9911 Taxiway Realignment-City of Chehalis Jesse Dragoo 125,000 Sterling Breen Concrete 10/2/2019 1% 9912 Country Homes Blvd. Tom Baldwin 20,000 Inland Asphalt Company 8/1/2019 10% 9913 Cycle 7 Traffic Calming Tom Baldwin 100,000 Bacon Concrete 11/1/2019 10% 9914 Walla Walla-Scarsella Jesse Dragoo 145,000 Scarsella Bros 11/1/2019 10% 9916 SIA West Surface Parking Lot Expansion Cory Colvin 250,000 Shamrock Paving/SIA 10/1/2019 1% Page 2 COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 COMPLETED PROJECTS BY COLVICO, INC. Lakeland Village Cottages Nurses Call 2019 Install new door and window alarms Contract Value: $409,504.00 General Contractor: Colvico Owner: Department of Enterprise Services Kristina Frontino- 509-565-4240 SR 99 Underground Electrical Services 2018 Installation of underground conduit and conductors to refeed existing services for Tacoma Power Contract Value: $144,638.00 General Contractor: Colvico Owner: City of Fife- Public Works Department Kenneth Gunther- 253-896-8203 Wandermere Fast Charger 2018 Installation of 50kw EVSE and level 2 EVSE and new electrical switch gear. Contract Value: $51, 868.00 General Contractor: Avista Owner: Spokane Transit Authority Randall Farley- 509-495-2823 Airfield Electrical Upgrades- Homerun Infrastructure and Re-cabling 2018 Vaults, boring, conduit and new cabling for new homerun infrastructure for all electrical to the airfield Contract Value: $337,296.00 General Contractor: Colvico Owner: King County Trisha Roth- 206-263-1964 Scappoose Airport 2018 New taxiway lighting Contract Value: $589,936.00 General Contractor: Tapani Owner: FAA Krystye Kearney- 360-687-1148 SIA C Store coYLV_1 co NC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 2018 Installation of new roadway lighting and miscellaneous communication upgrades Contract Value: $$145,088.00 General Contractor: Piersol Construction Owner: Spokane International Airport John Cannon- 509-535-2901 Security Screening Checkpoint Expansion 2018 Design build with Spokane Airport ,TSA, and Garco Construction. Coordinate and install the power and communications needs for new TSA scanning equipment lanes, modify existing security, access control, and CCTV systems, complete electrical modifications for passenger lanes and TSA screening Contract Value: $76,606.00 General Contractor: Garco Construction Owner: Spokane International Airport Rob Decker- 509-535-4688 Repair Taxiway G- Fairchild AFB 2018 Install new taxiway lighting Contract Value: $398,688.00 General Contractor: MJ Takisaki, Inc Owner: Department of Airforce, 92"d Contracting Squadron Brian Meyer- 509-244-7080 Broadway/Argonne/Mullan Intersections 2018 New traffic signals Contract Value: $430,750.00 General Contractor: ACME Concrete Paving Owner: City of Spokane Valley Steve Clark- 509-242-1234 WSP Phase III Electrical Upgrade 2018 Installation of 13,200 volt cabling and associated infrastructure. Contract Value: $420,550.00 General Contractor: Colvico Owner: Department of Corrections Richard Howerton- 360-725-8358 Sprague Street Preservation 2018 Installation of new signal equipment at Sprague and Corbin Contract Value: $51,550.00 COL ICO TV INC, PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509) 534-3551 General Contractor: Inland Asphalt Owner: City of Spokane Valley Tony Vice- 509-534-2657 Monroe Phase I- Indiana to Chelan 2018 Install pedestrian lighting on Monroe Street Contract Value: $582,300.00 General Contractor: Shamrock Paving Owner: City of Spokane Kat Merrick/Chuck Green- 509-224-2800 Berg Corp. Service Upgrade 2018 Install 1600amp service and miscellaneous switch gear upgrades Contract Value: $83,159.00 General Contractor: Colvico Owner: Berg Corp. Randy Ferguson- 509-624-8921 SR 26 VMS Installation 2018 Installation of new variable message sign for WSDOT Contract Value: $51,686.00 General Contractor: Colvico Owner: WSDOT Wick McCurdy- 509-667-3067 Well Station Transformer 2018 Remove and replace 200KVA transformer Contract Value: $105,118.00 General Contractor: Colvico Owner: City of Spokane Steve Burns- 59-742-8154 Rocky Reach Fire Alarm Upgrade 2018 COI. ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Complete fire alarm replacement at Rocky Reach dam Contract Value: $960,050.00 General Contractor: Colvico, Inc. Owner: Chelan County Tom Beebe- 509-661-8443 Spokane International Airport- Airfield Pavement Weather Sensors 2018 RPU's, sensors, cabling and all associated improvements to add weather sensors to runway and taxiways Contract Value: $850,000.00 General Contractor: Colvico Inc. Owner: Spokane International Airport Lisa Corcoran- 509-466-6406 Highlands Generator Replacement 2016 Install new generator, install generator fuel system with separate fuel tank, Provide and install generator structure, installation of fiber optic cable for City, Provide and install of new service and metering for tenants, Installation of new conduit ,cabling and antenna on water tank for City of Renton redundant 911 system Contract Value: $461,980.00 General Contractor: Colvico Inc. Owner: City of Renton JD Wilson- 425-430-7295 Philips-Alard Pump Station 2018 Installation of owner furnished generator, new electrical switchgear, control panels and miscellaneous site improvements Contract Value: $338,910.00 General Contractor: Colvico, Inc. Owner: Pierce County Tina Basil- 253-798-2426 Wall Street Surface Improvements 2016 Install new lamination and signal on Wall Street at Main and Spokane Falls Blvd. Contract Value: $186,195.00 General Contractor: Bacon Concrete Owner: City of Spokane COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509) 534-3551 Greg Bacon- 509-924-3900 University of Washington MV Switch and Cable Replacement 2016 Install new medium voltage switch and cables. Contract Value: $764,530.00 General Contractor: Colvico, Inc. Owner: University of Washington Cindy Magruder- 206-221-4396 Lake Easton RV Electrical 2016 RV electrical upgrade Contract Value: $492,081.00 General Contractor: Colvico, Inc. Owner: Washington State Parks and Recreation Commission Arnie Larsen- 509-665-4334 Anderson Field Runway Lighting 2017 Install new runway lighting Contract Value: $519,764.00 General Contractor: J-U-B Owner: City of Brewster Lou Lott- 509-458-3727 PDX Runway 321 2017 Install new runway lighting Contract Value: $221,824.00 General Contractor: K&E Excavating Owner: Port of Portland Steve Harrison- 503-399-4833 VAMC Cooling Towers 2017 New VFDs and electrical conduits and conductors to three new cooling towers and miscellaneous lighting upgrades Contract Value: $99,886.00 General Contractor: Burton Construction Owner: Veteran's Administration Steve Breeden- 509-468-4932 Rosalia Airport Lighting 2017 COL AC O INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509) 534-3551 New runway lighting Value: $650,509.00 General Contractor: Colvico Owner: Town of Rosalia Time Ike- 509-458-3727 STA West Plains Fast Charger 2017 Installation of 50kw EVSE and level 2 EVSE and new electrical switch gear Value: $57,400.00 General Contractor: Avista Owner: Spokane Transit Authority Rendell Farley- 509-495-2873 Spokane County Signal Safety 2017 Signal modifications at Spokane County intersections Value: $162,090.00 General Contractor: Cameron Reilly Owner: City of Spokane Valley Lisa Clifford- 509-466-5555 Liberty Lake Fast EV Charger 2017 Installation of 50kw EVSE and level 2 ECVSE and new electrical switch gear Value: $57,383.00 General Contractor: Avista Owner: Spokane Transit Authority Rendall Farley- 509-495-2873 SR 26 and US195 Safety Improvements 2017 Installation of 2 remote weather stations for WSDOT Value: $115,662.00 General Contractor: Colvico Owner: WSDOT Rebecca Fouts- 509-324-6559 SIA Signage Upgrade 2017 Install new sign bridges and cantilever structures on airport drive COL ICO VT INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 drill and slip form pole bases, install new directional signage on sign structures, install new owner provided 40' variable message Sign at the Airport entry, install power service and power distribution, install new fiber optic communications link to variable message sign Value: $748,521.00 General Contractor: Colvico Owner: Spokane International Airport Margaret Merin- 509-455-6404 _Lopez Island Airport-Airfield Lighting System Rehab 2017 Signage, cabling, runway end lighting, New Reils and PAPIs and all associated infrastructure Value: $627,139.00 General Contractor: Colvico Owner: Port of Lopez Helen Cosgrove- 360-468-4116 Arlington Municipal Airport Taxiway C Lighting 2017 New Lighting, signage and associated improvements to taxiway C Value: $520,309.00 General Contractor: WH Pacific Owner: City of Arlington Eric Strong- 425-951-4816 Washington Trust Generator Replacement 2017 Upgrade emergency power system for critical data, Remove existing generator, Set up temporary generator, Install modify service, Install new Emergency switch gear and automatic transfer switches, Install 2- new 100KVA UPS systems, Install new 10KVA emergency back power system for exit lighting, install new 500KVA generator and associated mechanical work, isolate all server operations including lighting and HVAC from normal power sources Value: $786,800.00 General Contractor: Colvico Owner: WA Trust Bank Duane Swizer- 509-625-1283 Point Defiance Ferry Terminal Emergency Generator 2017 Installation of new emergency generator ATS sensing and miscellaneous site improvements Value: $218,868.00 General Contractor: Colvico Owner: WSDOT Angie Delaney- 360-705-7569 COL AC O INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 King County Airfield Safety (Signage Replacement and Maqvar Update) 2017 Magnetic variance airfield signage replacement. Value: $1,367,675.00 General Contractor: Colvico Owner: King County Trisha Roth- 206-263-1964 McNary Pool to US12 Paving 2017 Install new traffic signal and pedestrian push button for WSDOT Value: $402,740.00 General Contractor: Central WA Paving Owner: WSDOT Tracy Garland-Cruz 509-765-5757 Monroe Street Improvements-Francis -Greta Ave 2017 Install new traffic signal at intersection of Monroe and Wall Value: $174,850.00 General Contractor: Red Diamond Construction Owner: City Of Spokane Mike Schimmels- 509-922-6674 Evergreen Pumping Plant-XFMR Replacement 2017 Replace transformer at Evergreen pumping plant Value: $293,488.00 General Contractor: Colvico Owner: Quincy Columbia Basin Irrigation District Roger Sonnichsen- 509-787-3591 Liberty Lake Road Restoration Upgrade signal system on Liberty Lake Road at Appleway and Country Vista Value: $391,500.00 General Contractor: Rolling Rock Excavating Owner: City of Liberty Lake Melanie Craft- 509-863-7534 Appleway Shared Use Path 2017 Install illumination along Appleway between Pines and Evergreen Value: $516,295.00 COI. I CO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 General Contractor: TLariviere Excavation Owner: City of Spokane Valley Scott Foster- 208-683-2646 CWU Student Village Medium Voltage Improvements 2017 Install new medium voltage feeders Value: $563,888.00 General Contractor: Colvico Owner: Central Washington University Gary Gleason- 509-488-6325 McMinnville Airport Runway 4-22 Rehab 2017 Install new conduit, vaults and airfield cabling, install new runway lighting, install new taxiway lighting, install new airfield signage, install new wind cone, install new PAPI's on Runway 4 & 22, install new Electrical Service, install new regulators, install new radio controller Value: $632,799.00 General Contractor: Kerr Contractors, Inc Owner: City of McMinnville Joseph Dewey- 971-216-0050 SIA South Pilot Ramp Rehab 2017 Install new taxiway edge lighting and signage, install new duct bank crossings and vaults, install new ramp lighting for the US Customs facility, wire new entry gate and access controls Value: $187,251.00 General Contractor: ACME Concrete Paving, Inc. Owner: Spokane International Airport Diana Zartman- 509-242-1234 Airfield Safety (Signage Replacement) Boeing Field 2017-2018 Magnetic variance airfield signage replacement. Owner- King County, 7277 Perimeter Road S., Seattle WA 98108 Contact- Peter Dumaliang- 206-477-0212 Contract Value- $1,367,000.00 General Contractor- Colvico, Inc. Replacement of Airfield Signage. Involves complete removal of concrete, rewiring and placement of 75 runway and taxiway signs Riverfront Park - Recreational Ice Rink & SkyRide Facility -2016-2017 Complete electrical system for the ice rink and supporting facilities. Owner- City of Spokane, 808 Spokane Falls Blvd. Spokane WA Contact- Harvey Morrison 509-981-9945 Contract Value: $1,100,000.00 General Contractors - Contractors Northwest COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Complete electrical system for the new facility, including refrigeration system, fire alarm, lighting, HVAC, etc. Lakeland Village Electrical Infrastructure Upgrades -01/06/2017 — 01/20/2018 Installation of 2 backup generators and replacement of 15KV cabling Owner — Dept. of Social Health Services, 2320 S. Salnave Rd. Medical Lake WA Contact — Malcolm Hain 509-327-1538 Contract Value- $850,000.00 General Contractors — Colvico Inc. Replacement of sectionalizers,15 KV cabling and the addition of 2 backup diesel generators. Portland- PDX Bravo Taxiway Rehab & 3-21 Runway Rehab -2017 Rehabilitation of Bravo taxiway and runway 3-21 Owner- Port of Portland, Portland International Airport, Portland OR Contact- Steve Hanson -503-576-0830 Contract Value - $1,500,000.00 General Contractor— K&E Excavating Installation of new taxiway lighting, runway signage, new underground conduit and wiring as needed. Diablo Powerhouse AC Panel Upgrade 06/01/2017 Electrical Panel Replacement Owner— Seattle City Light, Seattle WA Contact— Josh Jackson — 206-684-3828 Contract Value — $638,800.00 General Contractor — Colvico Inc. Replacing all sub electrical panels and wiring in the powerhouse. C4 Improvements Project 12/1/2016 — 12/1/2017 Installation of new UPS system Owner— Port of Seattle, 2711 Alaskan Way, Seatac WA Contact— Moshe Berman 206-787-7560 Contract Value — 1,480,000.00 General Contractor— Colvico Inc. Installation of a new 160 KVA UPS Battery backup system at SeaTac airport, complete with removal of old systems, new conduit and wire. Lakeland Village Fiber Optic Replacement -12/1/2016-7/25/2017 Replacement of fiber optic duct bank, complete with fiber and construction of the data server room. Owner — Department of Social Health Services, 2320 S. Salnave Rd. Medical Lake WA Contact- Bill Rash- 509-838-8240 Contract Value -$650,000 General Contractor— Colvico Inc. COL ICO INC. PO Box 2682 Ph: (509) 536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Construction of a new data server room with fiber optic ductbanks serving the campus. New electrical service for the server room. Food Service Electrical Switchboard Replacement— 12/1/2016 -5/2512017 Replace main electrical switchboard in the food service building at Lakeland Village. Owner— Department of Social Health Services, 2320 S. Salnave Rd. Medical Lake WA Contact — Jim Cortner -509-363-1039 Contract Value- $300,000 General Contractor— Colvico Inc. Installation of a new 2000 amp service panel, new conduit and feeders, and demolition of existing panel. Eastern State Hospital Fire Alarm Improvements- 4/6/2015-6/1/2016 Replacement of complete fire alarm in the north wing of the hospital. Owner— Department of Social Health Services, 850 Maple Street. Medical Lake WA 99022 Contact- Rob Pennell - 509-747-1888 Contract Value - $800,000 General Contractor- Colvico Inc. Replacement of complete fire alarm system in the north wing of an operational psychiatric hospital. Temporary fire alarm installed for each floor during the replacement. Grant Elementary Generator Replacement 2016 Generator replacement Value: $62,143.00 General Contractor: Colvico Owner: School District 81 Tim Ryan— 509-354-7127 Hoffman Hill Booster Station 2016 Miscellaneous electrical upgrades at Hoffman Hill Booster Station Value: $57,987.14 General Contractor: Gray and Osborne Owner: City of Dupont Dominic Miller— 360-292-7481 COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Fairchild Exterior Lighting 2016 New apron lighting Value: $1,195,600.00 General Contractor: MJ Takisaki Owner: Department of the Airforce, 92nd Contracting Squadron Steve Irwin— 509-244-8070 Wenatchee State Park 50amp Upgrades 2016 Install new power distribution panels, trench for new power feeders to RV panels, install RV Panels, concrete bases and restore landscaping Value: $398,776.00 General Contractor: Colvico Owner: Public Utility District No. 1 of Chelan Contact: Courtney Hill— 509-661-4143 Orcas Island Airport Improvements 2016 New weather station and generator Value: $180,600.00 General Contractor: Razz Construction Owner: Port of Orcas Eric Strong— 253-957-6800 Packwood Airport Improvements 2016 New taxiway edge lights Value: $196,109.00 General Contractor: Nutter Corp Owner: FAA Ann Parry— 360-573-2000 Riverside Drive Phase 2A 2016 Install light and I/C conduit on Riverside Ave Value: $168,921.00 General Contractor: Halme Construction Owner: City of Spokane Marshall Sampson— 509-725-4200 SIA Flint Road Realignment COL =7- NC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 2016 Install Polens on Flint Road and supply power for railroad Value: $53,630.00 General Contractor: WM Winkler Owner: Spokane International Airport Dan Rauscher— 509-489-6100 Broadway Street Preservation 2016 Install I/C loops, Wavetronix at intersection of Broadway at Walmart entrance Value: $51,071.00 General Contractor: Inland Asphalt Owner: City of Spokane Valley Tony Via— 509-534-2657 Freya Street Interchange Ramp Improvements 2016 1-90 Freya off ramp improvements Value: $96,800.00 General Contractor: Shamrock Paving Owner: WSDOT Scott Williams— 509-244-2800 Jefferson Lot Improvements 2016 Install new security cameras Value: $388,096.00 General Contractor: Colvico Owner: Spokane Transit Authority Don Skillingstad— 509-34-1896 Civic Stadium Field Lighting Replacement of Musco lighting Value: $562,292.48 General Contractor: Colvico Owner: City of Port Angeles Tim Amiot— 360-417-4706 Pine Lodge- Fire Alarm Reconfiguration 2016 Replace fire alarm system COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Value: $180,000.00 General Contractor: Colvico Owner: Department of Health and Services Cortner Architectural- 509-363-1039 Thun Field Runway Wire Replacement 2016 Install new airport wiring and fixtures at Pierce County Airport Value: $175,325.45 General Contractor: Colvico Owner: Pierce County Public Works and Utilities Pierce County- 253-221-4637 Yakima Air Terminal 2015 Install new navigation systems and lighting Value: $516,066.00 General Contractor: Colvico Owner: FAA Mike Uhlman- 509-966-7000 Felts Field Taxiways B,D& E 2015 Install ductbanks, airfield signage and associated work. Value: $650,000.00 General Contractor: L&L Cargile Owner:Spokane International Airport Contact: Fred- 509-534-3737 Indiana Phase I Install Wavetronix system at Indiana and Ruby/Division Value: $56,850.00 General Contractor: Red Diamond Construction Owner: City of Spokane Mike Schimmels- 509-922-6674 SEATAC Runway 16L/34R Replacement Project- 2015 Construct New Electrical Systems for Runway Replacement Project Project #AIP 3-53-0072-45 MC-0318131/WP#104102 Owner - Port of Seattle, 2711 Alaskan Way, Seatac WA Contact - Moshe Berman 206-787-7560 Contract Value $5,000,000 - $6,000,000 General Contractor - Scarcella/Acme Paving Complete replacement of runway 16-34, with complete electrical infrastructure. New signage, lighting, conduit and wire, regulators and demolition. COtvvI CO NC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Paine Field Runway 16R-34L & Taxiway Alpha Electrical Improvements - 2015 Replace Centerline Lights and Add Touchdown Zone Lights Complete with Associated Infrastructure Contract Value $1,100,000.00 General Contractor— Colvico Project will contain most work items inside the RSA Percent of subcontract not completed by Colvico — 10% Engineer— CH2M Hill — Kevin Cooley — 503-872-4710 Long Lake Dam — HED LED Upgrade Project— 2015 Upgrade of entire Long Lake Dam to LED Lighting. Contract Value $400,000.00 General Contractor— Colvico Avista Contact — Crystal Lewis — 509-495-2331 Little Falls Dam — Control Room and Restroom Upgrade - 2015 Addition of Control room and restrooms complete with new lighting, power and data upgrades. Contract Value - $45,000.00 General Contractor— Garco Jamie Welsh — 509-535-4688 Snohomish County Airport Paine Field Installation of Rollout Visual Range-2015 Construct Electrical Systems and Associated Work for the Installation of the RVR Project #DTFANM-1 5-R-001 39 Contract Value - $130,000.00 General Contractor— Colvico Inc. Portions of work were within RSA Project completed on time Patrick McDermott — 425-227-1552 Award date 07-28-2015 Completion date 08-21-2015 Bozeman PAP[ — Bozeman Montana - 2015 Construct Electrical Systems and Associated Work for the installation of new PAPI Project #DTFAN M-1 5-C-00261 Contract Value - $300,000.00 General Contractor— Colvico Inc. Portions of work within RSA Project completed on time Austin Mixsell 425-227-2367 Award date 7/1/2015 Completion date 05/01/2016 COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Appleway Trail Phase 2 2014 Install electrical services, pedestrian crosswalk system, and decorative illumination for the Appleway Pedestrian Trail. Value: $508,375.00 General Contractor: Stone Creek Land Development Owner: City of Spokane Valley Ty Shutzle— 509-892-4025 Friday Harbor Airport 2014 Grading and drainage improvements, Asphalt marking and aircraft tiedowns, New parking lot lighting, Rotating Beacon, Installation of new runway & Taxiway edge lights, signs, and REIL lights, Heli pad lighting, Lighting controls, Installation of new Service and Regulators,Upgrade Generator or back up Value: $1,230,848.05 General Contractor: Colvico Owner: Port of Friday Harbor Dave Ryan— 360-378-2688 Spokane International Airport— PAPI Install Contract 2014 Construct New PAPI System Project #DTFANM-14-R-00080-0004 Contract Value: $197,000.00 General Contractor: Trinity/Colvico Owner: FAA Matt King: 425-227-2684 Project contains work items inside RSA and work relating to NAV-AID equipment Project schedule was met and successfully complete. Microsoft Project was used to assist in keeping schedule. Percent of subcontract work not completed by Colvico — 25% Award Date — June 2014 Completion Date: August 2014 Eastern Washington University — Huston Hall Phase III 2014 Supply and install 2 propane backup generators, UPS system, associated site work, new distribution equipment and associated conduit and feeder replacement Contract Value - $660,000.00 General Contractor— Colvico Inc. Owner— EWU John Henry — 509-359-4205 Spokane Transit— Emergency Generator Replacement = DOV01 CO NC. PO Box 2682 Ph: (509) 536-1875 Spokane,WA 99220-2682 Fax: (509) 534-3551 2013 Removal and Installation of diesel backup generators, associated site work, new distribution equipment and associated conduit and feeder replacement Contract Value: $280,000.00 General Contractor: Colvico Inc. Owner: Spokane Transit Authority Jessica Charlton 509-325-6049 US395 NSC BNSF Railway Structure 2013 Install Utility/Communication conduit, pull boxes & vaults in bridge barrier walls. Value: $122,991.00 General Contractor: Apollo Owner: WSDOT Tyler Welch— 509-987-1533 King County International Airport- Taxiway Alpha Rehab 2011-2012 Installation of new airfield lighting and control system Contract Value: 1,650,000.00 General Contractor: ICON Materials Owner: King County Mark Bergam — 206-296-7427 Pangborn Memorial Airport— 2011 Taxiway A Lighting and Airfield Improvements 2011-2012 Installation of new emergency generator, airfield lighting, airfield signage, runway painting, weather system and other misc. repairs Contract Value: $1,250,000.00 General Contractor: Colvico Inc. Owner: Pangborn Airport Ron Russ: 509-884-2494 Spokane International Airport— Runway 21 Line of Sight Projects 2010, 2011 and 2012 Approach light system, runway and taxiway lighting, guidance signs, regulators, 5 KV cabling and splicing, PAPI, REIL, and SAWS installation and commissioning Project #AIP 3-53-0072-45 AIP 3-53-0072-45/46 Contract Value: 789,250.00 General Contractor: Acme Concrete Owner: SIA COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Matt Breen: 509-455-6455, Jim Baggs: 425-227-1345 Project involved installing NAV-AID systems and work inside the RSA Schedule was set by the General Contractor. Colvico was able to meet and in most cases able to overachieve schedule parameters. Percent of subcontracted work not performed by Colvico — 15% Award Date 03/2010 Completion 10/2012 Snohomish County Airport— Paine Field -Runway 16R-34L Shoulder Rehabilitation and Related Work 2011-2012 Runway and taxiway lighting, guidance signs, regulators, 5KV cabling and splicing, runway weather system and related work Project #AIP 3-53-0028-050 Contract Value: $3,200,000.00 General Contractor: IMCO Owner: Paine Field Bruce Goetz —425-353-2110 Project contains boring and work inside RSA Schedule was set by the General Contractor. Colvico was able to meet and in most cases able to overachieve schedule parameters. Percent of subcontract work not completed by Colvico — 25% Grand Coulee Dam Airport— 2010 Airport Improvements 2010-2011 Install new electrical service, new tip down beacon and other misc. repairs Contract Value: $200,000.00 General Contractor: Colvico Inc. Owner: Grant County Robert Babler: 509-633-2669 Fairchild AFB — Replace Fuel Distribution System 2010-2011 Install Cathodic Protection system to support new fuel line Contract Value: $400,000.00 General Contractor: Garco Construction Owner: USAF Steve Dodroe, Corp of Engineers — 509-244-5571 ext. 1231 Spokane International Airport— Extend Runway 3/21 and Related Work 2010 COL =CO INC. PO Box 2682 Ph: (509) 536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Install new TDZ lighting, renovate RAN centerline lighting, install new RAN & TAN edge lighting, relocate R/W 3 NavAid, ALSF, Glide Slope, PAPI's, Localizer, including all cable, vault, conduit work, system shelters and signage complete. Project # Contract Value $7,300,000.00 General Contractor: Acme Concrete Owner: SIA Matt Breen: 509-455-6455 Project involved installing NAV-AID systems and work inside the RSA Schedule was set by the General Contractor. Colvico was able to meet and in most cases able to overachieve schedule parameters. Percent of work not performed by Colvico - 5% Award Date 05/2009 Completion 11/2010 SeaTac International Airport Body Scanner Infrastructure 2010 Electrical and data infrastructure upgrades at all gates to accommodate body scanners Contract Value: $1,400,000.00 General Contractor: ICE Technical Services Owner: Transportation Security Administration Garth Rader: 206-214-1127 Spokane Int'I Airport Extend Runway 03 2009-2010 Installation of new airfield lighting and control system Contract Value: $6,990,112.00 General Contractor: Acme Paving Owner: Spokane International Airport Matt Breen - 509-455-6413 Inland Empire Paper Company 2008-2009 Wiring and installation of new pulp processing plant including substation upgrades and installing 1 5kv feeders and distribution system for new plant including wiring of two 15,000 horse power 15kv motors (5t" largest motors in the world) Contract Value: $1,900,000.00 General Contractor: Colvico Inc. Owner: Inland Empire Paper Shirene Young - 509-924-1911 Spokane Int'I Airport Taxiway A Rehabilitation & Lighting Upgrades 2008 Installation of new power distribution cable, vaults, conduits and regulator COL ICO INC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509) 534-3551 Contract Value: $2,400,000 General Contractor: Inland Asphalt Owner: Spokane International Airport Matt Breen — 509-455-6413 Phase 7C Family Housing, Malmstrom AFB 2008-2010 Install complete 15kv distribution system and all interior wiring for 140 family housing units Contract Value: $3,216,200.00 General Contractor: Garco Construction Owner: USAF Steve Dodroe, Corp Of Engineers — 509-244-5571 ext. 1231 Buckhorn Mine 35KV Substations and On Site Distribution 2007-2008 Construct all electrical systems for the new mine — 35kv systems to 480 volt systems Contract Value: $3,400,000.00 General Contractor: Garco Construction Owner: Kinross Gold Dick Pyle, Garco Construction — 509-535-4688 Phase 6 Family Housing, Malmstrom AFB 2006-2008 Install complete 15kv distribution system and all interior wiring for 206 family housing units Contract Value: $5,312,218.00 General Contractor: Garco Construction Owner: USAF Steve Dodroe, Corp Of Engineers — 509-244-5571 ext. 1231 Olympia Airport Rehabilition of Runway 17-35 2005 Installation of new power distribution cable, vaults, conduits and modify existing electrical Contract Value: $794,000 General Contractor: Northwest Construction Owner: Port of Olympia 360-528-8010 King County Boeing Field Runway 13R-31L Safety Area 2004-2005 Install new vaults, 5 kv wire, conduit, air field regulators and airfield control systems Contract Value: $888,000 General Contractor: Merlino Construction Owner: King County Int'I Airport Rick Renaud — 206-296-7427 COYLV_1CO NC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 Paine Field Airport Lighting Upgrade Project 2004-2005 Install owner provided modular regulators, new 600Volt switchgear, backup generators, vaults, conduits and wiring Contract Value: $1,048,000 General Contractor: Colvico, Inc. Owner: Paine Field Bruce Goetz - 425-353-2110 Substation C Replacement - University of Washington 2004 Installation of new switch gear, transformers and feeders Contract Value: $1,010,869 General Contractor: Colvico, Inc. Owner: University of Washington Dean Lyman - 206-221-3940 Resurface Runway 3-21 2004 Installation of new TDZ lighting and adjust all existing lighting Contract Value: $950,000 General Contractor: Inland Asphalt Owner: Spokane International Airport Matt Breen - 509-455-6413 Spokane Int'I Airport- Construct Taxiway C 2003-2004 Install new power distribution cable, vaults, conduits and regulator Contract Value: $983,000 General Contractor: Acme Concrete & Paving Owner: Spokane International Airport Matt Breen - 509-455-6413 Utility Upgrade Eugene - University Of Oregon 2000-2001 Upgrade utility system at Autzen Field Contract Value: $1,013,000 General Contractor: Colvico, Inc. Owner: University Of Oregon Alex Gordon Inland Empire Paper Company EL ICO NC. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509) 534-3551 1999-2001 Wiring and installation of new paper machine including substation upgrades and installing 15kv feeders and distribution system Contract Value: $5,000,000.00 General Contractor: Inland Empire Paper Owner: Inland Empire Paper Shirene Young — 509-924-1911 Rebuild Airfield Power Distribution 1988-1999 Installation of 5kv & 15kv power distribution system and 300kw 5000 volt generator Contract Value: $2,200,000 General Contractor: Colvico, Inc. Owner: Department of the Navy Ken Opdyke, PE — 360-257-1474 Ault Field & Sea Plane Base Utility Upgrades - Dept of the Navy 1998-1999 Installation of new cabling, transformers and upgrade 115 kV substation Contract Value: $4,000,000.00 General Contractor: Colvico, Inc. Owner: Department of the Navy Ken Opdyke, PE — 360-257-1474 West Receiving Substation - University of Washington 1997-1998 Installation of new substation, switch gear, new building, vault, cabling and terminations Contract Value: $3,600,000 General Contractor: Colvico, Inc. Owner: University of Washington Dick Saums — 206-543-7370 COL ICO I NG. PO Box 2682 Ph: (509)536-1875 Spokane,WA 99220-2682 Fax: (509)534-3551 � \ ............ .... ---------------- k` -C ) \ ° k « \ / 2 � \ i <_# _ , �> . ; \{ u , 2 � } \ \ § \ OR ) u , r . � > � c : a> -e . \ _ ' ) § IE ` � . -------- ! { p § oo ».. .�. sTvrES OF w' ti STAT, ids .L`r O� eA0 Ni O fpThe btate of �.:�t:e s• �e d x obe Secretary of State I,KIM WYMAN, Secretary of State of the State of Washington and custodian of its seal,hereby issue this CERTIFICATE OF EXISTENCE OF COLVICO,INC. I CERTIFY that the records on file in this office show that the above named entity was formed under the laws of the State of Washington and that its public organic record was filed in Washington and became effective on 03/04/1987. I FURTHER CERTIFY that the entity's duration is Perpetual,and that as of the date of this certificate,the records of the Secretary of State do not reflect that this entity has been dissolved. I FURTHER CERTIFY that all fees,interest,and penalties owed and collected through the Secretary of State have been paid. I FURTHER CERTIFY that the most recent annual report has been delivered to the Secretary of State for filing and that proceedings for administrative dissolution are not pending. Issued Date: 09/13/2019 UBI Number: 601 009 703 Given under my hand and the Seal of the State of Washington at Olympia,the State Capital Kim Wyman, Secretary of State Date Issued:09/13/2019 �rrriera-� �wti��tta►�wF= Coy 1CO P: 509.536.1875 PO. Box 2682 F: 509.534.3551 Spokane, WA 99ZZ0 October 28, 2019 Colvico Inc.within the last three years immediately preceding this bid solicitation date, is not a "willful" violator as defined in RCW 49.48.082, of any provisions of chapters 49.46,49.48, or 49.52 RCW, as determined by a final and binding citation and not of assessment issued by the Department of Labor and Indus ' s or through a civil judgement entered by a court of limited or general jurisdiction. Jes a Dragoo Vice President Colvico Inc. w F a F- F- 0 o o 0) 0) 0 0) Z 0) Z ooz °' (3) co zz rn orn0) o N w o p o 0 o No o Q o Q o o Q o 0 0o Q Q O o o o p 0 Q N J N Q N Q N Q N Q Q N Z_ QQ N _Q Z Q QQ N N Z_ Q Q Q N Q Q Q Q Q N N Z_ Z_ Q N N N N N w z } 0 m Z O Z Z z >- z z Z Z a Z z z m ap g z Z Z > Z Z Z z z 0 (� g Z F- Z J J F- w � LL Q Q 2 aw � w � LLLLL) QQ ww w 0 a a a a s J N 7 (o C0 O 0) r O LO L m LO F- C) (D O V' (o (D V c0 r m m N r 00 00 r PI- m C) F- O O 6) M 0) 0) 0) O O 0) 0) M O m m Z_ Z m �2 N m � O O) a a. a (D m O � m m -_ � m � 0) F . p a ocD rzp0- aT CL0- , 00aaoppo ma ; 0aa CLaaU) CL mq- O Q _NONONOC) QOOOpNdN � 0N00 (\ JJOOJ (n � NQOO 0000 Oc� 00 ® U 'n = pp J � 2 � x rg2SSJ (� Spp 2 (OSSr002 = Opppm = S 2220 = 022 O O Co J J r w r U) U) (n Cn (n 0r J (n r Cn U) � Cn m (n w o J J M Q CO U) mn U U) r W Cl) OOmcf) � � v0 v OOrU v Y � � Y U J a a a w a 0 a J p p Q p W w Lyw w YUaw w LL J Y � - a W W � 2 J x J _J � LL w Y J �' Q w W D Q 0 F Y Y w m � W W Y � m W mn Q N Q Cf Q � W LL J Q W � Q U -) Q_ J_ W � Of F � QY CL 0r w W U U -_r 2 J U g J g a g a W a w F 0 Q w a p Y a >2 a W F- W W W W Y W z p Q z S O d O 2 O Q F- V F- _J V F- W _J a. a O O a' U tD O Q ~ O -J U) a U mn -J C p v ! Q F 0 Q Z ~ m mn Cn F F In = W Q O W J Q Q Q Q Q H F F H a W w w ~ W a F U w W U Z CL w Z 2 J W w W Z p W X W z CL F W - of � R' � w w CL a s a W J Cr Z Cr W J �j m O W F W Q F U QY Cr W w ~ N c) LO Q F Q ~ F F F- F F F- O Oa YaQa0w Og � - waa � oop ( aV a x O � � O U 2 U > S W w S W a Z = a z Z a w U U Q > j W Q Q Q Q ~ Q m 0 0 rn (n Y0 � � 0 -' 0 aOgYO » Y � w > Oa � OOp ~ m 00 � F- > U » » Y > -� v w C) C) D U C) w 2 W L) < C) F- m F- O Y U U d g ~ I-- U O Qr o - X < w 0 Q FT LO Z m �_ p �_ 2 �_ w af p ~ m U W W Co W w Ll,r Q M Q a' W p g N - N W w U` M w W W w m w Q Q m pQ W Q � QF Z = < w (nw > XCo < < z LL 0QXgrmn Um (nCnU) U) UW co � > � ~ V) U) w � F— po F- w W op F- _04 � oU) - 00 � LL W w r U) r U) � (fl O Q C) N N Z Y (0 W E J p p pp It (0 v vov ZWp m `f N wa m Z o �j W � X X X X X O X M 0 O 0, 0 0 Q„ W N LL m p LL O O N V V V v M v O Q U N LL IL LL- W V O LL.. U F• 00 d m Q O p 0 0 UF- (DUcpo °) Y (c) cOY Y `orn > L UUo 0 oNUw Voo Qv °o > C) rn rnLOLO O Y LO Q U LL Y O 0 0 N O LL O LL Y to to N � to to LL V m co N M N N ry pOp 0O -1 M co p m M c0 J o, U) v O C) a0 to p cn M M d U' � p N mn z mn mn LO r LL 00 00 Lo LO (o to to r r Q LL Y J LU +(J LO L) if ck� N W D z z 0 of of O � z Z F- > > = z � > z D w w - W j p w W CL w w w w J Q W W - S W p p l~ � p < F- Q ~ - t F- p O Y U) g w g � U w mn mn U) 2 Qn J Cn Y U W U) g Qr (r g F CL 2 Y - U - � U U Q QJQSJ0E- Q2QJQQ lywQ > Q W 2 aQJJJO0 SpOaCD =Jw =' W =, 2 =, 0 = = cn .n Up pLL UQUQUU w = U Up - Q F F- xF- - F wU Q = UZ) p w (L (DLL CC LL > _ mn U) CL z � 'J l_n (n (n CL Cn W CO LL) O D � 2 J 2 Z Z t' w J LL Y R N (fl It r r r co m N m w N co V v CD 0) O V N O m O m w O C M m to co U-) m r Y ¢ rn rn r r rn r m co (D 00 rn m r r co r m m co co m m m co Q) co m co r m o r m r m m m O D w rn rn rn m rn rn rn rn rn rn T rn rn m rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn rn 00 rLO O O Mp (') v r O N 0) r m N (o N 0�j r m O N 0) 000 000 N 1t O d7 N M M (D N (n N p O J (D LO r = r O r N V O N N V (D V LO to r r p Cl) Q m Cl) O Q Q 0O M r p to V' OLr) Q Q C, M N S O o) m M M p V' CL M r (N7 O) Cl) CD r 2 (n O 00 � Q U U (D N S (D a. r Cl) O Q 2 2 # N p V c0 M O_ V U (D r N (D N _ W (D (D COz J to r M m N M = (D r r 2 0 > LL 0) (D CD p N N U) r N m 0 `- U > Z C0 O > C' O r N 6) r N V O 0 r u') N N N m r M V' 2 M Q O V O V m p O O V O O to O O O O O U N r CC r �n > 0 0 r p U � 0 0 0 O O Q N O M O M Z m V p O O N U (J r p O m > m 0 0 X V In Z m a' N Y W = N V p m r p 1- Q (n r d' 0) N Lo O U m C� co (D O 0 CD (D (3 r C9 N 0 � _ C� M r o � N a X rn -) w O N � Lr)— ---) CO V U) T U- CD U 0) N R x Q M O J Y 2 U _ ) Q -� -� r mow -) 0 � � u JY C) cl) U n pr > N � LL. U p Y F U p p r Z) LL zo N = r N N LL r r 2 2 r w LL > p = p J rN.1 = JN o) (� � XU > m Doom QU - QpmN z Q r` v � rn N _rn Q Q Q Q _� Y Q X Q Cl) � Q _p �_ LO P Q N Q Q co Q Q N = J Q °) F x w Z m m O 0) Z N z N Z Z m Z (D z a) V Z N N (D m d' r'- '0') r 0) N (D , m N O N 04 'O U M p r M r (D N O N r M YY O (O V r M Z Z Z O Z Z M (n p V Z to p M m N tf') m CO m `- °) (D N O r m ? Lo V to Q m 00 Q m .- to N N m °) m m Q r CO V (D m 0) O N V to (p 0) r O O r = N co m m r a) V to C) m C) (D r 0) O tD m m 0 N Lo r m Cl) (D r m 0) O CD CD C) O C) r r NC w r N NU-)V V Lo U-) tO to (D (D m (D r r r m m m 0) m 0) O 0) r r r r r r r r r r r r r r r r r # r N m V tO CD r m O O r N M V to (D r m O O N N N N N N N N N OM M M M M M M M M M -q V V V V V 'T V 0 oorn o 0o 0) rnrn rn oornrnrnF rn rnrnrn rnrnrnrno 0 CD N N N N N N w N O N O co O Q Q p O O Q O Q O N Q Q N Q Q pN ON Q pN Q O N N O O Q O O N O Q O O O O O Q � ¢ CN O N Q N Z zzZ0- Q ? zQw ZaW ZZ U ZZZLZZZ > w (UCJCU � b doozbbb > wz -� Z >- mzb LL < w ¢ W m D w Z) O ¢ w w w w w w w w w w 0 ¢ ¢ w w 3 ¢ » Q � U) zip ppap ppp pppZ � � LL p O LO (0 LO (D V M LO 00 (D (D to O M N ti 00 (0 O (D LO n N (D O 00 (D (O Cl) V M N (D 00 co r- r- rn r r- co r- r- r` coo o 00 t- t- o) U) rn rn a) rn rn M 0) rn rn 0) 0) 0) rn rn rn rn Cl' r- O D co Z 00 rn 00 00o O co DD o Cl. 00LL rn do00 oZo) 0) m00 co n 0ooaaooda0— °20- 0 �-nr Cl. C:) O r oo0040 � 0 � : JNOQNN0Q - w00N0000p000 NN UNN0a0NC)JJU0) 0U) 0U) NN -pLn 0U) Ln p tO2p _ N0 1: a: 2 = = = - 0 0v = = = = = ti = pQ 0 w O U N0 \ U - (NU) J c Lo 0r J co o0 m M rn O a U) O p m J F-- Y Z m O J � O U Y w Y 0 w w a LL w U Y w Wof J O Q = J Y Q Y p d a a U a LL a a p LLO a j � < cr W SwF Ulm -j � Q w ¢ U D Y U a. >- a » p » ppw 00E Y Z) Dowry W YOO - UOF- O d W � cr- a `1 W U � LLLLLLa W 0D of YYYm � F- � U Y U U) U) Q ¢ U) U) iD J F- ~ U > U W 2 D = 2 F- O Y F W d W � F.- p --r U U U J F- d P U Y Q F- ¢ � U) co � U) U) rn Q p p p � W Y Y Y Y U) m U - � F' W - U � z w w W w F w z w x 0 W 0 Z a w w W Q F- p m U U U U � w a a a w a a a a g Q 2 = p F- O a L1 - W Q w 2 w 2 w F- U z Z F- z z Z z LL x U-L J W Z pp F- � F- F- dQ� F OUd � n� v ~ mU � g � F- mU J � Z = � aaaaw z F JJO =I - zmazF- z U pF- z DF- F- z QY � J > 00 < 0000z X O — Qw � � w � � � � w w110 pwgZQ ¢ W > UpzzzzQrroF F- F- F- F- F- 0W -q LL < > Uw � � � » Y002W0Q0Fmg � 0 = pYww � > U_ J ¢ p0000 � (Wnrvv vvvv` F- 0wwQF- JQZ LL L 0 — U U U CL -r C) � U LL F- LL E- = O LL' U ~ X LL � m F- Cl) co � M M M M •-- LL J J � m � N � w � D � LL � i m Q W Q 2 ZF- BOLL ¢ Q V V V V } z p p p Q p p p p pwmco ¢ 0 wz W m - O - 0 _ cl�-j p m0 wco0 = MMMM O U) Q 2 cn U) < < 0of < � Q0 a zz F- F- > > U � Np � � � � � � F- F- W v� O W 00 ¢ Cl) O ui O T r ¢ N m V N N N N N N N !Y (� = M o z U) Ln p Cl) O 0 p w C 0 0 ( a_ LLorf O J m N N N p O r � p w � N vw Q � ow � vvv �r � gg Xv ? o Q W O LL u- m 0 u- LL V X LL o C) o m r- O Y w X X X X M O 0 0 0 0 0 0 0 0 0 a a N O X m o F- o 0 0 o F- U c v v o 0 0 �r o LO p o o U U g o U o U N in iD o o O M LO g O LL O o ¢ r L0 Lo LO LO LO LO LO Ln Lo LO In Q ¢ M (D Y 'V' O O r- 00 F- O O O O N M N N V N N N N M N d _ O 7 LL m `^- LO r `- N N LL M LL LL to U) LL LL LL LL LL LL LL LL U U U) Lo L U g U) O tb LL M W LO m > �L O Z LL LL N LL o U U J J = U) O N g r a F- N Z Z Ln LL m F- g D � � z � af O J z O O 0 p 0 ] p p Q p - W W p W p U W 0 0 0 0 Y > > 0 0 0 0 0 0 0 0 Q z Z F LL J w o Cg ¢ QU (� U) JUUw w � U) U � Of � � wwOf � � � ofQ XWX ¢ ¢ a C) U) � Og = W = -j = = F- Jo -� � = J_ ¢ ¢ = = 0cr O oQ = oOoo � = Soo000000 �, � 2 1:< 0 LL D LL D F- Z U U - - LL w LL LL U - LL LL LL LL Q U U LL LL LL LL LL LL LL LL J J J a w U LL m U) 0 w U) CO U) ¢ > H > � "j ¢ ¢ m o co W O C) cc) M O (O m (0 0) 'ITLO LO r- m r- n CD 0) r r r <- M 00 N N N N N Cl Cl N tb LO LO N M co Cl) c0 O c0 I- co 0) M co O O O O O O 00 00 O O CD 0) 00 00 00 O O O O lb O 0) O O O O O O O O 00 O O O O N O O D O O O O O O O O O O 0) O) O O d) Q1 O O O 0) O O) 0 0 0 C) 0 0) 0 0 0 0 0 CD 0 0 C) 0 0 0 0 0 0) O �- N N N N r r N N N N N N N N r N N r r N r r r r r r r r r r r r r r r r r r r U) LO M CD ti CD C N N M N V LO O OM M Cl) Lo V' LO N r v' N r- M 00 r r- L('I M O O) t` co O O O M N O N O N N r- N N N N r� (') 00 N N fl-00 N N 0) a7 N O O O M O O (O (D r` CO r` n 00 00 00 00 Lo � M O O J M V M N LO M O r- O (D Ln M N 0 O M N 'T q M M Nr r M N M M N N N N O r- 0 0) a z co t` M V N r` ¢ co O N N O Q ¢ ¢ O_ ¢ Q to m _ M O V N Z U) v M = �* 0 n (° > v a r ¢ _ _ > C) (D w Cow w w o N w w w Co w w w w w U U 0- 2 M w � vfommLnc_o � U) 00 F- CD > � � LL CIA N N N N N N N N Cl)M (') ~ M o X r` O N N X M co (D Lfl O r O V N O O n co 0) co O O N r- Lo m Z Z tb CO N N C.0 S` 00 Ln Z r r M M U M N N " O N 2' 2 C7 p. O d Q. O J J J J N LL' Q' J J U) J J J - --J m m N � � LO n w r- > Q r 0 0 d M O U- (D c F- W ^ N r O n U M N N N N LO It V � 0 0 M 0 0 0 O M m 0) (D (D ¢ 4 V CO (9 0 2 co (� N M N N V N N N N O o N (7 N J g p O LL U) LPL a M U1 d LL O 2 Y N LL (7 LL LL O V U LL LL LL LL LL LL LL LL O to Ln W N X LL a J a LL LL q N O) 0) m -) ] N F p rn 2 0 U) F- W w p � H h H H 1 m H H 0 F- FZ-- F- H p 0) -) H~ LL LL �� ED 2 = LL > LL 2 LL LL LL LL ~ Ur LL LL LL LL LL LL LL LL U 2 LL M p LL Z N N J S -) N p N 2 M M M Z U N Z 2i Z Z Z Z Z LL' LL Q. 0 W C) p > )- > V X >- MC\l N 0 L01'7 r- r W (fl Z M m (D (D r. N M d O V _ Q` lD O Q ^ Q Q Q Q (V _Q Q O) CO CO M O N M 6) N N LO t!') O N M Q co Q Lo r N (D Z N_ M (+Oj Z O d' Z O O Z Z O V O Z (D (D Z (D z LO cr Ln r N Ln Co u) LO Ln LO w r O M Lo (D r Ln ITcm) Cl) to O V V V V cO - c, r (D M t() Z to (p Z (D ] Q O m OD O V M N M ,� N Q m o m m Q m m m m LO O Co m M m m N N N O N m to N O h U m m oo [D 0) Ln () m M to N 0) Co V M V n CO 0) M to M M C) O I'D r M V' (2 r� fX) m (D n O O) O r N M Ln (D n co O O N co (D 00 O N to (n (D (D t� ap 00 tb W N 6) O (T O O O O O .- r N N N N N M M M M M M (o Cl) Cl) Cl) V V V' V' V V to to L!) r r 0 r r r r r r 00 r .-- r r r r e- r N N N N N N N N N N Cl N N N N N N N N N N N N N N N N N N N N N N OS O N Cl) V to (D M 6) O N M V to CD r 00 6) O r N c) V L CO 0) O r N M V to CD 00 O C) N M It LO (D r\ 00 0) V LO Ln LO LO LO LO t() LO LO LO CD (D (D (D CD (D (D (D (D (D h r- r- � r- r` r- r-- r- co M M W W 00 00 (O c0 M 0) O (3) O O O 0) m a) M 00o oa) o) 00 0) 0) 0 oo mm rn _mmmmrn_ rn_ o ooz N N p N N N N N O O O O O N 0) 0 0) Q1 O p _ _ O O C) O O O O O 0 0 0 O O N N N N N N N N N N N W N N N Q Q N N N Q O N N O O O O O p O 0 0 0 o p p 0 O O O O O O O O O O N Q Q Q N N N Q N N Q N N N N N N N N N N N N N N Q N Q N N N N N N N Q N N Q Q UUmZZ } ZaZ J } >-zzz0 �joZ � crzmmmmmmU � ZZZJUUZUZUd000UmZ mm � z wWW a � w as WWa as wwwwwwwM » QDWW w wwwwwww ww � Dow � � w � � � oo � � � LLLLLLLLLLLL � a � ') � -� oo 0 ocnoo0o (L LL w a N M Lo O r` to rl- Cl) Lo 00 L0 t` 00 (D N 0) - N Lo N V O Cl) 00 V' OO V' O Cl) Lf) O Cl) V Cl) V O O rl- N 00 O r._ 00 r_ 00 00 00 t` 00 CO 00 00 ao (O r OD O O 0) 0) 0) (3) O O 0) O O 01 O 0) 0) 0) 0) 0) () Q Z Z W Z U) U 0 z00 p 00 O CO m M 0) D) 0) U) Z Z U F Q w 00 0) O O of N 00 O r` a0 p 0- w � w n � n a as U) z � mmmm mm !-) mw - } n rya oa O � o000 000 00 o OZ nw2 _jo 0 0 0 > � m o0 o (y o OJO0C-4cj 0NNNO (DONNON00S0 � OLL wN0000N00NONOJ � ONNO ci -Q ON S d S in v 2 to o S p S Lo 2 Lo 2 2 W Z O N S 2 2 2 2 2 2 S Q LL 2 M v S 2 W W U) p �- NLC) U) c-- U) J (/� N U) r• U) U) H U) U) 0 0 w 0 0 N U) 0 � w C2 0 S V- g 0 N � U) N � U) r <n � rv0) rvrn 0 c� v co Q ~O � � ap } fir Cl) r` � v w < ima __' Y aaaadU ww w as w -' » > Q Y U w w J a a Y Y J J w Y Y Z) Z) D D D > W � Z) D D w 2 NC Y Y Y Y Y � U 0 U 0 Y Y Y Y Y Y � > J Q Y Y Y J U U ~ U U U W 0 0Y 0 o U U U U � U 0 0 0 - w � O U U Q - m Y Y LL U - a W W U U LL Q iaa wa » > 0Of0 x UU =, aaa a00 ~ JJ 0U0aaaa � � J wwF_ T) m m W 0 � af w r Y Y Q !- H H W W Y m m m m w H H F- a Q a F- Q ♦- m m Y J J !- 2 � r t- 000WaLLaz m mt- w22a a � am m0oo � aaQZU_ t Q Q O Q O z z O2 z J U > Q O Q a Q Q Q a C7C� - � > > > Q Q Q Q w w z � w w � U0Y0 } aaYa � � � a 000000 of t- Q a000Umm Ooi- E- 2 - t- - UZw » U > ~ ~ W OfU0C) OUwUJCoF_ F_ gD1E 2i Cl. "3- -) OadwUWxF— F_ F- t- � w0 aw 0 � v v Q W Z Z W X J m X X X X X W w `2 � X W w x )< ..] O _mj 0` o _ L w X Q f- J J Q J F_ W W O O Q mQ Y Y J W W w w w z O W J o W W W W W W O W m X C� 2 � m S > U) W. �. U U O O U J W W 2 LL LL W O K w O 2 m m m Z 3 Z Z Z z Z Z Z m O w Q Q W Q Z Z Z W Q a Q O Z Z Q Q Z U p z Z Z Z Z } CO 0 0 D00 22 2 Y02 > 0 mm � 00000 - aQ � oo J_ � S � OO0000 � `o °oUU 0 H (, U) t- N N F- F- L- f- E F- r Q � H H ~ ~ H H J v H 0 W v v r Q v v v o g v v v g n co M O Z M M M ('7 co 0 0 LL N M M M M r r zo LL X C) N d CL ON W V W X V' N S W -� W _J _J 7 v v J X v J J O 'J 0 V n V V V V V V CO Q Q U) V T V, '7 U) H C X X W d O O J O m U) K Op Op 't w t (? X X X X X o coLL of � N L o Lo X X X X N W F- � g 7 V V O O O 0 V d V V' V' 'V' 'V V to (O V V V V' O O LL J C (fl (D O (D a s M O 00 �--- d tf) U J J ~ ~ r M p M Lo U) L6 LL LL LL rr n Lo LOO a U) 0 S S Z) LP) O 0 0 0 U) p O N to to to to C) c) 0 to Z Z r 0 o m M m O O O U) LL m 0 N V m r` d V N N O U) U) U) ~ M N Q' d' O O p C7 N N N N N O M Q Q o F' N N N N (D N c- N O L LL LL U) too) O LL U r- f� LL LL LL LL LL r 0 0 �- �-- LL LL LL LL. 0 U) O N Lo J J co Lo 0 J w 0 0 } 0 0 0 2 2 U 0 0 0 w w w a o J Y Y w 00 0 0 0 0 0 ::) - Z Z Q a EEO 0 0 0 0 0 0 0 a 0 O O W w Of UUcnUUUU � 2UUUc� UU � � � � � � � mgaa � � � � � D � � � � � � � � (D (D O O Q a a = 2 Q 2 2 = m O w Q Q 2 Q S 2 W 0 0 0 O O O w -� w } } } 1w, Y 0 0 0 0 0 0 } w Q Q U L LL LL U U U - - - m0 LL 0 � � U a LL LL LL LL LL LL w D J J w J J J a a LL LL LL LL LL LL J a U U m 0 w a a LL 0 0 0 00 CL O M M OO W CO co (3) (3) tT N V O N to �-- O O CO M �-- C O O) d) M M N N N_ N N N m N N t` to J O O O 0) O M M d) CO CD N O d) O O O O O) O O r 0) O O r— O O O p m r p O O O M O O O O 0) O O O 0) 0) 0) p 0 0 0) O O) 6) O O O O1 0 0 0 0 0 0 0) O O 0) O O O O m O O O O O O O O O O 0) O V N N .- r N �--- r N .--- N c- r N r N N N N N N r N N r N N N N - N N N N N N N N N N - N tp O «) (D p M tf) N (D 0) N_ N V M Lo V t0 N O 00 N Cl) V' (M V O O V o 0 Lo � O � d1 W O V 00 0) r- 0) d) Q) 0 00 O N V V V V M M OV M M O C') V No O n Lo M (D co co (D (O (D p M O N O O O O O O V r (D coM Lo O tp 00 C. N 00 r` N V N � N N 0) N O Ln (D U) N O O O O O O O 0) 00 r,- (D M O O O O _O _O 0) N •� (.-j U) (D (D (D tf) 0 O O N m M n to M to p (D m LO O O N u U 0 v v ` S S to S S S W °O S S S cT Co m m m m W O o 0 0 o o_ Cl) Ln N m m m m w w o 0 0 0 _M W W N N W W W w w p 0 0 Op I- "T O W W W W F- co Z F O Cl) O M Y Y '7 } O M m O t- Cl) d N O U rn N r- M.) 00 � O c(DD V' O) V O (D X � 100 O N ci I Lf) (D 'q Cl m m m m m (,.) q M R Q' O a d7 to (D � M u-) ti rn O O O N io M M 0 0) Lo «) N N N N Y Y (p LL O N a N J 'V' V' (O CD N V d Q. N _ _ �' p (D (D (D (D (D (} N N N X M O N O N O M O O O U U O X N c0 to v M (O (O (O N N N U 0 n N N SD N N N N CO Q N Q Q a Ur m m m m m m r M LL N N CO Q� M Co CO CO CO M M 00 N V N LUo � X X � ' 0 -=ice - � � aa � OU � � � � � � LJi Np DOH d � � � � � � � C) H L~i d 2 2 2 2 2 2 ~ ~ L~i L~i L~i L~i L~i 0 d N N U X L~L LLLL. LLLL FL- m U m v 2 2 LL X r X LL LL _ v v J F LL Y LL LL Y Y J Y Z Z Z Z Z W W W W X N a X U' C7 D D 2 = = Z Z N 0 0) 0) 2 Cl) N 00 0) r` 0) co V N O M O 0) N w O N N V Lo M r- O ? 0 Lo Q Q 00 00 Q CO M r Q V' Q to to to Q Lo to Q t� n M W > � � Q Cl) Q to L() Lo to CO (D > Q > } X Q (D n to N N V cr n V 0) O O D1 p p 0 p O O - w V O O r� co V co co co co co M 00 O lr) M O N e- z z N r- f� Z f� N Z (D Z �f V V z It V Z (D N CD co co co O ap O Z Q) Z f� f� r t` r h rn Z M Lo Z 0) 00 00 00 Cl) M O co N N N N (D (D (D () CO co z (D n r- M n r 00 Cl) (o Cl) co Cl) Cl) r n r,- N m m (O m m m m m m m m m m m m m m m in m U o O Cl) M Lo Lo ,- () CO m m m m m 00 ' r V (D r-IWIMICD N co I I Lo M r— 00 O N M V to (O r-_ co O O N M V p t` w m O r N M r (f) (D r,- 00 mP N M 7 Lo (Oto to to Lo m (D p O M O M 0 p O r__ r` r- ti r� t` r` r- N f� OO t0 CO CD 00 OO 00 00 00 O a7 m 0) O m m m m m O OO O O O ON N N N N N N N N N N N N N N N N N NNN NN N N N N N N N N N N M M co M (o co M N co V Lo (D r- M O O N M V to CD f� M p 0 N M V' to (D r p m O N M V Lo CO t� O O O N M V to CD r� M O O 3 0 0 0 0 0 p O 0 0 r c- N N N N N N N N N N M M M M M M M M M M n m O O m m m m m O O O O O O m m m m O m m O O m w O m o O O p :) 0 0 0 0 0 0 0 0 0 O O O O O O p 0 0 0 0 O O O p O O O "o 'o O 'oV N Q N N N N N N N N Q N N Q Q Q Q Q N N " N (u N N N N Q Q N Q N Q N Q Q Q Q Q Q Q Q N Q N N N N N N N L U Z U U U U U U > a ZC� b Z Z Z Z z (j F- F- F_ F- z m z z Z m Z m Z } Z Z Z Z Z Z Z Z _j Z F F- U M W > M 1J w w W W W w W O m a W w U U U U Q W Q W W Q D U U w W Q O W n ❑ 10,10 0101CIzQ Q ❑ ❑ OOOOQ -) a -) LL a 2E � 001 a2� zu- M 00 r N m h N CD h Cl) (D Lo m O N N (D N V' co M M Cl) (O co V V O (o M Cl) O N 00 h h 00 M h 00 h h W 00 M M 00 M 00 co 00 m m m m m m m m m m m m m m m m m m W Z f- J 0 w a p 0 a � W Z J L > r >- a a aaa a 0 as a aaaa aaa _ C� LL1rrr D wQ 0 0 _N000o (� 000oF O 00 000000 ij _� oC) OOO � rO W � � p wp V Y {Y C0 N w F- a F- Q N N m Z a o N > N to S h N S m S S S 2 p Op S S (' S S S S S ❑ to h S S S to M M m 7 a ❑ (n N (n N (n N (n (n (n ` ❑ (n N r r' LL Z W Z (n (n (n r fn U7 (n fn N 00 r (n (n (n r ❑ Q N J M N r J r } O � YM mr c� r � °j :'5 § V J a0 V 0Mc � MO � � QC) Mwv Q U U � U W U S S U W Y O = U U Lj m a a a w a a a a � w W a i ::) Z:) =:) n W a J Z) D D D of w F- Q L Y Y Y Y w w J Y Y Y Y Y w a Z ❑ CUUUU _J � � K wO w U F- � UUUUJ Fay Z wLL U U a an. aQQ00 wa Ja ❑ a � wan aaQ aYL-` � O ww aw w Y � a Dew a � ir U7 U) ❑ - a Q 0 o J 0 - w O J � 0 U Y Z W J Y W � mMMM F- cncnwQ ❑ w F F- (oaF- QmmMM W � � � � W (fl - SZF- O � Qw ❑ ma zF- J - J L Q Q Q Q a _J a Q Y F- O Q a Q Q Q Q J Q Q Q S W O m a Q W Q Q Q U ir W w m a H � - - a 0 W Z F- U F- F- - - C U U U U W W Of a F- ~ ❑ Q > U LL U) > F- U U U U W Q Q F- (n W Q u a Q > > Y = J F- 0 0 U S > > L F- F- s J ❑ Q Q J [n Q ❑ a a a F- a s (n N a J ~ F- O Q U U a ❑ u Z U Z z Y F- M a a Q gwNF- w0m � UwwwwwQF- F- � — ❑ r c� UQzwC) z000E- J ~ � w w w w Q >> LL, W ❑ [a X X m a a a a J a W 0 U W Q a X m W W U > W w F- F- Z) a W — a - Cif of > O O Z U F- W J O V W F- D D D D � W Y " ❑ LL 0 m a Q w ❑ a w ❑ `6 Q � � N N m 2 W uJ � UUUU J UU Q _J - JO X - � (n (n Cn Cn J W DUXa OF- F- W w � zzzz < CfaNa W > F- zOm `rZF- Z Z Z Z Q a ❑ ❑ V W W mgawUZ � ❑ (nJ a Z rZ ❑ Y � ❑ C00000CDQQ m m v � zo00000 mv � F LL W ❑ r�i 0O FO M L r N N F- F- F- F- oo 0 a W N N N J M M M M Q U 0 w U V V V V W X X X x x X X ~ ~ M ❑ F � 0 IT p O a (O Q! N Q IT Of N X X X X O (Q U F- (D O mw z U — O O V Cl) 222ooLL Uo o LnUovLn vJ c (� o oM x = 000x ❑ vvvvo � aF- z vo ova - 0 0 0 Q t(? U ❑ J U X r M m co (2 o 0 0 o tQ Y O ap (n M o m h n M p m to to Lo J M 7 a a d m to LL. U a X m Q M 00 to to to to a r U o cD c) o F- v U C� to F- W W 11 F- F- , 0000W W co Lo NT _ � � � W � � u.. t% titi W = a � � Na. LL 00 Hco ZmLr) toYa LL raJJ N N N N Y 0 w ~ F- F- a = _ W W w W a �_ a a - F- U = w Y S U a X Y w = w F- Z FU- X U` z x 0 0 0 0 w w z WU a U j Y v U a ❑ ❑ ❑ ❑ W w W U U y m J ❑ U w w Q 0 J j ❑ ❑ ❑ ❑ w z z w ❑ ❑ ❑ ❑ J J J J S� U W a Q a a a J J F Q Q U a a (n U � S W a F J F 1' } JJJF- I- YS Y >- F- C.� � M � = OU j wQ � mX w = C� Jfl �C 0 0 0 0 F- J S } O } } 0 0 0 0 - O S O 0 0 0 J 0000 S a. U -i U Z y J LL LL LL LL S a Y U O U` LL LL LL LL. W W — j (n (nU- F- 0Q W0QO mm U) (Z Q W m W U U mLLf- m - F- f- F > W ❑ ❑ 00 00 co r O co co 00 (D M M M M m M M CO CD M M M h h h (D h m V m m m CD M h CD O O CC:)' m CDO Cl m o o CD CD 0 CD (D CD m O m m m O ) 0 0 0 0 0 0 0 0 0 0 CD CD am) 0 0 0 0 0 0 0 O m O 'D O 0 0 0 0 0 O m -DO m m m 0 0 0 0 - N N N N N N N N N N N N N N N N N N N N r N N N N N N N N N r N N r r N N N N o m CO co h CO CD to U) 00 M N r (o N N N M M CO M M r N to Lo O M m V' Lo to to M CO V' N r p 0 V N N h N m M M 0 Lo m r m O co O M M M m h (D M m m co r O O N M N m N M (� N N r r M V V h m p h m to h O h V' M M to M M m m O O coM Co h O h N N p (O M M M M to O M M m (D h to N 7 (N N O h N O m 0 m O N O M _ h O to M h (D M h to O to r N N N N O a 00 O J h h m co m U U U h M -Mi S F- OO N N ❑ Q Co Q Q M S N F O (D (.,) v F- Y Y -j (V to (raj h Z N M O O N > Y N S S w U) O h OM U U U U Q to p M m m Q CO M O O V fD ❑ ❑ Y Y ❑ W d h M Cl) OO M h LL (D X X (D F- (D MhN 00 0') 00 Nm o o ❑ ❑ Lc) h (o o to to _ t� oQE XC� C77C) F- F- F- F- M p Y to of N M N N M r N M N p M O V (o h N m M a N > N N M N 0 CD V' Z N t1) Z M 2 2 00 O Q N J N W to S O to M ~ ~ F- F- O V v o LL o CO V Q M U N N m X (,.) W U v to to to to r > O m Lo r N M h m M r W W w W N to Q a r 0 (D h M o0 M V N Ur r M a V V - ❑ ❑ ❑ ❑ p m a' Ll `- LL T" LL X r X v a Q lL `_' W '- Z O to V' O 0 LL X W X F- F- F- F- F- C 04 QU mF- m LL XX U ❑ Og m J N a = X ❑ z ❑ M M co co > > m cn a) F u LL m > ❑ F, ❑ 0 a U ❑ > F > > UUUU > > am ❑ U C� ULLwLL LL (p0 = -� > CALL t~i LLa (DlLU- (o Cl) (`7 N U) > a s Lo �... V Z r LoLo U) U) xx ❑ � } � U- ❑ , m ❑ U wwLLQza (oottootC)rnum) Lo I> > ❑ ❑ oXQ } 'SQ � QQQ � � rnrnrn > � rCD < r- QMQQQQQQQornQrnhmo� MMNaoN O O O O Lo 00 of V Cl) (D M to to to to M (O M V (O 00 M to V (D 00 m N M � m m to (� M to Z r m z OD Z Z Z m Op M 00 M M h (D Z Z M Z '7 Z M Z Z Z Z Z Z Z co Z M M M (D N M (D (D (D (D C) a h h (D m h (D h O O O O M (O h - O V (D (D N m to N co O m m m m h h m N (o r m r m m m m co Cl) Nt m U Cl) U U U U U U m o to h O r N M 'ct M (D h 00 m O N M V to CD h N m 0 N M V Lo (D h 00 m 0 N co V to (D h 00 m 0 N M V to (D h CO m 0 r r N N N N N N N N N Cl) M Cl) c) Cl) M M co M M V V V r V' V V cY V V' (o to to to to to to to Lo to w M M M M M M co M M co M M M M co co Cl) M M M Cl) Cl) M Co CO M M co M co M M co M M M co co M M M co M M co M M M M M co co 1 Cl) V to M h CO m 0 N M V to (D h M m 0 N M V �o (O h M m 0 N M to M h 00 m 0 N M V to M h N m O r N M M to to to to to to (D CD (D (O (D (D (D (D M M h h h h h h h h h h W N 00 M M CD 00 M oo M m m m m m m m m m m O O O O r N N N N O m O O O m m O O O O O O O O m O O O O O O O O m m m z m m m m m 0 0 a O z N N N N N N N N N N N N w N N N N w O O 00 0 0 0 O O O O O O O O O O 0 0 0 0 0 O O O p 0 0 O O O O O O O O O m N Q Q Q N N N N N Q N N N N N N N N N N Q Q N N N N N Q N N N ¢ N N N N N N N N N N N Q ¢ N Z Z Z F Z tY Z Z lY Z F- ! Z ¢ Z z Q z z z c CO mmmmm � aUU F- UU � UUUUUwLYw � 2 Q w W w w w w w w w ¢ Q ¢ w w ¢ ¢ ¢ ¢ a a a w n w w w U w w W W W w W ¢ ¢ ¢ ¢ LL ❑ ❑ U) LL LL � � � � ¢ U) U) U) O ❑ ❑ w ❑ ❑ ❑ ❑ ❑ � � � � w a a co (0 to (o N _ N U-) 0) co co co to .- co -IT I- N (D N LO U,(D (D M 'ITM et LO 'ITm O M 'IT (o to O h h co h M h N co h 00 h h co h co co 00 OD h M m m m m m m m m m m m m m m m m m m 0) m Z F Z_ 0 Z w z 0 � z z 00 00 eo w o m O J F- 0 w Y CQj °O � mm omcoao � W w � m � � mm m mom > � tY o o a a a ❑ a a o a. o 0 o a ❑ w U> z o a a o o 0 0 a w w a a a a o 0 0 o a a o o a J a a N N O O O N O O N O o N N O Q w W w _N O O N N N (� O z Y � 0 0 0 0 N ¢ m N N O m 0 _N ' N O W O O Z O n N 2 2 S z 2 2 Ln S N in n S m a ❑ N S 2 �t 2 0 Of w S 2 S 2 LO m 2 � S 00 2 p S S W Z �- N W U) U) 0 w o U) � � U) } Y } .- U) U) N M N } U) J W a U) 0 U) W N N ` U) � U) r 0 U) U) zz � � tY � oocn 2E wQa rnM � rnof zOw MUrn � V C0 V a0 0 ( Q Q 2 w U 3 0 0 ❑ � ~ o Y z Z U LU L7 ❑ ❑ f3f ❑ w w OO wQ mLY ❑ Of M M M - _J � m mw Y U) U) w M M M M ww YO � awLLq Y — w. LYwLY Jpaa ¢ lY W Z Z J F- Q ¢ ¢ ¢ U Y Y U W W w J LY U Q W w W w a- � � Of0w QOa W W OJUUUU ❑ aa n UU) U) U) ❑ a JJJ ¢ W Y lY! oo YU) (� z Z S JF- F- m W ¢ ¢ Q 0 !- U) _ W X � � 2 U J Q W U U) (� ¢ ¢ _ X X w F- F F- F- J J J J m a m m m U w w F- m J J J J ¢ ¢ ¢ w w F- U) ❑ ❑ J m O w — > > w ¢ Q W _W m X X X X p p S 2 Q ¢ Q Q J Z ¢ p p m tr Z Z } } J a � > O ❑ W w W W a (� w — a F- F- F- _ — LYE r ¢ 2 � m p z z w z a Y w v v v �* X X ¢ ¢ Q ¢ U O D U U co CY Q � w U ¢ ¢ ¢ ¢ w w ~ ~ 0 F- _ U Y a Y F- W F- U J W W S S S S U F- F- F- _ F- 2 2 2 2 ❑ ❑ ❑ F- --i � p W XU � � C) O0Q JLYm = a v v vXa = pO » » w xXxrnCDF- ❑ n X » ❑ mwwwmm ¢ — F- F > U_ F- F- ~ W W W ❑ S W W LU Z_ ❑ W m m m J J ¢ p 2 ij W Q w 0 > X F- F- V V V (D U CD (D (D (D pp W U V' V w w _J J_ H W Z Z Z z p ¢ ¢ N N N N U V V d' w p ¢ p C1 N N N N J_ J_ _J O O J J O > LZ F- LYMMJ � ¢ ¢ wm0000LYcr � UZXXX ❑ LY x ntnJ ~ J -J Y ❑ ❑ CD IT X Cl) QY m z Q ` N Q W W Z W v �t v 0 > ¢ w v F F- F- h h ¢ } Q ¢ ¢ v F- F- J p > Z Z 0 W Z Z z J > Z Z cO a0 00 U O 2E � Y o as x zMMM � (Oww F ~ OOONa cD00 oCOcncn LO g � � w 00 N `t � vvMw ov � � w X cococoU) N M ❑ p F w J w LU O O (DO 0 0 0 0 w r r O O O O M 0 0 0 0 w (D 2i M < < X W M N J to U) to w J m 00 N (D (D (D (D U) U) U) a. a. O o L CD U IT 0 0 0 n- r O M 0 0 0 X 0 ❑ pi U U U U x M O O O N Q O D U U U N N N 0 0 } } O O Cl) F- (� F- O O to Lo Lo O O Y Y Y Y o ('') Lo to LO o F" to Y Y Y Y N (V N M M to h F- F- C. U) F- (o ❑ 0. a U7 co M N N N t!') m U V U U U U a N N N M N M p ❑ N U U U U N N a W (� U r m F- Q (O o 0 o a F- v LL LL LL v cq w LL w x J O LL m m X F- Q Q O U F- O 0 c O L% Y Y Y Y iL -� w w N Y Y Y Y F_ F_ W F_ rn N NxG � a an. aa � cn a0- 0- 0- 000 2 2w � 0000 U 0000 U') to F- F- F- � F- E- F F- LLl S LY W W 0� x X w 2 F- Y Z Q U U U 2 2 N ¢ Q O w U W W W W W W J ❑ ❑ ❑ ❑ D ❑ ❑ ❑ 0 U J ❑ U U W C7c� J UUUU 2 F- UUUUaaa wppUO ❑ U) g U U) CO F- F- U ❑ m m E w U Z Z LY m tY ¢ W F- 0Y D D -i U W ¢ _I = ❑ ❑ } ¢ S Z S U M !/) 2 2 w w } J Z Z 2i LY Y 00 CEO - 0000 - 00 Oz000 } F_ 2 LYO } } } > Q U ❑ ❑ U ¢ - - LL LL w W Q Q C� C� C� C7 LL w LL LL LL Y U 0 w W U U J J J Y Y > Q O O w w > F_ m m �p U) F- W 0 O 0 F- F-FQ-- � 2 S O 2 p a Z U U- — S O m (D M_ N M h h m V h h h (D M M M O O O O h h h h h CO V (D 00 O h O 0 C) 0 N V V M M O h M m m n O O O m O O O O O m O m 0 O O O O O m M O fr 0 0 0 0 O O O O O O O O O O m 0 0 0 0 0 0 0 0 0 0 0 0 m O m O 0 0 0 0 0 0 0 0 0 0 0 0 m m O N N N N N N N N N N N N N N N N N N N N N N N N N N — N — N N N N N N N N N N N N N — N T m O m M U) O p m 0 N m h m N Lo 0 _� M m Lo N IT OM Cl) V V O (D to (D m I (fl V (O h V r M m to LO L0 to U) O � M m N N (D m (D N Lo 0 0 N � N h M to V N N N h ONO 00 to h C2 (O N M m tL') m m O 00 CD '7 LO V Lo N CN 00 h (OD 0 W M O CO U7 M CV to (D (fl (D 'T h (DLC) V U) M m (V U') 0 0 M 00 00 00 00 � 10 NO p m m m m U m to V O m O M m CD 0 CD m m m m m m M V O M O N V _ h m 0 S W a M 6 0 0 = 0 0 0 U co M U m U 00 h 2 0 U m m m O r, N N O w N > V m [7 W W W Y S m m O M M Y w w W N Q W '"") -7 M F- F- F- 00 a U C' m LL C M (D o h LL (� ❑ o M 2 2 a > }_ > > 2 h m } } } } v v h m rn TO N Lo (D O m m (D N (D to m X 2 S S d. ❑ ❑ CO m to M M 2 2 = h m N } S N V N m U W W M M M (3) O X Lo Ur Cl) V N N N z N (D (D (00 XD U Z M CD Co _m m m w (D CD LY ¢ O m 0] Lb m N N N U) to N ON N CO O M U o g p p U h V V g O m m m W N m m W CM M m m O M N U N 0� 00 m co M M (') h h O > 'z N N Z O O 2 = 2 2 > N N N N �- N W Q N 2 = 2 S N N U N U Z ❑ � Z � ❑ ❑ 2 h h h LL O J J W W W C7 > X X X N m F- F- x m (D CD CD LL LL e- N ¢ Q h F) F- (D F- � m > > m F- F- F- F- F- -� ❑ ❑ p ❑ W h h h U) p h O C� 0 C) F- F- F- ? Q = = m S co M > L m CO = J w LL w w 2 LO LO 0 U C7 L7 L~L. LL LL L~L. ❑ t~ C7 U U C7 U U U > p Ur a w U- LL- > tT] J J J J -) m m m m co Z J N m (D Lo N N N N N N (D h N 0 O LO h V N V co Lo Q Q M Q o CD ¢ ¢ ¢ ¢ ¢ r- cCOO ((6cjQ (o (n000L� r°°) c°°irMwm _o _o _o _orn NN_ � _rn QQ m O Z Z z N V w M Z N 00 00 �t M M M Z Z O O O O N Z Z LMj (Mj h CO CO M Op M M Z Z Z Z Z N O 00 00 m LO Lf) Lo M co M h M V' V V h m h h h h h M M co O co h N h m m CD m M M Cl) M O (`') O M U U U h h h h U h U U U U U U U U U U U U U m M U — U U U U U N N N N V U J M -T m (D h 00 m 0 N M '7 to (D h M m 0 N M V' Lo (D h 00 m 0 N M "' Lo (0 h OO m 0 N M V (o (D h CO.m 0 .-- N M O (D (D (D CD (D M h h h h h h h h h h CO 0� CO CO CO W M aD 00 M m p) m m m m m m m m (D 0 0 0 0 a 0 0 0 0 7 M M M M M M M M M M M M M M M M M M M M M M M M M M M M M co Cl) M (M M M M M V 'V' V 'q V r t Lo (D h 00 m 0 N_ M V' tD (D h M m 0 N M �' Lo CO h CD m 0 N M V to (D h 00 m 0 N M V to (D h M m 0 N M V' to O O O O O r c- N N N N N N N N N N M M M M M (M M M M M V V V ct V' V 'ct V' V V U) to LC) to LO to J N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N rn o rn rn rn rn rn rn rn rn rn D 0 0 0 0 0 0 0 0 0 0 N N Q N Q N N N Q N Q Q N N Q Q N N Q Q z Q z 0 z Q z z O Q z z Q O zW OO N It N (o L In Cl) (o Cl) (D Cl) 00 V to Cl) O O to V Lo V Lo M V Cl) co (b co co co r- n 00 r co ti M W 00 O O O O O O O O D) O O p (r Cr w 00 g o COLLrn (D00co00C� rn (orn0torn (n (no C) W000p0C � 000D = 0000 �- N N N N N N N N J N N N N O ON w to O to N (D U7 N U - � N to LO Y N O N W N N lz N M CO MCF) Cn .- .- m .-- M Q 0 N V Cl) w 0 w } Y m 'IT G� w Y x -j D =) Q Q 1J Q X O J U m Y w Y Y O N O w J < � wmQ � O_ I- 00O oaa � zmm0 Q > F- F- 0 LLB w YCZ " C) W � ° c) � nC)<< w3g ° � v � ox � � C/) < mz zUU (nmwLL � n � m (j w Q m W � F h X X p Y o o - Z o z m m Q 0 x w w w Y Q N N -j C) 0o -i � O �nUw vzzv) � XXCD oQQ CO v Soc~v ~ 00 } wm X XOO aoomJ co LO O V 0_ -i Q ` Y = O M LoCD U C) Cl) M Q O Lo F- m V O � O D O M LL U O O M N LL w O _to Cl) (D (O U p p J �i 0 0 <L m LL- U O_ F- LL U W LL Lo LL F- � X x W 5 ~ W >< r M M w r W W = F- 0 W W = z O L p 0 p O w 2 p J w woo U w > J m m 0_ � Q X X > Ow0 -' } � Ow -j OOW > OOW LL Y w z LL CD 5 _ = LL LL Q 0 LL w w F- Y 0 0 F- D Q o t` M I� n N co CD rn M M M �7 61 - D00000rno00000000000 V N N N N N N N N N N N N N N N N N D ~ (D r' (D V f� Cr CDN 7 co O O tD Lo V (D r- 00 7 LO M N (D M 'V r n M M m m (o p O m V N (+7 M ^ V CD Z O m N M W Y N o w w W W 0 F- O O O L ^ r`ri � o = Z � Nom wY Yp2YY li O O CN7 W M Y Y (D (XD 00O O D L L N - M Q M O O p m m pN (0 = _ n F- z F-F- D Q F- Cr-LL U) N O O F- F- U` W W X ALL LL > XLL F- F- LLLL 00 ~ U') r U') L 0 Z J U :E Z J Z Z m m rn CN F Q Q Q CD N O VO M Z F- Z co u) 00 Z M Z Z ( � Z Z T 1 Z (n co 00 00 LO oU U °' UU t` UU mm Y to CD o N M V. m co I- co O o N �- N N N N N N N N N N M M CM D Ih co m O N M V (fi co n co O O N M V m w I� M m O N co V to CO I` co m O N M V u7 7 to Lo (l1 w fD (D O O M (D (D (D (D I` ti I` ti I` n n t` � ti co M w w N m w co co W O Cr O m (T D] 1 N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N N BIDDER RESPONSIBILITY CRITERIA Statement that Bidder Has Not Been Disqualified This statement is required by state law (RCW 39.04.350(1)(f)) to be submitted to the City before the contract can be awarded. The bidder hereby certifies that, within the three-year period immediately preceding the bid solicitation date (October 29, 2019), the bidder has not been disqualified from bidding on any public works contract under RCW 39.06.010 or 39.12.065(3). Colvico Inc . Bidd r' usiness Name Sig ature of Authorized Official* Jesse Dragoo Printed Name Vice President Title October 28, 2019 Spokane WA Date City State * If a corporation, proposal must be executed in the corporate name by the president or vice-president (or any other corporate officer accompanied by evidence of authority to sign). If a co-partnership, proposal must be executed by a partner. PS 3 Electrical System Improvements/Araucto 16 October 10, 2019 Project Number: 17-7999.6 BIDDER RESPONSIBILITY CRITERIA Certification of Compliance with Wage Payment Statutes This certification is required by state law (RCW 39.04.350(2)) to be submitted to the City before the contract can be awarded. The bidder hereby certifies that, within the three-year period immediately preceding the bid solicitation date (October 29, 2019), the bidder is not a 'willful" violator, as defined in RCW 49.48.082, of any provision of chapters 49.46, 49.48, or 49.52 RCW, as determined by a final and binding citation and notice of assessment issued by the Department of Labor and Industries or through a civil judgment entered by a court of limited or general jurisdiction. I certify under penalty of perjury under the laws of the State of Washington that the foregoing is true and correct. Colvico Inc . Bidder' siness Name SignatM46 of Authorized Official* Jesse Dragoo Printed Name Vice President Title October 28, 2019 Spokane WA Date City State * If a corporation, proposal must be executed in the corporate name by the president or vice-president (or any other corporate officer accompanied by evidence of authority to sign). If a co-partnership, proposal must be executed by a partner. PS 3 Electrical System Improvements/Araucto 17 October 10, 2019 Project Number: 17-7999.6 PROPOSAL SIGNATURE PAGE The undersigned bidder hereby proposes and agrees to start construction work on the Contract, if awarded to him/her, on or before ten (10) calendar days from the date of the Notice to Proceed, and agrees to complete the Contract within forty (40) working days after issuance of the City's Notice to Proceed. The undersigned bidder hereby agrees to submit all insurance documents, performance bonds and signed contracts within ten (10) calendar days after City awards the Contract. The City anticipates issuance of the Notice to Proceed on the day of the preconstruction meeting. No bidder may withdraw his/her bid for a period of sixty (60) calendar days after the day of bid opening. The required bid security consisting of a bid bond, cashier's check or cash in an amount equal to 5% of the total amount is hereto attached. Notice of acceptance of this bid or request for additional information shall be addressed to the undersigned at the address stated below. Receipt of Addendum No.'s 0 to the plans and/or specifications is hereby acknowledged. Failure to acknowledge receipt of the addenda may be considered an irregularity in this proposal. By signing this Proposal Signature Page, the undersigned bidder agrees to accept all contract forms and documents included within the bid packet and to be bound by all terms, requirements and representations listed in the bid documents whether set forth by the City or by the Bidder. DATE: October 28, 2019 Colvico Inc . NAM IDDER Sign ture of Authorized Representative Jesse Dragoo, Vice President (Print Name and Title) 2812 N Pittsburg Street Address Spokane, WA 99207 PS 3 Electrical system Improvements/Araucto 18 October 10, 2019 Project Number: 17-7999.6 BID BOND FORM KNOW ALL MEN BY THESE PRESENTS: That we, Colvico, Inc. , as Principal, and Travelers Casualty and Surety Company of America as Surety, are held and firmly bound unto the CITY OF KENT, as Obligee, in the penal sum of ***Five Percent of Bid*** (5/) Dollars, for the payment of which the Principal and the Surety bond themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, by these presents. The condition of this obligation is such that if the Obligee shall make any award to the Principal for Pump Station No. 3 Electrical System Improvements/Project Number: 17-7999.6 According to the terms of the proposal or bid made by the Principal thereof, and the Principal shall duly make and enter into a contract with the Obligee in accordance with the terms of said proposal or bid and award and shall give bond for the faithful performance thereof, with Surety or Sureties approved by the Obligee; or if the Principal shall, in case of failure so to do, pay and forfeit to the Obligee the penal amount of the deposit specified in the invitation to bid, then this obligation shall be null and void; otherwise it shall be and remain in full force and effect and the Surety shall forthwith pay and forfeit to the Obligee, as penalty and liquidated damaged, the amount of this bond. SIGNED, SEALED AND DATED THIS 29th DAY OF October 2019. 0"""""'"' Colvico J c. pN0 SURF- J�j•• ��► PRIN AL Q: HARTFORD, CONN. O Travelers Casualty and Surety Company of America �4- 1t * d SURETY Shawn M. Wilson, Attorney-in-Fact 20 Received return of deposit in the sum of $ PS 3 Electrical System Improvements/Araucto 19 October 10, 2019 Project Number: 17-7999.6 Travelers Casualty and Surety Company of America AM Travelers Casualty and Surety Company TRAVELERS J St. Paul Fire and Marine Insurance Company POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company are corporations duly organized under the laws of the State of Connecticut (herein collectively called the "Companies"),and that the Companies do hereby make,constitute and appoint Shawn M Wilson of SPOKANE , Washington , their true and lawful Attorney-in-Fact to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF,the Companies have caused this instrument to be signed,and their corporate seals to be hereto affixed,this 17th day of January, 2019. rgYMkky,.� y�6 SURtt c ypr, �. SG P p°� 9 CONK. o. LTK S. senaw State of Connecticut By: City of Hartford ss. Robert L. Rane enior Vice President On this the 17th day of January, 2019, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of said Companies by himself as a duly authorized officer. MQrA9.g. IN WITNESS WHEREOF, I hereunto set my hand and official seal. A i.OiAP,v My Commission expires the 30th day of June,2021 ;« #. .' Anna P.Nowik,Notary Public This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Travelers Casualty and Surety Company of America,Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, which resolutions are now in full force and effect, reading as follows: RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances,contracts of indemnity,and other writings obligatory in the nature of a bond,recognizance,or conditional undertaking,and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her;and it is FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary;and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or (b) duly executed (under seal, if required)by one or more Attorneys-in-Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority;and it is FURTHER RESOLVED,that the signature of each of the following officers: President,any Executive Vice President,any Senior Vice President,any Vice President,any Assistant Vice President,any Secretary,any Assistant Secretary,and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in-Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached. I, Kevin E. Hughes, the undersigned, Assistant Secretary of Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, do hereby certify that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies,which remains in full force and effect. Dated this 29th day of October 2019!! SU9 a'-1Y 4,0 TU 4P `tea 'bdl Diet K l I Kevin E. Hughes,Assistant Secretary To verify the authenticity of this Power of Attorney,please call us at 1-800-421-3880. Please refer to the above-named Attorney-in-Fad and the details of the bond to which this Power of Attorney is attached. CITY OF KENT COMBINED DECLARATION FORM: NON-COLLUSION, MINIMUM WAGE NON-COLLUSION DECLARATION I, by signing the proposal, hereby declare, under penalty of perjury under the laws of the United States that the following statements are true and correct: 1. That the undersigned person(s), firm, association or corporation has (have) not, either directly or indirectly, entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bidding in connection with the project for which this proposal is submitted. 2. That by signing the signature page of this proposal, I am deemed to have signed and to have agreed to the provisions of this declaration. AND MINIMUM WAGE AFFIDAVIT FORM I, the undersigned, having duly sworn, deposed, say and certify that in connection with the performance of the work of this project, I will pay each classification of laborer, workman, or mechanic employed in the performance of such work not less than the prevailing rate of wage or not less than the minimum rate of wage as specified in the principal contract; that I have read the above and foregoing statement and certificate, know the contents thereof and the substance as set forth therein is true to my knowledge and belief. Pump Station No. 3 Electrical System Improvements Project Number: 17-7999.6 NAME OF PROJECT Colvico Inc . NAME OF BIDDER'S FIRM SIG4&4kE OF AUTHORIZED REPRESENTATIVE OF BIDDER PS 3 Electrical System Improvements/Araucto 20 October 10, 2019 Project Number: 17-7999.6 This change order form is for example purposes only. By submitting a bid, the bidder agrees to be bound by the terms of this change order form for any change orders. CHANGE ORDER NO. [Enter # 1, 2, 3, etc.] NAME OF CONTRACTOR: jInsert Company Namel ("Contractor") CONTRACT NAME & PROJECT NUMBER:jInsert Name of Original Contract & Project #, if applicablel ORIGINAL CONTRACT DATE: FInsert Date Original Contract was Signed] This Change Order amends the above-referenced contract; all other provisions of the contract that are not inconsistent with this Change Order shall remain in effect. For valuable consideration and by mutual consent of the parties, the project contract is modified as follows: 1. Section I of the Agreement, entitled "Description of Work," is hereby modified to add additional work or revise existing work as follows: In addition to work required under the original Agreement and any prior Amendments, Contractor shall provide all labor, materials, and equipment necessary to: [Insert detailed description of additional materials, services, etc., that are needed which necessitate this change order - Be as detailed as possible. You may also refer to an attached exhibit, but clearly identify the exhibit by title and date] 2. The contract amount and time for performance provisions of Section II "Time of Completion," and Section III, "Compensation," are hereby modified as follows: Original Contract Sum, $ (including applicable alternates and WSST) Net Change by Previous Change Orders $ (incl. applicable WSST) Current Contract Amount $ (incl. Previous Change Orders) Current Change Order $ Applicable WSST Tax on this Change $ Order Revised Contract Sum $ PS 3 Electrical System Improvements/Araucto 21 October 10, 2019 Project Number: 17-7999.6 Original Time for Completion (insert date) Revised Time for Completion under prior Change Orders (insert date) Days Required (t) for this Change working days Order Revised Time for Completion (insert date) In accordance with Sections 1-04.4 and 1-04.5 of the Kent Special Provisions and WSDOT Standard Specifications, and Section VII of the Agreement, the Contractor accepts all requirements of this Change Order by signing below. Also, pursuant to the above-referenced contract, Contractor agrees to waive any protest it may have regarding this Change Order and acknowledges and accepts that this Change Order constitutes final settlement of all claims of any kind or nature arising from or connected with any work either covered or affected by this Change Order, including, without limitation, claims related to contract time, contract acceleration, onsite or home office overhead, or lost profits. This Change Order, unless otherwise provided, does not relieve the Contractor from strict compliance with the guarantee and warranty provisions of the original contract, particularly those pertaining to substantial completion date. All acts consistent with the authority of the Agreement, previous Change Orders (if any), and this Change Order, prior to the effective date of this Change Order, are hereby ratified and affirmed, and the terms of the Agreement, previous Change Orders (if any), and this Change Order shall be deemed to have applied. The parties whose names appear below swear under penalty of perjury that they are authorized to enter into this contract modification, which is binding on the parties of this contract. 3. The Contractor will adjust the amount of its performance bond (if any) for this project to be consistent with the revised contract sum shown in section 2, above. IN WITNESS, the parties below have executed this Agreement, which will become effective on the last date written below. CONTRACTOR: CITY OF KENT: By: By: (signature) (signature) Print Name: Print Name: Timothy 3. LaPorte P.E. Its Its Public Works Director (title) (title) DATE: DATE: APPROVED AS TO FORM: (applicable if Mayor's signature required) Kent Law Department PS 3 Electrical System Improvements/Araucto 22 October 10, 2019 Project Number: 17-7999.6 BIDDER'S CHECKLIST The following checklist is a guideline to help the Contractor make sure all forms are complete. The bidder's attention is especially called to the following forms. Failure to execute these forms as required may result in rejection of any bid. Bidder's Package should include the following: Bid Document Cover Sheet filled out with Bidder's Name ....................❑ Orderof Contents.................................................................................❑ Invitationto Bid...................................................................................❑ ContractorCompliance Statement........................................................❑ Date............................................................................................❑ Have/have not participated acknowledgment.............................❑ Signatureand address ................................................................❑ Declaration - City of Kent Equal Employment Opportunity Policy ........❑ Dateand signature .....................................................................❑ Administrative Policy ...........................................................................❑ Proposal...............................................................................................❑ Firstline of proposal - filled in ...................................................❑ Unitprices are correct ................................................................❑ Subcontractor List (contracts over $100K) ..........................................❑ Subcontractorslisted properly....................................................❑ Signature ....................................................................................❑ Subcontractor List (contracts over $1 million).....................................❑ Subcontractors listed properly....................................................❑ Dateand signature .....................................................................❑ Contractor's Qualification Statement ...................................................❑ Complete and notarized ..............................................................❑ Statement that Bidder Has Not Been Disqualified ................................❑ Certification of Compliance with Wage Payment Statutes....................❑ ProposalSignature Page......................................................................❑ AllAddenda acknowledged .........................................................❑ Date, signature and address .......................................................❑ BidBond Form .....................................................................................❑ Signature, sealed and dated .......................................................❑ Powerof Attorney.......................................................................❑ (Amount of bid bond shall equal 50/o of the total bid amount) CombinedDeclaration Form .................................................................❑ Signature ....................................................................................❑ ChangeOrder Form..............................................................................❑ Bidder's Checklist ................................................................................❑ The following forms are to be executed after the Contract is awarded: A) CONTRACT This agreement is to be executed by the successful bidder. B) PAYMENT AND PERFORMANCE BOND To be executed by the successful bidder and its surety company. The following form is to be executed after the Contract is completed: A) CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE STATEMENT To be executed by the successful bidder AFTER COMPLETION of this contract. PS 3 Electrical System Improvements/Araucto 23 October 10, 2019 Project Number: 17-7999.6 PAYMENT AND PERFORMANCE BOND * T TO CITY OF KENT Wi.yNlNpTok Bond No. 107177516 KNOW ALL MEN BY THESE PRESENTS: That we, the undersigned; Colvico Inc. as Principal, and Travelers Casualty and Surety Company of America a Corporation organized and existing under the laws of the State of Washington, as a Surety Corporation, and qualified under the laws of the State of Washington to become Surety upon bonds of Contractors with Municipal Corporations, as Surety, are jointly and severally held and firmly bound to the CITY OF KENT in the penal sum of $345,186.60 , together with any adjustments, up or down, in the total contract price because of changes in the contract work, for the payment of which sum on demand we bind ourselves and our successors, heirs, administrators or personal representatives, as the case may be. This obligation is entered into in pursuance of the statutes of the State of Washington, and the Codes and Ordinances of the CITY OF KENT. Nevertheless, the conditions of the above obligation are such that: WHEREAS, under and pursuant to a motion, duly made, seconded and passed by the City Council of the City of Kent, King County, Washington, the Mayor of.the City of Kent has let or is about to let to the above bounden Principal, a certain contract, the said contract providing for construction of Pump Station No. 3 Electrical System Improvements/Project Number: 17-7999.6 (which contract is referred to herein and is made a part hereof as though attached hereto), and WHEREAS, the Principal has accepted, or is about to accept, the contract, and undertake to perform the work therein provided for in the manner and within the time set forth: NOW, THEREFORE, for non-FHWA projects only; if the Principal shall faithfully perform all the provisions of said contract in the manner and within the time herein set forth, or within such extensions of time as may be granted under the said contract, and shall pay all laborers, mechanics, subcontractors and material men, and all persons who shall supply the Principal or subcontractors with provisions and supplies for the carrying on of said work and shall indemnify and hold the CITY OF KENT harmless from any damage or expense by reason of failure of performance as specified in said contract or from defects appearing or developing in the material or workmanship provided or performed under said contract, then and in that event this obligation shall be void; but otherwise it shall be and remain in full force and effect. IN WITNESS WHEREOF, the above bounden parties have executed this instrument under their separate seals. The name and corporate seal (if required by law) of each corporate party is hereto affixed and duly signed by its undersigned representatives pursuant to authority of its governing body. PS 3 Electrical System Improvements/Araucto 24 October 10, 2019 Project Number: 17-7999.6 TWO WITNESSES: Colvico Inc. PRINCIPAL (enter principal's name above) BY: TITLE: ��, DATE: November 13th, 2019 DATE: November 13th 2019 CORPORATE SEAL: Shawn M. Wilson PRINT NAME DATE: November 13th, 2019 Travelers Casualty and Surety Company of America SURETY ,,` gHlllffJ/ll . BY DATE: November 13th, 2019 ' TITLE: Shelly Donovan Attorney In Fact � !��'�� Alk.• '"' ADDRESS: 818 W. Riverside Ave., Ste. 800 ru Spokane, WA 99201 CERTIFICATE AS TO CORPORATE SEAL I hereby certify that I am the (Assistant) Secretary of the Corporation named as Principal in the within Bond; that Who signed the said bond on behalf of the Principal Colvico, Inc. of the said Corporation; that I know his signature thereto is genuine, and that said Bond was duly signed, sealed, and attested for and in behalf of said Corporation by authority of its governing body. SECRETARY OR A ISTANT SECRETARY PS 3 Electrical System Improvements/Araucto 25 October 10, 2019 Project Number: 17-7999.6 Travelers Casualty and Surety Company of America Travelers Casualty and Surety Company TRAVELERS St. Paul Fire and Marine Insurance Company POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company are corporations duly organized under the laws of the State of Connecticut (herein collectively called the "Companies"),and that the Companies do hereby make,constitute and appoint SHELLY DONOVAN of SPOKANE , Washington , their true and lawful Attorney-in-Fact to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF,the Companies have caused this instrument to be signed,and their corporate seals to be hereto affixed,this 17th day of January, 2019. daw ?,IV A4, CON 't 7 State of Connecticut By: City of Hartford ss. Robert L.Rane enior Vice President On this the 17th day of January, 2019, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of said Companies by himself as a duly authorized officer. P ffi ad�iP ,4 ., IN WITNESS WHEREOF, I hereunto set my hand and official seal. r 0, fiOtAAv My Commission expires the 30th day of June,2021 :r d4. 3 "``c / " Anna P.Nowik,Notary Public ��nvFc��',�'' This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Travelers Casualty and Surety Company of America,Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company,which resolutions are now in full force and effect,reading as follows: RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer,the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances,contracts of indemnity,and other writings obligatory in the nature of a bond,recognizance,or conditional undertaking,and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her;and it is FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary;and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or (b) duly executed (under seal, if required)by one or more Attorneys-in-Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority,and it is FURTHER RESOLVED,that the signature of each of the following officers:President,any Executive Vice President,any Senior Vice President,any Vice President,any Assistant Vice President,any Secretary,any Assistant Secretary,and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents,Resident Assistant Secretaries or Attorneys-in-Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof,and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached. I, Kevin E. Hughes, the undersigned, Assistant Secretary of Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, do hereby certify,that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies,which remains in full forc�� e�Pe i�- '_; 71 Dated this 13th day of November 2019 �'.~� V�wxer aitr Ahpa . VTgll l�W� J C1 {A n;j l� r 7 S� FAI G � •. z CIk N. 8 CON. P ' .N ` �'!, j�, •••••�•• ' '��`' 6 Kevin E. Hughes,Assistant Secretary To verify the authenticity o> �ey,p/ease call us at 1-800-421-3880, Please refer to the above-named Attorney m-Fa�e i/s of the bond to which this Power ofAttorney is attached. CONTRACT THIS AGREEMENT, is entered into between the CITY OFKENT' aWashington municipal corporation ("City"), and CoIvi�o, Zoo � - ' organized under the laws Ofthe State of Washington located and doing business at 2812 IJ PittsburgS± Spokane, VV]l 9[�207-- (.Contractor.). WITNESS: In Consideration of the terms and conditions contained in this Agreement and in the project documents, p|anS, and specifications all of which are a part of this Agreement, the parties agree asfollows: l . The Contractor shall do all work and furnish all tools, materials, and equipment for: Pump Station No. 3 Electrical System Improvements/Project Number: 17~7999.6 in accordance with and a5described in the Contract and shall perform any alterations in or additions to the work provided under the Contract and every part thereof. The Contract shall include all project specifications, provisions, and plans; the CitY'Sgeneral and special conditions; the 2018 Standard Specifications for Road' Bridge, and Municipal Construction, as prepared by the Washington State Department of Transportation and the Washington State Chapter of the American Public Works Association, including all published amendments issued by those organizations, if applicable (^StandardSpecifioadons''); the CiTn's bid documents; and the Contractor's response to the City's bid. The Contractor is responsible to obtain copies of the 2018 WSDOT Standard Specifications including the latest amendments issued by VVS[]QT as of the date of bid opening. Unless otherwise directed by the City. work shall start within ten (10) days after the City issu�s it� Notice to Proceed and be completed within forty (40) working days. The Contractor shall provide and bear all expense of all equipment, work, and labor of any sort whatsoever that may be required for the transfer of materials and for constructing and completing all the work provided for in the ContraCt, except where the specifications allocate that responsibility tothe City, 2. The City hereby promises and agrees with the Contractor to employ, and does employ, the Contractor to provide the materials and to do and cause to be done the above described work and to complete and finish the same according to the Contract and the terms and conditions herein contained and hereby contracts to pay for the same according to the Contract and the schedule of unit or itemized prices provided b\/ Contractor in its response 1Othe CitV's bid' at the time and in the manner and upon the conditions provided for in the Contract. 3. The Contractor for |tse|f, and for its heirs' executors, administrators, successors, and assigns, does hereby agree tothe full performance of all covenants herein contained upon the pert of the Contractor. 4. It is further provided that no liability shall attach to the City by reason of entering into this contract, except as expressly provided herein. PS3 Electrical System |mp,vvmnnents/Aruucmo 26 0cuvuerlO. 201e Project Number: 17-7989.6 5. Contractor shall defend' indemnify, and hold the Chv' its officers, officials, employees, agents, volunteers and assigns harmless from any and all claims, iryur|os, damages, losses or suits, including all legal costs and attorney fees, arising out of or in connection with the performance of this CoOt[Qct, except for i .ur|es and d8rnageScaused by the sole negligence of the City. The [itV's inspection or acceptance of any of Contractor's work when C0n0p|e1ed shall not be grounds tO avoid any of these covenants nfindemnification. Should a court ofcornpetentjurisdiCtion determine that this contract is sub iect to RCVV 4.24.115, then, in the event of liability for damages arising out Of bodily i 'un/ tO persons Or damages to property caused by or resulting from the concurrent negligence Ofthe Contractor and the City, its officers' officials, employees, agents and volunteers, the Contractor's liability hereunder shall be only tothe extent of the Contractor's negligence, IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THE INDEMNIFICATION PROVIDED HEREIN CONSTITUTES THE CONTRACTOR'S WAIVER OF IMMUNITY UNDER INDUSTRIAL INSURANCE, TITLE 51 RCVV' SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PARTIES FURTHER ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER. The provisions of this section shall survive the expiration or termination of this contract. G. Contractor agrees, upon the City'swritten dernand, to make all books and records available to the City for inspection, review, photocopying' and audit in the event of contract related dispute' claim, modification, or other contract related action at reasonable times (not toexceed three (3) business days) and at places designated by the City, 7. The Contractor shall procure and maintain, during the term of construction and throughout the specified term of maintenance, insurance of the types and in the amounts described in Exhibit attached and incorporated by this reference. 8. Contractor is responsible for locating any underground utilities affected by the work and is deemed to be an excavator for purposes ofRCVVCh. 19.122' as amended. Contractor shall be responsible for compliance with RCVV Ch. 19.122' including utilization of the "One ca||" locator service before commencing any excavation activities. PS Electrical System |mp,ovoments/Aravc»n 27 octobe, ln. 2018 Project Number: 77'799e.6 CITY OF KENT --pa BY DANA RALPH, MAYOR DATE: o� A TTES Q • KIMBERLEY A �TTO, CITY CLERK APPROVED AS TO FORM: 0&-7F,-k, KENT LAW DEPARTMENT CONTRACTOR BY: PRINT NAME: Cory Colvin TITLE: President DATE: November 13, 2019 PS 3 Electrical System Improvements/Araucto 28 October 10, 2019 Project Number: 17-7999.6 EXHIBIT A INSURANCE REQU I REMENTS FOR CONSTRUCTION PROJECTS Insurance The Contractor shall procure and maintain for the duration of the Agreement, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees or subcontractors. A. Minimum Scope of Insurance Contractor shall obtain insurance of the types described below: 1 . Commercial General Liability insurance shall be written on ISO occurrence form CG 00 01 or its equivalent, with minimum limits of $3,000,000 per occurrence and in the aggregate for each 1 year policy period. This coverage may be any combination of primary, umbrella or excess liability coverage affording total liability limits of not less than $3,000,000 per occurrence and in the aggregate. Products and Completed Operations coverage shall be provided for a period of 3 years following Substantial Completion of the work. The Commercial General Liability insurance shall be endorsed to provide the Aggregate per Project Endorsement ISO form CG 25 03 11 85. The City shall be named as an Additional Insured under the Contactor's Commercial General Liability insurance policy with respect to the work performed for the City. All endorsements adding Additional Insureds shall be issued on form CG 20 10 11 85 or a form deemed equivalent, providing the Additional Insureds with all policies and endorsements set forth in this section. 2. Automobile Liability insurance covering all owned, non-owned, hired and leased vehicles. Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. 3. Workers' Compensation coverage as required by the Industrial Insurance laws of the State of Washington. B. Minimum Amounts of Insurance Contractor shall maintain the following insurance limits: 1 . Commercial General Liability insurance shall be written with minimum limits of $3,000,000 per occurrence and in the aggregate for each 1 year policy period. This coverage may be any combination of primary, umbrella or excess liability coverage affording total liability limits of not less than $3,000,000 per occurrence and in the aggregate. Products and Completed Operations coverage shall be provided for a period of 3 years following Substantial Completion of the work. PS 3 Electrical System Improvements/Araucto 29 October 10, 2019 Project Number: 17-7999.6 EXH I B I T A (Continued) 2. Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1 ,000,000 per accident. C. Other Insurance Provisions The insurance policies are to contain, or be endorsed to contain, the following provisions for Automobile Liability and Commercial General Liability: 1 . The Contractor's insurance coverage shall be primary insurance as respect the City. Any insurance, self-insurance, or insurance pool coverage maintained by the City shall be excess of the Contractor's insurance and shall not contribute with it. 2. The Contractor's insurance shall be endorsed to state that coverage shall not be cancelled by either party, except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City. 3. The City of Kent shall be named as an additional insured on all policies (except Professional Liability) as respects work performed by or on behalf of the contractor and a copy of the endorsement naming the City as additional insured shall be attached to the Certificate of Insurance. The City reserves the right to receive a certified copy of all required insurance policies. The Contractor's Commercial General Liability insurance shall also contain a clause stating that coverage shall apply separately to each insured against whom claim is made or suit is brought, except with respects to the limits of the insurer's liability. D. Contractor's Insurance for Other Losses The Contractor shall assume full responsibility for all loss or damage from any cause whatsoever to any tools, Contractor's employee owned tools, machinery, equipment, or motor vehicles owned or rented by the Contractor, or the Contractor's agents, suppliers or contractors as well as to any temporary structures, scaffolding and protective fences. E. Waiver of Subrogation The Contractor and the City waive all rights against each other any of their Subcontractors, Sub-subcontractors, agents and employees, each of the other, for damages caused by fire or other perils to the extend covered by Builders Risk insurance or other property insurance obtained pursuant to the Insurance Requirements Section of this Contract or other property insurance applicable to the work. The policies shall provide such waivers by endorsement or otherwise. PS 3 Electrical System Improvements/Araucto 30 October 10, 2019 Project Number: 17-7999.6 EXH I B I T A (Continued) F. Acceptability of Insurers Insurance is to be placed with insurers with a current A.M. Best rating of not less than A:VII. G. Verification of Coverage Contractor shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the Automobile Liability and Commercial General Liability insurance of the Contractor before commencement of the work. H. Subcontractors Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor. All coverages for subcontractors shall be subject to all of the same insurance requirements as stated herein for the Contractor. PS 3 Electrical System Improvements/Araucto 31 October 10, 2019 Project Number: 17-7999.6 , __"s COLVINC-01 MILLER ,acORo CERTIFICATE OF LIABILITY INSURANCE DATE1/8/2D/YYYY) `--'� 1 /8/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsements. PRODUCER CONTACT LeAnne Tope,CIC NAME: Alliant Insurance Services,Inc. PHONE FAX 818 W Riverside Ave Ste 800 (A/C,No,E:t):(509)343-9528 (A/C,No): Spokane,WA 99201 nDoRlEss:LeAnne.Tope@_Alliant.com INSURERS AFFORDING COVERAGE NAIC# INSURER A:Charter Oak Fire Insurance Company 25615 INSURED INSURER B:Travelers Indemnity Company of America 25666 Colvico,Inc INSURER C:Travelers Property Casualty Company of America 25674 PO BOX 2682 INSURER D: Spokane,WA 99220 INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF POLICY EXP LIMITS A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE FIVX OCCUR DTC08M26715000F19 11/1/2019 11/1/2020 DAMAGE TO RENTED 300,000 X X PREMISE E occurrence) $ MED EXP(Any oneperson) $ 10,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY�X TE LOC I PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: B AUTOMOBILE LIABILITY EOMBINdEDI SINGLE LIMIT $ 1,000,000 X ANY AUTO X X 8108M2745461926G 11/1/2019 11/1/2020 BODILY INJURY Perperson) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY Per accident $ HIRED NON-OWNED PROPERTY DAMAGE AUTOS ONLY AUTOS ONLY Per accident $ C+ UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ 9,000,000 X EXCESS LIAB I I CLAIMS-MADE CUP8M3246341926 11/1/2019 11/1/2020 AGGREGATE $ 9,000,000 DED I X I RETENTION$ 10,000 A WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY Y/N TAT TE ER ANY PROPRIETOR/PARTNER/EXECUTIVE DTC08M26715000F19 11/1/2019 11/1/2020 1,000,000 OFFICER/MEMBER EXCLUDED? ❑ N/A E.L.EACH ACCIDENT $ (Mandatory in NH) 1,000000 E.L.DISEASE-EA EMPLOYEE $ , If yes,describe under _ - -- -��— - DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Pump Station No.3 Electrical System Improvements/Project Number:17-7999.6 City of Kent is Additional Insured as respects the General Liability for the Ongoing and Completed Operations of the Named Insured as required by written contract,coverage is Primary&Non-contributory. Primary&Non-contributory Additional Insured applies to the Autombile Liability. Waiver of Subrogation applies as indicated above. Forms attached. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Kent THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 220 4th Ave S ACCORDANCE WITH THE POLICY PROVISIONS. Kent,WA 98032-5895 AUTHORIZED REPRESENTATIVE ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD COLVICO ELECTRICAL, INC. Who Is An Insured — Newly Acquired Or Formed Organizations Who Is An Insured - Broadened Named Insured —Unnamed Subsidiaries Blanket Additional Insured —Owners, Managers or Lessors of Premises Blanket Additional Insured — Lessors Of Leased Equipment Blanket Additional Insured - States or Political Subdivisions— Permits Knowledge and Notice of Occurrence or Offense Unintentional Omission Blanket Waiver of Subrogation Amended Bodily Injury Definition Contractual Liability- Railroads Class Schedule Composite General Liability Class Codes: Class Final State .. • Description SublineExposure WA 69863 CONSTRUCTION- Combined SALES/RECEIPTS Optional Coverages: Premium: Employee Benefits Liability (Claims Made Coverage) Aggregate Limit $2,000,000 Each Employee Limit $1,000,000 Deductible NONE Retroactive date: 11/1/2018 Commercial General Liability Forms ADDL INSD-OWNERS/LESSEE/CONTRACTOR B CG 20 10 ADDITIONAL INSURED-OWNERS, LESSEES CG 20 37 EXCLUSION-LEAD CG DO 76 EXCLUSION - DISCRIMINATION CG D1 42 AMEND-POLL EXCL-INCL LTD COV POLL COST CG D1 73 AMEND-NON CUMULATION OF EACH OCC CG D2 03 EXCL-EXTERIOR INSULATION & FINISH SYSTEM CG D2 04 DESIGNATED PROJECTS(S) GEN AGGR LIMIT CG D2 11 EXCLUSION -SILICA OR SILICA-RELATED DUST CG D2 40 BLANKET AI-W/COMP OPS IF REQ BY CONTRACT CG D2 46 EXCL-CONSTR MAN ERRORS AND OMISSIONS CG D2 93 XTEND ENDORSEMENT FOR CONTRACTORS CG D3 16 EXCL-SUITS ONE NAMED INS AGAINST ANOTHER CG D3 22 ADDL INSD-OWNERS/LESSEE/CONTRACTOR B CG D3 61 EXCL-PROJ SUBJ TO WRAP-UP-LTD EXCEPTIONS CG D3 91 DAMAGE TO PROPERTY ENDORS-LEGAL LIABILIT CG D4 10 EXCL-ARCH ITECT/ENG/SURVEY PROF SERV CG D5 46 EXCL-VIOLATION OF CONSUMER FIN PROT LAWS CG D6 18 ELECTRONIC DATA LIABILITY COVERAGE CG D8 23 WASHINGTON - FUNGI OR BACTERIA EXCLUSION CG F2 41 WA CHANGES EMPLOY RELATED PRACTICES EXCL CG F2 66 DEDUCTIBLE LIAB INSURANCE -WASHINGTON CG F3 07 Consult Policy for Actual Terms and Conditions TRAVELERS Page 11 Date of Proposal: Print Date: 11106119 COLVICO ELECTRICAL, INC. WASHINGTON CHANGE -WHO IS AN INSURED CG F4 66 COMM'L GENERAL LIABILITY DEC CG TO 01 DECLARATIONS PREMIUM SCHEDULE CG TO 07 KEY TO DECLARATIONS PREMIUM SCHEDULE CG TO 08 EMPLOYEE BENEFITS LIAB COV PART DEC CG TO 09 TABLE OF CONTENTS- COM GEN LIAB COV CG TO 34 EMPLOYEE BENEFITS LIAB TABLE OF CONTENTS CG TO 43 COMMERCIAL GENERAL LIABILITY COV FORM CG T1 00 EMPLOYEE BENEFITS LIABILITY COV FORM CG T1 01 EXC-HAZARD-CONNECTED DESIGNATED EXPOSURE CG T4 81 "YOUR WORK"ON OR FOR ANY PROJECT THAT, IN WHOLE OR IN PART, IS OR WILL BECOME: 1. ANY SINGLE-FAMILY HOUSING; 2. ANY MULTI-FAMILY HOUSING OTHER THAN ANY RESIDENTIAL APARTMENT; OR 3, ANY RESIDENTIAL CONDOMINIUM EMPLOYERS OVERHEAD LIABILITY GN 01 13 NUCLEAR ENERGY LIABILITY EXCLUSION ENDOR IL 01 98 COMMON POLICY CONDITIONS-WASHINGTON IL TO 05 EARLIER NOT CANCEL/NONRENEWAL PROV BY US IL T3 20 AMNDT COMMON POLICY COND-PROHIBITED COVG IL T4 12 CAP ON LOSSES CERTIFIED ACT OF TERRORISM IL T4 14 FEDERAL TERRORISM RISK INS ACT DISCLOSE IL T3 68 DESIGNATED ENTITY CANC PROVIDED BY US IL T4 05 This policy is subject to a general liability deductible You will be required to reimburse Travelers for paid losses which are within the general liability deductible stated above Deductible plan losses will be billed on a monthly basis. Additional terms and conditions regarding this deductible are contained in the above referenced endorsement. Deductible Liability Insurance. Consult Policy for Actual Terms and Conditions TRAVELERS ; ' Page 12 Date of Proposal: Print Date: 11106119 COLVICO ELECTRICAL, INC. • HIRED CAR PHYSICAL DAMAGE CA TO 03 COMPREHENSIVE $500 DEDUCTIBLE COLLISION DEDUCTIBLE $1,000 • BUSINESS AUTO COVERAGE FORM CA 00 01 • WASHINGTON CHANGES CA 01 35 • LESSOR-ADDITIONAL INSURED AND LOSS PAYEE CA 20 01 • WASHINGTON UNDERINSURED MOTORISTS COVERAGE CA 21 34 • AUTO MEDICAL PAYMENTS COVERAGE CA 99 03 • DRIVE OTHER CAR COVERAGE-BROADENED COVERAGE FOR NAMED CA 99 10 INDIVIDUALS • BUSINESS AUTO COVERAGE PART DECLARATIONS (ITEMS 1 AND 2) CA TO 01 • BUSINESS AUTO COVERAGE PART DECLARATIONS (ITEMS 4 AND 5) CA TO 03 • BUSINESS AUTO/AUTO DEALERS/MOTOR CARRIER COVERAGE PART CA TO 30 SUPPLEMENTARY SCHEDULE-UNINSURED MOTORISTS COVERAGE AND UNDERINSURED MOTORISTS COVERAGE (ITEM 2) • SHORT TERM HIRED AUTO-ADDITIONAL INSURED AND LOSS PAYEE CA T4 52 • AMENDMENT OF EMPLOYEE DEFINITION CA T4 59 • BLANKET ADDITIONAL INSURED- PRIMARY AND NON-CONTRIBUTORY WITH CA T4 74 OTHERINSURANCE • WASHINGTON CHANGES- DEFENSE COSTS IL 01 23 • NUCLEAR ENERGY LIABILITY EXCLUSION ENDORSEMENT(BROAD FORM) IL 01 98 • COMMON POLICY DECLARATIONS IL TO 02 • COMMON POLICY CONDITIONS-WASHINGTON IL TO 05 • LENDER'S CERTIFICATE OF INSURANCE - FORM A IL TO 10 • CALCULATION OF PREMIUM-COMPOSITE RATES IL T3 02 • EARLIER NOTICE OF CANCELLATION/NON RENEWAL PROVIDED BY US IL T3 20 • DESIGNATED ENTITY- NOTICE OF CANCELLATION PROVIDED BY US IL T4 05 Consult Policy for Actual Terms and Conditions TRAVELERS. Page 16 Date of Proposal: Print Date: 11106119 COLVICO ELECTRICAL, INC. • AMENDMENT OF COMMON POLICY CONDITIONS-PROHIBITED COVERAGE- IL T4 12 UNLICENSED INSURANCE AND TRADE OR ECONOMIC SANCTIONS • CALCULATION OF PREMIUM-COMPOSITE RATES IL T8 25 • BUSINESS AUTO EXTENSION ENDORSEMENT CA T3 53 A. Broad Form Named Insured B. Blanket Additional Insured C. Employee Hired Auto D. Employees As Insured E. Supplementary Payments- Increased Limits F. Hired Auto—Limited Worldwide Coverage—Indemnity Basis G. Waiver Of Deductible—Glass H. Hired Auto Physical Damage—Loss Of Use—Increased Limit 1. Physical Damage—Transportation Expenses—Increased Limit J. Personal Property K. Airbags L. Notice And Knowledge Of Accident Or Loss M. Blanket Waiver Of Subrogation N. Unintentional Errors Or Omissions Consult Policy for Actual Terms and Conditions TRAVELERS.I Page 17 Date of Proposal: Print Date: 11106119 COMMERCIAL AUTO THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET ADDITIONAL INSURED - PRIMARY AND NON-CONTRIBUTORY WITH OTHER INSURANCE This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM PROVISIONS 2. The following is added to Paragraph B.5., Other 1. The following is added to Paragraph A.1.c., Who Insurance of SECTION IV — BUSINESS AUTO Is An Insured, of SECTION II — COVERED CONDITIONS: AUTOS LIABILITY COVERAGE: Regardless of the provisions of paragraph a. and This includes any person or organization who you paragraph d. of this part 5. Other Insurance, this are required under a written contract or insurance is primary to and non-contributory with agreement between you and that person or applicable other insurance under which an organization, that is signed by you before the additional insured person or organization is the "bodily injury" or "property damage" occurs and first named insured when the written contract or that is in effect during the policy period, to name agreement between you and that person or as an additional insured for Covered Autos organization, that is signed by you before the Liability Coverage, but only for damages to which "bodily injury" or "property damage" occurs and this insurance applies and only to the extent of that is in effect during the policy period, requires that person's or organization's liability for the this insurance to be primary and non-contributory. conduct of another"insured". CA T4 74 02 16 u 2016 The Travelers Indemnity Company.All rights reserved. Page 1 of 1 Includes copyrighted material of Insurance Services Office, Inc.with its permission. COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. XTEND ENDORSEMENT FOR CONTRACTORS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART GENERAL DESCRIPTION OF COVERAGE— This endorsement broadens coverage. However, coverage for any injury, damage or medical expenses described in any of the provisions of this endorsement may be excluded or limited by another endorsement to this Coverage Part, and these coverage broadening provisions do not apply to the extent that coverage is excluded or limited by such an endorsement. The following listing is a general coverage description only. Read all the provisions of this endorsement and the rest of your policy carefully to determine rights, duties, and what is and is not covered. A. Who Is An Insured—Unnamed Subsidiaries C. Incidental Medical Malpractice B. Blanket Additional Insured — Governmental D. Blanket Waiver Of Subrogation Entities — Permits Or Authorizations Relating To E. Contractual Liability—Railroads Operations F. Damage To Premises Rented To You PROVISIONS a. An organization other than a partnership, joint A. WHO IS AN INSURED — UNNAMED venture or limited liability company; or SUBSIDIARIES b. A trust; The following is added to SECTION II — WHO IS as indicated in its name or the documents that AN INSURED: govern its structure. Any of your subsidiaries, other than a partnership, B. BLANKET ADDITIONAL INSURED — joint venture or limited liability company, that is GOVERNMENTAL ENTITIES — PERMITS OR not shown as a Named Insured in the AUTHORIZATIONS RELATING TO OPERATIONS Declarations is a Named Insured if: a. You are the sole owner of, or maintain an The following is added to SECTION II — WHO IS ownership interest of more than 50% in, such AN INSURED: subsidiary on the first day of the policy period; Any governmental entity that has issued a permit and or authorization with respect to operations b. Such subsidiary is not an insured under performed by you or on your behalf and that you similar other insurance. are required by any ordinance, law, building code or written contract or agreement to include as an No such subsidiary is an insured for"bodily injury" additional insured on this Coverage Part is an or "property damage" that occurred, or "personal insured, but only with respect to liability for"bodily and advertising injury" caused by an offense injury", "property damage" or "personal and committed: advertising injury" arising out of such operations. a. Before you maintained an ownership interest The insurance provided to such governmental of more than 50% in such subsidiary; or entity does not apply to: b. After the date, if any, during the policy period a. Any "bodily injury', "property damage" or that you no longer maintain an ownership "personal and advertising injury" arising out of interest of more than 50% in such subsidiary. operations performed for the governmental For purposes of Paragraph 1. of Section II —Who entity; or Is An Insured, each such subsidiary will be b. Any "bodily injury" or "property damage" deemed to be designated in the Declarations as: included in the "products-completed operations hazard". CG D3 16 02 19 ©2017 The Travelers Indemnity Company.All rights reserved. Page 1 of 3 Includes copyrighted material of Insurance services Office, Inc.,with its permission. COMMERCIAL GENERAL LIABILITY C. INCIDENTAL MEDICAL MALPRACTICE pharmaceuticals committed by, or with the 1. The following replaces Paragraph b. of the knowledge or consent of, the insured. definition of "occurrence" in the 5. The following is added to the DEFINITIONS DEFINITIONS Section: Section: b. An act or omission committed in providing "Incidental medical services" means: or failing to provide "incidental medical services", first aid or "Good Samaritan a. Medical, surgical, dental, laboratory, x-ray services" to a person, unless you are in or nursing service or treatment, advice or the business or occupation of providing instruction, or the related furnishing of professional health care services. food or beverages; or 2. The following replaces the last paragraph of b. The furnishing or dispensing of drugs or Paragraph 2.a.(1) of SECTION II — WHO IS medical, dental, or surgical supplies or AN INSURED: appliances. Unless you are in the business or occupation 6. The following is added to Paragraph 4.b., of providing professional health care services, Excess Insurance, of SECTION IV — Paragraphs (1)(a), (b), (c) and (d) above do COMMERCIAL GENERAL LIABILITY not apply to "bodily injury" arising out of CONDITIONS: providing or failing to provide: This insurance is excess over any valid and (a) "Incidental medical services" by any of collectible other insurance, whether primary, your "employees" who is a nurse, nurse excess, contingent or on any other basis, that assistant, emergency medical technician is available to any of your "employees" for or paramedic; or "bodily injury" that arises out of providing or (b) First aid or "Good Samaritan services" by failing to provide "incidental medical services" any of your "employees" or "volunteer to any person to the extent not subject to workers", other than an employed or Paragraph 2.a.(1) of Section II — Who Is An volunteer doctor. Any such "employees" Insured. or "volunteer workers" providing or failing D. BLANKET WAIVER OF SUBROGATION to provide first aid or "Good Samaritan services" during their work hours for you The following is added to Paragraph 8., Transfer will be deemed to be acting within the Of Rights Of Recovery Against Others To Us, scope of their employment by you or of SECTION IV — COMMERCIAL GENERAL performing duties related to the conduct LIABILITY CONDITIONS: of your business. If the insured has agreed in a contract or 3. The following replaces the last sentence of agreement to waive that insured's right of Paragraph 5. of SECTION III — LIMITS OF recovery against any person or organization, we INSURANCE: waive our right of recovery against such person or For the purposes of determining the organization, but only for payments we make applicable Each Occurrence Limit, all related because of: acts or omissions committed in providing or a. "Bodily injury" or "property damage" that failing to provide "incidental medical occurs; or services , first aid or "Good Samaritan services" to any one person will be deemed to b. "Personal and advertising injury" caused by be one"occurrence". an offense that is committed; 4. The following exclusion is added to subsequent to the execution of the contract or Paragraph 2., Exclusions, of SECTION I — agreement. COVERAGES — COVERAGE A — BODILY E. CONTRACTUAL LIABILITY—RAILROADS INJURY AND PROPERTY DAMAGE LIABILITY: 1. The following replaces Paragraph c. of the Sale Of Pharmaceuticals definition of "insured contract" in the "Bodily injury" or "property damage" arising DEFINITIONS Section: out of the violation of a penal statute or c. Any easement or license agreement,- ordinance relating to the sale of Page 2 of 3 ©2017 The Travelers Indemnity Company.Al rights reserved. CG D3 16 02 19 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. COMMERCIAL GENERAL LIABILITY 2. Paragraph f.(1) of the definition of "insured a. Any premises while rented to you or contract" in the DEFINITIONS Section is temporarily occupied by you with permission deleted. of the owner; or F. DAMAGE TO PREMISES RENTED TO YOU b. The contents of any premises while such The following replaces the definition of "premises premises is rented to you, if you rent such damage" in the DEFINITIONS Section: premises for a period of seven or fewer Premises damage means property damage"to: consecutive days. CG D3 16 02 19 ©2017 The Travelers Indemnity Company.All rights reserved. Page 3 of 3 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. i COMMERCIAL AUTO THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BUSINESS AUTO EXTENSION ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM GENERAL DESCRIPTION OF COVERAGE — This endorsement broadens coverage. However, coverage for any injury, damage or medical expenses described in any of the provisions of this endorsement may be excluded or limited by another endorsement to the Coverage Part, and these coverage broadening provisions do not apply to the extent that coverage is excluded or limited by such an endorsement. The following listing is a general cover- age description only. Limitations and exclusions may apply to these coverages. Read all the provisions of this en- dorsement and the rest of your policy carefully to determine rights, duties, and what is and is not covered. A. BROAD FORM NAMED INSURED H. HIRED AUTO PHYSICAL DAMAGE — LOSS OF B. BLANKET ADDITIONAL INSURED USE — INCREASED LIMIT C. EMPLOYEE HIRED AUTO I. PHYSICAL DAMAGE — TRANSPORTATION EXPENSES — INCREASED LIMIT D. EMPLOYEES AS INSURED J. PERSONAL PROPERTY E. SUPPLEMENTARY PAYMENTS — INCREASED K. AIRBAGS LIMITS L. NOTICE AND KNOWLEDGE OF ACCIDENT OR F. HIRED AUTO — LIMITED WORLDWIDE COV- LOSS ERAGE — INDEMNITY BASIS M. BLANKET WAIVER OF SUBROGATION G. WAIVER OF DEDUCTIBLE —GLASS N. UNINTENTIONAL ERRORS OR OMISSIONS PROVISIONS A. BROAD FORM NAMED INSURED this insurance applies and only to the extent that The following is added to Paragraph Al., Who Is person or organization qualifies as an "insured" An Insured, of SECTION II — COVERED AUTOS under the Who Is An Insured provision contained �— LIABILITY COVERAGE: in Section II. Any organization you newly acquire or form dur- C. EMPLOYEE HIRED AUTO o= ing the policy period over which you maintain 1. The following is added to Paragraph Al., 50% or more ownership interest and that is not Who Is An Insured, of SECTION II — COV- separately insured for Business Auto Coverage. ERED AUTOS LIABILITY COVERAGE: 0_ Coverage under this provision is afforded only un- An "employee" of yours is an "insured" while til the 180th day after you acquire or form the or- operating an "auto" hired or rented under a �= ganization or the end of the policy period, which- contract or agreement in an "employee's" ever is earlier. name, with your permission, while performing duties related to the conduct of your busi- B. BLANKET ADDITIONAL INSURED ness. The following is added to Paragraph c. in A.1., 2. The following replaces Paragraph b. in B.5., Who Is An Insured, of SECTION II — COVERED Other Insurance, of SECTION IV — BUSI- AUTOS LIABILITY COVERAGE: NESS AUTO CONDITIONS: Any person or organization who is required under b. For Hired Auto Physical Damage Cover- a written contract or agreement between you and age, the following are deemed to be cov- that person or organization, that is signed and ered "autos" you own: executed by you before the "bodily injury" or (1) Any covered "auto" you lease, hire, "property damage" occurs and that is in effect rent or borrow: and during the policy period, to be named as an addi- tional insured is an "insured" for Covered Autos (2) Any covered "auto" hired or rented by Liability Coverage, but only for damages to which your "employee" under a contract in an "employee's" name, with your CA T3 53 0215 Oc,2015 The Travelers Indemnity Company.All rights reserved. Page 1 of 4 Includes copyrighted material of Insurance Services Office, Inc. with its permission. 008337 COMMERCIAL AUTO permission, while performing duties (a) With respect to any claim made or "suit" related to the conduct of your busi- brought outside the United States of ness. America, the territories and possessions However, any "auto" that is leased, hired, of the United States of America, Puerto rented or borrowed with a driver is not a Rico and Canada: covered "auto". (i) You must arrange to defend the "in- D. EMPLOYEES AS INSURED sured" against, and investigate or set- tle any such claim or "suit" and keep The following is added to Paragraph A.1., Who Is us advised of all proceedings and ac- An Insured, of SECTION II — COVERED AUTOS tions. LIABILITY COVERAGE: Any "employee" of yours is an "insured" while us- (ii) Neither you nor any other involved ing a covered "auto" you don't own, hire or borrow "insured" will make any settlement in your business or your personal affairs. without our consent. (iii) We may, at our discretion, participate E. SUPPLEMENTARY PAYMENTS — INCREASED in defending the "insured" against, or LIMITS in the settlement of, any claim or 1. The following replaces Paragraph A.2.a.(2), "suit". of SECTION II — COVERED AUTOS LIABIL- ITY COVERAGE: (iv) We will reimburse the "insured" for sums that the "insured" legally must (2) Up to $3,000 for cost of bail bonds (in- pay as damages because of "bodily cluding bonds for related traffic law viola- injury" or "property damage" to which tions) required because of an "accident" this insurance applies, that the "in- we cover. We do not have to furnish sured" pays with our consent, but these bonds. only up to the limit described in Para- 2. The following replaces Paragraph A.2.a.(4), graph C., Limits Of Insurance, of of SECTION II — COVERED AUTOS LIABIL- SECTION II — COVERED AUTOS ITY COVERAGE: LIABILITY COVERAGE. (4) All reasonable expenses incurred by the (v) We will reimburse the "insured" for "insured" at our request, including actual the reasonable expenses incurred loss of earnings up to $500 a day be- With our consent for your investiga- cause of time off from work. tion of such claims and your defense of the "insured" against any such F. HIRED AUTO — LIMITED WORLDWIDE COV- .'suit", but only up to and included ERAGE —INDEMNITY BASIS within the limit described in Para- The following replaces Subparagraph (5) in Para- graph C., Limits Of Insurance, of graph B.7., Policy Period, Coverage Territory, SECTION II — COVERED AUTOS of SECTION IV — BUSINESS AUTO CONDI- LIABILITY COVERAGE, and not in TIONS: addition to such limit. Our duty to (5) Anywhere in the world, except any country or make such payments ends when we have used up the applicable limit of jurisdiction while any trade sanction, em- insurance in ..payments for damages, bargo, or similar regulation imposed by the settlements or.defense expenses. United States of America applies to and pro- hibits the transaction of business with or (b) This insurance is excess over any valid within such country or jurisdiction, for Cov- and collectible other insurance available ered Autos Liability Coverage for any covered to the "insured" whether primary, excess, "auto" that you lease, hire, rent or borrow contingent or on any other basis. without a driver for a period of 30 days or less (c) This insurance is not a substitute for re- and that is not an "auto" you lease, hire, rent quired or compulsory insurance in any or borrow from any of your "employees", country outside the United States, its ter- partners (if you are a partnership), members ritories and possessions, Puerto Rico and (if you are a limited liability company) or Canada. members of their households. Page 2 of 4 02015 The Travelers Indemnity company.A➢rights reserved. CA T3 53 0.215 Includes copyrighted material of Insurance Services Office, Inc.with its permission. COMMERCIAL AUTO You agree to maintain all required or (2) In or on your covered "auto". compulsory insurance in any such coun- This coverage applies only in the event of a total try up to the minimum limits required by theft of your covered "auto". local law. Your failure to comply with compulsory insurance requirements will No deductibles apply to this Personal Property not invalidate the coverage afforded by coverage. this policy, but we will only be liable to the K AIRBAGS same extent we would have been liable The following is added to Paragraph B.3., Exclu- had you complied with the compulsory in- sions, of SECTION III — PHYSICAL DAMAGE surance requirements. COVERAGE: (d) It is understood that we are not an admit- Exclusion 3.a. does not apply to "loss" to one or ted or authorized insurer outside the more airbags in a covered "auto" you own that in- United States of America, its territories flate due to a cause other than a cause of "loss" and possessions, Puerto Rico and Can- set forth in Paragraphs A.1.b. and A.1.c., but ada. We assume no responsibility for the only: furnishing of certificates of insurance, or a. If that "auto" is a covered "auto" for Compre- for compliance in any way with the laws hensive Coverage under this policy; of other countries relating to insurance. j b. The airbags are not covered under any war- G. WAIVER OF DEDUCTIBLE —GLASS ranty; and The following is added to Paragraph D., Deducti- c. The airbags were not intentionally inflated. ble, of SECTION III — PHYSICAL DAMAGE We will pay up to a maximum of $1,000 for any COVERAGE: one "loss". No deductible for a covered "auto" will apply to L. NOTICE AND KNOWLEDGE OF ACCIDENT OR glass damage if the glass is repaired rather than LOSS replaced. The following is added to Paragraph A.2.a., of H. HIRED AUTO PHYSICAL DAMAGE — LOSS OF SECTION IV —BUSINESS AUTO CONDITIONS: USE — INCREASED LIMIT Your duty to give us or our authorized representa- The following replaces the last sentence of Para- tive prompt notice of the "accident" or "loss" ap- graph A.4.b., Loss Of Use Expenses, of SEC- plies only when the "accident" or "loss" is known TION III —PHYSICAL DAMAGE COVERAGE: to: However, the most we will pay for any expenses (a) You (if you are an individual); �= for loss of use is $65 per day, to a maximum of$750 for any one "accident". (b) A partner (if you are a partnership); (c) A member (if you are a limited liability com- I. PHYSICAL DAMAGE — TRANSPORTATION pany); EXPENSES — INCREASED LIMIT (d) An executive officer, director or insurance The following replaces the first sentence in Para- manager (if you are a corporation or other or- graph A.4.a., Transportation Expenses, of ganization); or SECTION III — PHYSICAL DAMAGE COVER- (e) Any "employee" authorized by you to give no- AGE: tice of the "accident" or "loss". We will pay up to $50 per day to a maximum of M. BLANKET WAIVER OF SUBROGATION $1,500 for temporary transportation expense in- The following replaces Paragraph A.5., Transfer curred by you because of the total theft of a cov- Of Rights Of Recovery Against Others To Us, Bred "auto" of the private passenger type. of SECTION IV — BUSINESS AUTO CONDI- J. PERSONAL PROPERTY TIONS: The following is added to Paragraph A.4., Cover- 5. Transfer Of Rights Of Recovery Against _ age Extensions, of SECTION III — PHYSICAL Others To Us DAMAGE COVERAGE: We waive any right of recovery we may have Personal Property against any person or organization to the ex- We will pay up to $400 for "loss" to wearing ap- tent required of you by a written contract signed and executed prior to any "accident" parel and other personal property which is: or "loss", provided that the "accident" or "loss" (1) Owned by an "insured"; and arises out of operations contemplated by CA T3 53 02 15 ©2015 The Travelers Indemnity Company. All rights reserved. Page 3 of 4 Includes copyrighted material of Insurance Services Office. Inc. with its permission. 008338 COMMERCIAL AUTO such contract. The waiver applies only to the The unintentional omission of, or unintentional person or organization designated in such error in, any information given by you shall not contract. prejudice your rights under this insurance. How- N. UNINTENTIONAL ERRORS OR OMISSIONS ever this provision does not affect our right to col- The following is added to Paragraph B.2., Con- lect additional premium or exercise our right of cealment, Misrepresentation, Or Fraud, of cancellation or non-renewal. SECTION N — BUSINESS AUTO CONDITIONS: I Page 4 of 4 Cc:2015 The Travelers Indemnity company.All rights reserved. CA T3 53 02 15 Includes copyrighted material of Insurance Services Office, Inc. with its permission. COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET ADDITIONAL INSURED (Includes Products-Completed Operations If Required By Contract) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PROVISIONS (1) Any "bodily injury", "property damage" or The following is added to SECTION II —WHO IS AN "personal injury" arising out of the providing, INSURED: or failure to provide, any professional Any person or organization that you agree in a architectural, engineering or surveying written contract or agreement to include as an services, including: additional insured on this Coverage Part is an (a) The preparing, approving, or failing to insured, but only: prepare or approve, maps, shop a. With respect to liability for "bodily injury" or drawings, opinions, reports, surveys, "property damage" that occurs, or for "personal field orders or change orders, or the injury" caused by an offense that is committed, preparing, approving, or failing to subsequent to the signing of that contract or prepare or approve, drawings and agreement and while that part of the contract or specifications; and agreement is in effect; and (b) Supervisory, inspection, architectural or b. If, and only to the extent that, such injury or engineering activities. damage is caused by acts or omissions of you or your subcontractor in the performance of "your (2) Any "bodily injury' or "property damage" work" to which the written contract or agreement caused by "your work" and included in the applies. Such person or organization does not "products-completed operations hazard" qualify as an additional insured with respect to unless the written contract or agreement the independent acts or omissions of such specifically requires you to provide such person or organization. coverage for that additional insured during The insurance provided to such additional insured is the policy period. subject to the following provisions: c. The additional insured must comply with the a. If the Limits of Insurance of this Coverage Part following duties: shown in the Declarations exceed the minimum limits required by the written contract or (1) Give us written notice as soon as practicable agreement, the insurance provided to the of an "occurrence" or an offense which may additional insured will be limited to such result in a claim. To the extent possible, such minimum required limits. For the purposes of notice should include: determining whether this limitation applies, the , (a) How, when and where the "occurrence' minimum limits required by the written contract or or offense took place; agreement will be considered to include the minimum limits of any Umbrella or Excess (b) The names and addresses of any injured liability coverage required for the additional persons and witnesses; and insured by that written contract or agreement. (c) The nature and location of any injury or This provision will not increase the limits of damage arising out of the "occurrence" insurance described in Section III — Limits Of Insurance. or offense. b. The insurance provided to such additional (2) If a claim is made or "suit" is brought against insured does not apply to: the additional insured: CG D2 46 04 19 0 2018 The Travelers Indemnity Company. All rights reserved. Page 1 of 2 COMMERCIAL GENERAL LIABILITY (a) Immediately record the specifics of the (4) Tender the defense and indemnity of any claim or"suit' and the date received; and claim or "suit" to any provider of other (b) Notify us as soon as practicable and see insurance which would cover such additional to it that we receive written notice of the insured for a loss we cover. However, this claim or"suit" as soon as practicable. condition does not affect whether the insurance provided to such additional (3) Immediately send us copies of all legal insured is primary to other insurance papers received in connection with the claim available to such additional insured which or "suit", cooperate with us in the covers that person or organization as a investigation or settlement of the claim or named insured as described in Paragraph 4., defense against the "suit", and otherwise Other Insurance, of Section IV — Commercial comply with all policy conditions. General Liability Conditions. Page 2 of 2 ©2018 The Travelers Indemnity Company. All rights reserved. CG D2 46 04 19 COMMERCIAL GENERAL LIABILITY c. Method Of Sharing a. The statements in the Declarations are If all of the other insurance permits contribution accurate and complete; by equal shares, we will follow this method also. b. Those statements are based upon Under this approach each insurer contributes representations you made to us; and equal amounts until it has paid its applicable c. We have issued this policy in reliance upon limit of insurance or none of the loss remains, your representations. whichever comes first. The unintentional omission of, or unintentional error If any of the other insurance does not permit in, any information provided by you which we relied contribution by equal shares, we will contribute upon in issuing this policy will not prejudice your by limits. Under this method, each insurer's rights under this insurance. However, this provision share is based on the ratio of its applicable limit does not affect our right to collect additional of insurance to the total applicable limits of premium or to exercise our rights of cancellation or insurance of all insurers. nonrenewal in accordance with applicable insurance d. Primary And Non-Contributory Insurance If laws or regulations. Required By Written Contract 7. Separation Of Insureds If you specifically agree in a written contract or Except with respect to the Limits of Insurance, and agreement that the insurance afforded to an any rights or duties specifically assigned in this insured under this Coverage Part must apply on Coverage Part to the first Named Insured, this a primary basis, or a primary and non- insurance applies: contributory basis, this insurance is primary to a. As if each Named Insured were the only other insurance that is available to such insured Named Insured; and which covers such insured as a named insured, and we will not share with that other insurance, b. Separately to each insured against whom claim provided that: is made or"suit" is brought. (1) The"bodily injury' or"property damage"for 8. Transfer Of Rights Of Recovery Against Others which coverage is sought occurs; and To Us (2) The "personal and advertising injury' for If the insured has rights to recover all or part of any which coverage is sought is caused by an payment we have made under this Coverage Part, offense that is committed; those rights are transferred to us. The insured must subsequent to the signing of that contract or do nothing after loss to impair them. At our request, agreement by you. the insured will bring "suit" or transfer those rights to us and help us enforce them. 5. Premium Audit 9. When We Do Not Renew a. We will compute all premiums for this Coverage If we decide not to renew this Coverage Part, we will Partin accordance with our rules and rates. mail or deliver to the first Named Insured shown in b. Premium shown in this Coverage Part as the Declarations written notice of the nonrenewal advance premium is a deposit premium only. At not less than 30 days before the expiration date. the close of each audit period we will compute If notice is mailed, proof of mailing will be sufficient the earned premium for that period and send proof of notice. notice to the first Named Insured. The due date for audit and retrospective premiums is the date SECTION V—DEFINITIONS shown as the due date on the bill. If the sum of 1. "Advertisement" means a notice that is broadcast or the advance and audit premiums paid for the published to the general public or specific market policy period is greater than the earned segments about your goods, products or services premium, we will return the excess to the first for the purpose of attracting customers or Named Insured. supporters. For the purposes of this definition: c. The first Named Insured must keep records of a. Notices that are published include material the information we need for premium placed on the Internet or on similar electronic computation, and send us copies at such times means of communication; and as we may request. b. Regarding websites, only that part of a website 6. Representations that is about your goods, products or services By accepting this policy, you agree: for the purposes of attracting customers or supporters is considered an advertisement. Page 16 of 21 ©2017 The Travelers Indemnity Company.All rights reserved. CG T1 00 02 19 Includes copyrighted material of Insurance Services Office, Inc. with its permission. KENT SPEC I AL PROV I S I ONS TABLE OF CONTENTS PAGE DIVISION 1 GENERAL REQU 1 REMENTS ..................................... 1-1 1 -01 Definitions and Terms...................................................... 1-1 1-02 Bid Procedures and Conditions.......................................... 1-3 1-03 Award and Execution of Contract....................................... 1 -5 1-04 Scope of the Work .......................................................... 1-6 1-05 Control of Work .............................................................. 1-8 1 -06 Control of Material .......................................................... 1-1 1 1 -07 Legal Relations and Responsibilities to the Public................. 1-14 1 -08 Prosecution and Progress ................................................. 1-19 1-09 Measurement and Payment .............................................. 1-23 1-10 Temporary Traffic Control ................................................ 1-25 DIVISION 8 MISCELLANEOUS CONSTRUCTION ......................... 8-1 8-01 Erosion Control and Water Pollution Control ........................ 8-1 8-02 Roadside Restoration....................................................... 8-7 8-30 Project Signs.................................................................. 8-12 DIVISION 9 MATERIALS............................................................ 9-1 9-14 Erosion Control and Roadside Planting ............................... 9-1 TECHN I CAL SPEC I F I CAT I ONS ......................................................... A-1 SITE AND EQUIPMENT PHOTOS ...................................................... A-2 PREVAILING WAGE RATES.............................................................. A-3 PS 3 Electrical System Improvements/Araucto October 10, 2019 Project Number: 17-7999.6 KENT SPECIAL PROVISIONS The Kent Special Provisions ("Kent Special Provisions" or "KSP") modify and supersede any conflicting provisions of the 2018 Standard Specifications for Road, Bridge, and Municipal Construction, as prepared by the Washington State Department of Transportation and the Washington State Chapter of the American Public Works Association, including all published amendments issued by those organizations ("WSDOT Standard Specifications"). Otherwise all provisions of the WSDOT Standard Specifications shall apply. All references in the WSDOT Standard Specifications to the State of Washington, its various departments or directors, or to the contracting agency, shall be revised to include the City and/or City Engineer, except for references to State statutes or regulations. Finally, all of these documents are a part of this contract. DIVISION 1 - GENERAL REQUIREMENTS 1-01 DEFINITIONS AND TERMS SECTION 1-01. 1 IS SUPPLEMENTED BYADDING THE FOLLOWING: 1-01.1 General When these Kent Special Provisions make reference to a "Section," for example, "in accordance with Section 1-01 ," the reference is to the WSDOT Standard Specifications as modified by these Kent Special Provisions. SECTION 1-01.2(2) IS SUPPLEMENTED BY ADDING THE FOLLOWING: 1-01.2(2) Items of Work and Units of Measurement EA Each Eq. Adj. Equitable Adjustment FA Force Account HR Hour M GAL Thousand gallons N I C Not In Contract SF Square Feet SECTION 1-01.3, "CONTRACT"DEFINITION, IS DELETED AND REPLACED WITH THE FOLLOWING: 1-01.3 Definitions Contract The written agreement between the Contracting Agency and the Contractor. It describes, among other things: 1 . What work will be done, and by when; 2. Who provides labor and materials; and PS 3 Electrical System Improvements/Araucto 1 - 1 October 10, 2019 Project Number: 17-7999.6 3. How Contractors will be paid. The Contract includes the Contract (agreement) Form, Bidder's completed Proposal Form, Kent Special Provisions, Contract Provisions, Contract Plans, WSDOT Standard Specifications (also including amendments to the Standard Specifications issued by WSDOT as of the later date of bid advertisement or any subsequent addenda), Kent Standard Plans, Addenda, various certifications and affidavits, supplemental agreements, change orders, and subsurface boring logs (if any). Also incorporated in the Contract by reference are: 1 . Standard Plans (M21-01) for Road, Bridge and Municipal Construction as prepared by the Washington State Department of Transportation and the American Public Works Association, current edition; 2. Manual on Uniform Traffic Control Devices for Streets and Highways, current edition, and; 3. American Water Works Association Standards, current edition; 4. The current edition of the "National Electrical Code." Responsibility for obtaining these publications rests with the Contractor. SECTION 1-01.3, "DEFINITIONS" IS SUPPLEMENTED BY ADDING THE FOLLOWING DEFINITION: Incidental Work The terms "incidental to the project," "incidental to the involved bid item(s)," etc., as used in the Contract shall mean that the Contractor is required to complete the specified work and the cost of such work shall be included in the unit contract prices of other bid items as specified in Section 1-04.1 (Intent of the Contract). No additional payment will be made. "REMOVE", "REMOVAL", "EXCAVATE", "EXCAVATION" Unless otherwise noted, the words "remove", "removal", "excavate" and "excavation" in the contract plans and specifications shall mean that the Contractor is required to haul and dispose of the material at a legal off-site location. The cost for haul and disposal, including disposal and permit fees, shall be included in the unit contract prices of other bid items as specified in Section 1-04.1 . No additional payment will be made. Drawing or Drawings; see definition for Plans. Owner; see definition for Engineer. PS 3 Electrical System Improvements/Araucto 1 - 2 October 10, 2019 Project Number: 17-7999.6 1-02 BID PROCEDURES AND CONDITIONS SECTION 1-02.1 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-02.1 Qualification of Bidders Bidders shall be qualified by ability, experience, financing, equipment, and organization to do the work called for in the Contract. The City reserves the right to take any action it deems necessary to ascertain the ability of the Bidder to perform the work satisfactorily. This action includes the City's review of the qualification information in the bid documents. The City will use this qualification data in its decision to determine whether the lowest responsive bidder is also responsible and able to perform the contract work. If the City determines that the lowest bidder is not the lowest responsive and responsible bidder, the City reserves its unqualified right to reject that bid and award the contract to the next lowest bidder that the City, in its sole judgment, determines is also responsible and able to perform the contract work (the "lowest responsive and responsible bidder"). SECTION 1-02.2 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-02.2 Plans and Specifications Upon awarding the Contract, the City shall supply to the Contractor, for its own use, up to ten (10) copies of the plans and specifications. If the Contractor requests more than ten (10) copies, the City may require the Contractor to purchase the additional sets. SECTION 1-02.5 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-02.5 Proposal Forms Prospective bidders may obtain Bid Documents including a "Bid Proposal" for the advertised project by downloading at no charge at KentWA.gov/doing-business/bids-procurement; however, a prospective bidder remains responsible to obtain Bid Documents, even if unable to download all or any part of the documents, whether or not inability to access is caused by the bidder's or the City's technology. SECTION 1-02.6 IS REVISED BY DELETING THE THIRD PARAGRAPH AND REPLACING WITH THE FOLLOWING: 1-02.6 Preparation of Proposal It is the Bidder's sole responsibility to obtain and incorporate all issued addenda into the bid. In the space provided on the Proposal Signature Page, the Bidder shall confirm that all Addenda have been received. All blanks in the proposal forms must be appropriately filled in. PS 3 Electrical System Improvements/Araucto 1 - 3 October 10, 2019 Project Number: 17-7999.6 SECTION 1-02.6 IS SUPPLEMENTED BY ADDING THE FOLLOWING TO THE LAST PARAGRAPH: Proposals must contain original signature pages. FACSIMILES OR OTHER FORMS OF ELECTRONIC DELIVERY ARE NOT ACCEPTABLE AND ARE CONSIDERED NON-RESPONSIVE SUBMITTALS. SECTION 1-02.7 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-02.7 Bid Deposit A deposit of at least 5 percent of the total Bid shall accompany each Bid. This deposit may be cash, cashier's check, or a proposal bond (Surety bond). Any proposal bond shall be on the City's bond form and shall be signed by the Bidder and the Surety. A proposal bond shall not be conditioned in any way to modify the minimum 5-percent required. The Surety shall: (1) be registered with the Washington State Insurance Commissioner, and (2) appear on the current Authorized Insurance List in the State of Washington published by the Office of the Insurance Commissioner. The failure to furnish a Bid deposit of a minimum of 5 percent with the Bid shall make the Bid nonresponsive and shall cause the Bid to be rejected by the Contracting Agency. SECTION 1-02.9 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-02.9 Delivery of Proposal All bids must be sealed and delivered in accordance with the "Invitation to Bid." Bids must be received at the City Clerk's office by the stated time, regardless of delivery method, including U.S. Mail. SECTION 1-02.10 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-02.1 O Withdrawing, Revising, or Supplementing Proposal After submitting a Bid Proposal to the Contracting Agency, the Bidder may withdraw or revise it if: 1 . The Bidder submits a written request signed by an authorized person, and 2. The Contracting Agency receives the request before the time for opening Bids. The original Bid Proposal may be revised and resubmitted as the official Bids Proposal if the Contracting Agency receives it before the time for opening Bids. PS 3 Electrical System Improvements/Araucto 1 - 4 October 10, 2019 Project Number: 17-7999.6 SECTION 1-02. 11 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-02.11 Combination and Multiple Proposals No person, firm or corporation shall be allowed to make, file, or be interested in more than one bid for the same work unless alternate bids are specifically called for; however, a person, firm, or corporation that has submitted a subproposal to a bidder, or that has quoted prices of materials to a bidder is not disqualified from submitting a subproposal or quoting prices to other bidders or from making a prime proposal. SECTION 1-02. 13 IS REVISED BY DELETING ITEM 1(a) AND REPLACING ITEM 1(a) WITH THE FOLLOWING: 1-02.13 Irregular Proposals a. The bidder is not prequalified when so required. SECTION 1-02. 14 IS REVISED BY DELETING ITEM 3 AND REPLACING WITH THE FOLLOWING: 1-02.14 Disqualification of Bidders 3. The bidder is not qualified for the work or to the full extent of the bid. 1-03 AWARD AND EXECUTION OF CONTRACT SECTION 1-03. 1 IS REVISED BY INSERTING THE FOLLOWING PARAGRAPH AFTER THE SECOND PARAGRAPH IN THAT SECTION: 1-03.1 Consideration of Bids The City also reserves the right to include or omit any or all schedules or alternates of the Proposal and will award the Contract to the lowest responsive, responsible bidder based on the total bid amount, including schedules or alternates selected by the City. SECTION 1-03.2 IS REVISED BY REPLACING "45 CALENDAR DAYS" WITH "60 CALENDAR DAYS"RELATING TO CONTRACT AWARD OR BID REJECTION. 1-03.2 Award of Contract SECTION 1-03.3 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-03.3 Execution of Contract No claim for delay shall be granted to the Contractor due to its failure to submit the required documents to the City in accordance with the schedule provided in these Kent Special Provisions. PS 3 Electrical System Improvements/Araucto 1 5 October 10, 2019 Project Number: 17-7999.6 SECTION 1-03.7 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-03.7 Judicial Review Any decision made by the City regarding the award and execution of the contract or bid rejection shall be conclusive subject to the scope of judicial review permitted under Washington State Law. Such review, if any, shall be timely filed in the King County Superior Court, located in Kent, Washington. 1-04 SCOPE OF THE WORK 1-04.1 Intent of the Contract SECTION 1-04. 1(2) IS DELETED AND REPLACED WITH THE FOLLOWING: 1-04.1 (2) Bid Items Not Included in the Proposal The Contractor shall include all costs of doing the work within the bid item prices. If the contract plans, contract provisions, addenda, or any other part of the contract require work that has no bid item price in the proposal form, the entire cost of labor and materials required to perform that work shall be incidental and included with the bid item prices in the contract. SECTION 1-04.2 IS SUPPLEMENTED BY ADDING THE WORDS, "KENT SPECIAL PROVISIONS, KENT STANDARD PLANS"FOLLOWING THE WORDS, "CONTRACT PROVISIONS" IN THE FIRST SENTENCE OF THE FIRST PARAGRAPH. SECTION 1-04.2 IS REVISED BY DELETING ITEMS 1 THROUGH 7 IN THE SECOND PARAGRAPH AND REPLACING WITH THE FOLLOWING 8 ITEMS: 1-04.2 Coordination of Contract Documents, Plans, Special Provisions, Specifications, and Addenda 1 . Approved Change Orders 2. The Contract Agreement 3. Kent Special Provisions 4. Contract Plans 5. Amendments to WSDOT Standard Specifications 6. WSDOT Standard Specifications 7. Kent Standard Plans 8. WSDOT Standard Plans SECTION 1-04.4 IS REVISED BY DELETING THE THIRD PARAGRAPH (INCLUDING SUBPARAGRAPHS A AND B). 1-04.4 Changes PS 3 Electrical System Improvements/Araucto 1 - 6 October 10, 2019 Project Number: 17-7999.6 SECTION 1-04.4 IS REVISED BY DELETING THE FIFTH PARAGRAPH AND REPLACING IT WITH THE FOLLOWING: For Item 2, increases or decreases in quantity for any bid item shall be paid at the appropriate bid item contract price, including any bid item increase or decrease by more than 25 percent from the original planned quantity. SECTION 1-04.4 IS REVISED BY DELETING THE EIGHTH PARAGRAPH (NEXT TO THE LAST PARAGRAPH) AND REPLACING WITH THE FOLLOWING: Within 14 calendar days of delivery of the change order the Contractor shall endorse and return the change order, request an extension of time for endorsement or respond in accordance with Section 1-04.5. The Contracting Agency may unilaterally process the change order if the Contractor fails to comply with these requirements. Changes normally noted on field stakes or variations from estimated quantities, will not require a written change order. These changes shall be made at the unit prices that apply. The Contractor shall respond immediately to changes shown on field stakes without waiting for further notice. SECTION 1-04.6 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-04.6 Variation in Estimated Quantities Payment to the Contractor will be made only for the actual quantities of Work performed and accepted in conformance with the Contract. SECTION 1-04.9 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-04.9 Use of Private Properties Staging and storage locations needed for the Project must be properly permitted for that use. Limits of construction are indicated or defined on the plans. The Contractor shall confine all construction activities within these limits. If a staging and storage area is shown on the plans, the City will obtain all permits and approvals necessary for the Contractor's use. Whether the City does or does not provide a staging area, if the Contractor selects its own staging and storage area(s), it is the Contractor's sole responsibility to obtain all necessary permits/approvals to use the private property, specifically including, without limitation, all permits or approvals subject to State Environmental Policy Act, Shoreline Management Act, and critical areas regulations. Before using any other property as a staging or storage area (or for any other use), the Contractor shall thoroughly investigate the property for the presence of critical areas, buffers of critical areas, or other regulatory restrictions as defined in Kent City Code, county, state or federal regulations, and the Contractor shall provide the City written documentation that the property is not subject to other PS 3 Electrical System Improvements/Araucto 1 - 7 October 10, 2019 Project Number: 17-7999.6 regulatory requirements or that the Contractor has obtained all necessary rights of entry, permits and approvals needed to use the property as the Contractor intends. Upon vacating the private property, the Contractor shall provide the City written verification that it has obtained all releases and/or performed all mitigation work as required by the conditions of the permit/approval and/or agreement with the property owner. The Contractor shall not be entitled to additional compensation or an extension of the time of completion of the Contractor for any work associated with the permitting, mitigation or use of private property. SECTION 1-04. 11 ITEM 2 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-04.11 Final Cleanup 2. Remove from the project all unapproved and/or unneeded material left from grading, surfacing, paving, or temporary erosion control measures. 1-05 CONTROL OF WORK SECTION 1-05.4 IS REVISED BY DELETING THE LAST FOUR PARAGRAPHS. 1-05.4 Conformity With and Deviations From Plans and Stakes SECTION 1-05.4 IS REVISED BY ADDING THE FOLLOWING PARAGRAPH AFTER PARAGRAPH 7: To the extent a conflict exists between the requirements of WSDOT Section 1-05.4 and Kent Special Provision Section 1-05.5, the requirements of KSP Section 1-05.5 will prevail. 1-05.8 City's Right to Correct Defective and Unauthorized Work If the Contractor fails to remedy defective or unauthorized work within the time specified by the Engineer, or fails to perform any part of the work required by the contract, the Engineer may provide the Contractor written notice establishing a date after which the City will correct and remedy that work by any means that the Engineer may deem necessary, including the use of City forces or other contractors. If the Engineer determines that the Contractor's failure to promptly correct any defective or any unauthorized work creates a situation that could be potentially unsafe or might cause serious risk of loss or damage to the public, the Engineer may have the defective and unauthorized work corrected immediately, have the rejected work removed and replaced, or have the work the Contractor refuses to perform completed by using City or other forces. PS 3 Electrical System Improvements/Araucto 1 - 8 October 10, 2019 Project Number: 17-7999.6 Direct and indirect costs incurred by the City attributable to correcting and remedying defective or unauthorized work, or work the Contractor failed or refused to perform, shall be paid by the Contractor. Payment may be deducted by the Engineer from monies due, or to become due, the Contractor. Direct and indirect costs shall include, without limitation, compensation for additional professional services required, compensation and engineering and inspection services required, and costs for repair and replacement of work of others destroyed or damaged by correction, removal, or replacement of the Contractor's unauthorized work. No increase in contract time or compensation will be allowed because of the delay in the performance of the work attributable to the exercise of the City's rights provided by this section nor shall the exercise of this right diminish the City's right to pursue any other remedy available under law with respect to the Contractor's failure to perform the work as required. SECT/ON 1-05.9 /S SUPPLEMENTED BY ADDING THE FOLLOWING NEW SUBSECTION: 1-05.9 Equipment 1-05.9(1) Operational Testing It is the intent of the City to have at the Physical Completion Date a complete and operable system. Therefore when the work involves the installation of machinery or other mechanical equipment, street lighting, electrical distribution of signal systems, building or other similar work, it may be desirable for the Engineer to have the Contractor operate and test the work for a period of time after final inspection but prior to the Physical Completion Date. Whenever items of work are listed in the contract provisions for operational testing they shall be fully tested under operating conditions for the time period specified to ensure their acceptability prior to the Physical Completion Date. In the event the contract does not specify testing time periods, the default testing time period shall be twenty-one (21) calendar days. During and following the test period, the Contractor shall correct any items of workmanship, materials, or equipment that prove faulty or that are not in first class operating condition. Equipment, electrical controls, meters, or other devices and equipment to be tested during this period shall be tested under the observation of the Engineer, so that the Engineer may determine their suitability for the purpose for which they were installed. The Physical Completion Date cannot be established until testing and corrections have been completed to the satisfaction of the Engineer. The costs for power, gas, labor, material, supplies, and everything else needed to successfully complete operational testing shall be included in PS 3 Electrical System Improvements/Araucto 1 - 9 October 10, 2019 Project Number: 17-7999.6 the various contract bid item prices unless specifically set forth otherwise in the contract. Operational and test periods, when required by the Engineer, shall not affect a manufacturer's guaranties or warranties furnished under the terms of the Contract. SECTION 1-05. 10 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-05.1 O Guarantees In addition to any other warranty or guarantee provided for at law or in the parties' contract, the Contractor shall furnish to the Contracting Agency any guarantee or warranty furnished as a customary trade practice in connection with the purchase of any equipment, materials, or items incorporated into the project. Upon receipt of written notice of any required corrective work, the Contractor shall pursue vigorously, diligently, and without disrupting city facilities, the work necessary to correct the items listed in the notice. Approximately sixty (60) calendar days prior to the one year anniversary of final acceptance, the Contractor shall be available to tour the project, with the Engineer, in support of the Engineer's effort to establish a list of corrective work then known and discovered. SECTION 1-05. 13 IS REVISED BY INSERTING THE FOLLOWING PARAGRAPH AFTER THE FIRST PARAGRAPH: 1-05.13 Superintendents, Labor, and Equipment of Contractor Within ten (10) days of contract award, the Contractor shall designate the Contractor's project manager and superintendent for the contract work. SECTION 1-05. 13 IS REVISED BY INSERTING THE FOLLOWING PARAGRAPH AFTER THE THIRD PARAGRAPH (AS PRINTED IN THE 2018 WSDOT STANDARD SPECIFICATIONS): If at any time during the contract work, the Contractor elects to replace the contract manager or superintendent, the Contractor shall only do so after obtaining the Engineer's prior written approval. THE LAST PARAGRAPH OF 1-05.13 IS DELETED AND REPLACED WITH THE FOLLOWING: Whenever the City evaluates the Contractor's qualifications or prequalifications pursuant to Section 1-02.1 or RCW 47.28.070, the City may take these or other Contractor performance reports into account. PS 3 Electrical System Improvements/Araucto 1 - 10 October 10, 2019 Project Number: 17-7999.6 SECTION 1-05. 14 IS SUPPLEMENTED BY ADDING THE FOLLOWING: 1-05.14 Cooperation With Other Contractors Details of known projects are as follows: N/A SECTION 1-05 IS SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECTIONS: 1-05.16 Water and Power The Contractor shall make necessary arrangements, and shall bear the costs for power and water necessary for the performance of the work, unless the Contract includes power or water as bid items, or unless otherwise provided for in other bid items. 1-05.17 Oral Agreements No oral agreement or conversation with any officer, agent, or employee of the City, either before or after execution of the contract, shall affect or modify the terms or obligations contained in any of the documents comprising the contract. Such oral agreement or conversation shall be considered unofficial information and in no way binding upon the City, unless subsequently recorded and/or put in writing and signed by an authorized agent of the City. 1-06 CONTROL OF MATERIAL 1-06.2 Acceptance of Materials SECTION 1-06.2(2) IS DELETED IN ITS ENTIRETY. 1-06.2(2) Statistical Evaluation of Materials for Acceptance SECTION 1-06 IS SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECTIONS: 1-06.7 Submittals 1-06.7(1) Submittal Procedures All information submitted by the Contractor shall be clear, sharp, high contrast copies. Contractor shall accompany each submittal with a letter of transmittal containing the following information: 1 . Contractor's name and the name of Subcontractor or supplier who prepared the submittal. 2. The project name and identifying number. 3. Each new submittal shall be sequentially numbered (1 , 2, 3, etc.). Each resubmittal shall include the original number with a sequential alpha letter added (1 A, 1B, 1C, etc.). PS 3 Electrical System Improvements/Araucto 1 - 11 October 10, 2019 Project Number: 17-7999.6 4. Description of the submittal and reference to the Contract requirement or technical specification section and paragraph number being addressed. 5. Bid item(s) where product will be used. 1-06.7(2) Schedule of Submittals The Contractor shall create and submit three (3) copies of a schedule of submittals showing the date by which each submittal required for product review or product information will be made. The schedule can be modified, deducted, or added to by the City. The schedule shall be available at the preconstruction conference (see 1-08.0 of the Kent Special Provisions). The schedule of submittals must be accepted prior to the City making the first progress payment. The schedule shall identify the items that will be included in each submittal by listing the item or group of items and the Specification Section and paragraph number and bid item under which they are specified. The schedule shall indicate whether the submittal is required for product review of proposed equivalents, shop drawings, product data or samples or required for product information only. The Contractor shall allow a minimum of 21 days for the Engineer's review of each submittal or resubmittal. All submittals shall be in accordance with the approved schedule of submittals. Submittals shall be made early enough to allow adequate time for manufacturing, delivery, labor issues, additional review due to inadequate or incomplete submittals, and any other reasonably foreseeable delay. 1-06.7(3) Shop Drawings, Product Data, and Samples The Contractor shall submit the following for the Engineer's review: 1 . Shop Drawings: Submit an electronic copy or three paper copies. Submittals will be marked, stamped and returned to the Contractor. The Contractor shall make and distribute any required copies for its superintendent, subcontractors and suppliers. 2. Product Data: Submit an electronic copy or three paper copies. Submittals will be marked, stamped and returned to the Contractor. The Contractor shall make and distribute any required copies for its superintendent, subcontractors and suppliers. 3. Samples: Submit three labeled samples or three sets of samples of manufacturer's full range of colors and finishes unless otherwise directed. One approved sample will be returned to the Contractor. Content of submittals: 1 . Each submittal shall include all of the items required for a complete assembly or system. 2. Submittals shall contain all of the physical, technical and performance data required to demonstrate conclusively that the items comply with the requirements of the Contract. PS 3 Electrical System Improvements/Araucto 1 - 12 October 10, 2019 Project Number: 17-7999.6 3. Each submittal shall verify that the physical characteristics of items submitted, including size, configurations, clearances, mounting points, utility connection points and service access points, are suitable for the space provided and are compatible with other interrelated items. 4. The Contractor shall label each Product Data submittal, Shop Drawing or Sample with the bid item number and, if a lump sum bid item, provide a reference to the applicable KSP paragraph. The Contractor shall highlight or mark every page of every copy of all Product Data submittals to show the specific items being submitted and all options included or choices offered. The City encourages a creative approach to complete a timely, economical, and quality project. Submittals that contain deviations from the requirements of the Contract shall be accompanied by a separate letter explaining the deviations. The Contractor's letter shall: 1 . Cite the specific Contract requirement including the Specification Section bid item number and paragraph number for which approval of a deviation is sought. 2. Describe the proposed alternate material, item or construction, explain its advantages, and explain how the proposed alternate meets or exceeds the Contract requirements. 3. State the reduction in Contract Price, if any, which is offered to the City. The Engineer retains the exclusive right, at his or her sole discretion, to accept or reject any proposed deviation with or without cause. The Engineer will stamp and mark each submittal prior to returning it to the Contractor. The stamps will indicate one of the following: 1 . "APPROVED AS SUBMITTED" — Accepted subject to its compatibility with the work not covered in this submission. This response does not constitute approval or deletion of specified or required items not shown in the partial submission. 2. "APPROVED AS NOTED" — Accepted subject to minor corrections that shall be made by the Contractor and subject to its compatibility with the work not covered in this submission. This response does not constitute approval or deletion of specified or required items not shown in the partial submission. No resubmission is required. 3. "AMEND AND RESUBMIT" — Rejected because of major inconsistencies, errors or insufficient information that shall be resolved or corrected by the Contractor prior to subsequent re- submittal. An amended resubmission is required. Re-submittals that contain changes that were not requested by the Engineer on the previous submittal shall note all changes and be accompanied by a letter explaining the changes. PS 3 Electrical System Improvements/Araucto 1 - 13 October 10, 2019 Project Number: 17-7999.6 1-06.7(4) Proposed Equivalents The Engineer retains the exclusive right, at his or her sole discretion, to accept or reject any proposed equivalent with or without cause. 1-07 LEGAL RELATIONS AND RESPONSIBILITIES TO THE PUBLIC 1-07.2 State Taxes SECTION 1-07.2(1) IS REVISED BY DELETING THE SECOND PARAGRAPH AND REPLACING WITH THE FOLLOWING: 1-07.2(1) State Sales Tax: WAC 458-20-171—Use Tax Without waiving the Contractor's obligation to understand and apply these tax rules correctly, the City has indicated those parts of the project that are subject to use tax under Section 1 -07.2(1) in the proposal bid items. SECTION 1-07.2(2) IS REVISED BY DELETING THE SECOND PARAGRAPH AND REPLACING WITH THE FOLLOWING: 1-07.2(2) State Sales Tax: WAC 458-20-170—Retail Sales Tax Without waiving the Contractor's obligation to understand and apply these tax rules correctly, the City has indicated those parts of the project that are subject to retail sales tax under Section 1 -07.2(2) in the proposal bid items. SECTION 1-07.6 IS SUPPLEMENTED BY INSERTING THE FOLLOWING PARAGRAPH BEFORE THE FIRST PARAGRAPH: 1-07.6 Permits and Licenses The City has obtained the following permits: N/A SECTION 1-07.6 IS SUPPLEMENTED BY INSERTING THE FOLLOWING PARAGRAPHS AFTER THE LAST PARAGRAPH: A copy of each permit and/or license obtained by the Contractor shall be furnished to the City. Approved permits shall be furnished to the City upon completion of the project and prior to final acceptance. The Contractor shall promptly notify the City in writing of any variance in the contract work arising from the issuance of any permit. 1-07.9 Wages SECTION 1-07.9(1) IS SUPPLEMENTED BY INSERTING THE FOLLOWING PARAGRAPH AFTER THE SIXTH PARAGRAPH: PS 3 Electrical System Improvements/Araucto 1 - 14 October 10, 2019 Project Number: 17-7999.6 1-07.9(1) General To the extent allowed by law, the wage rates that will be in effect during the entire contract work period are those in effect on the day of bid opening, unless the City does not award the Contract within six months of the bid opening. SECTION 1-07.9(3) IS DELETED AND REPLACED WITH THE FOLLOWING: FOLLOWING: 1-07.9(3) Apprentices All contracts with an estimated construction cost greater than $1 ,000,000 (one million dollars) shall require that no less than 15 percent of the labor hours performed by workers subject to prevailing wages employed by the contractor or its subcontractors be performed by apprentices enrolled in a state-approved apprenticeship program. Definitions For the purposes of this specification, the following definitions apply: 1 . Apprentice Utilization Requirement is expressed as a percentage of the project Labor Hours performed by Apprentices. 2. Labor Hours are the total hours performed by all workers receiving an hourly wage who are directly employed on the project site including hours performed by workers employed by the prime Contractor and all Subcontractors. Labor Hours do not include hours performed by foremen, superintendents, owners, and workers who are not subject to prevailing wage requirements. 3. Apprentice is a person enrolled in a State-approved Apprenticeship Training Program. 4. State-approved Apprenticeship Training Program is an apprenticeship training program approved by the Washington State Apprenticeship Council. 5. Good Faith Effort is a demonstration that the Contractor has strived to meet the Apprenticeship Utilization Requirement including but not necessarily limited to the specific steps as described elsewhere in this specification. Plan The Contractor shall submit an "Apprentice Utilization Plan" within 30 calendar days of Notice of Award, demonstrating how they intend to achieve the Apprentice Utilization Requirement. The plan shall be updated and resubmitted as appropriate as the Work progresses. The intent is to provide the City with enough information to track progress in meeting the utilization requirements. Reporting The Contractor shall submit a "Monthly Apprentice Reporting Form" on a monthly basis. The report shall be submitted to the City by the last working day of the subsequent month, until the Physical Completion Date. The date reported shall be cumulative to date and consolidated to PS 3 Electrical System Improvements/Araucto 1 - 15 October 10, 2019 Project Number: 17-7999.6 include the Contractor and all Subcontractors. At the Contractor's request, the Engineer may suspend this reporting requirement during periods of minimal or no applicable work activities on the project. The Contractor shall submit documentation of their Good Faith Effort if: (1) they are unable to provide a plan demonstrating how they intend to meet the Apprentice Utilization Requirement; or (2) the project has been completed without meeting the Apprentice Utilization Requirement. Contacts The Contractor may obtain information on State-approved Apprenticeship Training Programs by contacting the Department of Labor and Industries at: Specialty Compliance Services Division, Apprenticeship Section, P.O. Box 44530, Olympia, WA 98504-4530 or by phone at (360) 902-5320. Compliance In the event that the Contractor is unable to accomplish the Apprentice Utilization Requirement, the Contractor shall demonstrate that a Good Faith Effort has been made as described within this specification. Failure to comply with the requirements as specified is subject to penalties for noncompliance as set forth in KCC 6.01 .030(E). Good Faith Efforts In fulfilling the Good Faith Effort, the Contractor shall perform and, when appropriate, require its Subcontractors to perform the following steps: 1 . Solicit Apprentice(s) from State-approved Apprenticeship Training Program(s). 2. Document the solicitation and, in the event Apprentice(s) are not available, obtain supporting documentation from the solicited program(s). 3. Demonstrate that the plan was updated as required within this specification. 4. Provide documentation demonstrating what efforts the Contractor has taken to require Subcontractors to solicit and employ Apprentice(s). In the event that the preceding steps have been followed, the Contractor may also supplement the Good Faith Efforts documentation with the following documentation: 5. Submit documentation demonstrating successful Apprentice utilization on previous contracts. 6. Submit documentation indicating company-wide Apprentice utilization efforts and percentages of attainment. Payment Compensation for all costs involved with complying with the conditions of this specification is included in payment for the associated Contract items of work. PS 3 Electrical System Improvements/Araucto 1 - 16 October 10, 2019 Project Number: 17-7999.6 1-07.13 Contractor's Responsibility for Work SECTION 1-07. 13(4) IS REVISED BY DELETING THE SECOND SENTENCE OF THE FIRST PARAGRAPH AND DELETING THE LAST PARAGRAPH. 1-07.13(4) Repair of Damage SECTION 1-07. 14 IS REVISED BY ADDING THE FOLLOWING TO THE BEGINNING OF THAT SECTION: 1-07.14 Responsibility for Damage To the extent a conflict exists between the terms of this Section 1-07.14 and Section 5 of the Contract, the terms of the Contract will control. Any reference to the State, Governor, Commission, Secretary, or all officers and employees of the State also will include the City, its officers and employees. 1-07.15 Temporary Water Pollution Prevention SECTION 1-07. 15(1) IS REVISED BY ADDING THE FOLLOWING PARAGRAPH AFTER THE LAST PARAGRAPH: 1-07.15(1) Spill Prevention, Control, and Countermeasures Plan When the proposal form includes multiple bid schedules and the "SPCC Plan" bid item is present in only one bid schedule, the lump sum payment item for the "SPCC Plan" in that one schedule will apply to all bid schedules for all costs associated with creating and updating the accepted SPCC Plan, and all costs associated with the setup of prevention measures and for implementing the current SPCC Plan as required by this Specifications. SECTION 1-07. 17 IS REVISED BY ADDING THE FOLLOWING SENTENCE TO THE END OF THE SECOND PARAGRAPH: 1-07.17 Utilities and Similar Facilities If a utility is known to have or suspected of having underground facilities within the area of the proposed excavation and that utility is not a subscriber to the utilities underground location center, the Contractor shall give individual notice to that utility within the same time frame prescribed in RCW 19.122.030 for subscriber utilities. SECTION 1-07. 17 IS SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECTIONS: 1-07.17(3) Utility Markings Once underground utilities are marked by the utility owner or its agent, and/or once new underground facilities have been installed by the PS 3 Electrical System Improvements/Araucto 1 - 17 October 10, 2019 Project Number: 17-7999.6 Contractor, the Contractor/excavator is responsible to determine the precise location of underground facilities that may conflict with other underground construction. The Contractor shall maintain the marks or a record of the location of buried facilities for the duration of time needed to avoid future damage until installation of all planned improvements at that location is complete. 1-07.17(4) Payment All costs to comply with subsection 1-07.17(3) and for the protection and repair of all identified or suspected underground utilities specified in RCW 19.122 are incidental to the contract and are the responsibility of the Contractor/excavator. The Contractor shall include all related costs in the unit bid prices of the contract. No additional time or monetary compensation shall be made for delays caused by utility re- marking or repair of damaged utilities due to the Contractor's failure to maintain marks or to locate utilities in accordance with this section. 1-07.17(5) Notification of Excavation Within ten business days but not less than two business days prior to the commencement of excavation, the Contractor shall provide written notice (or other form of notice acceptable to the Engineer) to all owners of underground facilities, whether public or private, that excavation will occur, and when excavation will occur. 1-07.17(6) Site I nspection Contractor warrants and represents that it has personally, or through its employees, agents and/or subcontractors, examined all property affected by this project and that it is knowledgeable of specific locations for water, gas, telephone, electric power and combined sewerage utilities within those areas. The following list of contacts is provided only as a convenience to the Contractor. It may not be accurate and may not constitute a complete list of all affected utilities. CenturyLink Comcast Gabrielle Skorupa Jerry Steele 206-305-4395 253-288-7532 206-391-1763 (cell) Puget Sound Energy Gas Puget Sound Energy Power Glenn Helton Hong Nguyen 253-395-6926 425-449-6609 (cell) 425-559-4647 (cell) Verizon Scott Christenson 425-636-6046 425-471-1079 (cell) PS 3 Electrical System Improvements/Araucto 1 - 18 October 10, 2019 Project Number: 17-7999.6 SECTION 1-07. 18 IS REVISED BY ADDING THE FOLLOWING PARAGRAPH BEFORE THE FIRST PARAGRAPH. 1-07.18 Public Liability and Property Damage Insurance To the extent a conflict exists between the terms of this Section 1-07.18 and the insurance requirements in Section 7 of the Contract, the terms of the Contract will control. Any reference to the State, Governor, Commission, Secretary, or all officers and employees of the State also will include the City, its officers and employees. SECTION 1-07.24 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-07.24 Rights of Way Street right of way lines, limits of easements and limits of construction are indicated or defined on the plans. The Contractor's construction activities shall be confined within these limits, unless arrangements for use of private property are made. It is anticipated that the City will have obtained all right of way, easements or right of entry agreements prior to the start of construction. Locations where these rights have not been obtained will be brought to the Contractor's attention prior to start of construction. The Contractor shall not proceed with any portion of the work in areas where right of way, easements or rights of entry have not been acquired until the Engineer certifies to the Contractor that the right of way or easement is available or that the right of entry has been received. SECTION 1-07.26 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-07.26 Personal Liability of Public Officers Neither the City, the Engineer, nor any other official, officer or employee of the City shall be personally liable for any acts or failure to act in connection with the contract, it being understood that, in these matters, they are acting solely as agents of the City. 1-08 PROSECUTION AND PROGRESS SECTION 1-08 IS SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECTION: 1-08.0 Preconstruction and Preconstruction Conference The Engineer will furnish the Contractor with up to ten (10) copies of the plans and specifications. Additional documents may be purchased from the City at the price specified by the City or in the Invitation to Bid. Prior to undertaking each part of the work, the Contractor shall PS 3 Electrical System Improvements/Araucto 1 - 19 October 10, 2019 Project Number: 17-7999.6 carefully study and compare the Contract and check and verify all pertinent figures shown and all applicable field measurements. The Contractor shall promptly report in writing to the Engineer any conflict, error or discrepancy that the Contractor discovers. After the Contract has been executed, but prior to the Contractor beginning the work, a preconstruction conference will be held with the Contractor, the Engineer and any other interested parties that the City determines to invite. The purpose of the preconstruction conference will be: 1 . To review the initial progress schedule. 2. To establish a working understanding among the various parties associated or affected by the work. 3. To establish and review procedures for progress payment, notifications, approvals, submittals, etc. 4. To verify normal working hours for the work. 5. To review safety standards and traffic control. 6. To discuss any other related items that may be pertinent to the work. The Contractor shall prepare and submit for approval, at or prior to the preconstruction conference the following: 1 . A price breakdown of all lump sum items. 2. A preliminary construction schedule. 3. A list of material sources for approval, if applicable. 4. Schedule of submittals. (See 1-06.6(2)) 5. Temporary Erosion/Sedimentation Control Plan (TESCP) for approval. 6. Traffic Control Plan (TCP) for approval. 7. Request to sublet, for approval by the Engineer, of all subcontractors. SECTION 1-08.4 IS DELETED AND REPLACED WITH THE FOLLOWING; 1-08.4 Notice to Proceed, Prosecution and Hours of Work Notice to Proceed will be given after the contract has been executed and the contract bond and evidence of required insurance have been approved by and filed with the City. Unless otherwise approved in writing by the Engineer, the Contractor shall not commence the work until the Notice to Proceed has been given by the Engineer. The Contractor shall commence construction activities on the Project Site within ten working days of the Notice to Proceed Date. The Work thereafter shall be prosecuted diligently, vigorously, and without unauthorized interruption until physical completion of the work. Voluntary shutdown or slowing of operations by the Contractor shall not relieve the Contractor of the responsibility to complete the work within the time(s) specified in the Contract. PS 3 Electrical System Improvements/Araucto 1 - 20 October 10, 2019 Project Number: 17-7999.6 Except in the case of emergency or unless otherwise approved by the Engineer, the normal straight time working hours for the Contractor shall be any consecutive 8 hour period between 7:00 a.m. and 6:00 p.m. Monday through Friday, unless otherwise specified in the Kent Special Provisions, with a 5-day work week, plus allowing a maximum one-hour lunch break in each working day. The normal straight time 8-hour working period for the contract shall be established at the preconstruction conference or prior to the Contractor commencing work. If a Contractor desires to perform work on holidays, Saturdays, Sundays, or before 7:00 a.m. or after 6:00 p.m. on any day, the Contractor shall apply in writing to the Engineer for permission to work those times. The Contractor shall notify the Engineer at least 48 hours in advance (72 hours in advance for weekend work) so that the Inspector's time may be scheduled. Permission to work longer than an 8-hour period between 7:00 a.m. and 6:00 p.m. is not required. For any work outside of normal straight time working hours that requires city surveyors, all reasonable efforts shall be made by the Contractor to allow time for surveying to be completed during normal straight time hours. If city surveyors are required to work other than normal straight time hours at the convenience of the Contractor, all such work shall be reimbursed by the Contractor. Permission to work between the hours of 10:00 p.m. and 7:00 a.m. during weekdays and between the hours of 10:00 p.m. and 9:00 a.m. on weekends or holidays may also be subject to noise control requirements. Approval to continue work during these hours may be revoked at any time the Contractor exceeds the City's noise control regulations or the city receives complaints from the public or adjoining property owners regarding noise from the Contractor's operations. The Contractor shall have no claim for damages or delays should this permission be revoked for these reasons. The Engineer may grant permission to work Saturdays, Sundays, holidays or other than the agreed upon normal straight time working hours, but may be subject to other conditions established by the City or Engineer. These conditions may include, but are not limited to the following: hours worked by City employees; impacts to the construction schedule; or accommodations to adjoining properties affected by the contract work. 1-08.4(A) Reimbursement for Overtime Work of City Employees Following is a non-exclusive list of work that may require Contractor reimbursement for overtime of City employees. The City will bill the Contractor at the OVERTIME RATE in order for locate crews to complete other work. If the locate request is for nights, weekend, holidays or at other times when locate crews are not normally working, all locate work and expenses, including travel, minimum call out times, and/or Holiday premiums will be borne by the Contractor. PS 3 Electrical System Improvements/Araucto 1 - 21 October 10, 2019 Project Number: 17-7999.6 1 . Locate work required to re-establish marks for City-owned underground facilities that were not maintained or recorded by the Contractor in accordance with RCW 19.122.030. 2. Work required by city survey crew(s) as the result of reestablishing survey stakes or markings that were not maintained or recorded by the Contractor or other work deemed to be for the convenience of the Contractor and not required of the City by the contract. 3. Work required by City personnel or independent testing laboratories to re-test project materials, utility pressure or vacuum tests, camera surveys or water purity tests as the result of initial test failure on the part of the Contractor. 1-08.4(B) General The City allocates its resources to a contract based on the total time allowed in the contract. The City will accept a progress schedule indicating an early physical completion date but cannot guarantee the City resources will be available to meet the accelerated schedule. No additional compensation will be allowed if the Contractor is not able to meet its accelerated schedule due to the unavailability of City resources or for other reasons beyond the City's control. Unless previously approved by the Engineer, the original and all supplemental progress schedules shall not conflict with any time and order-of-work requirements in the contract. If the Engineer deems that the original or any necessary supplemental progress schedule does not provide adequate information, the City may withhold progress payments until a schedule containing needed information has been submitted by the Contractor and approved by the Engineer. The Engineer's acceptance of any schedule shall not transfer any of the Contractor's responsibilities to the City. The Contractor alone shall remain responsible for adjusting forces, equipment, and work schedules to ensure completion of the work within the times specified in the contract. SECTION 1-08.5 IS REVISED BY DELETING THE THIRD PARAGRAPH AND REPLACING WITH THE FOLLOWING: 1-08.5 Time for Completion Contract time shall begin on the day of the Notice to Proceed. The Contract Provisions may specify another starting date for Contract time, in which case, time will begin on the starting date specified. SECTION 1-08.6 IS REVISED BY DELETING THE FIFTH, SIXTH, AND SEVENTH PARAGRAPHS AND REPLACING WITH THE FOLLOWING: 1-08.6 Suspension of Work PS 3 Electrical System Improvements/Araucto 1 - 22 October 10, 2019 Project Number: 17-7999.6 If the performance of all or any part of the Work is suspended for an unreasonable period of time by an act of the Contracting Agency in the administration of the Contract, or by failure to act within the time specified in the Contract (or if no time is specified, within a reasonable time), the Engineer will make an adjustment for any increase in the cost or time for the performance of the Contract (excluding profit) necessarily caused by the suspension. However, no adjustment will be made for any suspension if (1) the performance would have been suspended by any other cause, including the fault or negligence of the Contractor, or (2) an equitable adjustment is provided for or excluded under any other provision of the Contract. If the Contactor believes that the performance of the Work is suspended for an unreasonable period of time and such suspension is the responsibility of the Contracting Agency, the Contractor shall immediately submit a written notice of protest to the Engineer as provided in Section 1-04.5. No adjustment shall be allowed for any costs incurred more than 10 calendar days before the date the Engineer receives the Contractor's written notice to protest. In any event, no protest will be allowed later than the date of the Contractor's signature on the Final Pay Estimate. The Contractor shall keep full and complete records of the costs and additional time of such suspension, and shall permit the Engineer to have access to those records and any other records as may be deemed necessary by the Engineer to assist in evaluating the protest. The Engineer will determine if an equitable adjustment in cost or time is due as provided in this Section. The equitable adjustment for increase in costs, if due, shall be subject to the limitations provided in Section 1-09.4, provided that no profit of any kind will be allowed on any increase in cost necessarily caused by the suspension. SECTION 1-08.7 MAINTENANCE DURING SUSPENSION IS REVISED BY DELETING THE FOURTH AND SIXTH PARAGRAPHS. 1-09 MEASUREMENT AND PAYMENT 1-09.9 Payments SECTION 1-09.9 IS SUPPLEMENTED BYADDING THE FOLLOWING NEW SECTION; 1-09.9(2) City's Right to Withhold Certain Amounts In addition to the amount that the City may otherwise retain under the Contract, the City may withhold a sufficient amount of any payments otherwise due to the Contractor, including nullifying the whole or part of any previous payment, because of subsequently discovered evidence or subsequent inspections that, in the City's judgment, may be necessary to cover the following: 1 . The cost of defective work not remedied. PS 3 Electrical System Improvements/Araucto 1 - 23 October 10, 2019 Project Number: 17-7999.6 2. Fees incurred for material inspection, and overtime engineering and inspection for which the Contractor is obligated under this Contract. 3. Fees and charges of public authorities or municipalities. 4. Liquidated damages. 5. Engineering and inspection fees beyond Completion Date. 6. Cost of City personnel to re-establish locate marks for City-owned facilities that were not maintained by the Contractor in accordance with RCW 19.122.030 (3). 7. Additional inspection, testing and lab fees for re-doing failed, water, other utility tests. 1-09.11 Disputes and Claims SECTION 1-09. 11(3) IS DELETED AND REPLACED WITH THE FOLLOWING: 1-09.11 (3) Time Limitations and Jurisdiction This contract shall be construed and interpreted in accordance with the laws of the State of Washington. The venue of any claims or causes of action arising from this contract shall be exclusively in the Superior Court of King County, located in Kent, Washington. For convenience of the parties to this contract, it is mutually agreed that any claims or causes of action which the Contractor has against the City arising from this contract shall be brought within 180 days from the date of Final Acceptance of the contract by the City. The parties understand and agree that the Contractor's failure to bring suit within the time period provided shall be a complete bar to any such claims or causes of action. It is further mutually agreed by the parties that when any claims or causes of action that a Contractor asserts against the City arising from this contract are filed with the City or initiated in court, the Contractor shall permit the City to have timely access to any records deemed necessary by the City to assist in evaluating the claims or actions. SECTION 1-09. 13 IS DELETED AND REPLACED WITH THE FOLLOWING: 1-09.13 Final Decision and Appeal All disputes arising under this contract shall proceed pursuant to Section 1-04.5 and 1-09.11 of the WSDOT Standard Specifications and any Kent Special Provisions provided for in the contract for claims and resolution of disputes. The provisions of these sections and the Kent Special Provisions must be complied with as a condition precedent to the Contractor's right to seek an appeal of the City's decision. The City's decision under Section 1-09.11 will be final and conclusive. Thereafter, the exclusive means of Contractor's right to appeal shall only be by filing suit exclusively under the venue, rules and jurisdiction of the Superior Court of King County, located in Kent, Washington, PS 3 Electrical System Improvements/Araucto 1 - 24 October 10, 2019 Project Number: 17-7999.6 unless the parties agree in writing to an alternative dispute resolution process. 1-1 O TEMPORARY TRAFF I C CONTROL 1-10.2 Traffic Control Management SECT/ON 1-10.2(1) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 1-10.2(1) General The TCS shall be certified as a work site traffic control supervisor by one of the following: Evergreen Safety Council 401 Pontius Avenue North Seattle, WA 98109 1-800-521-0778 or 206-382-4090 The Northwest Laborers-Employers Training Trust 27055 Ohio Avenue Kingston, WA 98346 360-297-3035 The American Traffic Safety Services Association 15 Riverside Parkway, Suite 100 Fredericksburg, VA 22406-1022 Training Dept. Toll Free (877) 642-4637 or (540) 368-1701 SECT/ON 1-10.5 /S DELETED AND REPLACED WITH THE FOLLOWING: 1-10.5 Payment No additional payment will be made to the Contractor for traffic control items required in connection with the movement of equipment or the hauling of materials outside of the reservoir site property. This cost shall be considered incidental to the various items on the project. PS 3 Electrical System Improvements/Araucto 1 - 25 October 10, 2019 Project Number: 17-7999.6 DIVISION 8 - MISCELLANEOUS CONSTRUCTION 8-01 EROSION CONTROL AND WATER POLLUTION CONTROL SECT/ON 8-01.1 /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-01.1 Description This work consists of temporary erosion and sedimentation control procedures (TESCP) as shown on the construction plans, specified in these Kent Special Provisions, and ordered by the Engineer as work proceeds. The TESCP are intended to minimize erosion and sedimentation as well as protect waters of the state and the city's municipal separate storm sewer system (MS4) as required by law. SECT/ON 8-01.2 /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-01.2 Materials Materials shall meet the requirements of the following sections of the Kent Special Provisions and the WSDOT Standard Specifications: Seed ....................................8-01 .3(2)B and 9-14.2 Fertilizer ...............................8-01 .3(2)B and 9-14.3 Mulch and Amendments ..........8-01 .3(2)D and 9-14.4 Tackifier ...............................8-01 .3(2)E and 9-14.4(7) 8-01.3 Construction Requirements SECT/ON 8-01.3(1) /S SUPPLEMENTED BYADD/NG THE FOLLOWING: 8-01.3(1) General Preventing and controlling pollution, erosion, runoff, and related damage requires the Contractor to install temporary stormwater best management practices (BMPs) as per the plans and as directed by the City. As site conditions dictate, additional BMPs may be required. The Contractor shall anticipate the need for additional best management practices and propose necessary changes to the City. Should the Contractor fail to install the required temporary erosion and sediment control (TESC) measures or to perform maintenance in a timely manner, or fail to take immediate action to install additional approved measures, all fines, cost of cleanup, costs for delays and down time shall be borne by the Contractor. All cost for this work shall be paid for under the unit contract bid prices. The upgrading of the TESCP facilities shall not constitute a basis for additional working days for this project. PS 3 Electrical System Improvements/Araucto 8 - 1 October 10, 2019 Project Number: 17-7999.6 The Contractor shall provide the Engineer a minimum of two working days notice prior to clearing adjacent to any wetland, creek or other sensitive area. During the construction period, no disturbance beyond the flagged clearing limits shall be permitted. The flagging shall be maintained by the Contractor for the duration of construction. The TESC facilities shall be in accordance with and conform to the Kent Surface Water Design Manual, the WSDOT Standards Specifications, and the Ecology Construction Stormwater General Permit (if applicable), except as modified by the Kent Design and Construction Standards or these Kent Special Provisions. It shall be the responsibility of the Contractor to notify the City at once of any TESC deficiencies or changes in conditions such as rutting and or erosion that may occur during construction. The Contractor may recommend possible solutions to the Engineer in order to resolve any problems that are occurring. The requirements of this section shall apply to all areas of the site subject to construction activity as described in the WSDOT Standard Specifications, the Kent Special Provisions and contract plans, including Contractor construction support facilities, Contractor personnel parking areas, equipment and material storage/laydown areas, and other areas utilized by the Contractor for completion of the work. Nothing in this section shall relieve the Contractor from complying with other contract requirements. SECTION 8-01.3(1)A IS SUPPLEMENTED BYADDING THE FOLLOWING: 8-01.3(1)A Submittals Prior to the start of any construction activities, the Contractor shall submit for the Engineer's review and approval, the following, as necessitated by the work: 1 . Dewatering Plan 2. Spill Prevention Control and Countermeasures Plan 3. Stream Bypass Plan for in-water work 4. Name and contact info for Contractor's CESCL SECTION 8-01.3(1) IS SUPPLEMENTED BYADDING THE FOLLOWING NEW SECTIONS: 8-01.3(1)F Applicable Regulations and Criteria All construction activities are subject to applicable federal, state, and local permits. The Contractor shall comply with requirements of applicable state and local regulatory requirements, including, but not limited to the following: 1 . WAC 173-201A Water Quality Standards for Surface Waters of the State of Washington 2. RCW 90.48.080 Discharge of pollutants in waters prohibited PS 3 Electrical System Improvements/Araucto 8 - 2 October 10, 2019 Project Number: 17-7999.6 3. City of Kent 2002 Surface Water Design Manual 4. Construction Stormwater General Permit — WA Department of Ecology B-01.3(1)G Water Quality Monitoring Sampling of site stormwater discharges is only required if the project is covered under the WA Department of Ecology Construction Stormwater General Permit or if there is a suspected discharge that exceeds state water quality standards. If the project is covered under the Construction Stormwater General Permit, then the Contractor shall conduct sampling as per the conditions listed in the permit. Any results that are outside the appropriate range of compliance will require immediate implementation of adaptive management as outlined in applicable permits, stormwater pollution prevention plan, and as directed by the Engineer. All sampling records shall be submitted to the Engineer by the last day of the monitoring period. All necessary adaptive management requirements shall be the responsibility of the Contractor to implement and maintain. All costs for this work shall be included in the various unit contract bid prices. B-01.3(2) Seeding, Fertilizing and Mulching SECTION B-01.3(2)B IS DELETED AND REPLACED WITH THE FOLLOWING: B-01.3(2)B Seeding and Fertilizing Topsoil and all other unpaved and unsodded areas within easements and right-of-way disturbed as part of this project shall be seeded. Hydroseeding shall be the method of seed application. Hydroseed shall consist of a slurry composed of water, seed, fertilizer, tackifier, and mulch and shall be evenly broadcast over areas to be seeded. All work shall conform in all respects to Section 8-01 of the WSDOT Standard Specifications, except as modified herein. The Contractor shall notify the Engineer not less than 48 hours in advance of any hydroseeding operation and shall not begin the work until areas prepared or designated for hydroseeding have been approved. Following the Engineer's approval, hydroseeding of the approved slopes shall begin immediately. Hydroseeding shall not be done during windy weather or when the ground is frozen, excessively wet, or otherwise untillable. Hydroseed mixture to be applied by an approved hydro seeder which utilizes water as the carrying agent, and maintains continuous agitation PS 3 Electrical System Improvements/Araucto 8 - 3 October 10, 2019 Project Number: 17-7999.6 through paddle blades. It shall have an operating capacity sufficient to agitate, suspend, and mix into a homogeneous slurry the specified amount of seed and water or other material. Distribution and discharge lines shall be large enough to prevent stoppage and shall be equipped with a set of hydraulic discharge spray nozzles that will provide a uniform distribution of the slurry. The seed and fertilizer cannot be placed in the tank more than 30 minutes prior to application. The seed and fertilizer shall have a tracer added to visibly aid uniform application. This tracer shall not be harmful to plant and animal life. If wood cellulose fiber is used as a tracer, the application rate shall not exceed 25 pounds per acre. Areas where hydroseeding is not practical, must be seeded by approved hand methods as approved by the engineer. When seeding by hand, Contractor shall incorporate seed into the top 1/4 inch of soil. The hydroseed slurry shall consist of the following materials mixed thoroughly together and applied in the quantities indicated. 1 . Grass Seed: Mixture shall be fresh, clean, new crop seed. Seed to be mixed mechanically on the site or may be mixed by the dealer. If seed is mixed on site, each variety shall be delivered in the original containers bearing the dealer's guaranteed analysis. If seed is mixed by the dealer, the Contractor shall furnish to the Engineer the Dealer's guaranteed statement of the composition of the mixture and the percentage of purity and germination of each variety. Grass seed shall be purchased from a recognized distributor and shall be composed of the varieties mixed in the proportions indicated in the WSDOT Standard Specifications and Kent Special Provisions. Seed shall meet the minimum percentages of purity and germination specified in Section 9-14.2 of the Kent Special Provisions. Seed shall be applied at the rate of 120 pounds per acre. The Contractor shall protect seed from hydration, contamination, and heating during delivery, storage, and handling. Seed shall be stored in a cool dry location away from contaminants. Mix A shall be used as the standard hydroseed mix unless otherwise specified herein or on approved project plans. Mix B shall be used exclusively for seeded areas adjacent to grass lawns, within seeded medians, and within seeded traffic islands. In addition, Mix B shall be used for all seeded areas not specifically showing Mix A on the plans, or where otherwise directed by the Engineer. 2. Water: The Contractor shall begin maintenance immediately after seeding for a minimum of ten (10) weeks or longer as needed. Water seeded areas before hydroseed slurry has completely dried PS 3 Electrical System Improvements/Araucto 8 - 4 October 10, 2019 Project Number: 17-7999.6 out. Water slowly and thoroughly with fine spray nozzle. Water the hydroseeded areas at least twice daily (in the early morning and late afternoon) until the grass is well established as determined by the Engineer. Repeat watering operation as required by climatic conditions to keep areas moist for a minimum period of 2 weeks from the day of first watering and as necessary for healthy growth. 3. Mulch: As needed to meet requirements of Sections 8-01 .3(2)D and 9-14.4. 4. Fertilizer: All areas which are seeded shall receive fertilizer of the following proportions and formulation applied at the rate of 400 pounds per acre. All areas which are seeded shall receive fertilizer meeting the requirements of Section 9-14.3 of the Kent Special Provisions. Fertilizer shall not be applied on any creek sideslopes in order to avoid contamination of these creeks. 5. Hand Seeding: Seeding shall be applied at the rate of 6 pounds per 1 ,000 square feet. The seed shall be applied by an approved hand held spreader. The seed shall be evenly distributed over the disturbed area. Apply seed mix after fertilizing and rake the seed into the surface soil to a depth of 1/4-inch. 6. If the slurry is used for temporary erosion control it shall be applied at the following rates: EROSION CONTROL: Seed 170 lbs/acre of "Mix A" unless otherwise directed by Engineer. Fertilizer 400lbs/acre Wood Fiber 2,000 Ibs/ acre Tackifier 80lbs/acre SECTION 5-01.3(2)D IS DELETED AND REPLACED WITH THE FOLLOWING: 8-01.3(2)D Mulching Wood cellulose fiber mulch conforming to Section 9-14.4 of the WSDOT Standard Specifications shall be used where mulch is called for on this project. The application rate shall be 2,000 pounds to the acre in accordance with Section 8-01 of the WSDOT Standard Specifications. Mulch shall be incorporated into the slurry of seed and fertilizer. Mulch of the type specified in Section 9-14.4(2) shall be included in the hydroseeding process. Wood cellulose fiber used as a mulch shall be suitable for application with hydroseeders as specified in Section 8-01 .3(2)B. The application of seed, fertilizer, and mulch shall be required in a single operation for all seed applications, unless otherwise directed. Mulch materials, shall be furnished, hauled, and evenly PS 3 Electrical System Improvements/Araucto 8 - 5 October 10, 2019 Project Number: 17-7999.6 applied at the rates indicated, and shall be spread on seeded areas immediately after seeding unless otherwise specified. Distribution of straw mulch material shall be by means of an approved type mulch spreader, which utilizes forced air to blow mulch material on seeded areas. In spreading straw mulch, the spreader shall not cut or break the straw into short stalks. Straw mulch shall be applied at a rate to achieve a loose, overall thickness of three (3) inches. Areas not accessible by mulching equipment shall be mulched by approved hand methods and shall achieve similar results. Mulch sprayed on signs or sign structures shall be removed the same day. SECTION 8-01.3(2)E IS SUPPLEMENTED BY ADDING THE FOLLOWING: 8-01.3(2)E Soil Binders and Tacking Agents Unless specified otherwise, wood cellulose fiber mulch per Section 9-14.4(2) of the WSDOT Standard Specifications shall have tackifier incorporated into the mulch fiber during manufacture. If additional tackifier is required, the tackifier shall be Type A as specified in Section 9-14.4(7) of the WSDOT Standard Specifications. When specified, soil binders and tacking agents shall be applied in accordance with the manufacturer's recommendations. SECTION 8-01.3(2)F IS REVISED BY DELETING THE FIRST THREE PARAGRAPHS AND REPLACING WITH THE FOLLOWING: 8-01.3(2)F Dates for Application of Final Seed, Fertilizer, and Mulch Unless otherwise approved by the Engineer, the final application of seeding, fertilizing, and mulching of slopes shall be performed during the following periods: West of the summit of the Cascade Range - March 1 to May 15 and August 15 to October 1 . Where contract timing is appropriate, seeding, fertilizing, and mulching shall be accomplished during the spring period listed above. Written permission to seed after October 1 will only be given when physical completion of the project is imminent and the environmental conditions are conducive to satisfactory growth. SECTION 8-01.3(2)G IS SUPPLEMENTED BYADDING THE FOLLOWING: 8-01.3(2)G Protection and Care of Seeded Areas Protect adjacent property, public walks, curbs and pavement from damage. Do not place soil directly on paved surfaces. Locate all underground utilities prior to the commencement of work. Keep streets and area drains open and free flowing. Protect all seeding against wind, storm, and trespassing. Replace any plants that become PS 3 Electrical System Improvements/Araucto 8 - 6 October 10, 2019 Project Number: 17-7999.6 damaged or injured. In seeded areas, treat and reseed damaged spots larger than one square foot. SECT/ON 8-01.3(2)H /S SUPPLEMENTED BYADD/NG THE FOLLOWING: B-01.3(2)H I nspection Inspection of seeded areas shall be made upon completion of seeding operations, at the end of the maintenance period, and at any time during the maintenance period. The Contractor shall reseed, re-mulch or re-fertilize as required to establish a uniform, thick stand of grass. A uniform stand of grass shall be defined as any grass area with no spots greater than one square foot. Areas failing to show a uniform thick, healthy stand of grass after the maintenance period shall be reseeded consistent with the Kent Special Provisions at the Contractor's expense. Reseeded areas will be subject to inspection for acceptance. B-01.3(9) Sediment Control Barriers SECT/ON 8-01.3(9)D /S SUPPLEMENTED BY ADDING THE FOLLOWING: B-01.3(9)D Inlet Protection Cleaning and maintenance of inlet protection shall not flush sediment, or sediment-laden water into the downstream system. SECT/ON 8-01.3 /S SUPPLEMENTED BYADD/NG THE FOLLOWING NEW SECT/ON: B-01.3(17) Vehicle Maintenance and Storage Handling and storage of fuel, oil and chemicals shall not take place within 50 feet of waterways. Storage shall be in dike tanks and barrels with drip pans provided under the dispensing area. Shut-off and lock valves shall be provided on hoses. Fuel, oil, and chemicals shall be dispensed only during daylight hours unless approved by the engineer. Fencing shall be provided around storage area. Locks shall be provided on all valves, pumps, and tanks. Materials used to clean up fuel, oil, and chemical spills shall be disposed of as directed by the engineer. Water used for washing vehicles and equipment shall not be allowed to enter storm drains or other State waters. No processed waste water(s) of any kind shall be discharged onto the ground, to surface waters, or to stormwater conveyance systems. B-02 ROADS I DE RESTORAT I ON SECT/ON 8-02.1 /S SUPPLEMENTED BY ADDING THE FOLLOWING: PS 3 Electrical System Improvements/Araucto 8 - 7 October 10, 2019 Project Number: 17-7999.6 8-02.1 Description Drawings and Specifications: Definitions: The word "provide" means "furnish and install" (for landscaping only). Dimensions and Measurements: Dimensions govern when shown. Scale is approximate. Contractor shall check all dimensions in the field and verify them with respect to adjacent or incorporated work. Any discrepancies in the drawings shall be brought to the immediate attention of the Engineer before work proceeds further. Number of Specified Items Required: Wherever in these Kent Special Provisions an article, device or piece of equipment is referred to in the singular number, such reference shall include as many such items as are shown on drawings or required to complete the installation. SECTION 8-02. 1 IS SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECTION: 8-02.1 (1) Submittals The Contractor shall submit within 20 days after Notice to Proceed date a list of all plant material indicating source of supply, order invoice, size and quantity for such species or variety. All plant materials shall meet requirements of State and Federal laws with respect to inspection for plant diseases and infestations. Inspection certificates required by law shall accompany each shipment of plant material and submitted to the Engineer. SECTION 8-02.2 IS DELETED AND REPLACED WITH THE FOLLOWING: 8-02.2 Materials Materials shall meet the requirements of the following sections: Topsoil Type A, Type B, and Type C............. 9-14.1 (1), (2), (3) Seed ....................................................... 9-14.2 Fertilizer.................................................. 9-14.3 Mulch and Amendments............................. 9-14.4 Wood Cellulose Fiber ................................. 9-14.4(2) Special Planting Mixture............................. 9-14.4(9) Erosion Control Devices ............................. 9-14.5 Plant Materials.......................................... 9-14.6 Street Trees............................................. 9-14.6(1)A Stakes, Guys and Wrapping ....................... 9-14.7 Tree Ties ................................................. 9-14.7(1) Water for Plants........................................ 9-25.2 PS 3 Electrical System Improvements/Araucto 8 - 8 October 10, 2019 Project Number: 17-7999.6 Botanical identification and nomenclature of plant materials shall be based on descriptions by Bailey in "Hortus Third" or superseding editions and amendments. 8-02.3 Construction Requirements SECT/ON 8-02.3(1) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(1) Responsibility During Construction The Contractor shall at all times keep the planted areas free from accumulations of waste materials or rubbish. Upon completion of the planting work, the Contractor shall immediately remove all refuse and debris resulting from the planting activities. The project will not receive either preliminary or final approval if the cleanup does not meet with the approval of the Engineer. SECT/ON 8-02.3(3) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(3) Weed and Pest Control During the maintenance and establishment period, all weeds are to be removed by hand. SECT/ON 8-02.3(5) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(5) Planting Area Preparation The Contractor shall excavate planting pits to a depth of three feet below the top of adjacent sidewalks, or adjacent ground if trees are not being planted in sidewalk cutouts. Tree pits shall be about three feet in diameter, and shall be neat and uniform basins around each tree. The Contractor shall then place special planting mixture into the tree basins, bringing to grade about one and one-half foot below the top of the planter by compaction by repeated watering. Refer to Section 8-02.3(4) of the WSDOT Standard Specifications. SECT/ON 8-02.3(7) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(7) Layout of Planting The location of plantings shall be according to the landscaping details, unless otherwise directed by the Engineer. The Contractor shall layout tree, shrub and herbaceous plant locations and receive the approval of the Engineer before planting begins. SECT/ON 8-02.3(8) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(8) Planting All plants shall be carefully placed in excavated holes to prevent damage to fibrous root systems during placement and backfilling PS 3 Electrical System Improvements/Araucto 8 - 9 October 10, 2019 Project Number: 17-7999.6 operations, with burlap or container removed. Plants shall be set vertically in the center of the pits, backfilled with native soil, watered and settled so that the crown of the root ball will have the same relation to finished grade as it bore to the grade of the ground from which it was dug. All street trees shall be planted in general conformance to Kent Standard Plan 6-55M. SECTION 8-02.3(9) IS SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(9) Pruning, Staking, Guying, and Wrapping Pruning shall be limited to the minimum amount necessary to remove injured twigs and branches. Only cut injured limbs to the nearest lateral bud. Do not apply tree wound paint or petroleum product to tree cuts. The Contractor shall use rootball bracing (triangle method) rather than staking or guying to support new trees. SECTION 8-02.3(11) IS DELETED AND REPLACED WITH THE FOLLOWING: 8-02.3(11) Wood Chip Mulch Revise all references in this section from bark or wood chip mulch to "wood chip mulch." A sample of the wood chip mulch shall be provided to the Engineer or project Ecologist in a 1-gallon re-closable bag at least seven (7) days prior to application. SECTION 8-02.3(13) IS SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(13) Plant Establishment Plant establishment shall extend for a period of two calendar years. Plant establishment shall begin immediately upon written notification from the Engineer of the completion of initial planting for the project. The two calendar years shall be extended an amount equal to any periods where the Contractor does not comply with the plant establishment provisions. The entire body of plant establishment work including but not limited to removing foreign material, removing garbage, weeding, pruning, removing dead plant material, replacing rejected plants, replacing stolen or damaged plants, over the entire site shall occur on a frequency of no less than twice a year and be completed to the satisfaction of the Engineer. Failure to comply with minimum work frequency shall constitute justification for the Contracting Agency to take corrective steps and deduct all costs from monies due the Contractor. The Contractor shall operate the irrigation system to assure watering frequency and amount to maintain all shrubs in a thriving condition. PS 3 Electrical System Improvements/Araucto 8 - 10 October 10, 2019 Project Number: 17-7999.6 Maintenance and operation of the irrigation system is critical to the survival of the shrubs. The contractor shall winterize the irrigation system in the fall before November V. The Contractor shall energize the irrigation system each spring before May 15t". The Contractor will make all necessary repairs and perform all preventative maintenance to assure proper irrigation system operation and longevity. Water for the irrigation system shall be provided by the Owner without charge to the Contractor. SECT/ON 8-02.3(14) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.3(14) Plant Replacement The Contractor shall replace all trees and shrubs which, in the opinion of the City Nursery Supervisor, have failed to establish themselves during the maintenance period at its sole expense. All replacement planting shall be conducted in conformance to these specifications. SECT/ON 8-02.3 /S SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECT/ON: 8-02.3(17) Plant and Site Protection During Entire Construction Period The Contractor shall: 1 . Protect existing trees to remain and new plants against injury and damage, including but not limited to: cutting, breaking, or skinning of roots, trunk or branches, or smothering by stockpiling construction material, or compaction by equipment. 2. Keep all heavy equipment (e.g., backhoe) outside of the drip lines of all existing trees, so as not to damage the root systems. 3. Notify Engineer immediately if a conflict arises between construction activity and the protection of trees and shrubs; alter methods as necessary and as approved by the Engineer. SECT/ON 8-02.5 /S SUPPLEMENTED BY ADDING THE FOLLOWING: 8-02.5 Payment "PSIPE Cornus Kousa (2 inch Caliper)" "PSIPE Osmanthus Delavayi (5 Gallon Container)" "PSIPE Spiraea Japonica (2 Gallon Container)" The unit contract price per each for the above items constitutes complete compensation for the plants, all labor, materials, tools, supplies and equipment necessary for planting the plants in accordance with the plans and described in the specifications. This item includes but is not limited to mulch, soil, fertilizer, watering, planting mixture, pruning, cleaning, weeding and maintaining and establishing the plants for a period of not less than two calendar years from plant acceptance. PS 3 Electrical System Improvements/Araucto 8 - 11 October 10, 2019 Project Number: 17-7999.6 8-30 PROJECT S I GNS 8-30.1 Description This work shall consist of providing all posts, braces, and hardware and installation and maintenance of City-furnished project signs where shown in the plans or where directed by the Engineer. Contractor shall pick up signs at the City Maintenance Shop on West James Street, telephone 253-856-5600. Contractor shall provide two weeks notice to the Shops prior to installation to schedule pickup. All project signs become the property of the City at the end of the project, and the Contractor shall return project signs to the same facility when so directed by the Engineer. 8-30.2 Materials Sign posts shall be 4 inch x 6 inch Fir. 8-30.3 Construction Requirements 8-30.3(1) Erection of Posts All posts shall be set reasonably vertical, and deep enough to sustain sign and expected wind loads as determined by the Engineer. 8-30.3(2) Design A Three (3) vertical 4 inch x 4 inch Fir posts shall be attached to the sign board. Three horizontal 2 inch x 4 inch Fir braces shall be attached to the back of the sign board, one each on the top, the bottom, and in the middle. Attachment of posts and bracing shall meet with the approval of the Engineer. 8-30.3 Installation Fasten two (2) vertical 4 inch x 6 inch Fir posts evenly spaced at the back of the sign board. Posts shall be of break-away design with no more than 12.25 square inches of drilled shear area at a point 2 inches above the ground, or as directed by the Engineer. Attachment of posts and bracing shall meet with the approval of the Engineer. 8-30.4 Measurement Project signs will be measured by the installed and maintained unit. Failure of the Contractor to adequately maintain the project signs—as determined by the Engineer—shall be deemed noncompliance with this Specification. 8-30.5 Payment Payment will be made in accordance with Section 1-04.1 , for the following bid item when included in the Proposal: PS 3 Electrical System Improvements/Araucto 8 - 12 October 10, 2019 Project Number: 17-7999.6 The unit contract price per each for "Project Sign" constitutes complete compensation for furnishing all labor, tools, supplies, equipment and materials, to fabricate, install, maintain project sign(s) for the life of the project and removal and delivery of sign(s) to the City Shops upon closeout of the project. Failure to adequately maintain and return project signs to the City Maintenance Shop shall be deemed reasonable grounds for the Engineer to adjust the payment made under this bid item. Said adjustment shall be determined solely by the Engineer and is not negotiable except at the Engineer's discretion. PS 3 Electrical System Improvements/Araucto 8 - 13 October 10, 2019 Project Number: 17-7999.6 DIVISION 9 - MATERIALS 9-14 EROSION CONTROL AND ROADSIDE PLANTING 9-14.1 Topsoil SECT/ON 9-14. 1(1) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 9-14.1 (1) Topsoil Type A Topsoil Type A (Compost Amended Planting Soil) shall consist of 50 — 67% sand and/or sandy loam and 33 — 50% composted organic material by volume. Total organic matter shall be at least 5% by dry weight for areas where turf will be installed, and at least 10% by dry weight for all other landscape areas. Organic matter shall be determined by Loss-on-Ignition test. Acceptable tests include the most current version of ASTM D2974 "Test Methods for Moisture, Ash, and Organic Matter of Peat and Other Organic Soils," and TMECC 05.07A "Loss-On-Ignition Organic Matter Method." Compost-Amended Planting soil shall not contain any viable seeds or roots capable of sprouting any State-listed noxious weed, or invasive root-propagating plants including but not limited to horsetail, ivy, clematis, knotweed, Scot's broom, reed canary grass, Himalayan blackberry, etc. Soil found to contain these prohibited viable plant materials shall be removed and replaced at the Contractor's expense. A. The soil shall meet the following requirements. 1 . The mixed soil shall meet the following gradation: Screen Percent Size * Passing 2 inch 100 1 inch 99-100 5/8" 90 — 100 1/4" 75-100 *Maximum particle length of 6 inches B. Shall have a pH range between 5.5 and 8.5. The pH shall be determined by soil test. C. Organic material shall consist of composted yard debris or organic waste material composted for a minimum of 3 months. Compost shall consist of 100% recycled content and meet all requirements for compost in section 9-14.4(8) of the Standard Specifications. D. Submit a certified laboratory analysis from an accredited soils testing laboratory indicating the Material source and compliance with all planting soil and compost specifications to the Engineer or project Ecologist for approval no less than seven (7) days before delivery to PS 3 Electrical System Improvements/Araucto 9 - 1 October 10, 2019 Project Number: 17-7999.6 the Project Site. The analysis shall be with a sample size of no less than 2 pounds. E. Site specific soil testing (after placement of material) may be required for projects requiring more than 50 cubic yards of compost- amended planting soil A Contractor provided accredited laboratory approved by the Engineer shall make recommendations for amendments required for optimum growth at no cost to the owner. The Contractor will be allowed five (5) Working Days to complete the testing from the time of written notice given by the Engineer. F. A sample of the compost amended planting soil shall be provided to the Engineer or project Ecologist in a 1-gallon re-closable bag at least seven (7) days prior to application. SECT/ON 9-14. 1(1) /S SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECT/ON: 9-14.1 (1)C Sandy Loam Sandy loam shall consist of soil having a maximum clay content of ten percent by weight. In addition, soil particles shall meet the following requirements for grading: Passing 1 inch sieve (square opening) ......... 100% Passing 1 mm sieve .................................. 80% minimum Passing 0.15 mm sieve .............................. 15% maximum SECT/ON 9-14.2 /S SUPPLEMENTED BY ADDING THE FOLLOWING: 9-14.2 Seed Hydroseed: Seed shall be "Blue Tag" or certified quality. The Contractor shall deliver in unopened containers with mixture seed content and inert material content plainly marked on the outside of the container. Grasses used shall meet the following specifications: Mix A (Roadside and Erosion Control Grass): Weight Seed Mix "A" Min. % Min. % Max. % Proportion Ingredient Pure Seed Germination Weed Seed 40% Perennial R e rass 98% 90% 0.5% 40% Creeping Red Fescue 98% 85% 0.5% 10% Colonial Bent grass 98% 90% 0.5% 10% White Dutch Clover 98% 90% 0.5% (Pre-inoculated) PS 3 Electrical System Improvements/Araucto 9 - 2 October 10, 2019 Project Number: 17-7999.6 Mix B (Landscaped Area Grass): Weight Seed Mix "B" Min. % Min. % Max. % Proportion Ingredient Pure Seed Germination Weed Seed 15% Creeping Red Fescue 95% 90% 0.5% 10% Chewin s Fescue 95% 90% 0.5% 40% Perennial R e rass 95% 90% 0.5% 20% Alta Tall Fescue 95% 90% 0.5% 15% Annual R e rass 95% 90% 0.5% The Contractor shall submit to the Engineer the manufacturer's Certificate of Conformance for seed. A complete analysis of the seed shall be submitted to the City for approval including percent of pure seed, germination, other crop seed, inert and weed and the germination test date. The City reserves the right to reject any or all plant material at any time until final inspection or acceptance. The Contractor shall remove rejected plants immediately from site. The Contractor shall produce upon request sales receipt for all nursery stock and certificates of inspection. SECT/ON 9-14.3 /S SUPPLEMENTED BY ADDING THE FOLLOWING: 9-14.3 Fertilizer Fertilizer for trees: Fertilizer shall consist of slow-release commercial fertilizer (6-10-8). Fertilizer for upland seeded areas: Lilly Miller or approved equal to provide the following nutrients: All areas which are seeded shall receive fertilizer of the following proportions and formulation: Total available Nitrogen ........... 16% of weight (of which 50% is derived from ureaform) Total available Phosphorous ..... 16% of weight Total available Potassium ......... 16% of weight Fertilizer for wetland seeded areas: All areas which are seeded in wetlands or in detention ponds shall receive fertilizer of the following proportions and formulation: Total available nitrogen ........... 21% (Analyzed as N) Available phosphorous............. 0% (Analyzed as P205) Available potassium ................ 10% (Analyzed as K20) Above percentages are proportioned by weight. The Contractor shall deliver fertilizer to the site in original unopened containers bearing manufacturer's chemical analysis, name, trade PS 3 Electrical System Improvements/Araucto 9 - 3 October 10, 2019 Project Number: 17-7999.6 name, trade mark, and indication of conformance to state and federal laws. Instead of containers, fertilizer may be furnished in bulk with certificate indicating the above information. 9-14.4 Mulch and Amendments SECT/ON 9-14.4(8) /S SUPPLEMENTED BY ADDING THE FOLLOWING: 9-14.4(8) Compost Compost shall not contain any sawdust, straw, green or under- composed organic matter, under-sterilized manure or toxic or otherwise harmful materials. SECT/ON 9-14.4 /S SUPPLEMENTED BY ADDING THE FOLLOWING NEW SECT/ON: 9-14.4(12) Wood Cellulose Fiber Wood cellulose mulch shall be specially processed 100 percent virgin wood fiber containing no growth or germination-inhibiting ingredients. It shall be manufactured in such a manner that after addition and agitation in slurry tanks with water, the fibers in the material will become uniformly suspended to form a homogenous slurry. When hydraulically sprayed on the ground, the material shall allow the absorption and percolation of moisture. Wood cellulose fiber shall be Weyerhaeuser Silva-Fiber Plus w/Tackifier or approved equal. Organic matter content shall be at least 93 percent on an oven-dry basis as determined by ASTM D 586. The moisture content shall be no more than 15 percent as determined by oven dried weight. Each package of the cellulose fiber shall be marked by the manufacturer to show the dried weight content. PS 3 Electrical System Improvements/Araucto 9 - 4 October 10, 2019 Project Number: 17-7999.6 TECHNICAL SPECIFICATIONS The following specification, written in the CSI format, supplement all other plans and specifications which have been prepared for this project and are considered to be a part of the Kent Special Provisions for this project. PS 3 Electrical System Improvements/Araucto A - 1 October 10, 2019 Project Number: 17-7999.6 Kent Pump Station No.3 Electrical System Improvements Project No. 17-7999.6 ENGINEERING TECHNICAL SPECIFICATIONS TABLE OF CONTENTS SECTION DESCRIPTION 01110 SUMMARY OF WORK 01200 MEASUREMENT AND PAYMENT 16010 GENERAL 16011 DEMOLITION 16145 MISC. ELECTRICAL EQUIPMENT 16201 LOAD TRANSFER SWITCHES 16400 UTILITY POWER SERVICE 16432 ARC FLASH HAZARD ANALYSIS 16500 LIGHTING 16921 INSTRUMENTATION AND CONTROL SYSTEM The electrical technical specifications have been prepared under the direction of the Professional Engineer,registered in the State of Washington, whose seal and signature appear below: ♦ ■ . 8347 NAL 10/04/2019f=� 0000-1 Kent Pump Station No. 3 Electrical System Improvements SUMMARY OF WORK Project No. 17-7999.6 SECTION 01110 SUMMARY OF WORK PART GENERAL 1.1 SCOPE OF WORK A. The work specified in this Section consists of furnishing all labor, materials, and equipment necessary for the electrical upgrade of Pump Station #3, as shown on the Plans, and hereinafter specified. Work shall include, but not be limited to, the following: 1. Coordinate with the local power utility and replace the existing power service to the site with a new service. 2. Provide temporary utility power service, 480V and 120/240V panels, MTS and connection to the existing generator for operations of the pump station during construction. 3. Relocate existing control and telemetry panels for temporary operations of the pump station during construction. 4. Demolish existing equipment and associated raceways and wire at the site and re-use instrumentation and other equipment as shown on the plans. 5. Provide service entrance equipment per the serving utility's requirements. Remove existing service equipment and associated raceways and wire. 6. Remove existing transfer switch and associated wire and raceways and provide service entrance rated automatic transfer switch (ATS). 7. Remove existing wiring and raceways to the existing generator and provide all new power and control wiring and raceways. 8. Remove existing power distribution equipment and associated wire and raceways and provide new power distribution equipment, panelboards and transformer. 9. Remove existing motor starters and associated wire and raceways and provide VFDs for the existing pumps. 10. Remove existing control panels and associated raceways and wire and provide CP — Main Control Panel with PLC for control and monitoring and alarming of all equipment. 11. Provide PLC, Operator Interface and SCADA programming for control, operation, monitoring and alarming of all equipment and instrumentation. 12. Remove existing wiring and raceways to the existing instrumentation and provide all new wiring and raceways. 13. Provide smoke detector& flood switch FOLLETT ENGINEERING, PLLC 01110-1 425-765-6304 Kent Pump Station No.3 Electrical System Improvements SUMMARY OF WORK Project No. 17-7999.6 14. Remove existing and provide new lighting and receptacles, heating and ventilation equipment 15. Provide wire and raceways for all equipment power and control circuits. 16. Provide O&M, record drawings and training. 1.2 PROJECT INFORMATION A. The Contract Documents show the location, arrangement, and type of work to be performed under the proposed project. B. The Contractor shall be responsible for proper notification to, and coordination with all utility districts, service districts, and all other persons and services that will be affected by this project at least one week in advance of beginning any construction that affects them. C. The Contractor shall notify the Owner (or other water utility purveyor) at least 48 hours in advance of any proposed water system shut downs. The Contractor shall also be responsible for notifying all impacted water users 48 hours in advance of any water shutoff. D. Water system shutdowns will be scheduled with the appropriate agency, under strict supervision, with an approved plan of construction. The pump station site must remain in service at all times during the Project. E. The Contractor shall take all necessary precautions required to prevent damage to existing piping, utilities, and structures above or below ground during construction. Verification of elevations and locations of existing items shall be the responsibility of the Contractor. F. All electrical equipment installed on the project shall be labeled and listed by a nationally recognized electrical testing laboratory for the application, or approved by the Washington State Department of Labor and Industries for installation on this Project. G. All electrical work by the Contractor on existing equipment shall be performed such that is does not invalidate the "UL" listing and labeling. If the Contractor fails to comply with this requirement, he shall provide a "Site Evaluation" by an L&I approved testing laboratory to satisfy L&I requirements or the local authority having jurisdiction. The Site Evaluation and all work required to reestablish the components "UL" listing shall be provided by the Contractor at no additional cost to the Owner. H. It is the intent and purpose of these Contract Documents to have constructed complete facilities in good working order for the least practical cost to the Owner. Suggestions, recommendations, as well as inquiries from the Contractor that will serve this purpose are welcome and will be given consideration by the Owner and the Engineer. 1.3 CONTRACTOR USE OF SITE AND PREMISES A. Construction operations shall be limited to the areas noted on the Drawings and subject to the approval of the Owner and per KSP 1-08.4. FOLLETT ENGINEERING, PLLC 01110-2 425-765-6304 Kent Pump Station No.3 Electrical System Improvements SUMMARY OF WORK Project No. 17-7999.6 1.4 ORDER OF WORK A. The order of work will be at the option of the Contractor, in keeping with good construction practice, time restrictions, and requirements of the permits applicable to this project. The Contractor shall conduct the order of work to allow the existing facilities to remain operational during the construction of the Project and shall coordinate all of his activities through the Engineer with the Owner's operations and maintenance staff. The Contractor shall prepare a complete project schedule in accordance with Section 01320. B. The implementation of any measure required to protect the environment shall supersede any order of work designated within these Specifications. The Contractor shall meet the conditions as outlined in any and all permits and requirements of the Federal, State, County, and City regulatory agencies. END OF SECTION FOLLETT ENGINEERING, PLLC 01110-3 425-765-6304 Kent Pump Station No.3 Electrical System Improvements MEASUREMENT& PAYMENT Project No. 17-7999.6 SECTION 01200 MEASUREMENT & PAYMENT PART GENERAL 1.1 SCOPE A. This Section further defines Measurement and Payment for certain items for this project. Not all items are included in this Section. Measurement and Payment for other proposal items are included in the Section referenced in the Proposal documents. Any item not specifically included in a Measurement and Payment description shall be considered incidental to the project. 1.2 RELATED WORK SPECIFIED ELSEWHERE SECTION ITEM A. 01110 Summary of Work B. 01300 Submittals 1.3 MEASUREMENT A. Measurement for all items shall be as indicated in these Specifications for unit price and lump sum price bid items. Bid items are outlined in detail in this Specification Section and listed in the Proposal. B. Measurement shall be in accordance with Section 1-09.1 of the WSDOT Standard Specifications. Volumes of gravel materials and concrete volumes shall be measured by the Engineer in the field and quantities will be limited to the relative neat line dimensions shown on the Plans or as approved by the Engineer in the field. C. Weighing equipment, scale verification checks, load tickets for quarry spalls, rock riprap, cobbles, gravel materials, hot mix asphalt, bituminous construction materials, etc., shall conform to Section 1-09.2 of the WSDOT Standard Specifications. Load tickets shall include all gravel materials, cast- in-place concrete, cement grout, CDF, hot mix asphalt, ATB, and reinforcing steel. The Owner will pay for no material received by weight unless they have been weighed as required in this Section or as required by another method the Engineer has approved in writing. All costs incidental to weighing shall be merged into the various unit prices bid. 1.4 PAYMENT BID ITEMS A. GENERAL 1. The following is a partial list of bid items for the project. The Contract price for each item constitutes full compensation for furnishing all equipment, labor, materials, tools, supplies, appurtenances, and 01200-1 Kent Pump Station No.3 Electrical System Improvements MEASUREMENT & PAYMENT Project No. 17-7999.6 incidentals, and performing all operations necessary to construct and complete the various bid items in accordance with the Contract Documents. Payment for each item shall be considered as full compensation, notwithstanding that minor features may not be mentioned herein. Work paid for under one item will not be paid for under any other item. If a particular item of work shown on the Plans or described in Specifications is not described in a specific bid item, this item of work shall be considered as incidental to the work and the costs for this work shall be merged into the various respective unit price and lump sum bid items. B. PARTIAL BID ITEM LIST 1. Temporary Operations a) Measurement: Will be measured by lump sum. b) Payment: The lump sum price bid for TEMPORARY OPERATIONS shall include all costs per Paragraph 1.4.A herein for providing the following: • Temporary utility service, service pole, 480V and 120/240V panelboards and 480-120/240V transformer. • MTS and temporary power cable from the existing generator to the MTS. • Wiring connections from the temporary power panels to equipment (lights, receptacles, HVAC, control / telemetry panels, CL2 analyzer, pump 2 motor starter, etc.) • Relocation of the existing control and telemetry panels and connections for wiring to the existing components, instrumentation, and pump 2 motor starter etc. • Removal and disposal of demolished equipment. 2. Demolition a) Measurement: Will be measured by lump sum. b) Payment: The lump sum price bid for DEMOLITION shall include all costs per Paragraph 1.4.A herein for providing the following: • Demolition of the existing electrical equipment (panelboards, MTS, service equipment, service breaker, transformer, motor starters) and all associated wire and raceways • Demolition of the existing controls equipment (control panels, telemetry panel) and all associated wire and raceways. • Demolition of the existing lighting, receptacles, HVAC and other miscellaneous electrical devices and all associated wire and raceways. • Removal and disposal of demolished equipment 3. New Electrical Equipment a) Measurement: Will be measured by lump sum. b) Payment: The lump sum price bid for the new ELECTRICAL EQUIPMENT shall include all costs per Paragraph 1.4.A herein for providing the following: • ATS, 480V panelboard, 120/240V transformer and panelboard. 01200-2 Kent Pump Station No. 3 Electrical System Improvements MEASUREMENT & PAYMENT Project No. 17-7999.6 • New service equipment • Permits and associated fees 4. New Controls Equipment (MCP and VFDs) a) Measurement: Will be measured by lump sum. b) Payment: The lump sum price bid for the new CONTROLS EQUIPMENT shall include all costs per Paragraph 1.4.A herein for providing the following: • MCP and the VFDs for both pumps 1 & 2. • New instrumentation (Smoke detector and flood switch) 5. New Raceways, Wire & Installation a) Measurement: Will be measured by lump sum. b) Payment: The lump sum price bid for the RACEWAYS, WIRE & INSTALLATION shall include all costs per Paragraph 1.4.A herein for providing the following: • New raceways and wire • New raceways and wire and all connections to the new and existing equipment, components, and instrumentation. • New electrical equipment (ATS, panelboards, transformer & service equipment) • New controls equipment (MCP and the VFDs for both pumps 1 & 2 and new instrumentation). • Service conductors including overhead connection and disconnection 6. New lighting, receptacles, HVAC and Misc. Electrical a) Measurement: Will be measured by lump sum. b) Payment: The lump sum price bid for the LIGHTING, RECEPTACLES, HVAC & MISC. ELECTRICAL shall include all costs per Paragraph 1.4.A herein for providing the following: • Light fixtures, receptacles, light switches, HVAC equipment and any other misc. components / equipment. • New raceways and wire and installation and connections associated with the lighting, receptacles, HVAC, & other miscellaneous components/equipment. 7. Programming services (PLC/SCADA) a) Measurement: Will be measured by lump sum. b) Payment: The lump sum price bid for the PROGRAMMING SERVICES shall include all costs per Paragraph 1.4.A herein for providing the following: • Downloading the existing PLC program into the new PLC and making modifications for the new features, controls, alarms and monitoring. • Updating the SCADA for the new controls, alarms and monitoring. 01200-3 Kent Pump Station No. 3 Electrical System Improvements MEASUREMENT& PAYMENT Project No. 17-7999.6 • Configuration and testing of the radio communications • Configuration of the VFDs. • Programming support for the shop testing of the MCP and VFDs • On site programming support for temporary operations and equipment transitions. • On site programming support for construction, testing & troubleshooting, temporary operations, commissioning, final installations and communications. • O&M manual • Training END OF SECTION 01200-4 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 SECTION 16010 ELECTRICAL GENERAL PART 1 GENERAL 1.1 SCOPE: A. This section specifies general requirements for electrical work. Detailed requirements for specific electrical items are specified in other sections but are subject to the general requirements of this section. The electrical drawings and schedules included in this project manual are functional in nature and do not specify exact locations of equipment or equipment terminations. 1.2 DEFINITIONS: A. The word "provide" shall be interpreted to mean furnish and install. B. "Owner".City of Kent C. "Contractor" is the party who furnishes and installs all materials and equipment. This includes the Prime Contractor, Electrical Contractor, Control System Integrator, and all other Contractors and Sub Contractors. D. "Control System Integrator" also referred to as the System Integrator or Integrator or control system manufacturer is the Party that furnishes all programming services and control components including motor controls, VFDs, instrumentation and designs the detailed control wiring diagrams plus the layout and assembly of the custom control panels. 1. The Control System Integrator shall be Systems Interface Inc. 10802 4711 Avenue West Mukilteo, WA 98275 — contact Rob Schommer @ 425-481-1225. E. "Control System" includes all equipment, instruments, computers and wiring for control and monitoring of all operating pumps and equipment. This includes custom control panels, motor control center, packaged control panels, and control equipment furnished with other systems and mechanical equipment. All sensing, transmitting, indicating, control and recording of all functions as specified and shown are also included in the control system. 1.3 GENERAL DESCRIPTION OF WORK: A. The Contractor shall: 1. Provide all labor, material, tools, equipment and services required to complete the furnishing, installation, wiring, connection, calibration, adjustment, testing and operation of all electrical equipment, devices and components as indicated and implied by the plans and these specifications. FOLLETT ENGINEERING, PLLC 16010-1 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 2. Provide identification (nameplates and wire tags) of all electrical equipment and wiring. 3. Complete the wiring to, connection to, adjustment and calibration of, testing of equipment having electric motors and/or built-in or furnished electrical components. Install electrical components that are furnished with mechanical equipment. 4. Complete the procurement, installation, wiring, connection, calibration, adjustment, testing and operation of all electrical devices, components, accessories and equipment which is not shown or specified but which is nonetheless required to make the systems shown and specified function properly. 5. Provide the size, type and rating of motor control devices, equipment and wiring necessary to match the ratings of motors furnished with mechanical equipment. 6. Provide adequate space for the electrical installation, including but not limited to, determination of access-ways and doorways, shipping sections, wall and floor space, and space occupied by mechanical equipment. Provide electrical equipment that fits in the areas shown on the drawings. All equipment shall be readily accessible for maintenance, shall have electrical clearances in accordance with NEC and shall be installed in locations that will provide adequate cooling. 7. Provide detailed wiring diagrams showing all equipment and instrumentation connections and terminations. 8. Check electrical equipment prior to installation so that defective equipment is not installed. Acceptance testing for electrical equipment shall be performed as discussed in Sections 16921. 9. Provide start-up, follow-up and training of the Owner's personnel for electrical systems. Make all corrective measures required during start- up. See specific requirements for training and start-up in other specification sections. 10. Provide field services of qualified technicians to supervise and check out the installation of the equipment, to supervise and check out interconnecting wiring, to conduct start-up of operation of the equipment, and to correct any problems, which occur during start-up. 11. Provide demolition of existing equipment per specification section 16011. 12. The VFDs, control panels, and instrumentation shall be supplied through the Control System Integrator and shop tested in the integrator's shop. 1.4 EQUIPMENT COORDINATION A. The Contractor is responsible to coordinate the equipment supplied from other manufacturers. This includes but is not limited to: 1. Obtaining specific information on equipment ratings and sizes and verifying the electrical components supplied meet, or match the requirements such as voltage, phase, frequency, starter types, etc. 2. Verifying the equipment supplied will fit within the space allocated. FOLLETT ENGINEERING, PLLC 16010-2 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 3. Coordination of equipment and the electrical power and control requirements. Provided in all sections of the specifications and drawings. 4. Providing power and control equipment, wiring, and raceways to meet the requirements of the mechanical equipment supplied. 5. Providing all necessary control wiring and components for any special requirements from an equipment manufacturer. B. The Contractor shall verify as a minimum: 1. Correct voltage, phase and frequency 2. Size and space requirements 3. Mounting requirements 4. Correct motor starter type 5. Proper coordination with the controls and control system Integrator. C. Any discrepancies between the electrical and other equipment shall be brought to the immediate attention of the Engineer. D. The Contractor shall take precautions to minimize instrumentation or control interferences that are created by the variable frequency drives (VFD's) or power wiring. The Contractor shall coordinate with the VFD manufacturer to provide necessary separation of conductors or shielding and/or filtering equipment as required by the VFD manufacturer. All power wiring shall be separated from instrumentation and control wiring by a minimum of 12" and 18" to any VFD power wiring. 1.5 PROJECT DESCRIPTION: A. In general the project consists of a substantial electrical upgrade of an existing water booster pump station. B. The following statements highlight the main portion of the electrical work: 1. Coordinate with the local power utility and replace the existing power service to the site with a new service. Note: the existing service is primary metered. The Contractor shall be responsible for all service work including the overhead conductors and connection to the existing transformers. 2. Demolish existing equipment and associated raceways and wire at the site and re-use instrumentation and other equipment as shown on the plans. 3. Provide temporary utility power service, 480V and 120/240V panels, MTS and connection to the existing generator for operations of the pump station during construction. 4. Relocate existing control and telemetry panels for temporary operations of the pump station during construction. 5. Provide service entrance equipment and metering equipment per the serving utility's requirements. Remove existing service equipment and associated raceways and wire. FOLLETT ENGINEERING, PLLC 16010-3 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 6. Remove existing transfer switch and associated wire and raceways and provide service entrance rated automatic transfer switch (ATS). 7. Remove existing wiring and raceways to the generator and provide all new power and control wiring and raceways. 8. Remove existing power distribution equipment and associated wire and raceways and provide new power distribution equipment, panelboards and transformer. 9. Remove existing motor starters and associated wire and raceways and provide VFDs for the existing pumps. 10. Remove existing control panels and associated raceways and wire and provide CP — Main Control Panel with PLC for control and monitoring and alarming of all equipment. 11. Remove existing wiring and raceways to the existing instrumentation and provide all new wiring and raceways. 12. Provide smoke detector & flood switch 13. Provide lighting and receptacles, heating and ventilation equipment 14. Provide wire and raceways for all equipment power and control circuits. 15. Provide O&M, record drawings and training. 1.6 TEMPORARY OPERATION AND CONSTRUCTION POWER: 1.6.1 CONSTRUCTION POWER: A. Provide a separately metered temporary power service with 480V distribution and 120/240V distribution panels for construction power. Provide power for operation of all equipment including lighting and HVAC during construction and testing. All coordination with the utility and associated construction costs for temporary construction power shall be paid for by the Contractor. The City shall pay the for the energy costs as billed by the utility on this "new" meter. B. Any necessary modifications to the existing electrical system for construction power shall be coordinated and paid for by the Contractor. C. Provide MTS and power cable from the existing generator for power to the facility during utility power outages. 1.7 STANDARDS AND CODES: A. Permits, licenses, approvals and other arrangements for work shall be obtained and paid for by the Contractor and included in the bid price. B. Electrical work shall be executed in strict accordance with the latest edition of the National Electrical Code and local ordinances and regulations. C. All electrical equipment, materials, construction methods, tests and definitions shall be in strict conformity with the established standards of the following in their latest adopted revision: 1. Underwriters' Laboratories, Inc. (UL) FOLLETT ENGINEERING, PLLC 16010-4 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 2. National Electrical Manufacturers Association (NEMA) 3. Canadian Standards Association (CSA) 4. Electrical Testing Laboratories (ETL) 5. Factory Mutual (FM) 6. All applicable Washington State Codes and local City Codes. D. All materials and equipment specified herein shall, within the scope of UL Examination Services, be approved by the Underwriter's Laboratories for the purpose for which they are used and shall bear the UL label. E. All materials shall be new, free from defects, of current manufacture, of quality specified or shown. Each type of material shall be of the same manufacturer throughout the work. 1.8 CONTRACT DOCUMENTS: A. The electrical layouts are generally diagrammatic. The location of equipment is approximate unless dimensioned. Exact locations and routing of conduits shall be governed by structural conditions and physical interference's and by locations of electrical terminations on equipment. 1.9 REFERENCE DOCUMENTS: A. The Contractor shall refer to the drawings, project data and shop drawings of other trades for additional details, which affect the proper installation of the work. Diagrams and symbols showing electrical connections are diagrammatic only, and so do not necessarily show the exact physical arrangement of the equipment. 1.10 SITE FAMILIARIZATION: A. Before submitting a bid, the Electrical Contractor shall become familiar with all features of the site, which may affect the execution of the work. The Contractor shall take all field measurements necessary for the work and shall assume full responsibility for their accuracy. The Contractor shall take full responsibility for locating and avoiding all substructures. Any damage to existing equipment shall be repaired or replaced by the Contractor at a cost negotiated with the Owner. 1.11 GROUND SYSTEM A. Provide grounding and ground system per the NEC. B. Provide a minimum of two 10 foot x 3/" copper coated steel ground rods or more if required by the drawings. Use pressure type connectors for underground connections and bolted type for exposed. C. Construct metallic raceways to provide a continuous ground path D. Connect all electrical equipment enclosures to the ground system. FOLLETT ENGINEERING, PLLC 16010-5 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 E. Nonelectrical equipment with metallic enclosures and metallic piping shall be connected to the grounding system as required by NEC. F. Ground system shall be tested per IEEE standard 81. If greater than 2 ohms then additional ground rods shall be added and paid for as extra work G. Bond ground system to metallic piping as required by NEC. H. Bond ground system to building steel in at least one location and at other locations as shown on the drawings. 1.12 PRE-CONSTRUCTION CONFERENCE A. The CONTRACTOR shall attend a Preconstruction Conference. Both CONTRACTOR and Control System Integrator shall attend. See Section 1- 08.0 of the Kent Special Provisions for additional requirements. B. The CONTRACTOR shall allot 2 hours (minimum) for the Conference. The conference shall take place at the Owner office C. The CONTRACTOR shall present the following for discussion at the Conference: 1. Discussion of submittal documents and format — submittals shall be electronic and delivered via email with the subject line as follows: a) "project name, EI&C submittal submittal #, spec section# - description." 2. Discussion of submittal schedule and critical path and long lead items and any concerns about lead times for any of the products. 3. A list of proposed modifications, deviations from specified components and anticipated change orders. 4. Proposed shop and field testing procedures for electrical equipment and instrumentation and controls. 5. An overview of the proposed plan for maintaining the operations of the facilities during construction and transferring over to the new equipment. 6. A preliminary schedule for the following activities: a) Electrical equipment submittals b) VFD submittal c) I&C submittal d) Factory testing e) Field 1/0 testing f) Startup g) System testing 1.13 SUBMITTALS: A. Project data shall be submitted in accordance with the general requirements and the following: FOLLETT ENGINEERING, PLLC 16010-6 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 B. In the front of each submittal document, provide a list of any deviations to the contract documents: materials/products, or installation method that are different than specified. C. Submittal documents shall be submitted via E-mail in PDF format. Separate Submittal a-mails shall be provided for each spec section. All products for each spec section shall be included in a single PDF document including the cover sheet and index in one single document. Submittals shall be indexed and identified as follows: 1. Email subject line shall be "project name, EI&C submittal submittal #, spec section#- description." 2. Cover sheet with: a) The project name and submittal # b) Contractor's and sub-contractor's name, phone number, and email address. c) Index sheet showing each product being submitted. 3. PDF index tabs per the electrical specifications by section and paragraph or equipment name e.g. provide a minimum of one tab section for each piece of equipment in all of the PART 2 PRODUCT Sections 2.01 - 2.'-'-. 4. Label each equipment submittal sheet with equipment name and number. Indicate location where each item of equipment submitted will be used on the job. Use equipment numbers when available. 5. Identify specific options and cross hatch out any information that is not a part of the specific information for the submitted component. D. Submittals shall include the manufacturer's name, address, trade name, catalog model or number, nameplate data, size, layout dimensions, capacity, project specification and paragraph reference. Include other information necessary to establish contract compliance of each item proposed to furnish. E. Long lead items may be submitted separately — if pre-approved by the Engineer. F. Each item shall be clearly marked and provided with adequate sales and technical information to clearly show conformance with all aspects of the specification. Packages not provided as described above or largely incomplete shall be returned to the Contractor, without comment. G. I&C (Instrument & Control) submittals shall be provided with a Bill of Materials showing quantity, manufacturer's name, catalog number, and supplier name and phone number. H. Certify on all submittals that the material being proposed conforms to the contract requirements. In the event of any variance, state specifically which portions vary and request a variance in writing. I. Certify that all furnished equipment is able to be installed in the allocated spaces by stating on each item: "This equipment will be able to be installed in the spaces allocated" FOLLETT ENGINEERING, PLLC 16010-7 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 J. Shop Drawings shall be provided on 11" x 17" sheets maximum size, and shall be scaled using standard engineering or architectural scales. Wiring diagrams shall identify circuit terminals, and indicate the internal wiring for each item of equipment and the interconnection between each item of equipment. K. NOTE: submittals received that do not meet the requirements outlined above and in the individual spec sections will be returned without review. L. Contractor should anticipate in the schedule that submittals will take a minimum of 4 weeks for comments to return. M. The engineer will have a minimum of 2 weeks to review submittals and a minimum of 3 weeks to review I&C submittals. PART 2 PRODUCTS 2.1 NAMEPLATES: A. Nameplates shall be provided on all electrical devices, (including but not limited to motor control equipment, MCC cubicles, control stations, junction boxes, panels, motors, instruments, solenoids, switches, indicating lights, meters, and all electrical equipment enclosures.) B. Nameplates shall also be provided on all electrical panel interior equipment, including but not limited to: relays, circuit breakers, power supplies, terminals, contactors, and other devices.) C. All nameplates shall include the equipment name and number (circuit number and function, if applicable). D. Nameplates of all powered equipment (including instruments, motors, control panels, HVAC, etc.) and all switches, disconnects, and receptacles shall have included on the nameplate the power source (circuit and panel number, MCP/control pnl and circuit #, or MCC and unit number, etc. ) that the equipment is fed from. E. Nameplates on light switches and receptacles shall include the panel and circuit and also include application such as outdoor lights, computer receptacle, etc. if relevant. Nameplates on switches and receptacles can be printed thermal tape. F. All motors shall have nameplates secured to the terminal box with 1/2" lettering or larger. G. Nameplates shall be made of 1/16" thick machine engraved laminated phenolic having black letters not less than 3/16" high on white background or as shown on the drawings or other sections of the specifications. Nameplates on the interior of panels and on light switches and receptacles shall be White Polyester with printed thermal transfer lettering and permanent pressure sensitive acrylic; TYTON 822 or equal. FOLLETT ENGINEERING, PLLC 16010-8 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 H. All nameplates shall include the equipment name and number (and function, and circuit number if applicable). I. Provide warning nameplates on all panels and equipment, which contain multiple power sources. Lettering shall be white on red background. J. Provide information or warning nameplates as required by the NEC or electrical inspector for identification of service disconnects, multiple service disconnects etc K. Nameplates shall be secured to equipment with stainless steel screws/fasteners/straps. Epoxy glue may be used where fasteners are not practical if first approved by the Engineer. 2.2 WIRE MARKERS A. Each power and control conductor shall be identified at each terminal to which it is connected. Conductors size No. 10 AWG or smaller shall have identification sleeves. Conductors shall be identified in accordance with Section 16145. B. The letters and numbers that identify each wire shall be machine printed on sleeves with permanent black ink. The figures shall be 1/8 inch high. Sleeves shall be white tubing, sized to fit the conductor insulation. The sleeves shall be shrunk to fit the conductor with hot air after installation. C. Wire markers shall be TMS Thermofit Marker System by Raychem Co., sleeve style wire marking system by W. H. Brady Co., or equal. Adhesive strips are not acceptable. Conductors No. 8 AWG and larger shall use cable markers of the locking tab type. Tabs shall be white plastic with conductor identification number permanently embossed. 2.3 RACEWAY MARKERS A. Raceway markers shall be non metallic with raceway number stamped in 3/16-inch minimum height characters. Tags shall be attached to the raceway with 316 stainless steel wire. 2.4 THERMAL (TEMPERATURE) RATINGS OF EQUIPMENT TERMINATIONS: A. Wiring and circuit breakers on this project are designed for 750C operation above 30 amperes; 600C for 30 amperes and below. B. All products furnished on this project shall have electrical terminations rated for 600C for ampacities of 30 amperes or less and rated for 750C for ampacities above 30 amperes. FOLLETT ENGINEERING, PLLC 16010-9 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 PART 3 EXECUTION 3.1 STORAGE AND INSTALLATION ENVIRONMENT: A. All electrical equipment shall be stored in a dry environment free from dust, moisture, sprays or vapors, which may be detrimental to their new condition. After installation of equipment, care shall be taken to protect all equipment from all dust, moisture, paint and other spray, harmful vapors, etc. until final acceptance and certificates of occupancy have been obtained. B. Equipment shall not be installed in indoor areas until the area is covered, dry and finished to the point that other work will not create dust, vapors, or moisture. Equipment with integral heaters and fans shall not be installed until power is available at the location and the heater and fan shall be energized within 6 hours of the equipment being installed. 3.2 SITE INSPECTIONS A. Prior to final acceptance the Engineer will perform one or more site observation trips to develop a "punch list" of items deemed incomplete B. Each punch list item shall be completed by the Contractor and checked off of the list. When all of the items on the list are completed or commented on, the list shall be signed by the Contractor and returned to the Engineer for verification. 3.3 FINAL ACCEPTANCE: A. When all work is complete, the Contractor shall call the Engineer for the final acceptance testing inspections. The Electrical Contractor and System Integrator shall be present while these inspections are taking place and shall be available for opening cabinets and operating and adjusting the system as is necessary for the Engineer to verify all equipment is installed and operates to the requirements of the contract documents. B. The contractor shall anticipate a minimum of 8 hours to complete the final acceptance testing. C. Prior to the Contractor calling for this observation, the Contractor shall have completed all items of work, including wire markers, nameplates, final tests and final test reports. All equipment shall be checked for proper operation and all signals verified for correct calibration and wiring. D. Final acceptance will not be given until: 1. All work is complete 2. All "site inspection" punch-lists are checked off and returned to the Engineer 3. All test reports are received 4. All O&M manuals are received 5. All spare parts are received FOLLETT ENGINEERING, PLLC 16010-10 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 6. All instrument test forms are received 7. All project record drawings are received. 3.4 PROJECT RECORD DRAWINGS: A. A set of drawings shall be maintained at the job site (by the Electrical Contractor) showing any deviations in the electrical systems from the original design. B. This set of drawings shall be readily available for inspection by the Engineer at all times. C. Another complete set of drawings shall be marked up in the office showing the changes made on the field set of drawings. All changes shall be clearly marked in red on the drawings. Drawings shall be submitted to the Engineer at the completion of the project. D. A set of electrical drawings marked in red to indicate the routing of conduit runs, shall be submitted to the Engineer for review at the completion of conduit rough-in and prior to cover or pouring of concrete. 3.5 GUARANTEE: A. The Contractor shall guarantee his work and all components thereof, excluding fuses, incandescent and fluorescent lamps for a period of 1 year from date of acceptance of the installation. The Contractor shall remedy any defects in workmanship and repair or replace any faulty equipment that shall appear within the guarantee period without additional cost to the Owner. 3.6 CLEANUP: A. The premises must be kept free of accumulated materials, rubbish and debris at all times. Surplus material, tools and equipment must not be stored at the job site. At the completion of the job, all equipment and fixtures shall be left clean and in proper condition for their intended use. B. All motor control equipment and control panels shall be cleaned inside and out at the completion of the project. 3.7 TESTS: A. Testing for installed feeder cables and motors is required as specified in other Sections. Test reports shall be submitted to the Engineer prior to final acceptance. All tests shall be performed in accordance with the applicable sections of NETA. B. Where specified in the individual product specification section, factory tests shall be performed at the place of fabrication and performed on completion of manufacture or assembly. The costs of factory tests shall be included in the contract price. FOLLETT ENGINEERING, PLLC 16010-11 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 3.8 MAINTAINED OPERATION REQUIREMENTS: A. This pump station is an existing and operating facility. The pump station maintains level in the City's reservoir, which is the main source of supply for the west hill. The pump station must have at least one pump remain fully operational with two power sources available connected to a transfer switch during construction. The following are the base requirements. 1. During normal working hours (8am - 3pm weekdays) when the Contractor is physically at the site, the pump station may be completely shutdown one time per day, (only during the transition to the temporary equipment and from the temporary equipment to the new equipment) with no pumps running for up to 4 hours; Provided the City has at least 24 hrs notice prior to the shutdown. No shutdown will be allowed without prior authorization by the Owner. 2. During non-working hours, or when the Contractor is not physically at the site, the automatic controls and telemetry system must be fully operational with at least one pump running in AUTO. 3. Two sources of power are required for pump station operation. The Contractor shall supply an MTS and connection of the existing generator for the temporary operations. The two sources shall be two of the following: 1) utility power 2) existing standby generator or 3) contractor furnished trailer mounted generator. The Contractor is responsible to maintain and pay for the fuel for any generator operation during construction. 4. The existing on site generator can only be used for the primary power source while the Contractor is physically on site and during normal work hours. 5. Other than during the scheduled shutdowns described above, one pump must remain operational in hand or automatic mode with two sources of power connected to a transfer switch: Operation in HAND is only allowed during normal working hours. HAND operation shall be solely controlled by City personnel. 6. The controls and remote alarm and monitoring (telemetry) system must be fully operational at all times; unless specifically coordinated with the Owner. 7. The existing control/telemetry system must remain fully operational until the new system is installed and inspected and passes testing. B. The Contractor shall submit a detailed plan with timelines and dates for the transition of equipment at the pump station showing how 1 through 7 above will be accomplished. C. Existing electrical power and control equipment may be relocated and reconnected to the existing equipment for temporary operation during construction. D. Temporary control systems shall be tested by the Contractor with the Owner and Engineer present for approval. FOLLETT ENGINEERING, PLLC 16010-12 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 E. All changes in pump stations operations shall be directly coordinated with the Owner. All power outages shall be coordinated with the Owner and the Utility. F. The Contractor shall test the telemetry communications pump fail and power fail alarms — through the telemetry system every afternoon (before 3pm) and verify with the Owner office that the alarm is functioning. 3.9 EXAMPLE CONSTRUCTION SEQUENCE A. The following is an example method for construction sequencing and maintaining the pumpstation operations during construction. The Contractor has the responsibility to develop their own means and methods for construction sequencing, scheduling, coordinating and maintaining pumpstation operations. 1. See drawing E4 — Temporary Operation 2. Provide a temporary power pole with a 480V panelboard and 120/240V load center, MTS and utility meter for construction and temporary operation power. 3. Relocate the existing control panels to the North wall. 4. Pump 2 running on existing relocated equipment; two sources of power temporary utility power and existing generator connected to an MTS. 5. Remove existing power distribution equipment and pump 1 starter etc. on the East wall. 6. Install new power and controls equipment (MCP, Panelboards, ATS, Pump 1 VFD). 7. Pump 1 running on the new equipment and new utility service and test. 8. Remove pump 2 starter and install VFD and interface to the new control system.. 3.10 OPERATION AND MAINTENANCE MANUALS: A. The Contractor shall prepare and assemble detailed operation and maintenance manuals. The manuals shall be bound in a 3 ring binder and tabbed with an index, in general the O&M manual format shall meet that of the submittal data in this section. The manuals shall include, but not be limited to, the following: 1. Catalog data and complete parts list for all equipment and devices 2. All cut sheets of equipment and components. 3. Preventative maintenance procedures 4. Trouble-shooting 5. Calibration 6. Testing 7. Replacement of components 8. Automatic mode operation FOLLETT ENGINEERING, PLLC 16010-13 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ELECTRICAL GENERAL Project No. 17-7999.6 9. Manual mode operation 10. System schematics /shop drawings and record drawings. 11. As-built wiring diagrams of cabinet and enclosure contained assemblies 12. As-built wiring diagrams of overall system 13. Listing of recommended spare parts 14. Listing of recommended maintenance tools and equipment. 3.11 TRAINING: A. Training shall be provided per the specific requirements in other Sections of these specifications The Contractor shall conduct specifically organized training sessions in the overall operation and maintenance of the electrical system for personnel employed by the Owner. The training sessions shall be conducted to educate and train the personnel in operations and maintenance of all components of the electrical system outside the training requirements in the other Sections. Training shall include, but not be limited to, the following: 1. Preventative maintenance procedures 2. Trouble-shooting 3. Calibration 4. Testing 5. Replacement of components 6. Equipment operation B. Training sessions, shall be conducted at the facility after start-up of the system. The Contractor shall prepare and assemble specific instruction materials for each training session and shall supply such materials to the Owner at least 2 weeks prior to the time of the training. END OF SECTION FOLLETT ENGINEERING, PLLC 16010-14 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements DEMOLITION Project No. 17-7999.6 SECTION 16011 ELECTRICAL DEMOLITION PART1 GENERAL 1.1 DESCRIPTION OF WORK: A. This work shall consist of the removal or modifications and disposal, wholly or in part, of all electrical equipment, conduit and wire as stated or shown on the drawings or specifications to be removed. This also includes removal of or modifications to electrical equipment associated with structural and mechanical equipment shown to be removed on the drawings or stated in the specifications. 1.2 PROJECT DESCRIPTION DEMOLITION WORK INCLUDES: A. Removal of the utility service equipment, and associated wire and exposed conduits. • Utility metering • main service breaker B. Removal of the existing power distribution equipment and associated wire and exposed conduits. • 480V wire way • 120/240V transformer • 120/240V panelboard • Manual transfer switch (MTS) C. Removal of the existing control panels, motor starters and associated wire and exposed conduits: • Main control panel • PLC control panel • Communications cabinet • Pump 1 motor starter • Pump 2 motor starter D. Removal of the existing lighting, receptacles, unit heater and associated wire and exposed conduits. 1.3 DISRUPTION OF OPERATIONS: A. All demolition work shall be conducted so that disruption of the pump stations is minimal. Shutdown of equipment must be approved by and performed by the Owner. B. Any electrical or controls modification or removal work which interrupts any ongoing pump station process or system or is required to be done in a FOLLETT ENGINEERING, PLLC 16011-1 425-765-6304 Kent Pump Station No.3 Electrical System Improvements DEMOLITION Project No. 17-7999.6 specific sequence to accommodate project scheduling shall be coordinated with the plant operations staff and the Engineer. The Contractor shall submit a work plan for review, coordination, and approval by the Engineer. 1.4 CONTROLS / TELEMETRY REPLACEMENT A. With the exception of the scheduled shutdowns, The existing controls and telemetry system must remain operational during the entire construction process, the existing control and telemetry panels shall be relocated in an "out of the way place" and new control / telemetry equipment shall be provided. The existing components will not be transferred to the new panel. B. The controls and telemetry panel shall only be without power while the Contractor is on site. C. Once the new control system and telemetry system is operational, tested and accepted by the City, then the existing system can be removed. 1.5 INSPECTION A. Existing electrical equipment shall be inspected jointly by the Contractor and Owner / Engineer for proper operation and rating of devices installed. Any deficiencies such as corrosion or non-functional devices or incorrect or unacceptable wiring shall be established by the Contractor prior to relocation or modifications. Contractor agrees that the quality of the modified installation will equal or exceed that of the existing installation. 1.6 SUBMITTALS A. Submittals shall be provided for the work under this section to insure that modification work is fully planned and coordinated with the requirements of the operating the pump station. 1. The Contractor shall forward submittals for review for all modification work under this Contract that requires interruption of station process or control. No work shall be allowed to commence on any of this modification work until submittals are reviewed and approved by the Owner. 2. Submittals required under this section shall include the following information: a) A general description of the overall plan to switch over power and control. This description should outline the steps involved in the overall plan, the interruptions to power and control required, the duration of the interruptions, and the steps that will be taken to minimize the duration of the interruptions. b) The submittals should indicate the support and assistance required from the City's operations staff where applicable. c) The description should include any and all provisions for standby power whether Contractor supplied or existing standby power generator will be utilized. FOLLETT ENGINEERING, PLLC 16011-2 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements DEMOLITION Project No. 17-7999.6 d) The description should include consideration of the sequence of the modification work under this section with respect to other new or modification work specified elsewhere. The Contractor's plan shall indicate that the work under this section is coordinated with these other requirements. The description of work shall indicate testing requirements where called for under these specifications as part of the sequence of construction. e) Any other preparation work required of the Owner in conjunction with the Contractor's work shall be clearly described. 1.7 DISPOSAL OF PRODUCTS OF DEMOLITION: A. The Contractor shall dispose of all materials associated with demolition and removal, at a site of his choosing. The Contractor shall be responsible for obtaining any and all necessary permits and shall comply with applicable codes, laws, and standards. PART2 PRODUCTS Not Used. PART 3 EXECUTION 3.1 GENERAL DEMOLITION: A. The Contractor shall conduct all demolition operations to avoid damage to adjacent property and structures. All electrical equipment associated with structural or mechanical equipment shown to be removed on the drawings shall be removed as part of the demolition of the mechanical or structural equipment. 3.2 WIRE DEMOLITION: A. All wire associated with equipment to be removed shall be disconnected and removed from the equipment back to the furthest point of connection which does not effect any other equipment operation. 3.3 CONDUIT DEMOLITION: A. All conduit associated with equipment to be removed shall be disconnected and removed from the equipment back to the furthest J-box or panel which will not effect any other equipment. B. Conduit removal shall include removal of all supports, boxes, etc. associated with the conduit to be removed which does not effect the operation of any other equipment. FOLLETT ENGINEERING, PLLC 16011-3 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements DEMOLITION Project No. 17-7999.6 c. If first approved by the Engineer, conduit that is to be demolished may remain if the Contractor can present (to the satisfaction of the Engineer) that the conduit can be used for new wire or equipment to be installed. 3.4 OTHER RELATED EQUIPMENT A. All motor starters, switches, control panels, and mounting stands shall be removed unless their removal impacts equipment that is to remain in service or is specifically noted for future service. Conduits where stubbed up to equipment being removed, relocated, or re-circuited and not being reused shall be removed. B. Holes left in floors or walls by removal of existing electrical equipment shall be filled and patched and finished to match the existing conditions. 3.5 PANEL DEMOLITION: A. Panels designated for demolition shall be removed or moved and reconnected for temporarily operation of equipment and tested where necessary. 3.6 MOTOR DEMOLITION: A. Motors designated for demolition shall be removed or moved and connected for temporarily operation of equipment where necessary. Provide temporary starters and control equipment if necessary for continued operation during construction. 3.7 CONDUIT RELOCATION: A. Existing conduit which interferes with new equipment shall be rerouted around the new equipment. 3.8 TEMPORARY INTERCONNECTIONS A. GENERAL: 1. Temporary interconnections shall be provided as required to maintain power, control, and signal during construction which involves demolition of existing raceway systems or modifications to process control. As a minimum requirement, temporary interconnections shall conform to the requirements of NEC Article 305. B. WIRING METHODS AND MATERIALS: 1. POWER, CONTROL AND SIGNAL (EXCEPT FIBER-OPTIC): Temporary interconnections which extend outdoors or between rooms indoors that are subject to damage shall be made with C-L-X or Teck type armored cable and shall be of construction approved for direct- burial and wet locations. Where required by existing area classifications, cables and termination fittings shall be approved for installation in classified locations. FOLLETT ENGINEERING, PLLC 16011-4 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements DEMOLITION Project No. 17-7999.6 2. MECHANICAL PROTECTION: Temporary interconnections shall be protected from mechanical damage, particularly where passing through pinch points, where subject to vehicular traffic, or in heavy construction usage areas. C. REMOVAL OF TEMPORARY INTERCONNECTIONS: 1. All temporary interconnections shall be removed following the testing and acceptance of the permanent connections for any given equipment or system described in the specifications. 3.9 INSTALLATION A. All modifications to existing electrical equipment specified in this section shall be performed in strict accordance with the recommendations of the equipment manufacturer. Nothing herein shall be construed to relieve the Contractor of his responsibility for this portion of the work. B. Fill all holes on the walls from removed components with plaster and finish for a smooth surface. 3.10 TESTING A. After completion of installation, all relocated or modified electrical and controls shall be field tested to demonstrate compliance with the required performance. Testing shall be in accordance with other sections of this specification. 3.11 EQUIPMENT TO BE RETAINED BY OWNER: A. Equipment designated to be retained by the Owner shall be transported to and unloaded at the Owner's designated storage site or prepared for shipment and loaded on the Owner's truck for storage off the immediate property. Equipment to be retained by the Owner is as follows: 1. Existing PLC cabinet and all contents END OF SECTION FOLLETT ENGINEERING, PLLC 16011-5 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 SECTION 16145 MISCELLANEOUS ELECTRICAL PART1 GENERAL 1.1 DESCRIPTION OF WORK: A. This section covers furnishing and installing miscellaneous electrical devices and equipment and other wiring devices indicated on the drawings. 1.2 STANDARDS AND CODES: A. All materials and equipment specified herein shall within the scope of UL Examination Services, be approved by the Underwriter's Laboratories for the purpose for which they are used and shall bear the UL label. B. All materials and equipment specified herein shall conform to all applicable NEMA, ANSI and IEEE standards. C. All materials and equipment specified herein and their installation methods shall conform to the latest published version of the National Electric Code, N.E.C. 1.3 COORDINATION A. The Contractor is responsible for coordination of mechanical equipment, fans, louvers, heaters, motors, starters, etc. and the electrical power and control requirements. Provided in this section and other sections of the specifications and drawings. B. The Contractor shall provide power and control equipment, wiring, and raceways to meet the requirements of the mechanical equipment supplied. C. The Contractor shall verify as a minimum: 1. Correct voltage, phase and frequency 2. Correct motor starter type 3. Proper coordination with the controls and control system Integrator. D. The Contractor shall provide all necessary control wiring and components for any special requirements from an equipment manufacturer. E. Any discrepancies between the electrical and mechanical equipment shall be brought to the immediate attention of the Engineer. FOLLETT ENGINEERING, PLLC 16145-1 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 1.4 SUBMITTALS: A. In accordance with the "submittals" requirements in Section 16010, submit catalog data showing material information and conformance with specifications. The intended use of each item shall be indicated. B. Submittal documents shall be submitted via E-mail in PDF format. Separate Submittal a-mails shall be provided for each spec section. All products for each Spec section shall be included in a single PDF document including the cover sheet and index in one single document. submittals shall be indexed and identified as follows: 1. Email subject line shall be "project name, EI&C submittal submittal #, spec section#- description." 2. Cover sheet with: a) The project name and submittal # b) Contractor's and sub-contractor's name, phone number, and email address. c) Index sheet showing each product being submitted. 3. PDF index tabs per the electrical specifications by section and paragraph or equipment name e.g. provide a minimum of one tab section for each piece of equipment in all of the PART 2 PRODUCT Sections 2.01 - 2.**. C. A copy of this specification section, with addendum updates included, and all referenced and applicable sections, with addendum updates included, with each paragraph check-marked to indicate specification compliance or marked to indicate requested deviations from specification requirements. Check marks (�) shall denote full compliance with a paragraph as a whole. If deviations from the specifications are indicated, and therefore requested by the Contractor, each deviation shall be underlined and denoted by a number in the margin to the right of the identified paragraph, referenced to a detailed written explanation of the reasons for requesting the deviation. The Engineer shall be the final authority for determining acceptability of requested deviations. The remaining portions of the paragraph not underlined will signify compliance on the part of the Contractor with the specifications. Failure to include a copy of the marked-up specification sections, along with justification(s) for any requested deviations to the specification requirements, with the submittal shall be sufficient cause for rejection of the entire submittal with no further consideration. D. For motors on VFDs submit verification that the installation is approved by both the VFD and motor manufacturer — submit on any line terminators or filters that the manufacturer's recommend for the application. E. Provide all electrical information — wire diagrams, terminal information and numbering and electrical / power data. F. Submit verification that stainless steel hardware will be used as required by this specification. FOLLETT ENGINEERING, PLLC 16145-2 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 PART 2 PRODUCTS 2.1 RACEWAYS 2.1.1 GENERAL A. All wiring shall be installed in raceways B. Ground Conductor: 1. All raceways shall contain a minimum of one continuous copper equipment grounding conductor sized in accordance with the N.E.C. 2.1.2 AREA CLASSIFICATIONS: A. The following classification of areas shall be used as a reference in determining application of material covered by this Section unless specifically shown otherwise on the drawings. Areas which fall under two or more of the following classifications shall conform to the minimum requirements of all of the area classifications listed for that area. B. Hazardous area classifications shall be defined by: • NEC Article 500 • NFPA 820 for all waste water facilities. C. Hazardous Areas: None D. Outdoor and Damp Areas: 1. All outdoor areas, pump room a) Raceway shall be rigid galvanized steel (GRS), Intermediate Metal Conduit (IMC). Conduit entrances shall be threaded and fittings shall have gasketed covers. b) Threaded fastening hardware and rods shall be 316 stainless steel. Raceway supports such as channel, clamps, and brackets shall be 316 stainless steel or aluminum or non-metallic. c) Panels and boxes shall be NEMA 3R outdoors and NEMA 12 indoors - aluminum, stainless steel or non-metallic (or as shown on the drawings). Device boxes shall be cast, copper free aluminum. E. Corrosive Areas: None 2.1.3 RACEWAY APPLICATION: A. Unless otherwise shown on the drawings, ABOVE GRADE CONDUITS shall meet the requirements of the "area classification" listed above and shall be: a) GRC, or IMC, for power and control wiring b) GRC, or IMC for signal & communications wiring. B. Unless otherwise shown on the drawings, CONDUITS BELOW GRADE shall be: a) Schedule 40 PVC for power and control wiring - GRC, as listed below: FOLLETT ENGINEERING, PLLC 16145-3 425-765-6304 Kent Pump Station No.3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 • Sweeps and risers for transition of PVC from below grade to above grade shall be GRC. C. ALL CONNECTIONS TO VIBRATING EQUIPMENT or motors shall be: a) liquidtight flexible metallic conduit for indoor, non corrosive areas and all motor leads from VFD's. b) Connections to equipment outdoors or in corrosive areas shall be with non metallic liquidtight flexible conduit (except for motor leads from VFD's shall be flexible metallic.) D. All raceways materials, sizes, etc. for UTILITY SERVICE shall be per the serving utilities requirements. 2.1.4 CONDUIT: A. Galvanized Rigid Steel Conduit (GRC): 1. Rigid conduit shall be steel, galvanized. Terminations shall be by means of threaded hubs or double locknuts and insulating grounding type bushings. B. Intermediate metal conduit (IMC): 1. Intermediate metal conduit shall be of steel and shall be galvanized. Fittings shall be threaded. C. Flexible Conduit (LFS): 1. Flexible conduit shall be interlocking single strip, galvanized and shall have a polyvinyl chloride jacket extruded over the outside to form a flexible watertight raceway. Non-metallic flexible conduit shall have non metallic threaded fittings. D. Nonmetallic Conduit(PVC): 1. Nonmetallic conduit shall be rigid PVC, Schedule 40 or 80. PVC installed above grade shall be UV resistant schedule 80. Fittings shall be of the same material as the raceway and installed with solvent per the manufacturer's instructions. Conduit, fittings and solvent shall all be manufactured by the same manufacturer. 2.1.5 BOXES AND FITTINGS: A. General 1. Materials for fittings shall be chosen to satisfy the requirements of - Area Classification described above. 2. Junction boxes, terminal boxes, device boxes, fixture support boxes, oblong, round and rectangular conduit fittings (condulets) shall be of the same material as required by the Area Classification for the raceway. 3. Boxes larger than 9"x9" shall be hinged. 4. Cast fittings and boxes shall be: a) zinc electroplated cast ferrous alloy:. FOLLETT ENGINEERING, PLLC 16145-4 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 b) Integrally cast threaded hubs or bosses shall be provided for all conduit entrances and shall provide for full 5 thread contact on tightening. Drilling and threading shall be done before finishing. c) The cover plate shall be of similar cast ferrous alloy material and finish. A full body neoprene gasket shall be provided with the cover. Stainless steel screws shall be provided for all covers. 5. All screws, nuts, bolts, straps, rods and other hardware used with supports, fittings and boxes shall be 316 stainless steel. 2.1.6 SPARE PARTS BOX: 1. Provide one spare parts NEMA 12 Box — wall mounted with at least 5 shelves 18" wide, 36" tall and 9" deep minimum size. 2. Provide labels on spare parts boxes or on shelves for the spare parts called out for the project. 2.1.7 CONDUIT&CABLE SUPPORTS: A. Rivet-type or Zamac fasteners are not allowed. All fasteners between channel, strut, etc. and walls shall be removable with a screwdriver. B. Support materials in general purpose areas may be hot-dip or electro-ga Ivan ized. All support materials used in damp areas, pump rooms, or outdoor, or corrosive areas shall be NEMA 4x Aluminum, Stainless steel, or non-metallic. C. All screws, nuts, bolts and other hardware used with conduit and cable supports shall be 316 stainless steel. 2.2 CONDUCTORS: A. All conductors shall be stranded copper. Insulation shall be THW, THWN, or THHN, chosen to satisfy environmental conditions. Conductors used for power circuits shall not be smaller than No. 12. Control conductors may be No. 14. 2.3 SHIELDED SIGNAL CABLE: A. Signal conductor cable shall be AWG #16 individually twisted, shielded pairs. BELDEN #8719, or equal. Conductors shall be tinned copper with color coded 90 degrees C PVC insulation and individual conductor jacket of nylon. Shielding shall be aluminum polyester 100% shield coverage with drain wire. The cable shall have an overall PVC jacket. The insulation system shall be rated for 300 volts. B. For applications where 600 volt insulation is required, use 1. BELDEN 1120A 2. #18 TWSP, stranded wire. C. 600 volt insulated signal wire shall only be used where required by Code. FOLLETT ENGINEERING, PLLC 16145-5 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 2.4 CONNECTORS A. All wiring shall be continuous from point to point — no splices of any kind are allowed. All control and signal wire shall land on numbered terminals. B. Ideal Industries "Wing Nut" or 3M Company "SCOTCHLOCK" pre-insulated connectors may be used for general purpose lighting and receptacle circuits for splices and taps in conductors No. 10 AWG and smaller. For No. 8 AWG and larger conductors, utilize T&B compression connectors. Compress using recommended die and tools. C. For connections of wire to cord to removable equipment provided with integral cords (such as floats, transmitters, limit switches, aerators, submersible pump motors, etc.) Provide junction box with terminals and spade/lug type terminations and coat with liquid insulation — Performix Liquid Tape or equal. D. For connections of wire to cord to Submersible motors of all size wire use a water proof motor stub insulator. Thomas and Betts multi splice insulator MSLT112-4 or equal. 2.5 SPLICE INSULATION: A. Splice insulation shall be equal to the conductor utilized. B. Insulate all permanent splices that are underground or in damp or corrosive environments with cast epoxy type insulation which covers the jacket of all cords and the insulation on all wire. Epoxy splice shall be Scotch #3570 or equal. 2.6 MOTOR TERMINAL SPLICE INSULATION: A. Provide motor terminal splice insulation in the motor connection box that will withstand constant vibration and abrasion without degrading the insulation of the splice. A product shall be used that is specifically designed for the purpose of motor terminations 2.7 WIRE MARKERS: A. Field installed wire markers shall be pre-printed, heat shrink type sleeves, Thomas&Betts Type HVM, Tyton Type THS or approved equal. See paragraph below for marking requirements. 2.8 SWITCHES AND RECEPTACLES: A. Standard wall switches shall be single-pole, or double-pole, three-way, as shown on the drawings or as required for the application. Switches shall be AC quiet type rated 20 amp, 125/277 volt with screw terminals. Wiring devices shall be ivory colored for general use office areas, and black when installed in mechanical rooms or when mounted on dark walls. Receptacles on emergency or backup power shall be labeled or color coded. ARROW HART, BRYANT, HUBBELL, P&S or equal. B. Weather proof switches for use in damp, corrosive or outdoor applications shall be FOLLETT ENGINEERING, PLLC 16145-6 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 • Die cast aluminum housing with lever type switch CROUSE-HINDS, DS 185 • or non metallic, UL marine listed, CARLON, E98TSC or equal. C. Weather proof receptacles for use in damp, corrosive or outdoor applications shall be • Die cast aluminum with spring and gasketed covers CROUSE-HINDS, WL series • or non metallic, CARLON or equal. D. Provide GFI receptacles where required by the NEC. E. Per the nameplate requirements, provide circuit and panel data labels on all switches and receptacles and label all light switches with function. 2.8.2 PLATES: A. Scope: Provide plate for each wiring device, for each signal or communication outlet. B. Device plates on flush devices, in general, shall be satin finish stainless steel Sierra 302 stainless steel line or approved equal, modern classic design, corrosion resistant. Special finish plates shall be provided to match special paneled walls as directed by Architect. C. Device plates for switches and receptacles in outdoor areas shall have weatherproof plates with hinged cover and stainless steel screws. Sierra Electric WP series or equal. D. Plates on exposed wiring shall be of metal, of the same manufacture as the conduit fittings; specifically suited for device and fitting used. E. Blank, Bushed or Special Outlet Plates: Provide for all signal communication system outlets as required. 2.8.3 SPECIAL ACCESSORIES 1. Provide accessories such as junction boxes, outlet boxes, etc. necessary to mount switches and receptacles in a proper and approved method. 2.9 HEATING AND VENTILATING EQUIPMENT 2.9.1 UNIT HEATERS A. Choose appropriate heater for the voltage and capacity as shown on the drawings. Heaters shall be resistance type with totally enclosed fan motor. Provide necessary auxiliary control equipment for complete operation as shown on the drawings. Provide all necessary mounting hardware for installation. B. Provide separate thermostats for all unit heaters. Provide with local disconnect if required by code. All thermostats shall be heavy duty, industrial grade and shall include setpoint numbers on adjustable dial. FOLLETT ENGINEERING, PLLC 16145-7 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 C. Unit heaters shall be provided with integral 24V control transformer. Provide heavy duty magnetic contactors for all 3 phase heaters and for all single phase heaters larger than 5KW. D. Provide with thermal cutouts for disconnecting power if overheating occurs. E. GENERAL PURPOSE UNIT HEATERS - Provide unit heaters as shown on the drawings. Unit heaters shall be Chromalox Type LUH or equal. Provide with remote thermostat Chromalox WR-80, WT, WTL chosen for the application or equal. 2.9.2 THERMOSTATS A. For general purpose areas provide heaters and fans with remote thermostat Chromalox WR-80, WT, WTL chosen for the application or equal. 2.10 DRY TYPE TRANSFORMERS A. Dry type transformers shall be constructed of heavy gauge sheet steel. Coil and terminal chamber shall be constructed with guarded opening for ventilation and convection cooling. Transformer shall be connected for the application. Unless otherwise shown or required for the application, primary coil shall be delta connected, secondary coil wye connected. B. Separate primary and secondary windings shall have Class H insulation and shall be rated for continuous operation at rated kVA with temperature rise of not over 150 degrees C above a 40 degree C ambient, with a maximum hot spot temperature of 220 degrees C. Windings, core and coil assembly shall be treated and built to resist the effects of dirt and moisture. C. Unless otherwise noted or shown, transformers shall be provided with a minimum of four full capacity taps, minimum of two 2-1/2 percent above and two 2-1/2 percent below normal (rated) primary voltage. D. Transformers furnished shall have a continuous rating of not less than the size noted on the drawings. E. The secondary neutral terminal on three-phase K-rated transformers shall be sized for 200% of secondary phase current. F. Provisions for external connections shall be made by means of a terminal board employing lugs compatible for the external conductors to be installed. G. The core of the transformer shall be grounded to the enclosure by means of a flexible grounding conductor sized in accordance with applicable NEMA, IEEE ANSI standards. H. Provide grounding per NEC. I. Provide enclosures per the requirements of the area installed — NEMA 3R for outdoor and damp areas, NEMA 12 for indoor areas J. Acceptable manufacturers for dry type transformers shall be General Electric, Cutler Hammer, Square D, Heavy Duty and approved equals. FOLLETT ENGINEERING, PLLC 16145-8 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 2.11 PANELBOARDS A. Panelboards shall be rated at proper voltage and current for intended use with bus bars of tin plated copper or aluminum. Panels shall have phases, voltage and current ratings as shown on the drawings. Panels shall have 100 percent neutral, with equipment ground bar, unless noted otherwise. Panelboards shall be dead front. B. Panels shall have as a minimum the number of circuits shown on the panel schedules on the drawings. C. The following interrupting capacity shall be considered minimum. Other ratings shall be as specified on the drawings. 1. 240V and 208Y/120V— sub-fed Panelboards 10,000 AIC symmetrical 2. 240V and 208Y/120V— Service Panelboards 20,000 AIC symmetrical 3. 480V Panelboards 30,000 AIC symmetrical D. Provide service entrance rated panelboards where shown on the plans or required by the NEC. E. Provide enclosures per the requirements of the area installed — NEMA 3R for outdoor and damp areas, NEMA 12 for indoor areas or as shown on the drawings. F. Mount breakers in all panelboards so that breaker handles operate in a horizontal plane. Circuit breakers shall be bolt-type only. Provide common trip on all multiple pole breakers. G. Where noted, provide spare breakers, complete for future connection of wiring circuits. Where "Space Only" is indicated for breakers, provide all bussing and breaker mounting hardware in the panelboard; provide steel knockouts in dead front metal closure of unused part of panel. If any steel knockouts are removed, provide breakers in such spaces or approved cover plates. Open spaces are not permitted. H. Panelboards shall be flush or surface as indicated; tight closing doors without play when latched. Where two cabinets are located adjacent to each other in finished areas, provide matching trim of the same height. I. Provide cabinets of sufficient dimensions to allow for future expansion and addition of circuit breakers within the panelboards as indicated on drawings. J. Provide lock for each cabinet door. All Electrical distribution equipment locks to be keyed identically. K. Fasten panelboard with machine screws with oval countersunk heads, finish hardware quality, with escutcheons or approved trim clamps. Clamps accessible only when dead front door is open are acceptable. Surface mounted panelboards with fronts greater than 48 inches vertical dimension shall have trim hinged at right side in addition to hinged door over dead front. L. Provide factory standard lacquer or enamel finish, ASA#49 gray. FOLLETT ENGINEERING, PLLC 16145-9 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 M. Provide Surge arrestors , with indicators, where shown on the one-line diagrams to protect against overvoltage transients. JOSLYN J9200 series with protective capacitor GE model 91_18 or equal. Select proper components for the application as shown on the drawings. N. Numbering and buss arrangement shall be as shown on the Panel Schedules on the drawings. O. Provide a type written circuit directory card for each panelboard with the load name, number, location and kVA. P. Provide engraved (color layer - engraved through outer layer) plastic name plate with 1/2 inch high characters for panel identification (for panel name); attached with stainless steel screws to each panelboard front. Emergency system - white on red; Normal system - black letters on white. Include voltage, phase and wire (i.e., 208Y/120V, 3 phase, 4 wire ) in 3/8 inch characters. Q. Secure in place with top of cabinet at 6' - 6", unless otherwise noted. Top of cabinet and trim shall be level. R. For each branch circuit panelboard: Provide neatly type written as-built information for each panelboard by circuit with its proper load designation. Mount the panelboard circuit directory inside the door of each panelboard in a clear plastic sleeve. Provide one spare blank card for each card used. S. Close all openings in dead front with closures manufactured for the purpose or install spare breakers. T. SURGE SUPPRESSION: 1. Where surge suppressor (SPD or TVSS) is specified or shown on the drawings, provide integral surge suppression device with the following minimum characteristics: a) Surge Current per phase — 120kA b) Surge Current L — N 60kA c) IEEE C3 Wave (10kA) — 9,000 2. Unit shall have overcurrent protection, infrared and thermal detection - Include diagnostic package and direct bus bar connection and 10 year warranty — Cutler Hammer Clipper CPS-S or equal. 2.12 FUSES: A. Fuses shall be of the type and amperage indicated on the drawings. The voltage rating shall be appropriate for the application indicated. The fuse types indicated on the drawings imply a certain set of fuse characteristics. No substitutions of fuse types will be allowed without written approval from the Engineer. B. All fuses used on the project shall be provided with "blown fuse" indicators. C. Where fuses in motor circuits are indicated but not sized, provide Manufacturer's recommended fuse size based on actual motor installed. FOLLETT ENGINEERING, PLLC 16145-10 425-765-6304 Kent Pump Station No.3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 D. Provide in-line or integrally-mounted fuse clips on control power or low-voltage transformer. E. Provide fuse puller or pullers for fuse sizes used. F. Provide surface mounted cabinet, sized to store required spare fuses at location coordinated with Owners Representative. G. Provide a minimum of two spare fuses for each fuse used. H. Acceptable Manufacturers: 1. BUSSMAN 2. GOULD SHAWMUT 3. LITTLEFUSE 4. RELIANCE 2.13 MOLDED CASE CIRCUIT BREAKERS: A. Molded case circuit breakers shall be quick-make and quick-break type. They shall have wiping type contacts. Each shall be provided with arc chutes and individual trip mechanisms on each pole consisting of both thermal and magnetic trip elements. Two and three pole breakers shall be common trip. All breakers shall be calibrated for operation in an ambient temperature of 40 degrees C. Molded case circuit breakers shall be trip-free. Each breaker shall have trip indication independent of the ON or OFF positions. B. Breakers shall have lugs UL listed for both copper and aluminum. C. Circuit breakers shall be capable of accepting the cable shown on the drawings. Circuit breakers not capable of accepting the cable shown shall not be acceptable. D. Breakers shall have the interrupting rating and trip rating indicated on the drawings. E. All breakers that serve motor loads shall be provided with disconnect handle mechanism to lock out the circuit in the open position 2.14 DISCONNECTS: A. Provide local equipment disconnects only if required by the manufacturer or NEC. B. Disconnect's rating shall be chosen by the Contractor to meet the requirements of the equipment served. C. Switch shall be heavy duty type, shall be quick-make quick-break and shall be horsepower rated. Switch shall have blades as required to open all ungrounded conductors and shall be single throw unless noted. D. Enclosure shall be suitable for location in which mounted. 1. Enclosures located outdoors or in damp or corrosive areas shall be NEMA 4X, aluminum or stainless steel. FOLLETT ENGINEERING, PLLC 16145-11 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 E. Fusible disconnects shall be as above with addition of fuse space and clips to accept Class R fuses. Use only where required by equipment manufacturer to meet UL installation requirements. F. Disconnects for motor loads shall be lockable in the open position 2.15 MOTORS 2.15.1 GENERAL A. Unless specifically accepted, all motors shall be of the "energy efficient" or "energy saver" type which meet the minimum efficiencies required by the Washington State energy codes. 1. All Motors shall be suitable both electrically and mechanically to drive the connected equipment under any and all modes of operation without exceeding the FLA (Full Load Amps) rating of the motor. B. All motors shall be suitable for the environment in which they are to be installed. The environment in which motors will be installed in this project will be 100% humidity continuously. C. Motor voltages shall be chosen to meet the requirements of the electrical system. The Contractor shall choose the motor voltages to meet what is shown on the plans. D. Motor enclosures shall be totally enclosed fan cooled (TEFC) unless otherwise specified or required by the environment installed. Provide explosion proof non- ventilated - (XPNV) or fan cooled (XPFC) motors in hazardous areas. E. All single-phase motors shall be self-protected. Single phase motors shall be provided with start capacitors if necessary for proper operation of the motor. The start capacitors shall be located within the motor housing. F. Enclosed Motors: Provide drain plugs for non-explosion proof motors and drain and breather for explosion proof motors. G. Finish: Provide a prime and final finish of the manufacturer's standard colors. H. Provide imbedded thermostats for thermal alarm or motor cut out for all motors 40 Hp and above unless otherwise shown. I. Provide a terminal connection box two sizes larger than normal to allow extra room for motor feeder splices. Refer to Motor Terminal Splice Insulation requirements. J. Provide NEMA Class B insulation, minimum, with additional nonhygroscopic moisture protection which will maintain a minimum resistance of 1.0 megohms after 168 hours of exposure at 100% humidity. K. Provide motors with a 1.15 service factor at maximum motor operating load. 2.16 HARDWARE A. The Contractor shall provide any necessary hardware for mounting equipment and devices. The mounting hardware shall be made of materials suitable for the FOLLETT ENGINEERING, PLLC 16145-12 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 environment installed. Provide materials made from aluminum, non-metallic, or stainless steel in outdoor, damp, or corrosive areas. PART 3 EXECUTION 3.1 GENERAL A. Provide services of an authorized representative of manufacturer to visit site of work and inspect, check, adjust if necessary, and approve equipment installation. B. Assure that equipment manufacturer's representative is present when equipment is placed in operation. C. Verify that equipment representative revisits job site as often as necessary until all trouble is corrected and equipment installation and operation are satisfactory, in opinion of Engineer. D. Verify that motor overcurrent protection is in accordance with the N.E.C. E. Verify the motor protection and control is in accordance with the equipment manufacturers requirements. 3.2 WIRE & RACEWAY SIZING A. The contractor shall size wire per NEC for the load being served. Raceways shall be sized per NEC for the wire or cables installed. Scheduled raceways and wire sizes are minimum size and contractor shall upsize if required for installation per the NEC. B. Size pull and terminal boxes per NEC. Pull box sizes, if shown on the drawings, are minimum size and the contractor shall upsize if required by NEC. 3.3 OUTLETS AND SWITCHES: 3.3.1 GENERAL A. For all receptacles, switches, and other related devices of the lighting and receptacle system, provide all necessary raceway and wire for a complete installation. B. Center all outlets with regard to building lines, furring and trim. Symmetrically arrange outlets in the room. Satisfactorily correct outlets improperly located or installed. C. Set outlets plumb and extend flush outlets to the finished surface of the wall, ceiling or floor without projecting beyond same. D. Install symmetrically all receptacles, switches and outlets shown on the trim and where necessary, set the long dimension of the plate horizontal or gang in tandem. FOLLETT ENGINEERING, PLLC 16145-13 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 E. Outlets in outdoor areas or wet areas shall be GFI — provide GFI outlets in other areas as required by Code. 3.3.2 MOUNTING HEIGHTS: A. Unless otherwise noted, wall mounted outlet devices shall generally be 24 inches above the floor, 18" in architecturally treated areas. In basement, underground or in areas subject to flooding, outlets shall be 36" above the floor. B. Switches shall be mounted 48 inches above the floor. C. Outlets mounted over work tables, desks and counters shall be 2"- 6" above the work surface. 3.4 RACEWAYS 3.4.1 GENERAL A. Not all conduits/raceways are scheduled. Wire diagrams and oneline diagrams show wiring requirements. Provide all necessary raceways for wiring as shown on the drawings. B. For all power and control equipment, provide all necessary raceways and wire per plans and specifications even if not specifically shown on the plans. C. Raceway routing shown on plans is general in nature, unless otherwise indicated on the drawings, the Contractor shall be responsible for determining conduit routing that conforms to the installation requirements required by the plans and specifications. D. The number of directional changes of a conduit shall be limited to 270 degrees in any run between pull boxes. E. Conduit runs shall be limited to a maximum of 400 feet, less 100 feet or fraction thereof, for every 90 degrees of change in direction. F. In general, conduit inside structures shall be exposed unless otherwise specified or indicated on the drawings. No conduit shall be exposed in water chambers unless so indicated on the drawings. G. Provide raceways/conduits per the conduit and wire schedule and additional as necessary to meet the requirements of the wiring. H. Scheduled conduit sizes are minimum. Contractor shall upsize conduits if necessary or if required by the NEC. I. Non scheduled conduits shall be a minimum of 1/4" or sized per the NEC for the wiring installed plus 20%. J. Conduit across structural joints where structural movement is allowed shall have an O-Z "Type DX" or Crouse-Hinds "Type XD," bonded, weathertight expansion and deflection fitting of that conduit size. FOLLETT ENGINEERING, PLLC 16145-14 425-765-6304 Kent Pump Station No.3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 K. Separate conduits of different voltages by a minimum of 2" — separate signal wire conduits from all other types of conduits by a minimum of 6". L. All conduits shall be a minimum of 3/4". M. Conduits entering underground structures shall be made water tight — see "handholes and Vaults"for more requirements. 3.5 WIRE AND CABLE INSTALLATION A. Splices in power and control and signal wires or cables is not allowed. All wire transitions shall be done on terminals. B. Keep all conductors within the allowable tension limits during installation. Lubricants for wire pulling, if used, shall be approved for the insulation and raceway material. Observe cable manufacturer's and industry standard cable bending radius recommendations. 3.6 WIRE AND CABLE TERMINATION: 3.6.1 GENERAL A. Power conductors, No. 8 AWG and larger may be terminated directly in box-type lugs. B. Solid conductors (when allowed for lighting and receptacle circuits ) of#10 and #12 may be directly terminated to screw terminals. C. For any power, control, or signal wire terminating on screw type terminals; provide spade or ring tongue type terminations. D. Stranded control conductors may be directly terminated in box type terminals at control panels. Insulated terminals shall be used also on all stranded instrumentation wiring. E. Terminal boxes shall be provided at instrument cable splices. If cable is buried or in raceway below grade at splice, an instrument stand shall be provided as specified with terminal box mounted approximately 3 feet above grade. F. Special instrumentation cables shall be terminated in accordance with the recommendations of the manufacturer of the equipment and subject to review by the Engineer. G. No splices shall be used in power, control and/or signal wiring. The wiring shall be continuous from point-to-point. Extending existing cables will not be allowed except where shown on the drawings. 3.6.2 TERMINAL MARKING: A. All terminals in instrument and relay compartments, motor control centers, in control panels, instrument panels, field panels and control stations, as well as connections to mechanical equipment shall have reference number and letter in accordance to the following. FOLLETT ENGINEERING, PLLC 16145-15 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 • h = Control power hot (usually 120v or 24v) • n = neutral • g = ground • c = control (use if none of the above letters apply) • p = power (usually 480v) • s = signal (usually 4-20ma or 1-5v ) (use if none of the above letters apply) • B = DC + and — 3.6.3 WIRE MARKING: A. All power and control conductors shall be tagged; including conductors in instrument and relay compartments of motor control centers, in control panels, instrument panels, field panels and control stations, as well as connections to mechanical equipment, shall be tagged at each end with legible, permanently coded tight fitting wire-marking sleeve showing the complete wire designation. B. Wire marking lettering shall be bold and type written. C. Wiring within a single enclosure shall be marked with the basic wire and terminal number at each end. D. Control and signal wires shall have wire numbers that relate to the control wire drawing number— panel shop drawings. E. All field wiring shall have wire labels at each end. The labels shall be marked with the output terminal number at the original equipment (control panel, MCP, RCP, LCP or MCC) or remote device terminal # (if applicable). F. For wire that terminates in at a control panel at both ends or a control panel and an MCC, the priority for the numbering shall be as follows 1. MCP 2. RCP 3. MCC 4. LCP END OF SECTION ATTACHMENT: ELECTRICAL SYSTEM TEST REPORTS FOLLETT ENGINEERING, PLLC 16145-16 425-765-6304 Kent Pump Station No.3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 16145 ELECTRICAL SYSTEM TEST REPORT -600V CABLE ELECTRICAL SYSTEM DESCRIPTION DATA SERVICE DESCRIPTION: nominal voltage, phase to phase phase to neutral - single or three phase- number of conductors SERVICE CONDUCTORS: phase size and insulation type neutral size and insulation type ground size and insulation type SERVICE DISCONNECT DESCRIPTION: circuit breaker or disconnect switch size (amps) fuse (amps) MEASURED CONDITIONS DATA Operating Load Voltage Volts Vab Vbc Vca Van Vbn Vcn Operating Load Feeder Current Amps la lb Ic Conductor Insulation Megohms a-b b-c c-a Resistance (record the indicated measurement for each of the Megohms a-g b-g c-g following circuits:) 1. Service Feeder 2. Pump Feeders 16145-17 12/18/2018 4:14 PM Kent Pump Station No. 3 Electrical System Improvements MISCELLANEOUS ELECTRICAL Project No. 17-7999.6 16145 - MOTOR DATA AND TEST REPORT EQUIPMENT NAME AND NUMBER: EQUIPMENT SPECIFICATION SECTION: MOTOR STARTER LOCATION CONTRACTORS REPRESENTATIVE DATE MOTOR NAMEPLATE DATA MFR Name/Model No. Voltage/Phase/HP FLA/LRA Service Factor Efficiency Index (or percent) NEMA Design Code Letter Insulation Type Temperature Rise Ambient Temperature RPM Enclosure Thermal Trip Setting Space HTR: Watts/Volts Other Data MOTOR STARTER INFORMATION Manufacturer/Type Overload Heater No * RECORDED FULL LOAD DATA VOLTS A-G B-G C-G FULL LOAD OPERATING VOLTAGE VOLTS A-B B-C C-A FULL LOAD OPERATING CURRENT AMPS A B C INSULATION RESISTANCE MEGOHMS A-G B-G C-G (deenergized) MOTOR CIRCUIT RESISTANCE OHMS A-B B-C C-A * VOLTAGE & CURRENT READINGS SHALL BE TAKEN AT THE CLOSEST ACCESSIBLE POINT TO THE LOAD END OF SECTION 16145-18 12/18/2018 414 PM Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 SECTION 16201 LOAD TRANSFER SWITCHES (ATS) PART1 GENERAL 1.1 DESCRIPTION OF WORK A. This section provides equipment and installation for load transfer switches automatic transfer switch (ATS). B. Automatic system load transfer switch shall be supplied by the System Integrator (See section 16921) as an integral component of the control system. The switch shall be rated for use as service entrance equipment C. Transfer switch shall be well documented with clear wiring diagrams and submittals shall include wiring diagram showing clearly all connections for field wiring with terminal numbering. 1. See wire diagrams in the bid documents for additional field wiring and control requirements. D. The Electrical Control System Integrator (see Section 16921) shall be responsible for the design and coordination of the required control features and field wiring interface between the transfer switch and the control system, Including all Related equipment as shown on the drawings and as specified herein. The Electrical Contractor shall be responsible for installing the Automatic transfer switch, interconnecting wiring and all related equipment per Control System Integrators design. E. Provide indicating lights, switches, meters, nameplates, and controls as shown on the drawings and specified herein. 1.2 STANDARDS AND CODES A. All materials and equipment specified herein shall within the scope of UL Examination Services, be approved by the Underwriter's Laboratories for the purpose for which they are used and shall bear the UL label. They shall be listed at the AIC ratings where installed on this project. B. All materials and equipment specified herein shall conform with all applicable NEMA, ANSI and IEEE standards. C. All materials and equipment specified herein and their installation methods shall conform to the latest published version of the National Electric Code, N.E.C.. FOLLETT ENGINEERING, PLLC 16201-1 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 1.3 SUBMITTALS A. Submittal documents shall be submitted via E-mail in PDF format. All products for each spec section shall be included in a single PDF document including the cover sheet and index in one single document. submittals shall be indexed and identified as follows: 1. Email subject line shall be "project name, EI&C submittal - submittal #, Spec section# - description." 2. Cover sheet with: a) the project name and submittal # b) Contractor's and sub-contractor's name, phone number, and email address. c) index sheet showing each product being submitted. 3. PDF index tabs per the electrical specifications by section and paragraph or equipment name e.g. provide a minimum of one tab section for each piece of equipment in all of the PART 2 PRODUCT Sections 2.01 - 2.**. 4. Label each equipment submittal sheet with equipment name and number. Indicate location where each item of equipment submitted will be used on the job. Use equipment numbers when available. 5. Identify specific options and cross hatch out any information that is not a part of the specific information for the submitted component. B. Submittals shall include the manufacturer's name, address, trade name, catalog model or number, nameplate data, size, layout dimensions, capacity, project specification and paragraph reference. Include other information necessary to establish contract compliance of each item proposed to furnish. C. Each item shall be clearly marked and provided with adequate sales and technical information to clearly show conformance with all aspects of the specification. Packages not provided as described above or largely incomplete shall be returned to the Contractor, without comment. D. After review by the ENGINEER, the CONTRACTOR shall submit the Shop Drawings of the service section to the utility company for approval prior to fabrication. 1.4 COORDINATION OF EQUIPMENT A. It is the Contractor's responsibility to coordinate equipment information with the transfer switch manufacturer so that the correct type of equipment is provided and sized properly for the devices being served and to supply such equipment with the proper protection. B. The Contractor shall verify that all equipment will fit physically within the space allotted per the contract drawings. The Contractor shall be responsible to coordinate the features, controls, ratings, etc. of the transfer FOLLETT ENGINEERING, PLLC 16201-2 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 switch to match the requirements of the generator as described in Section 16200. 1.5 COORDINATION WITH CONTROL SYSTEM A. The transfer switch manufacturer shall equip the assembly with all appurtenances and accessories (including but not limited to control relays, control contacts, control wiring and terminal strips) as required by the wire diagrams and the Control System Integrator for interface with the main control system and as required to interface with the generator to provide a totally integrated and operable system. B. The Control System Integrator, as specified in Section 16921, shall be responsible for coordination and integration of control system with the transfer switch controls. C. The System Integrator shall direct the transfer switch supplier to provide all intended details of the equipment which may influence or affect the control system. The System Integrator shall determine all requirements for and shall cause integration of the control system and the facility controls into a unified operating system. The System Integrator shall define all requirements for all interfacing equipment, appurtenances and accessories. 1.6 ACCEPTABLE MANUFACTURERS (AUTOMATIC TRANSFER SWITCHES) A. The size of the Automatic transfer switches, and features shown on the drawings is based on ONAN OTEC-SE series. Acceptable manufacturers are. 1. ONAN Corporation B. The equipment of the manufacturer selected must fit within the space restrictions as shown on the plans. 1.7 O&M DATA A. Provide O&M data for all transfer switch and related equipment in accordance to the general requirements in Section 16010. PART2 PRODUCTS 2.1 GENERAL REQUIREMENTS A. The transfer switches shall be equipped with three poles for normal and emergency service of 480 volts, 60 hertz, 3 phase. The transfer switches shall be rated 200 amperes. B. The transfer switch shall be mechanically and electrically held and rated to 600 volts for all classes of load and continuous inductive duty. FOLLETT ENGINEERING, PLLC 16201-3 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 C. The transfer switch shall conform to UL 1008 Revision 4 provisions for Withstand Current Ratings and Closing Ratings. The switch shall be rated for a minimum RMS symmetrical fault current (AIC rating) of • 35,000A for switches rated 400 amps and below, • 65,000A for switch ratings above 400 amps and below 1600 amps • 100,000A for switches rated 1600 amps and higher. D. The switch shall be capable of enduring 6000 cycles of complete opening and closing at rated current and voltage at a rate of 6 cycles per minute without failure. E. The automatic transfer switch shall, open transition type with a minimum adjustable pause in neutral capability of 10 seconds, incorporating isolating switching unit mechanisms and overcurrent protection on the utility supply with number of poles as specified on the drawings. F. The switch shall be double throw inherently interlocked mechanically and electrically to prevent supplying the load from both sources simultaneously. The operating current shall be obtained from the source to which the load is to be transferred. The transfer mechanism shall be of the double break design with solid silver cadmium surface contacts and individual heat resistant arc chambers. G. Single break contacts will also be acceptable if arc barriers and magnetic blow out coils are used. The contacts shall be capable of carrying 20 times the continuous rating for interrupting current. H. All contacts, coils, etc. shall be readily accessible for replacement from front of panel without major disassembly of associated parts. I. The transfer switch shall have UL 1008 label and listing. J. Transfer switches used as service entrance shall be labeled for service entrance use. 2.2 AUTOMATIC TRANSFER SWITCHES 2.2.1 SERVICE ENTRANCE RATED A. Service entrance rated ATS shall be rated for service entrance use and shall have a separate circuit breaker ahead of the switching mechanism. Interlocked circuit breaker type switches are not allowed. 2.2.2 CONTROLS HARDWARE A. All relays shall be provided with indicating LED lights for energized position indication. B. Time delay relays shall be provided with timing and timed out LED indicators FOLLETT ENGINEERING, PLLC 16201-4 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 C. Panel front Indication lights shall be push-to-test or the switch shall have a push to test feature for indication lights, unless lights are LED. D. All fuses shall be provided with "blown fuse" indicators. E. All wiring shall be numbered at each end with basic wiring numbering scheme. F. All terminals shall be clearly labeled G. All internal equipment shall be labeled H. All external devices shall be clearly labeled I. Provide nameplate on transfer switch as shown on the drawings J. Provide transfer switch with solid state logic, ONAN -POWER SENTRY CONTROL K. Provide transfer switch with LED status annunciator showing graphic display of source availability and switch position. 2.2.3 CONTROLS FEATURES A. Automatic transfer switches shall include the following accessories: 1. Undervoltage Sensor: Adjustable solid state low voltage sensing relays (pick up at 85 to 98 percent of normal voltage - set at 98%; drop out at 75 to 100 percent - set at 90% of pickup setting). Provide for each phase. 2. Time Delay Start and Stop on Drop Out: Solid state adjustable time delay on start (0 to 15 seconds). Set start delay for 15 seconds. Timer will send start signal to gen. set CID, where louver timer will allow 15 second delay for louvers to open prior to starting genset. 3. Time Delay Stop: Solid state adjustable time delay (0 to 10 minutes) to allow generator cool down after normal power is restored and retransfer occurs. Set at 5 minutes. 4. Time Delay Transfer & Retransfer: Solid state time delay relay adjustable 2 to 120 seconds for transfer to emergency and 0 to 30 minutes for retransfer to normal. Set at 5 minutes for retransfer to normal. Set at 5 seconds for transfer to emergency. 5. With or Without Load Selector Switch: Switch to select exercise with or without load. 6. Normal-Test Switch: Switch such that in the "Normal" mode the transfer switch will operate automatically and in the "Test" mode the generator will start for test purposes. This switch shall work in conjunction with the "With" or "Without" load switch. An extra contact block shall be provided on the normal-test switch for wiring to the Programmable Controller, if one is required. FOLLETT ENGINEERING, PLLC 16201-5 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 7. Exercise Clock: An exerciser clock shall be provided which shall be programmable to exercise the generator set. The exerciser shall be adjustable from 15 to 60 minutes once each week. The exercise shall be either with or without load. If power fails during the exercise cycle, the load shall automatically pick up. 8. Programmed Transition: The load transfer control shall be capable of remaining in the neutral position for an adjustable time of .5 to 60 seconds when transferring from one line power source to the other to allow residual voltages to decay before application of the source. 9. Provide the following dry contacts each with terminals for field connection, 2 amp rated at 120 VAC. a) Two separate normally open dry auxiliary contacts, one indicating transfer switch is in NORMAL position and one indicating switch is in EMERGENCY position, b) Four separate normally open dry contacts two indicating "commercial power / normal power" available and two indicating generator / emergency power available. c) Normally open dry contact indicating generator called to run. 10. Position lights for normal and emergency position indication 11. Two indication lights, one for emergency power available and one for normal power available 12. Note: provide LED type lights or push to test feature for all indication lights. 2.2.4 ADDITIONAL CONTROL FEATURES 1. Provide the ATS controls with a dry contact output for a pre-transfer warning with an adjustable time delay of 0-120 seconds to allow for a controlled system shutdown prior to the ATS transferring back to utility power. 2. Provide the ATS controls with input from a remote normally closed dry contact input such that if the contact is opened, the ATS will hold from transferring from the generator power to the utility until the contact is closed. Note: if the generator fails (generator power not available), and utility power is available, then the "hold" shall be overridden and the ATS shall transfer back to utility power. PART 3 EXECUTION 3.1 GENERAL A. Transfer switches shall be assembled per the System Integrators and the existing generator controls requirements,. The transfer switch shall be delivered to System Interface's shop for testing and inspection by the City. Once fully tested, then the transfer switch shall be delivered to the site ready FOLLETT ENGINEERING, PLLC 16201-6 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 for external connections to field equipment. Transfer switch shall be leveled and securely anchored to the floor and / or wall. B. All assembly and wiring not completed by the manufacturer, due to shipping sections, multiple suppliers, etc. shall be the responsibility of the Contractor. C. Transfer switch shall be installed to meet seismic zone 3 requirements according to the manufacturers recommendations. 3.2 TESTING A. Automatic transfer switches shall be configured by the Contractor and field tested along with the control system and the generator per the requirements in this section, the control wire diagrams and 16921. Operation of all the automatic transfer switch functions shall be tested. The testing shall include, but not be limited to, operation of all input and output (1/0) points, control devices for a continuous period of 2 days. B. Testing and inspection of the automatic transfer switch shall include all components. . C. After completion of initial testing, Contractor shall conduct subsequent testing for inspection by the Engineer. The Contractor shall provide for time, equipment and support for the Engineer to test the automatic transfer switch for a period of up to 1 day. All control functions and all status and alarm monitoring and indication shall be demonstrated under simulated operating conditions. 3.3 INSTALLATION A. The transfer switch equipment shall not be shipped to the site until a suitable environment is available for installation of the equipment. A suitable environment for the purposes of this contract for the automatic transfer switch shall be dry, covered and heated to maintain a minimum ambient temperature of 60 degrees F. Prior to shipment of electrical equipment, the Contractor shall contact the Engineer for field verification of a suitable environment. B. The transfer switch shall be installed in accordance with the installation drawings and instructions. Installation shall be performed by workers who are skilled and experienced in the installation of motor control equipment. It is the contractors responsibility to provide sufficient space for the equipment and size of equipment to fit within the space requirements and meet all code requirements. 3.4 WIRING A. Refer to Section 16145-Wire and Cable Termination. FOLLETT ENGINEERING, PLLC 16201-7 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LOAD TRANSFER SWITCHES Project No. 17-7999.6 B. Separately bundle all signal and low voltage wiring from 120V and 480V wiring and maintain a minimum of 2 inches separation of conductors. END OF SECTION FOLLETT ENGINEERING, PLLC 16201-8 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements POWER SERVICE AND METERING Project No. 17-7999.6 SECTION 16400 UTILITY POWER SERVICE & METERING PART1 GENERAL Description of Work: A. Work consists of installation of new overhead service 480Y/277V, 3 phase, 200 amps. B. Also includes the removal of the existing overhead service to the pump station after the electrical upgrade is complete. C. Also includes the installation of a temporary service for facility operation during construction and construction power. D. Note the existing service is primary metered from a pole 1 span away from the pump station and that the overhead transformers are city owned and therefor the Contractor will be responsible for the overhead transformer work and connections/disconnections of the new and existing service conductors. 1.2 SCHEDULING WORK WITH THE UTILITY COMPANY: A. The Contractor shall be responsible for all scheduling and coordination with the utility company. The Contractor shall coordinate and schedule power outages, power service for operation and construction, and power service as may be required by the facility prior to project completion. B. The Contractor shall make all necessary applications for service with the utility, and shall notify the owner in writing of any obligations that the owner must fulfill for service to be started, installed, or modified. 1.3 CONTRACTOR/UTILITY INTERFACE RESPONSIBILITIES: A. The requirements shown on the drawings for power service to the site is general in nature and the Contractor shall meet all of the serving utilities requirement to deliver a complete electric service. B. During design contact was made with PSE. (Michelle— 888-321-7779 x887127). C. The contractor shall coordinate and provide all required work and equipment to provide service to the site as required by the plans and the serving utility. D. UTILITY CHARGES 1. All direct serving utility charges for the permanent service will be paid for by the Owner and shall not be included in the Contractor's bid price. 2. The Contractor is required to coordinate work with the power utility and other utilities as necessary for installation of new service and service entrance requirements. 3. Utility charges, including all costs associated with utility meter and/or transformer changes, for permanent service shall be paid directly by the FOLLETT ENGINEERING, PLLC 16400-1 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements POWER SERVICE AND METERING Project No. 17-7999.6 Owner. Contractor is to submit Utility invoices for such work, without markup, to the Owner. 1.4 QUALITY ASSURANCE A. Comply with all serving utility company standards and requirements. 1.5 STANDARDS AND CODES A. Work involving service installation shall be done in accordance with the serving utility's standards and the National Electric Code. B. Service equipment shall be listed and labeled by UL as "suitable for use as service equipment". 1.6 SUBMITTALS A. In conformance with the submittal requirements of Section 16010, submit catalog data showing material information and conformance with specifications on the following: B. Prior to submittal to the Engineer, the Contractor shall submit all equipment and construction details (such as size, mounting height, materials, location of equipment, etc.) to the serving utility for verification of compliance to the utility's requirements. PART 2 PRODUCTS 2.1 METER ENCLOSURE A. The existing meter is primary—there are no secondary metering requirements. B. The Contractor is responsible for all new work associated with the service conductors from the overhead transformers. 2.2 LIGHTNING ARRESTOR: A. Where lightning arrestors are shown on the oneline diagram provide an MOV type lightning/surge arrestor in combination with a surge capacitor rated for the service voltage to protect against overvoltage transients. Minimum 100KA rating for the surge arrestor. Delta lightning arresters, Inc. 600 series and CA603 capacitors or equal. Select proper components for the application as shown on the drawings. PART 3 EXECUTION 3.1 GROUND ELECTRODE SYSTEM A. The grounded conductor and ground bus shall be connected to the grounding electrode system, via the grounding electrode conductor as indicated on system one-line diagram and as required by the NEC. FOLLETT ENGINEERING, PLLC 16400-2 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements POWER SERVICE AND METERING Project No. 17-7999.6 B. The system shall be as indicated in Article 250-81 of the National Electrical Code. 3.2 SERVICE COMPONENTS A. Install all service components (service raceways, transformers, primary raceways, conductors, handholes, vaults, etc.) in accordance with the utility requirements, the NEC, and section 16145. B. Provide service handholes and vaults as required by the serving utility even if not shown on the plans. 3.3 UTILITY REQUIREMENT VERIFICATION A. The contractor shall coordinate and submit all equipment, materials, etc. related to the utility work to the serving utility to verify conformance to the Utility's requirements for service. The contractor shall also submit any plans for the installation of the primary and secondary service for approval by the Utility prior to excavation. Any discrepancy between the Utility requirements and the Contract documents shall be brought to the immediate attention of the Owner& Engineer. B. Contractor shall obtain permit and obtain L&I inspection prior to connection of power. END OF SECTION FOLLETT ENGINEERING, PLLC 16400-3 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ARC FLASH REPORT Project No. 17-7999.6 SECTION 16432 ARC FLASH REPORT PART GENERAL 1.1 SUMMARY A. This Section specifies the arc flash study and report for all voltage levels of the electrical power system. The "electrical power system" starts at and includes the highest voltage buses. Arc flash study shall include the method and recommendation in determining proper Personal Protective Equipment (PPE) and proper labeling of equipment as specified in this Section. 1.2 QUALITY ASSURANCE A. Referenced Standards: This Section incorporates by reference the latest revision of the following documents. These references are a part of this Section as specified and modified. In case of conflict between the requirements of this Section and those of the listed documents, the requirements of this Section shall prevail. B. Reference Title 1. IEEE 1584 IEEE Guide for Performing Arc-Flash Hazard Calculations 2. NFPA 70 National Electrical Code 3. NFPA 70E Standard for Electrical Safety Requirements for Employee Workplaces 4. OSHA 29-CFR, Part 1910 Occupational Safety and Health Standards: Electrical Subpart S. C. Qualifications: 1. Manufacturer of the switchboard or electrical testing service preparing the report: Regularly engaged in power system studies. D. Certification: 1. Arc flash report shall be prepared, stamped, dated, and signed by a Professional Engineer registered in the state of Washington. 1.3 SUBMITTALS A. Certified arc flash report. B. Templates of arc flash warning labels to be applied. C. Copies of all actual arc flash warning labels applied to specific equipment. D. Electronic models, data and databases used to develop reports and studies. Electronic information shall be compatible or equal with SKM Power Tools version 6.5 or newer. FOLLETT ENGINEERING, PLLC 16432-1 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements ARC FLASH REPORT Project No. 17-7999.6 1.4 ARC FLASH REPORT A. Prepare a report summarizing the arc flash study and conclusions or recommendations which may affect the integrity of the electric power distribution system. B. All calculations shall be prepared, stamped, dated, and signed by a Professional Engineer registered in the state of Washington. C. Perform arc flash calculations to determine the incident energy, arc flash boundary, and minimum PPE requirements for locations throughout the power system. D. Arc flash warning labels: 1. Produced and attached to the electrical equipment. 2. Indicate approach boundaries, incident energy level, and the minimum PPE that is required when servicing the equipment within the arc flash boundary. E. As a minimum, include the following in the report: 1. Equipment manufacturer's information used to prepare the study. 2. Assumptions made during the study. 3. Reduced copy of the one line drawing. 4. Arc flash evaluations summary spreadsheet as specified in this Section. 5. Bus detail sheets as specified in this Section. 6. Arc flash warning labels printed in color on adhesive backed labels. F. Submit report a minimum of 60 days before energizing electrical equipment. 1.5 ARC FLASH STUDY A. Perform an arc flash hazard study after the short circuit and protective device coordination study has been completed. B. Coordinate with Authority Having Jurisdiction (AHJ) for site-specific requirements. C. For each major part of the electrical power system, determine the following: 1. Flash hazard protection boundary. 2. Limited approach boundary. 3. Restricted approach boundary. 4. Prohibited approach boundary. 5. Incident energy level. 6. PPE hazard/risk category. 7. Type of PPE required. D. Produce arc flash warning labels as indicated in PART 3. E. Produce bus detail sheets that list the items above and the following additional items: 1. Bus name. 2. Upstream protective device name, type, and settings. 3. Bus line to line voltage. F. Produce an arc flash evaluation summary sheet listing the following additional items: FOLLETT ENGINEERING, PLLC 16432-2 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ARC FLASH REPORT Project No. 17-7999.6 1. Bus name. 2. Upstream protective device name, type, settings. 3. Numbering to match existing and contract document identification numbers. 4. Bus line-to-line voltage. 5. Bus operating fault current. 6. Protective device bolted fault current. 7. Protective device arcing fault current. 8. Protective device trip/delay time (SEC). 9. Breaker opening time (SEC). 10. Ground. 11. Equipment type. 12. Gap. 13. Arc flash boundary (IN). 14. Working distance (IN) per IEEE Table 3 default values. 15. Incident energy (CAL/cm2). 16. Required protective fire rated clothing type and class (PPE). G. Analyze the short circuit, protective device coordination, and arc flash calculations and highlight any equipment that is determined to be underrated or causes an abnormally high incident energy calculation. Propose approaches to reduce the energy levels. H. Where the study and associated report is completed on equipment not installed under this contract the study and associated report shall be redone at the contractor's expense. The contractor and not the manufacturer of the electrical equipment or the electrical testing service is responsible to acquire the necessary equipment information for the electrical equipment the contractor is proposing to install. This information shall be provided to the manufacturer of the electrical equipment under the study or to the electrical testing service or to the Engineer performing the arc flash study for their use in the creation of the study and subsequent report. PART 2 PART 2 PRODUCTS 2.1 LABELS A. Provide weatherproof labels for equipment mounted outdoors. B. Provide following data on each arc flash hazard warning label: 1. Flash Hazard Protection Boundary. 2. Incident Energy Level. 3. Required Personal Protective Equipment (PPE) Category with brief description. 4. Shock hazard when cover is removed. 5. Limited Approach Boundary. 6. Restricted Approach Boundary. FOLLETT ENGINEERING, PLLC 16432-3 425-765-6304 Kent Pump Station No.3 Electrical System Improvements ARC FLASH REPORT Project No. 17-7999.6 7. Prohibited Approach Boundary. 8. Include date of calculation, utility short circuit capacity and voltage as of that date. PART 3 PART 3 EXECUTION 3.1 GENERAL A. The Contractor shall work with the Study Firm for implementing the Arc Flash Hazard sign installation requirements for electrical equipment as specified in NEC Article 110.16 Flash Protection and NFPA 70E (2012). B. Perform the arc flash study in accordance with NFPA 70E, OSHA 29-CFR, Part 1910 Subpart S,and IEEE 1584 Standards. C. Perform the studies using actual equipment data and the data from the same manufacturer of protective relay devices as being provided by the switchboard manufacturer. D. Provide arc flash warning labels on equipment meeting standard ANSI Standard Z535.4-1998and as approved by the Project Representative and the Authority Having Jurisdiction. E. Labels: in color with adhesive backs. Labels to include all of the following: 1. WARNING - ARC FLASH HAZARD. 2. Date of Analysis. 3. Flash Hazard Category. 4. Incident Energy Level at 18 inches in cal per cm. sq. 5. Flash Hazard Boundary. 6. Personal Protection Equipment requirement within the Flash Hazard Boundary. F. Provide a list of lockout and tagout devices that are compatible with the equipment. END OF SECTION FOLLETT ENGINEERING, PLLC 16432-4 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LIGHTING Project No. 17-7999.6 SECTION 16500 LIGHTING PART1 GENERAL 1.1 DESCRIPTION OF WORK A. This section covers furnishing and installation of all light fixtures and lamps indicated on the drawings or specified herein. 1.2 STANDARDS AND CODES A. All materials and equipment specified herein shall within the scope of UL Examination Services, be approved by the Underwriter's Laboratories for the purpose for which they are used and shall bear the UL label. B. All materials and equipment specified herein shall conform with all applicable NEMA, ANSI and IEEE standards. C. All materials and equipment specified herein and their installation methods shall conform to the latest published version of the National Electric Code, N.E.C.. 1.3 SUBMITTALS A. Submit catalog data showing material information and conformance with specifications. The intended use of each item shall be indicated. PART2 PRODUCTS 2.1 LIGHT FIXTURES A. Fixture Schedule - Provide in accordance with Lighting Fixture Schedule & notes as shown on plans. B. The fixture catalog numbers listed in the fixture schedule indicate manufacturer, fixture design, quality of design and manufacture, appearance, features and options required. Lighting fixtures specified will be the basis for comparison in the consideration of fixtures of other manufacturers. Fixtures of lesser quality shall not be considered equivalent. C. Contractor shall investigate ceiling construction and other mounting locations and supply fixtures designed for the application. D. Contractor shall investigate possible interferences of equipment, hatches, overhead cranes, etc. and supply fixtures (size and profile) that will not interfere. FOLLETT ENGINEERING, PLLC 16500-1 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LIGHTING Project No. 17-7999.6 E. All fixture component parts shall be manufactured and/or assembled at the manufacturing plant for shipment. The shipment from the fixture manufacturer shall include integrally mounted and/or remote mounted ballasts where ballasts are required for the proper operation of the fixture lamps. 2.2 HARDWARE A. The Contractor shall provide any necessary hardware for mounting fixtures. The mounting hardware shall be made of materials suitable for the environment installed. Provide materials made from aluminum, non-metallic, or 316 stainless steel in outdoor, damp, or corrosive areas. 2.3 BALLASTS A. Ballasts shall be of the high power factor type. All ballasts shall be rated for 0 degree C operation and be equipped with automatic resetting protective devices in accordance with UL requirements. B. Ballasts shall be energy efficient GE Maxi-Miser II ballasts or equal. 2.4 LAMPS A. Provide all lamps as specified. Refer to the Lighting Fixture Schedule. B. Provide all fixtures with an LED lamps. Lamps shall be DLC qualified. Manufactured by LEDIZ, Greencreative, Sylvania or equal. Lamps shall be provided for all lighting fixtures 2.5 SPECIAL ACCESSORIES A. Provide accessories such as junction boxes, plastic frames, stem, hangers, canopies, couplings, cords, toggle bolts, etc., necessary to mount fixture in a proper and approved method. 2.6 CONTROLS 2.6.1 PHOTOELECTRIC RELAY A. Photoelectric relay- SPST normally closed, raintight 120V, 2000W TORK Time Controls Model 2101 or equal. B. Mount on North side of building and avoid locations of possible direct sun light. FOLLETT ENGINEERING, PLLC 16500-2 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LIGHTING Project No. 17-7999.6 PART 3 EXECUTION 3.1 RACEWAY & WIRE A. For all lights, switches, and other related devices of the lighting system, provide all necessary raceway and wire per section 16110, 16120 or 16145 for a complete installation. 3.2 FIXTURE MOUNTING A. The fixture supplier shall provide all necessary hanging or mounting devices for all fixtures and shall be responsible for checking the type needed for various ceiling conditions. B. The Contractor shall see that all lighting fixtures designed to be installed throughout the project shall be of the correct size and design to properly suit the requirements of each area prior to ordering fixtures. C. Contractor shall install fixtures to avoid access hatches, sky lights, rails, hoists, mechanical equipment, etc. D. Any additional hardware needed for installation of fixtures shall be provided by the Contractor; including poles, clamps, brackets, screws, bolts, etc. E. Fixtures and other equipment installed in hazardous areas shall be rated for the environment. Provide fittings and seals per NEC. F. Pendant mounted lighting fixtures shall be supported by a flexible fixture hanger CROUSE-HINDS Type "Al" and shall have locking couplings, CROUSE-HINDS Type "COUP". G. Pendant fixtures in hazardous areas shall have union hub fixture hangers, CROUSE-HINDS Type "EAHC". H. Where fixtures are indicated for installation on low-density ceiling material, mount on 1 1/2" ceiling spacers unless UL approved for mounting directly to ceiling material. I. Properly support and align fixtures and provide all necessary steel shapes for support of the fixtures. Coordinate complete fixture installation with the facility construction. Clean and mount all lighting fixtures with new lamps immediately prior to final inspection. J. Square and rectangular fixtures shall be mounted with sides parallel to building lines and parallel with ceiling lines. K. Install fluorescent fixtures as recommended by the manufacturer or as necessary to provide exact horizontal alignment, preventing horizontal or vertical deflection or angular jointing of fixtures installed in continuous rows. FOLLETT ENGINEERING, PLLC 16500-3 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements LIGHTING Project No. 17-7999.6 END OF SECTION SEE LIGHTING AND FIXTURE SCHEDULE & NOTES ON THE DRAWINGS FOLLETT ENGINEERING, PLLC 16500-4 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 SECTION 16921 INSTRUMENTATION AND CONTROLS PART GENERAL 1.1 DESCRIPTION OF WORK A. This spec section is intended to specify the components of the instrumentation and control system including: control panel(s) and the general requirements for the construction and arrangement of the associated equipment and field instrumentation. B. Work and materials specified in this section include: 1. PLC control cabinet(s) (MCP), 1/0, and associated equipment and instrumentation. 2. Power/control equipment (ATS, starters, VFDs) - Motor Controls 3. Field Instrumentation, installation and calibration requirements 4. Shop and field testing, and calibration of power & control system components and equipment. 1.2 SYSTEM DESCRIPTION A. Systems Interface general scope of supply: 1. Control panel (MCP) for all equipment control, monitoring and alarming. 2. Power equipment with VFDs, motor starters and controls, etc. for control and monitoring of the pumps and other equipment. 3. Automatic Transfer Switch (ATS). 4. Field instrumentation and control devices and installation details (pressure switches, flood switch, smoke detector, alarm beacon). 5. Programming services for temporary operations and final configuration. 1.3 SYSTEM INTEGRATOR A. The System Integrator shall be responsible for the final design and assembly of the instrumentation and control system and control panels. B. All programming of the PLC and operator interface shall be performed by the City's pre-selected System Integrator— Systems Interface. 1. The new PLC program code shall be written using the latest Siemens TIA Portal software V14 or higher. The code will need to closely represent the current Siemens S7-200 MicroWin code in use. The City will provide the current code to the integrator upon request. FOLLETT ENGINEERING, PLLC 16921-1 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 C. The System Integrator shall be responsible for the final design and assembly of the entire I&C system. The system shall be designed to provide the control capabilities and functions indicated and implied by the plans and these specifications and to provide trouble-free operation with minimum maintenance. The system shall readily enable manual operation of any and all functions in the event of failure of any one component. D. Only pre-approved integrators shall provide equipment under this contract E. The following are pre-approved System Integrators for this project 1. Systems Interface, Inc. — Mukilteo, WA 1.4 STANDARDS AND CODES A. All equipment and materials shall conform to the latest revised editions of applicable standards published by the following organizations: 1. American National Standards Institute (ANSI). 2. Institute of Electrical and Electronic Engineers (IEEE). 3. National Electrical Manufacturer's Association (NEMA) 4. Underwriters' Laboratories (U/L). 5. Instrument Society of America (ISA). B. All electrical equipment and materials, and the design, construction, installation, and application thereof shall comply with all applicable provisions of the National Electrical Code (NEC), the Occupational Safety and Health Act (OSHA), and any applicable Federal, State, and local ordinances, rules and regulations. C. All materials and equipment specified herein shall within the scope of UL examination services, be approved by the Underwriter's Laboratories for the purpose for which they are used and shall bear the UL label. D. All control panels shall bear a label by UL or by an approved testing authority for the completed assembled panel. 1.5 SHOP DRAWINGS A. The System Integrator shall develop any shop drawings required for design, fabrication, assembly and installation of the power and control panels. Shop drawings shall include all drawings required in manufacture of specialized components and for assembly and installation of them. Shop drawings shall include detailed "end-to-end" control wiring diagrams showing all interface of field equipment and instrumentation. In addition the following drawings shall be provided: B. CONTROL CABINET LAYOUT DRAWINGS 1. The System Integrator shall develop shop drawings for the control cabinets and wiring and terminals within the control cabinets to show all details of the control system. Drawings shall include scaled drawings of both interior and exterior elevation views. All components shall be identified by both the FOLLETT ENGINEERING, PLLC 16921-2 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 nameplate information and also the component number related to the bill of materials. C. EQUIPMENT AND INSTRUMENT WIRING DIAGRAMS 1. The System Integrator shall provide individual wiring diagrams (one drawing) also referred to as "LOOP DRAWINGS" for each field instrument and for each controlled motor load. All wiring interface for each instrument or equipment shall be shown on a single drawing* and the drawing shall be titled with the equipment or instrument name and number. Each drawing shall including field devices, PLC 1/0 and motor control, etc. associated with that instrument or equipment Include all terminals — terminal numbers, wire numbers (both internal and field), PLC 1/0 and memory address, and equipment TAG number. * for instruments of the same type - if space allows then more than one instrument of the same exact type may be shown on a single drawing. This exception applies for instruments only, not for equipment. D. CARD DRAWINGS 1. The System Integrator shall provide the information for each input and each output of the PLC on "PLC Card drawings". All details of each card must be shown on a single drawing — one 1/0 card per drawing*.. Each 1/0 point shall be designated with the memory address, point id tag number, point description and wiring diagram reference drawing number * cards of the same type — if space allows, then more than one card of the same exact type may be shown on a single drawing. E. TERMINAL ARRANGEMENT DRAWINGS 1. Provide terminal layout drawings that show the layout of all terminals in the cabinet. F. Shop drawings shall be drawn in AutoCAD 2012 or newer version and include the following: 1. Technical data sheets for all components with the complete part number of the component clearly designated with all required options. 2. Arrangement drawings of all cabinet front-mounted and internal-mounted instruments, switches, devices, and equipment indicated. Show all panel mounting details required. Include outer dimensions of all panels on the drawing. Deviations from approved arrangements require resubmittal and approval prior to installation. 3. Arrangement drawings shall be drawn to scale using standard Architectural or Engineering scales. 4. Shop drawings shall be provided on sheets 11" X 17". Shop drawings shall include specific product detail such as rating, size, and number of contacts, etc. Wiring diagrams shall be included for all components in the system including control equipment supplied with mechanical devices. FOLLETT ENGINEERING, PLLC 16921-3 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 5. For shop drawing packages provide the drawings in a separate 11" X 17" binder with an index for the drawings at the front. G. Installation details shall include the size, number, type and location of interconnecting wiring and conduit, installation of cabinets and enclosures, installation of sensors, instruments, limit switches, and other installation requirements. Shop drawings shall be submitted to Engineer for review and approval. 1.6 SUBMITTALS 1.6.1 SUBMITTAL REQUIREMENTS A. Submittal documents shall be submitted via E-mail in PDF format. B. I&C submittals shall be provided in two complete separate documents one with all product data and a second with all shop drawings as follows: 1. All products shall be included in a single PDF document including the cover sheet and index and bill of materials (BOM) in one single document. — Index the PDF document to show each individual product in the index column. 2. Shop drawings shall be included in a single PDF document including the cover sheet and index in one single document. C. Submittals shall be indexed and identified as follows: 1. Email subiect line shall be "project name, EI&C submittal submittal #, spec section#- description." 2. Cover sheet with: a) the project name and submittal # b) Contractor's and sub-contractor's name, phone number, and email address. c) BOM bill of materials showing each product being submitted. d) List of deviations from specified components 3. PDF index tabs per the electrical specifications by section and paragraph or equipment name e.g. provide a minimum of one tab section for each piece of equipment in all of the PART 2 PRODUCT Sections 2.01 - 2.**. D. Per the general submittal requirements in other sections of this specification and the following. The System Integrator shall develop and shall submit to the Engineer the following project data: 1. A detailed project schedule relating specifically to I&C - showing submittals, review time, long lead equipment, panel fabrication, expected site delivery date - startup, etc. highlight any anticipated critical path tasks. Provide a copy with the submittal and e-mail in PDF. 2. All shop drawings: (provide an electronic copy, in AutoCAD of all shop drawings on CD ROM to the Engineer with the submittals, revised submittals, and with final as-built drawings). FOLLETT ENGINEERING, PLLC 16921-4 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 3. Cut sheets for all products with a BOM - Bill of materials showing quantity, Manufacturer, catalog number, and the supplier name and phone number and relevant spec. paragraph number. Number each item in the bill of materials and relate the bill of materials to the submitted product index. 4. 1/0 checklist that verifies that all control and status/indication points in the control panels both implemented and spare have been tested. One copy of the 1/0 Checklist shall be submitted for the start of the Factory Test. One copy of the 1/0 Checklist shall be submitted prior to the Control system startup. The PLC Card drawings shall be used for this purpose. E. Provide reference numbering on all cut sheets to relate them to the bill of materials. Provide same reference numbering by the equipment shown on the shop drawings. F. Provide a listing of all spare parts to be provided. G. NOTE; submittals received by the Engineer that are incomplete or not organized or do not conform to the specifications or do not have complete drawings as specified shall REJECTED and returned without review. Contractor should anticipate that submittals and re-submittals can take up to 3 weeks from the date mailed to the date returned with review comments if using standard submittal procedures. 1.7 COORDINATION WITH OTHER EQUIPMENT A. The System Integrator shall be responsible for obtaining all necessary information/product data (wiring diagrams, load data, etc.) for other equipment and instrumentation used in the project that requires integration into the power and control system — even for equipment and instrumentation outside the System Integrator's scope of supply. This may include, but is not limited to (standby generator, ATS, flow transmitters and other instrumentation, control valves, motor data, etc.) B. System wiring diagrams shall include information from other equipment. C. See PART 4 of this specification for additional requirements 1.8 NAMEPLATES A. Nameplates shall be provided on all electrical devices — (equipment, instruments, boxes, etc.) B. Nameplates shall also be provided on all electrical panel interior and exterior equipment (including but not limited to: relays, 1/0 cards, circuit breakers, power supplies, terminals, contactors, switches, indicating lights, buttons, meters, and other devices.) C. Equipment nameplates shall have both the equipment name and number and equipment circuit number (if applicable). D. INSTRUMENT NAMEPLATES: Provide nameplates for all instruments with instrument name, number, and the ckt breaker, or fuse location for the power FOLLETT ENGINEERING, PLLC 16921-5 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 source. — for nameplates that cannot be attached to the instrument provide a stainless steel cable ring to attach it to the instrument. E. Nameplates shall be made of 1/16" thick machine engraved laminated phenolic having black letters not less than 3/16" high on white background or as shown on the drawings or other sections of the specifications. Nameplates on the interior of panels shall be White Polyester with printed thermal transfer lettering and permanent pressure sensitive acrylic; TYTON 822 or approved equal. All nameplates shall include the equipment name and number (and function, if applicable). F. Relays shall be provided with 2 nameplates, one on the backpan by the relay base and one on the face of the relay. G. Provide warning nameplates on all panels and equipment which contain multiple power sources. Provide nameplates describing locations of power sources and disconnects. Provide any other warning or information nameplates as required by NEC or UL. H. Nameplates shall be secured to equipment with stainless steel screws/fasteners. Epoxy glue or other quality adhesive may be used where fasteners are not practical if first approved by the Engineer. PART2 PRODUCTS 2.1 GENERAL 2.1.1 DESIGN AND ASSEMBLY A. All equipment and materials utilized in the system shall be the products of reputable, experienced manufacturers with at least five (5) years experience in the manufacture of similar equipment. Similar items in the system shall be the products of the same manufacturer. B. All equipment shall be of industrial grade and of standard construction, shall be capable of long, reliable, trouble-free service, and shall be specifically intended for control and monitoring of operation of motor-driven pumps and equipment. C. All equipment shall be of modular design to facilitate interchangeability of parts and to assure ease of servicing. All equipment, where practical, shall be of solid state, integrated circuit design. D. The system shall be completely assembled in the shop by the System Integrator. All components and equipment shall be prewired to the maximum extent possible. E. All components, including both internally and face-mounted instruments and devices, shall be clearly identified with phenolic nameplates of black background with white letters. Nameplates on the interior of panels shall be White Polyester with printed thermal transfer lettering and permanent pressure sensitive acrylic; TYTON 822 or approved equal. FOLLETT ENGINEERING, PLLC 16921-6 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 2.1.2 INTERCONNECTING WIRING/TERMINALS A. All conductors shall be stranded wire with thermoplastic insulation and shall be cabled to groups and supported so as to prevent breaking and to present an orderly arrangement and neat appearance. All outgoing wiring shall be terminated on a marked terminal strip capable of connection of at least 2 No. 14 wires and all terminal connections shall be numbered throughout the system. B. TERMINAL NUMBERING — 1. All field terminals shall have UNIQUE TERMINAL NUMBERS. This also includes NEUTRAL and LINE terminals shall be individually identified. (example NU1, NU2 ..etc. for UPS neutrals N1, N2 etc for normal power neutral terminals. C. In general: all field control wiring shall be #14 AWG. Internal wiring may be smaller #16 or #18 is acceptable as long as it is sized for the load and circuit protection. D. W I REWAYS 1. Provide wire ways as necessary in the enclosure to contain all internal wiring and all field wiring that exists on this contract with consideration given to future space and the future wiring. Size wireways such that there is ample room for the numbers of wires that will be wired to the terminals or terminal space in the cabinet plus room for an additional 30% future wire. 2. Provide corner wireways in the cabinet corners or as shown on the drawings 3. Low voltage DC control and signal conductors shall be bundled separately from alternating current circuits. Separate raceways and wire gutters shall be dedicated for AC and DC wiring, and labeled as such on the shop drawings. Wiring may cross at right angles if necessary. Special caution shall be used for PLC 1/0 card wiring and field terminations to accommodate the separation of AC and DC circuits. Intrinsically safe wiring shall be physically separated from non intrinsically safe wiring. 4. Internal wiring shall be in separate wireways from the field wiring. E. All wiring and tubing crossing hinges shall be installed in a manner to prevent chafing. Bundles of similar conductors shall be clamped securely to the door and to the panel, and the bundles shall run parallel to the hinge for at least 12 inches. Spiral nylon cable wrap shall be provided in the hinge section of the bundle to fully protect the conductors or tubing against chafing. 2.2 PROGRAMMABLE CONTROL EQUIPMENT 2.2.1 PROGRAMMABLE LOGIC CONTROLLER(PLC) A. The PLC shall be Siemens SIMATIC S7-1500 no substitutions. Selection shall be based on the number of 1/0 required. B. Provide PLC processors with on board Ethernet communications. C. Provide all PI-Cs with EEPROMS FOLLETT ENGINEERING, PLLC 16921-7 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 D. PLC rack w/ spare slots— if applicable E. 24VDC digital input cards F. 24VDC digital output cards. All digital outputs shall interface with the output relay terminals G. Analog input cards with individually isolated points H. Analog output cards with individually isolated points I. Note combination cards are not allowed except with special permission from the Engineer J. Provide power supplies as required and recommended by the manufacturer. K. Provide all necessary power supplies as required and recommended by the manufacturer. L. Provide isolated fused circuit for power to PLC M. Spare and empty slots in the PLC rack shall be covered with a blank slot filler. 2.2.2 SPARE AND FUTURE 1/0 A. INSTALLED SPARE: Provide all necessary analog and digital 1/0 for the project plus 20% installed spare, (round up to the nearest whole number) in each cabinet,. Provide terminals for all installed PLC 1/0 cards (including spares) to match the number of points in the card. For all spare 1/0 provide interface wiring to terminals. B. Provide 1 spare fused disconnect for every 4 spare digital input terminals. C. Spare digital outputs shall all be provided with interposing relays with one form C output wired to two terminals for a normally open contact interface. D. For each spare analog input provide one fused, and two non fused wired for a loop powered instrument input. Provide one shield ground terminal for every two spare analog inputs. E. FUTURE: Provide spare space to the right of the PLC for at least three additional 1/0 cards. Provide spare din rail for the additional terminals associated with the additional 1/0 cards (minimum of 12" for digital and 12" for analog terminals) and also account for the additional room in the wireways for the future wire. 2.3 COMMUNICATIONS EQUIPMENT 2.3.1 ETHERNET COMMUNICATION MODULE A. Provide Ethernet communications on the PLC processor for communications. 2.3.2 ETHERNET COMMUNICATIONS SWITCH A. All Ethernet switches used for this project shall be made by the same manufacturer. FOLLETT ENGINEERING, PLLC 16921-8 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 B. Provide an Ethernet switch with ports as required as shown on the drawings plus 1 spare port. Ethernet switches shall be din rail mountable. N-Tron, or equal. Provide mounting and power circuits as required for the equipment. 2.3.3 ETHERNET/ RECEPTACLE INTERFACE MODULE. A. Provide a combination Ethernet port/ 120V receptacle unit mounted with clear plastic hinged cover on the front door of each control cabinet with a PLC. So that the programmer can plug in without opening the cabinet door. 2.3.4 RADIO EQUIPMENT A. Provide one Radio in the MCP to match the Owner's existing radios B. Provide power supplies for radio power C. Provide Antenna Cable wired to surge protected bulk head on the top of the cabinet. 1. Provide communications cables for interface to the Radio and PLC and Operator Interface. 2. Provide antenna cable to extend from the Radio in the MCP to the existing Antenna. ( location shown on the drawings). 3. Provide all necessary fittings, bulkhead fittings, etc. for a complete Radio/antenna installation. 4. Provide cable lightning arrestor and any other components as recommended by the radio manufacturer. 5. Configure radio for communications to the existing SCADA system. 6. The system Integrator shall provide all necessary coordination, testing and troubleshooting for the telemetry system to communicate to headquarters. 2.4 PROGRAMMING OF PROGRAMMABLE CONTROLLER 2.4.1 GENERAL A. The programmable controller equipment shall be programmed by Systems Interface and the programming cost shall be included in the bid. B. The programmable controller shall be programmed by the System Integrator for all required control, monitoring, and alarming of the entire pump station, including communications and programming of the SCADA system at the City office. 2.5 EQUIPMENT ENCLOSURES 2.5.1 CABINET SIZE A. Sizes of enclosure for the power and control cabinet shall be chosen by the System Integrator to provide ample space for the installed components and still fit within the given space in the structure. The MCP enclosure shall be free standing. FOLLETT ENGINEERING, PLLC 16921-9 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 B. The enclosures minimum size shall be as shown on the drawings. With Engineer's approval, the Integrator shall upsize the cabinet if necessary to fit in the components. 2.5.2 CONTROL CABINETS A. Indoor Control cabinets shall be NEMA 12 — powder coated steel construction with a drip shield. B. Outdoor Cabinets shall be NEMA 3R — Stainless Steel, or Aluminum — with Stainless steel hinge pins and door handles. C. Control cabinets in corrosive areas or chemical rooms shall be stainless steel or non- metallic. D. Provide all control cabinets with a drip shield. E. Cabinets shall be hinged with stainless steel pins. F. Cabinets shall be provided with a stainless steel 3 point latch. G. Provide all control cabinets with a data pocket and insert the cabinet drawings in the pocket when shipped to the site. H. Provide all control cabinets which house PLC equipment with a 12x12" folding shelf HOFFMAN A-CSHELF12 or approved equal. Also provide an Ethernet port and 120V receptacle with a hinged clear cover for laptop interface on the outside of control panel door. I. Provide corrosion inhibitors in all control cabinets prior to shipping Amount of inhibitor shall be provided for the volume of the enclosure for one year. HOFFMAN AHC series or approved equal. J. Enclosure shall be manufactured by Hoffman Products, Inc. or approved equal. 2.5.3 ENCLOSURE DOOR LATCHES A. Door latches on all enclosures shall be fast operating type 3-point latch door handle. B. NEMA 4 and 4X shall also have 3-point latch if possible, but where a 3-point latch will not meet rating requirements and also for all types of enclosures that are too small for a 3 point latch use fast operating clamp assembles. Hoffman Bulletin A- 80 or equal. The latch handle shall operate toward the center of the panel to open the door, and be pointing down when closed. C. Small boxes and control stations shall have 2 screw driver or hand operated latches. 2.5.4 FOLDING SHELF/ DOOR STOP A. Provide a 12"x12" folding shelf on the door to all cabinets with remote 1/0 or PLC's for supporting a laptop computer. Hoffman A-CSHELF12 or approved equal. FOLLETT ENGINEERING, PLLC 16921-10 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 1. Mount the shelf so that when the cabinet is installed, the shelf will be 36" — 40" above the floor. B. On all cabinet doors with a folding shelf, provide a doorstop, Hoffman A-DSTOPK ALGSTOP-2 or approved equal,. 2.5.5 WIREWAYS A. Provide molded plastic wireways, slotted for wire connections for all wiring in the panels. They shall be complete with covers. Wireways shall be manufactured by Panduit or Taylor, or approved equal. 2.5.6 PANEL LIGHT, SWITCH AND CONVENIENCE OUTLET A. Provide LED lights with manual switch in control panels that contain a PLC rack , relays, or other equipment that would require troubleshooting or operator access for normal operation. Provide a simplex outlet, 120VAC 15A, in all panels that require a computer or other maintenance tools that may need a power source. These shall be on a separate dedicated circuit. 2.6 TERMINALS 2.6.1 GENERAL A. Provide terminals blocks arranged as described in this specification. B. PLC card — 1/0 terminal blocks shall be grouped together to match the terminal arrangement of the PLC card that they are connected to. C. TERMINAL NUMBERING — 1. Provide unique terminal numbers for all field wired terminals. 2. Terminal numbers and wire numbers shall relate to the shop drawing number. 3. Provide clear references on all wires that connect between drawings or are shown on more than one drawing. D. Provide terminals for all wire connections to field wiring and internal power distribution. For all terminals (including line voltage and neutral terminals) that are used for wiring out to field devices provide unique terminal numbers. E. Provide spare din rail space and spare terminals as indicated by the drawings or these specifications. F. For all energized circuits (power and control) powered from the panel and extend outside of the panel provide an individual fused terminal with appropriate fast blow fuse (1/2 amp for PLC inputs) and "blown fuse" indicator light for each circuit and unique terminal number. G. For all signal circuits that extend outside of the panel provide an individual fused terminal with appropriate fusing and integral blown fuse indication. All 4 to 20 mA circuits shall be individually fused with a 1/4 amp fast blow fuse; and blown fuse indicator. FOLLETT ENGINEERING, PLLC 16921-11 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 H. For all energized circuits powered outside of the panel which extend into the panel, provide a disconnecting terminal to isolate each individual circuit. I. Provide fusing of all DC circuits with appropriately sized fuses and blown fuse indicators. J. Analog loops that are 24 VDC powered shall have a knife switch to disable the loop. K. Connections shall have compression terminals capable of terminating 2 #14 AWG stranded wires. Terminals shall be DIN rail strip mounted Provide number strips for terminal blocks that are referenced by the wire marker. Provide bridge bars for jumpering between terminal blocks. Provide end clamps to separate and terminate terminal block groups. Provide end covers for groups of terminal blocks in sets to match the number points associated with individual 1/0 cards in the PLC rack. L. Provide Separation Plates on each side of terminals that are at a different potential or polarity than surrounding terminals. M. Provide clear plastic DIN rail mounted nametag stanchions for each block of terminations. Each nametag shall hold a preprinted label designating the PLC rack and PLC card (slot) that terminates to that set of terminals. N. Terminals shall be mounted such that there is a minimum of 2 inches of clear space on both sides of the terminal (between the terminals and the wireway); for ease of wiring and so that the entire wire tag will be visible outside the wireway. O. Mount all terminals strips on 2" standoffs from backpan. P. Provide wired terminals to match the number of points supplied on each 1/0 card in a cabinet. 2.6.1 GENERAL PURPOSE AND DIGITAL INPUT TERMINALS A. Terminal Blocks for general purpose and digital input terminations shall be Phoenix Contact UK 5, or equal. Provide UKK5 Double Hi, or equal, if space is limited. 2.6.2 ANALOG INPUT TERMINALS A. Terminal Blocks for use in analog input terminations shall be knife disconnect type, Phoenix UK 5-MTK , or equal. B. Provide one ground terminal for every two analog inputs for grounding the shield. C. Provide a fused terminal with a '/ amp fuse and blown fuse indicator for all analog inputs for loop power. 2.6.3 ANALOG OUTPUT TERMINALS A. UKK 5 Terminal blocks for analog outputs shall be fused, double hi with a separate ground terminal, or equal. FOLLETT ENGINEERING, PLLC 16921-12 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 2.6.4 DIGITAL OUTPUT RELAY TERMINALS A. Provide interface/interposing relays or relay output cards for all digital outputs that extend out of the control panel and for all spare and future digital outputs. Interface to digital output cards or relays as required to interface 1/0 module to DIN rail mounted relays, or equal. B. Provide relays to match the number of points supplied on each digital output card in a cabinet. C. Provide two descriptive labels for all din rail mounted relays. — One label on the backpan and one label on the relay. 2.6.5 FUSED TERMINALS A. Fuse terminal blocks shall be hinged disconnect level type with "blown fuse" indicators. PHOENIX CONTACT UK 5 HESI series, or equal 2.6.6 TEST AND CALIBRATION A. Provide 1 set for each Cabinet supplied plus 1 spare set consisting of: 1. Short Circuit Plug, 1 pair of Reducing Plugs, 1 pair of Test Adapters. 2.7 OPERATOR INTERFACE DEVICES A. All operator interface devices mounted on the panel front shall be rated for the environment in which they will be located. In general, devices mounted on indoor panels shall be NEMA 13 rated. Operator devices mounted outdoors, or in wet or corrosive environments shall be NEMA 4X rated. 2.7.2 ALARM BEACONS A. Alarm Beacons shall be heavy duty industrial, Marine Rated, high intensity strobe with minimum 800K peak candle power — Edwards 105 series w/ 8 joule high intensity strobe. Provide mounting bases and attachments as required for the application. 2.7.3 SELECTOR SWITCHES A. Selector switches shall be for use on 120 volt control circuits. Contacts shall have a continuous current rating of 10 amperes both inductive and resistive. Selector switches shall be of the heavy duty oil tight type. Allen Bradley 800T, 800H, GE CR104P, Square D Type K or approved equal. 2.7.4 PUSH BUTTONS A. Push buttons and illuminated push buttons shall be for use on 120 volt control circuits. and shall have continuous current rating of 10 amperes both inductive and resistive. Pushbuttons for "emergency" "help" applications shall have maintained contacts and red mushroom head operators. Allen Bradley Bulletin 800T, 800H or approved equal. FOLLETT ENGINEERING, PLLC 16921-13 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 2.7.5 INDICATING LIGHTS A. Indicating lights shall be push-to-test LED type. Illuminated pushbutton type with the pushbutton wired for the push-to-test function required. Appropriate lens caps shall be provided as shown.. 2.7.6 OPERATOR INTERFACE A. Provide an operator interface. provide a minimum 10" inch color graphic display and resistive touch screen. Interface shall be capable of color graphic displays. Software shall be TIA portal version consistent with the PLC program. Provide with Ethernet communications module. Operator Interface shall be Siemens, no substitutions B. Provide all necessary software and hardware for a complete system. C. Programming of the operator interface shall be done by the System Integrator (Systems Interface). 2.8 CABINET POWER DISTRIBUTION 2.8.1 CONTROL PANEL CIRCUIT BREAKERS A. Control panel circuit breakers shall be thermal-magnetic type, supplementary overcurrent devices. Circuit breakers shall be snap mountable on rails. Circuit breakers shall be sized for actual circuit load. or as shown on the drawings. 1. Provide 2 spare installed 5amp circuit breakers or the number of spares shown on the drawings, whichever is greater. Wire breakers out to terminals and provide number of spare neutral terminals to match number of hot terminals. B. Control panel circuit breakers shall be Allen-Bradley 1492-CB, or equal. C. In all control panels, provide a laminated drawing of the panel power distribution circuit breakers for referencing all circuit breakers in the panel. 2.8.2 GROUNDING A. Provide 3 spare ground terminals in each cabinet B. Provide a ground bus in each cabinet — minimum 6" long with screw terminals for grounding equipment and instrumentation. 2.8.3 FUSES A. Provide, fuse pullers; (one for each type of fuse), for removal of fuses. B. Provide blown fuse indicators on all fuses. 2.8.4 POWER SUPPLIES A. Power supplies shall be switching type, voltage, & sized to be able to supply the demand. Units shall be closed frame DIN rail type and have overvoltage and FOLLETT ENGINEERING, PLLC 16921-14 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 overcurrent protection. Units shall have LED power on light and 2 sets of output terminals. Power supplies shall be sized for the load plus an additional 30% PULS or equal. 2.8.5 UNINTERRUPTIBLE POWER SUPPLY(UPS) A. UPS shall be wired to provide uninterrupted power to PLC, Telemetry Radio, All 1/0 to include security elements (station entries) and station power indication information. UPS shall include analog output wired to the PLC such that if lost could potentially alarm the SCADA system. B. The uninterruptible 24VDC power supply (UPS) shall be a continuously on-line. Unit shall be sized to operate on 24VDC and maintain the 24VDC on battery backup for a minimum of 10 minutes. Unit shall be din rail mounted wired to control system power. The UPS size shall be chosen by the System Integrator for the load being served plus 20%. UPS shall be PULS.or equal. C. Provide labeling to differentiate UPS power circuits vs. non UPS powered circuits by adding a "U" suffix on the terminal name. 1. Provide 2 spare installed 5amp UPS circuit breakers or the number of spares shown on the drawings, whichever is greater. 2. Provide 3 spare "hot" terminals wired to the output of each spare UPS breaker and the same number of spare neutral terminals wired to the appropriate neutral. D. UPS INSTALLATION: The unit shall be din rail mounted. 2.9 RELAYS 2.9.1 RELAY LABELS A. Provide two labels for all relays one label on the backpan and one label on the front surface of the relay. 2.9.2 RELAYS FOR GENERAL PURPOSE A. Relays for general purpose shall have appropriate coil voltage for the application, contacts (amp and voltage) shall be rated for the application, minimum 2 amps. All relays shall have an integral indicating light to show if there is coil voltage present. They shall have pin/blade base and matching socket. Units shall be IDEC or equal. B. Appropriate relay (coil voltage and contact load ratings) shall be selected based on application from the control wiring diagrams and load served. 2.9.3 TIME DELAY RELAYS A. Time delay relays shall be multi-function, multi-range with plug-in base ,pin style terminations timing and timed out LED indicators, and calibrated scales. Relays shall have minimum 0.5 seconds to 60 minutes, 8 selectable timing ranges, 5 amp contacts. Select coil voltage for the application. Minimum accuracy FOLLETT ENGINEERING, PLLC 16921-15 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 requirements (plus or minus) shall be as follows: 1) Repeat accuracy 1/2% 2) Timing change over full voltage range 1/2% change over full temperature range 2% 3) Scale tolerance 5%. IDEC or equal. 2.9.4 DIGITAL OUTPUT RELAYS A. All digital outputs shall be provided with interposing relays wired out to terminals - including spares. Relays shall be group mounted with connecting cable to the PLC output card. Output relays can be single pole, N.O. or N.C. for the application — all Spare DO relays shall be form C with the N.O. contact wired to terminals. 2.10 INSTRUMENTATION 2.10.1 GENERAL REQUIREMENTS OF INSTRUMENTATION A. All Instruments, switches and control sensors shall be rated for the environment in which they will be located. In general, devices mounted indoors shall be NEMA 12 rated. Devices mounted outdoors, or in wet or corrosive environments shall be NEMA 4X rated. B. Devices mounted in hazardous areas shall be rated for the classification of the area that they are located. 1. Provide barriers, intrinsically safe relays, explosion proof boxes, or other equipment, if necessary to rate equipment for the environment installed. 2. Provide seal fittings per NEC C. Transmitters shall be indicating type when available and shall have local or direct reading indicators, unless otherwise shown. 1. Provide a pressure gauge for every pressure switch and transmitter. D. Select range of instruments for the application. E. Transmitter input power shall be 24VDC unless otherwise shown, output shall be 4-20 mA into a minimum 500 ohm load. F. For each instrument that has a separate power source, provide a power disconnect switch (rated for the environment and the application) mounted next to each instrument. G. Transmitters located outdoors shall be provided in an enclosure with a heater or provided with thermostat controlled heaters in their enclosure. H. Instruments shall automatically reset and resume normal operation after power interruption with out manual resetting. I. Instrument cords (for example: cords between the sensor and the transmitter) shall be provided: 1. With length sufficient for the application 2. With rating for the environment installed. FOLLETT ENGINEERING, PLLC 16921-16 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 J. Terminate all wiring on terminal strips, splicing wiring is not acceptable. K. Wire that terminates on screw type terminals shall be provided with a spade or loop type end connector. L. For all Indicating transmitters that are mounted inside enclosures, provide a window in the enclosure so that the display can be viewed without opening the enclosure. M. Instrumentation supplier shall provide installation inspection, calibration and training as required for proper installation. 2.10.2 DRYWELL LIQUID LEVEL SWITCHES (FLOOD SWITCH A. Provide drywell liquid level switch, hermetically sealed, magnetically actuated, snap action, 15W, 120V SPST, N.C. (dry). TRANSAMERICA DELAVAL - GEMS LS-1900 or 1950 chosen for the environment or approved equal. 2.10.3 INDOOR AIR TEMPERATURE TRANSMITTERS A. Air temperature transmitters shall be wall mounted type with 4-20mA output, temperature range of 0-135 degrees F. Accuracy in still air shall be minimum +or- 1.2 degrees F. OMEGA EWS series or equal. 2.10.4 SMOKE DETECTOR A. Smoke detectors shall be 120V power with a N.O. held closed contact for input into the MCP or FACP. Provide with 3 position switch test feature to simulate smoke conditions, LED condition indicator, 9V battery backup, strobe light with "FIRE" lettering. Smoke detectors shall be Edwards 517 series or approved equal. 2.11 MOTOR STARTERS / VFDS A. Motor starter units shall be of the combination type with components as indicated on the drawings. Magnetic contactors shall be heavy duty IEC or NEMA rated, All contactors shall be provided with two field convertible auxiliary contacts. Motor starters and associated equipment shall be provided to match or exceed the load being served. B. If IEC contactors are used, then the amp rating of the contactor shall be a minimum of 1.75 times the amp rating of the motor. C. Provide interface options for control, monitoring, and alarming as shown on the drawings and the wire diagrams. Manufacturer shall select the size and rating as required for the application. 2.11.2 OVERLOAD RELAYS A. Overload relays on starters shall be adjustable, solid state type with a minimum adjustment range of 3 to 1. Overload relays shall have selector for either auto or manual reset. Overload Relays shall monitor all energized conductors and FOLLETT ENGINEERING, PLLC 16921-17 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 shall trip on phase fail and ground fault. A Separate N.O. overload contact shall be provided in addition to standard N.C. overload contact. Overload relay shall be provided with a circuit test button which shall simulate an overload trip, trip indication, and reset pushbutton. Overload which trip on phase/power fail shall automatically reset upon normal power restoration. - Siemens 3RB12, Allen- Bradley E-1 or equal. B. Provide interface options for control, monitoring, and alarming as shown on the drawings and the wire diagrams. Manufacturer shall select the size and rating as required for the application. 2.11.3 CONTROL POWER TRANSFORMERS A. Each motor starter,soft starter, VFD etc. shall be equipped with its own individual control circuit transformer, 120 VAC secondary with primary and secondary fuses and blown fuse indicators. The transformer shall be sized to accommodate the contactor(s) and all connected control circuit loads. The transformer size shall also accommodate any devices connected or shown on the drawings as being served by the control circuit transformer. B. VFD control wiring shall be source wiring — control power shall be from the VFD source output. —typically 24VDC source output from the VFD 2.11.4 TRANSIENT SUPPRESSORS A. Provide all contactor coils with transient suppressors to limit the high voltage transients produced when power is removed from the coil. CUTLER HAMMER - C320AS1 or equal. 2.11.5 VARIABLE FREQUENCY DRIVES(VFD) A. VFDs shall be Danfoss VLT Aqua FC202 with full function HMI module mounted on the outer door or as shown on the drawings— VFD manufacturer shall select the size and rating as required for the application. Provide interface options for control, monitoring, and alarming as shown on the drawings and the wire diagrams. —. B. Provide DC bus chokes and 3% line reactors on all VFDs C. Provide DV/DT filters on the load side of the VFDs. D. Provide VFD control wiring for SOURCE control selection — SINKING inputs are not allowed. E. For VFDs furnished with fans — provide controls or thermostats so that the fans do not operate unless the equipment is running or the temperature is high. F. Provide VFDs with the following: 1. HOA switch and speed pot — in HAND speed will be controlled by the speed pot, In AUTO the VFD speed will be controlled from a remote 4-20mA input. FOLLETT ENGINEERING, PLLC 16921-18 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 2. Provide a programmable VFD input such that (with the switch in AUTO) when a remote dry contact connected to the input closes the VFD will start and operate at a pre set speed. (For backup pressure control). G. Configure VFDs so that any "bad power" (line side) fault will automatically reset when normal power returns and the VFD will automatically restart if called. H. Provide source power for control of VFD directly from the VFD or from a dedicated CPT for each individual VFD. Configure such that for the Drive to operate in HAND requires only the power source to the VFD. I. Provide relays as necessary for run, fail and other contacts for input to the PLC, indicator lights, louver/fan/heater controls etc. J. Configure the line side "faults" to maximum so that only major line side issues will shut down the VFD. Turn off any line side faults that are not required for protection of the VFD. Configure so that once line side faults clear and normal power returns the VFD will automatically reset and resume operation. K. Configure VFD for operation on both generator power and utility power so that the difference in line side power from the two sources will not fault the VFD. L. SERVICES OF MANUFACTURER 1. General: An authorized service representative of the manufacturer shall be present at the Site for three 1/2 Days to furnish the services listed below. For the purpose of this paragraph, a '/2 Day is defined as an 4 hour period excluding travel time. 2. Inspection, Startup, Field Adjustment: The authorized service representative shall supervise the following and certify the equipment and controls have been properly installed, aligned, and readied for operation. a) Installation of the equipment b) Inspection, checking, and adjusting the equipment c) Startup and field testing for proper operation d) Performing field adjustments such that the equipment installation and operation comply with requirements. 3. Instruction of OWNER's Personnel: The authorized representative shall instruct the OWNER's personnel in the operation and maintenance and configuration of the equipment, including step by step troubleshooting with test equipment. Instruction shall be specific to the equipment models provided. Training shall be scheduled a minimum of 3 weeks in advance of the first session. Training session shall be 2 hours minimum. Proposed training materials shall be submitted for review, and comments shall be incorporated. Training materials shall remain with the trainees. The OWNER may videotape the training for later use with the OWNER's personnel. 2.12 CIRCUIT BREAKERS A. Circuit breakers shall be molded case thermal-magnetic type. Circuit breakers other than those mounted in the panelboard shall be capable of being padlocked FOLLETT ENGINEERING, PLLC 16921-19 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 in the open position. Circuit breakers shall be quick-make and quick-break type. They shall have wiping type contacts. Each shall be provided with arc chutes, individual trip mechanisms on each pole. Two and three pole breakers shall be common trip. All breakers shall be calibrated for operation in an ambient temperature of 400C. Molded case circuit breakers shall be trip-free. Each breaker shall have separate trip indication independent of the ON or OFF positions. 1. Breakers shall have lugs UL listed for both copper and aluminum. 2. Breakers shall have the interrupting rating and trip rating indicated on the drawings. 3. All breakers for motor starters shall include auxiliary contacts which open when the breaker in the OFF position. 4. Provide service entrance rated breakers if required for the application by NEC. B. Provide interface options for control, monitoring, and alarming as shown on the drawings and the wire diagrams. Manufacturer shall select the size and rating as required for the application. 2.13 DRY TYPE TRANSFORMERS A. Provide dry type transformers in accordance to applicable requirements of Section 26 05 00. B. Where the one-line diagram calls out for isolation transformers; provide noise suppresser isolation transformers, Square D/Topaz Class 7610 or equal. 2.14 SURGE ARRESTORS A. Provide TVSS for control power circuit protection where shown on the plans, Islatrol IE-120. B. Provide Surge arrestors , with indicators, where shown on the one-line diagrams to protect against overvoltage transients. JOSLYN J9200 series with protective capacitor GE model 9L18 or equal. Select proper components for the application as shown on the drawings. 2.15 OPERATING MECHANISMS / MOTOR LOCKOUT A. The main disconnect/circuit breaker/fuse shall be provided with a lockable external "thru-the-door" operating handle with bypass. Square D Class 9422 or equal. B. Each Individual motor circuit breaker or disconnect shall be provided with a lockable external "thru-the-door" operating handle with bypass. mechanism for locking in the open position to meet the lockout/tagout requirements per the NEC. FOLLETT ENGINEERING, PLLC 16921-20 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 2.16 WIRE MARKERS: A. Field installed wire markers shall be T&B, SHRINK-KON HVM or approved equal. 2.17 SPARE PARTS STORAGE BOX A. Spare parts shall be provided in a NEMA 12 non-metallic storage box 18"x24"x9" (min size) with 3 shelves (to make four 6" compartments). Box shall include hinged door and hand operated latches - located as shown on the drawings or required by the Owner. 2.18 SPARE PARTS A. In addition to spare parts mentioned elsewhere in this section, the Contractor shall supply the following spare parts for use by the Owner: All spare parts shall be shipped with the equipment. 1. Qty 1 spare PLC processor to match, complete with Ethernet communications and all other options. 2. Qty. 1 spare (non installed) PLC input and output card of each type used. 3. Qty 1 spare power supply of each type and rating used. 4. Qty 1 Relay of each type used or 10 % whichever is the greater amount. 5. Qty 4 lamps of each type used. 6. Qty 200% spare fuses (two spare fuses for each fuse supplied). 7. Provide 10 spare nameplates 3" square or less with 20 letters 1/2" or less to be specified by the owner. PART 3 EXECUTION 3.1 INSTALLATION 3.1.1 GENERAL A. The instrumentation and control system shall be installed, in accordance with the contract drawings, installation details, and also instructions prepared by the System Integrator, and per special instruction from equipment or instrumentation Manufacturers. B. The Integrator shall provide detailed installation drawings and wiring diagrams for this purpose. C. Installation shall include all elements and components of the I&C system and all conduit and interconnecting wiring between all elements, components, and sensors. FOLLETT ENGINEERING, PLLC 16921-21 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 D. Provide instrument calibration sheets for all instruments to verify function, range, setpoints etc. 1. For analog instruments include range information and test at 0, 25%, 50% 75% and 100%. Unless otherwise shown set displays as follows — for level measurement in FEET, for pressure in PSI, for flow GPM. 2. For switches verify operation and check setpoint for correct operation — for floats verify trip level, pressure switch settings, etc. 3.1.2 WIRE AND CABLE TERMINATION: A. Stranded control conductors may be directly terminated using compression type terminals at control panels. Special instrumentation cables shall be terminated in accordance with the recommendations of the Manufacturer of the equipment and subject to review by the Engineer. B. No splices shall be used in power, control and/or signal wiring. The wiring shall be continuous from point-to-point. C. Terminals and connectors shall be installed with the compression tool recommended by the terminal Manufacturer. D. Any control or signal wire landing on a screw terminal shall be terminated with a spade or loop connector. E. All wire and cable shall be provided with a wire tag at each termination in accordance with the wire tagging requirements in the specification. F. Terminals shall be installed such that there is a minimum of 2" clear space between the terminal strip and the wireway on both sides of the terminal; for ease of wiring. 3.2 CONTROL PANEL DESIGN & FABRICATION 3.2.1 GENERAL A. Panels shall not be fabricated until Engineer has reviewed and approved the submittals or the integrator has written authorization from the Engineer to construct the panels. It shall be the integrator's responsibility to inform the Engineer in writing if there are limited time constraints that need to be met to start the panel fabrication to meet contract deadlines. 3.2.2 GENERAL LAYOUT A. Provide separate wire ways for field wiring and for internal wiring. Provide separate wireways for 120V and DC circuits. Mount PLC at top of control section, Mount digital input and output wireways and terminals on the left hand side and analog 1/0 terminals and wireways on the right side with power distribution down the middle of the control area. See drawings. 3.2.3 OPERATING DEVICE LOCATION FOLLETT ENGINEERING, PLLC 16921-22 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 A. Operating devices shall be mounted no higher than 6' - 4" and no lower than 4' - 0" above finished floor when panel is installed unless otherwise approved by the Engineer. Operating devices with displays (such as PLC interface, VFD interface, and power monitoring devices) shall be mounted so that the center of the display is between 4'-6" and 5-0" above finished floor unless otherwise approved by the Engineer. 3.2.4 POWER COMPONENTS 1. Provide lockable breakers for all motor load circuits to meet NEC lockout tagout requirements. 2. Provide cabinet power disconnect / door interlocking mechanism as required by UL, NEC, and any other authority. 3. Provide service entrance rated breaker if required for the application. 4. Provide all individual motor starters and VFDs with their own electrically isolated 120V control power transformer (CPT) or 120V control power circuit derived from the load side of the motor starter circuit breaker. Control power circuit for hand control shall be from the CPT so that motor load can be run manually when auto control power circuits have failed. 3.2.5 CONTROL CABINETS 1. Install PLC 1/0 card to terminal interface wiring with pre-manufactured, multi- conductor or bundled wire. 2. Install all terminals on 2" standoffs. 3. Terminals shall be installed to allow a minimum of 2" of clear space between the terminal and the wireway or any other components. 4. Coordinate terminals and wireway locations to account for the location of the conduit entrances into the cabinet. 5. Wire ways shall be 3" deep, width shall be chosen for the application. 6. Provide separate wire ways for internal and field wiring. 7. The UPS shall be din rail or shelf mounted — maintain at least 2" space between the bottom of the UPS and the bottom of the cabinet for field wiring. 8. Provide right angle connectors on cables if the cable connection prevents closing of access doors on equipment within the cabinet or on the control cabinet itself. 3.3 FACTORY TESTING & INSPECTION A. Prior to delivery to the site, the ATS, control panels and VFDs shall be tested by the System Integrator, all control devices shall be operated and the cabinet shall be powered with rated incoming voltage for at least 2 days. Simulating equipment shall be provided and wired into the control cabinet system for this testing. The entire control system shall be interconnected as it will be installed in the field if the actual equipment is not available, then simulation equipment shall be provided to fully demonstrate the functionality of the system. The System Integrator shall FOLLETT ENGINEERING, PLLC 16921-23 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 test all functionality of the system and verify proper operation of the hardware and software B. Following the System Integrators testing, the control panels and VFDs shall be tested and inspected by the Design Engineer prior to shipment to the project site. The testing shall include, but not be limited to, operation of all input and output (1/0) points, control devices and motor controllers and demonstration of all control functions with the actual equipment or via a simulation. The System Integrator shall revise, modify, adjust the system as required by the Engineer during the testing period. . The System Integrator shall inform and coordinate the time of the testing with the Engineer at least 4 weeks prior to the testing date. C. The System Integrator shall provide working space, a 6 foot table and 2 office/desk chairs for the test Engineers. 3.4 STARTUP AND TESTING A. All components of the control system shall be calibrated by the Manufacturer after completion of installation. Each component shall be adjusted to be within the Manufacturer's required range and for the specific application. B. Components that cannot be properly calibrated or that are found to exceed the Manufacturer's specified range or accuracy shall be removed and replaced at no additional cost to the Owner. C. The control system shall be placed into operation by the Contractor and System Integrator. D. All components shall be tested and recorded on check-off forms and shall be witnessed by the Engineer. 3.5 FIELD TESTING OF THE CONTROL SYSTEM 3.5.1 GENERAL A. When the installation is substantially complete, the Contractor shall commence field testing of the control system. This shall determine that all system components connect up correctly to each other so that the system works as designed. B. Field testing of the control system shall take place in 4 phases. 1. Continuity Testing, 2. 1/0 Testing, 3. Program Testing 4. System Validation Testing. 3.5.2 CONTINUITY TESTING A. As equipment wiring is completed, the Contractor and System Integrator shall perform a continuity test for every control to determine terminal to terminal FOLLETT ENGINEERING, PLLC 16921-24 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 continuity and verify all control and signal wiring is installed in accordance to the System Integrators wiring diagrams. 3.5.3 1/0 TESTING A. The entire I&C system shall be 1/0 tested. B. Prior to calling for 1/0 testing the Contractor shall: 1. Complete the continuity testing. 2. Label all wire at both ends. 3. Submit all associated test and calibration forms (Instrument, motor, wire, etc.) 4. Run all motors (in HAND) to verify correct operation and rotation 5. Provide all equipment and instrument labels per spec. 6. Test operation of"packaged sub systems" C. Prior to any equipment to be put into automatic operation, every digital and analog input and output shall be tested for correct operation and witnessed by the Electrical Engineer and/or Owner. D. The Integrator shall test all SCADA 1/0 with the Owner to ensure complete and accurate addressing to the Control Center HMI. In general, for discrete bits all "normal" conditions will be a 0 to the SCADA system and alarms or faults will be a 1. E. The contractor shall provide a set of the PLC Card drawings and instrument and control wiring diagrams on 81/2x11" sheets for a check-off list of all inputs and outputs. If a point cannot be verified within 5 minutes of starting the check that point shall be noted as a punch list item to be corrected and re-tested at a later time. F. Definition: Successfully 1/0 Tested. A piece of equipment of system shall be considered "successfully 1/0 tested" when all of the 1/0 for that equipment has been tested and verified by both the programmer and the Electrical Engineer and checked off of the wiring diagrams or PLC 1/0 card drawings. Note: The Electrical Engineer must witness and verify all 1/0 testing. G. Once all 1/0 associated with a piece of equipment of system has been successfully tested, then the equipment or system will be deemed ready for program testing. H. INPUTS: 1. The Contractor shall simulate an actual field condition whenever possible to provide both the digital and analog signal inputs into the PLC and these will be verified by the programmers. Where an actual field simulation is not practical, then the Contractor shall jumper the digital inputs at a point closest to the field device as possible and shall use an analog loop simulator for analog inputs. 2. Analog inputs shall be tested at 0,25%, 50%, and 100% of full range. I. OUTPUTS: FOLLETT ENGINEERING, PLLC 16921-25 425-765-6304 Kent Pump Station No.3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 1. The programmer will simulate outputs from the PLC and the Contractor shall verify the field operation of the output. The field operation verification shall be by actual operation of equipment when possible. When actual field operation of equipment is not practical for verification, then the Contractor shall use volt and amp metering to verify digital and signal outputs. 2. Analog outputs shall be tested at 0,25%, 50%, and 100% of full range. 3.5.4 PROGRAM TESTING A. The Contractor shall provide field support to the programmer for testing of the program. The Contractor shall provide field simulation of equipment as needed by the programmer to test all monitoring and alarm functions of the programming. The Contractor shall anticipate that the program testing will require up to a total of 24 hours of field support time for this project. The cost for this time shall be included in the bid. 3.5.5 SYSTEM VALIDATION TESTING A. After the program testing is complete, validation testing shall be by the Hardware and Software Engineer and Contractor, with the Owner and Engineer present. Validation testing shall include operation and verification of all control components and features of the entire control system. B. The Contractor shall simulate various field conditions to test all control operations, monitoring and alarms for all systems and equipment. C. The Contractor shall inform the Engineer of the testing schedule at least one week prior to the commencement of testing. Validation testing shall be considered complete when the Owner and Engineer have determined that all of the original system requirements have been met. D. The System Integrator shall revise, modify, adjust the system as required during and following start-up to provide the operation required by the contract documents. E. Note: the Engineer shall not be called out by the Contractor for validation testing on equipment until all components are installed, all wiring points have been checked, and operation has been tested and verified by the Contractor. 3.6 COMMISSIONING A. Once all systems have passed validation testing, then the facility will be operated for 2 weeks or time period as determined in the documents to verify all component and system operations prior to final acceptance. 3.7 SYSTEM MAINTENANCE A. The System Integrator shall be responsible for maintenance of the system from time of start-up to the date of acceptance, by formal action of the Owner, of all work under the contract. The System Integrator shall correct deficiencies and defects and make any and all repairs, replacements, modifications, and FOLLETT ENGINEERING, PLLC 16921-26 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 adjustments as malfunctions or failures occur. The System Integrator shall perform all such work required or considered to be required by the Owner to cause and maintain proper operation of the system and to properly maintain the system. 3.8 SERVICES OF SYSTEM INTEGRATOR A. General: An authorized service representative of the control panel System Integrator shall be present at the Site for two Days to furnish the services listed below. For the purpose of this paragraph, a Day is defined as a 6 hour period excluding travel time. B. Inspection, Startup, Field Adjustment: The authorized service representative shall supervise the following and certify the equipment and controls have been properly installed, aligned, and readied for operation. 1. Installation of the equipment 2. Inspection, checking, and adjusting the equipment 3. Startup and field testing for proper operation 4. Performing field adjustments such that the equipment installation and operation comply with requirements. C. Instruction of Owner's Personnel: The authorized representative shall instruct the Owner's personnel in the operation and maintenance of the equipment, including step by step troubleshooting with test equipment. Instruction shall be specific to the equipment models provided. Training shall be scheduled a minimum of 2 weeks in advance of the first session. Training shall include individual two sessions for 2 shifts of plant personnel (2 hours for each session). D. Proposed training materials shall be submitted for review, and comments shall be incorporated. Training materials shall remain with the trainees. The Owner may videotape the training for later use with the Owner's personnel. The System Integrator shall conduct specifically organized training sessions in operation and maintenance of the control system for personnel employed by the Owner. The training sessions shall be conducted to educate and train the personnel in maintenance and operation of all components of the control system. Training shall include, but not be limited to, the following: 1. Preventative maintenance procedures 2. Trouble-shooting 3. Calibration 4. Testing 5. Replacement of components 6. Automatic mode operation 7. Manual mode operation FOLLETT ENGINEERING, PLLC 16921-27 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 3.9 OPERATION AND MAINTENANCE DATA A. The System Integrator shall prepare and assemble detailed operation and maintenance manuals in accordance with the project general requirements . The manuals shall include, but not be limited to, the following: 1. Preventative maintenance procedures 2. Trouble-shooting 3. Calibration 4. Testing 5. Replacement of components 6. Automatic mode operation 7. Manual mode operation 8. System schematics / shop drawings 9. Electronic copy on CD ROM of all shop drawings in AutoCAD version 2000 or newer 10. As-built wiring diagrams of cabinet and enclosure contained assemblies 11. Catalog data and complete parts list for all equipment and control devices 12. Listing of recommended spare parts 13. Listing of recommended maintenance tools and equipment. B. 2 copies of the entire O&M manual shall be provided. C. 6 copies of the entire O&M manual shall be provided in electronic PDF format on CD ROMs. 3.10 RECORD DRAWINGS A. The System Integrator shall be responsible to provide a clean and neatly marked up set of record drawings showing any changes from the submittal and contract drawings. These drawings shall be provided prior to final approval of the project and release of the retainage. PART 4 WIRING DIAGRAM EXAMPLES 4.1 GENERAL A. The wiring diagrams shall be drawn and submitted in accordance with the following. 4.2 EQUIPMENT WIRING DIAGRAMS (LOOP DWGS) A. Provide one page wiring diagram for each motor / equipment load showing all of the control wiring associated with that load. Drawing shall show the motor control center wiring , field wiring, PLC 1/0, and control panel wiring all on one sheet; FOLLETT ENGINEERING, PLLC 16921-28 425-765-6304 Kent Pump Station No. 3 Electrical System Improvements INSTRUMENTATION & CONTROLS Project No. 17-7999.6 complete with terminal numbers and wire numbers. Include PLC Card information rack and slot and 1/0 designation for each point. 4.3 INSTRUMENT WIRING DIAGRAMS (LOOP DWGS) A. Show all wiring associated with each instrument on one page — including power supply location and signal wiring. Show all terminals numbers and wire numbers. Designate boundaries between field and control panels and etc. 4.4 NETWORK DIAGRAM A. Provide detailed drawings showing all of the components of the communications network — include all terminals and wire numbering. Designate equipment locations. 4.5 PLC 1/0 CARD DRAWINGS A. Provide 1/0 card drawings for all PLC 1/0 cards. Drawings shall show details specific to each 1/0 card, name of each input or output, reference drawing number for associated EQUIPMENT AND INSTRUMENT WIRING DIAGRAM, card number, slot number, control panel terminal and wire numbers, etc. END OF SECTION FOLLETT ENGINEERING, PLLC 16921-29 425-765-6304 SITE AND EQUIPMENT PHOTOS PS 3 Electrical System Improvements/Araucto A - 2 October 10, 2019 Project Number: 17-7999.6 Kent Pump Station No. 3 Electrical System Improvements Project No. 17-7999.6 ' Service Pole r Generator ; s` r } Pump Station 3 Entry Gate EXISTING PUMP STATION Kent Pump Station No. 3 Electrical System Improvements Project No. 17-7999.6 Service pole: Note - this is owned by the City, All service work including overhead line and service conductors will be done by the Contractor. 'I 911 a PS3 Service Pole and Telemetry Antenna EXISTING PUMP STATION Kent Pump Station No. 3 Electrical System Improvements Project No. 17-7999.6 1 PS3 North Side Ow r r� e h - PS3 South Side EXISTING PUMP STATION Kent Pump Station No. 3 Electrical System Improvements Service Disconnect Project No. 17-7999.6 Pump 1 Starter MTS } Transformer d 4. i- PS3 East Wall CL2 analyzer Pump 2 WIT" 74 { { Pump Station 3—West Wall EXISTING PUMP STATION Kent Pump Station No. 3 Electrical System Improvements Project No. 17-7999.6 PS 3 North Wall /- Pressure Switche Sl a Pressure Transmitters a r EXISTING PUMP STATION Kent Pump Station No. 3 Electrical System Improvements Project No. 17-7999.E Control Panel Pump 2 Starter PS3 Pressure switches and Pressure transmitters �u i 1 • PLC Cabinet + Heater PS3 South Wall n .. Pump 2 ya. wa.) .0k Pump Fi y. z 4 t PS3 looking West EXISTING PUMP STATION PREVAILING WAGE RATES PS 3 Electrical System Improvements/Araucto A - 3 October 10, 2019 Project Number: 17-7999.6 rayc i vi iv State of Washington Department of Labor & Industries Prevailing Wage Section - Telephone 360-902-5335 PO Box 44540, Olympia, WA 98504-4540 Washington State Prevailing Wage The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, worker's wage and benefit rates must add to not less than this total. A brief description of overtime calculation requirements are provided on the Benefit Code Key. Journey Level Prevailing Wage Rates for the Effective Date: 10/29/2019 County Trade Job Classification Wage Holiday Overtime Note *Risk Class King Asbestos Abatement Workers Journey Level $50.86 5D 1 H View King Boilermakers Journey Level $69.04 5N 1C View King Brick Mason Journey Level $58.82 5A 1M View King Brick Mason Pointer-Caulker-Cleaner $58.82 5A 1M View King Building Service Employees Janitor $25.581 5S 2F View King Building Service Employees Traveling Waxer/Shampooer $26.03 5S 2F View King Building Service Employees Window Cleaner (Non-Scaffold) $29.33 5S 2F View King Building Service Employees Window Cleaner (Scaffold) $30.33 5S 2F View King Cabinet Makers (In Shop) Journey Level $22.74 1 View King Carpenters Acoustical Worker $62.441 7A 4C View King Carpenters Carpenter $62.44 7A 4C View King Carpenters Carpenters on Stationary Tools $62.57 7A 4C View King Carpenters Creosoted Material $62.54 7A 4C View King Carpenters Floor Finisher $62.44 7A 4C View King Carpenters Floor Layer $62.44 7A 4C View King Carpenters Scaffold Erector $62.44 7A 4C View King Cement Masons Application of all Composition $62.97 7A 41J View Mastic King Cement Masons Application of all Epoxy Material $62.47 7A 41J View King Cement Masons Application of all Plastic Material $62.97 7A 4U View King Cement Masons Application of Sealing Compound $62.47 7A 41J View King Cement Masons Application of Underlayment $62.97 7A 41J View King Cement Masons Building General $62.47 7A 41J View King Cement Masons Composition or Kalman Floors $62.97 7A 41J View King Cement Masons Concrete Paving $62.47 7A 41J View King Cement Masons Curb Et Gutter Machine $62.97 7A 41J View King Cement Masons Curb Et Gutter, Sidewalks $62.47 7A 41J View King Cement Masons Curing Concrete $62.47 7A 41J View King Cement Masons Finish Colored Concrete $62.97 7A 41J View King Cement Masons Floor Grinding $62.97 7A 41J View King Cement Masons Floor Grinding/Polisher $62.471 7A 41J View King Cement Masons Green Concrete Saw, self- $62.97 7A 4U View powered King Cement Masons Grouting of all Plates $62.47 7A 41J View King Cement Masons Grouting of all Tilt-up Panels $62.47 7A 41J View h++nr-• //fnr+-rnr-r- tun n^� /I Innln n/n-AAInn I^^I- m nor - y r)/I r)11rli fl rays e- vi iv King Cement Masons Gunite Nozzleman $62.971 7A 4U View King Cement Masons Hand Powered Grinder $62.97 7A 41J View King Cement Masons Journey Level $62.47 7A 41J View King Cement Masons Patching Concrete $62.47 7A 41J View King Cement Masons Pneumatic Power Tools $62.97 7A 41J View King Cement Masons Power Chipping Et Brushing $62.97 7A 41J View King Cement Masons Sand Blasting Architectural Finish $62.97 7A 4U View King Cement Masons Screed Et Rodding Machine $62.97 7A 41J View King Cement Masons Spackling or Skim Coat Concrete $62.47 7A 41J View King Cement Masons Troweling Machine Operator $62.97 7A 41J View King Cement Masons Troweling Machine Operator on $62.97 7A 41J View Colored Slabs King Cement Masons Tunnel Workers $62.97 7A 41J View King Divers Et Tenders Bell/Vehicle or Submersible $116.20 7A 4C View Operator (Not Under Pressure) King Divers Et Tenders Dive Supervisor/Master $79.23 7A 4C View King Divers Et Tenders Diver $116.20 7A 4C 8V View King Divers Et Tenders Diver On Standby $74.23 7A 4C View King Divers Et Tenders Diver Tender $67.31 7A 4C View King Divers & Tenders Manifold Operator $67.31 7A 4C View King Divers Et Tenders Manifold Operator Mixed Gas $72.31 7A 4C View King Divers Et Tenders Remote Operated Vehicle $67.31 7A 4C View Operator/Technician King Divers Et Tenders Remote Operated Vehicle Tender $67.31 7A 4C View King Dredge Workers Assistant Engineer $56.44 5D 3F View King Dredge Workers Assistant Mate (Deckhand) $56.00 5D 3F View King Dredge Workers Boatmen $56.44 5D 3F View King Dredge Workers Engineer Welder $57.51 5D 3F View King Dredge Workers Leverman, Hydraulic $58.67 5D 3F View King Dredge Workers Mates $56.44 5D 3F View King Dredge Workers Oiler $56.00 5D 3F View King Drywall Applicator Journey Level $62.44 5D 1 H View King Drywall Tapers Journey Level $62.94 5P 1 E View King Electrical Fixture Maintenance Journey Level $30.59 5L 1E View Workers King Electricians - Inside Cable Splicer $83.17 7C 4E View King Electricians - Inside Cable Splicer (tunnel) $89.34 7C 4E View King Electricians - Inside Certified Welder $80.36 7C 4E View King Electricians - Inside Certified Welder (tunnel) $86.251 7C 4E View King Electricians - Inside Construction Stock Person $41.48 7C 4E View King Electricians - Inside Journey Level $77.55 7C 4E View King Electricians - Inside Journey Level (tunnel) $83.17 7C 4E View King Electricians Motor Shop Journey Level $45.081 5A 1 B View King Electricians - Powerline Cable Splicer $79.60 5A 4D View Construction King Electricians - Powerline Certified Line Welder $72.98 5A 4D View Construction King Electricians - Powerline Groundperson $47.94 5A 4D View Construction King Electricians - Powerline Heavy Line Equipment Operator $72.98 5A 4D View Construction King I liourney Level Lineperson $72.98 5A 4D View h+-#-nrr• / iAtn /Ini/u,nn 1^^1-.ntftn-AA/ ni-m%r Ir) 1r)fIr)Ir) rays .� vi iv Electricians - Powerline Construction King Electricians - Powerline Line Equipment Operator $62.06 5A 4D View Construction King Electricians - Powerline Meter Installer $47.94 5A 4D 8W View Construction King Electricians - Powerline Pole Sprayer $72.98 5A 4D View Construction King Electricians - Powerline Powderperson $54.55 5A 4D View Construction King Electronic Technicians Journey Level $51.07 7E 1 E View King Elevator Constructors Mechanic $94.22 7D 4A View King Elevator Constructors Mechanic In Charge $101.73 7D 4A View King Fabricated Precast Concrete All Classifications - In-Factory $18.25 5B 1R View Products Work Only King Fence Erectors Fence Erector $43.11 7A 4V 8Y View King Fence Erectors Fence Laborer $43.11 7A 4V 8Y View King Fla��ers Journey Level $43.11 7A 4V 8Y View King Glaziers Journey Level $66.51 7L 1Y View King Heat Et Frost Insulators And Journeyman $76.61 5J 4H View Asbestos Workers King Heating Equipment Mechanics Journey Level $85.88j 7F 1 E View King Hod Carriers Et Mason Tenders Journey Level $52.44 7A 4V 8Y View King Industrial Power Vacuum Cleaner Journey Level $12.00 1 View King Inland Boatmen Boat Operator $61.41 5B 1 K View King Inland Boatmen Cook $56.48 5B 1 K View King Inland Boatmen Deckhand $57.48 5B 1K View King Inland Boatmen Deckhand Engineer $58.81 5B 1K View King Inland Boatmen Launch Operator $58.89 5B 1K View King Inland Boatmen Mate $57.31 513 1K View King Inspection/Cleaning/Sealing Of Cleaner Operator, Foamer $31.49 1 View Sewer Et Water Systems By Operator Remote Control King Inspection/Cleaning/Sealing Of Grout Truck Operator $12.00 1 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Head Operator $24.91 1 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Technician $19.33 1 View Sewer Et Water Systems By Remote Control King Inspection/Cleaning/Sealing Of Tv Truck Operator $20.45 1 View Sewer Et Water Systems By Remote Control King Insulation Applicators Journey Level $62.44 7A 4C View King Ironworkers Journeyman $72.18 7N 10 View King Laborers Air, Gas Or Electric Vibrating $50.86 7A 4V 8Y View Screed King Laborers Airtrac Drill Operator $52.44 7A 4V 8Y View King Laborers Ballast Regular Machine $50.861 7A 4V 8Y View King Laborers Batch Weighman $43.11 7A 4V 8Y View King Laborers Brick Pavers $50.86 7A 4V 8Y View King ILaborers Brush Cutter $50.86 7A 4V 8Y View hfi�nr-• //fnr� rnrr ur- nnir/Ini/ru- nnlnnliin/r%ri AA/non 1^^1- nirmv 1 (1/1r)11)n Ir) rayc -r vi iv King Laborers Brush Hog Feeder $50.861 7A 4V 8Y View King Laborers Burner $50.86 7A 4V 8Y View King Laborers Caisson Worker $52.44 7A 4V 8Y View King Laborers Carpenter Tender $50.86 7A 4V 8Y View King Laborers Cement Dumper-paving $51.80 7A 4V 8Y View King Laborers Cement Finisher Tender $50.861 7A 4V 8Y View King Laborers Change House Or Dry Shack $50.86 7A 4V 8Y View King Laborers Chipping Gun (30 Lbs. And Over) $51.80 7A 4V 8Y View King Laborers Chipping Gun (Under 30 Lbs.) $50.86 7A 4V 8Y View King Laborers Choker Setter $50.86 7A 4V 8Y View King Laborers Chuck Tender $50.861 7A 4V 8Y View King Laborers Clary Power Spreader $51.80 7A 4V 8Y View King Laborers Clean-up Laborer $50.86 7A 4V 8Y View King Laborers Concrete Dumper/Chute $51.80 7A 4V 8Y View Operator King Laborers Concrete Form Stripper $50.861 7A 4V 8Y View King Laborers Concrete Placement Crew $51.80 7A 4V 8Y View King Laborers Concrete Saw Operator/Core $51.80 7A 4V 8Y View Driller King Laborers Crusher Feeder $43.11 7A 4V 8Y View King Laborers Curing Laborer $50.861 7A 4V 8Y View King Laborers Demolition: Wrecking Et Moving $50.86 7A 4V 8Y View (Incl. Charred Material) King Laborers Ditch Digger $50.86 7A 4V 8Y View King Laborers Diver $52.44 7A 4V 8Y View King Laborers Drill Operator (Hydraulic, $51.80 7A 4V 8Y View Diamond) King Laborers Dry Stack Walls $50.86 7A 4V 8Y View King Laborers Dump Person $50.86 7A 4V 8Y View King Laborers Epoxy Technician $50.86 7A 4V 8Y View King Laborers Erosion Control Worker $50.86 7A 4V 8Y View King Laborers Faller Et Bucker Chain Saw $51.801 7A 4V 8Y View King Laborers Fine Graders $50.86 7A 4V 8Y View King Laborers Firewatch $43.11 7A 4V 8Y View King Laborers Form Setter $50.86 7A 4V 8Y View King Laborers Gabian Basket Builders $50.86 7A 4V 8Y View King Laborers General Laborer $50.861 7A 4V 8Y View King Laborers Grade Checker Et Transit Person $52.44 7A 4V 8Y View King Laborers Grinders $50.86 7A 4V 8Y View King Laborers Grout Machine Tender $50.86 7A 4V 8Y View King Laborers Groutmen (Pressure) Including $51.80 7A 4V 8Y View Post Tension Beams King Laborers Guardrail Erector $50.86 7A 4V 8Y View King Laborers Hazardous Waste Worker (Level $52.44 7A 4V 8Y View King Laborers Hazardous Waste Worker (Level $51.80 7A 4V 8Y View King Laborers Hazardous Waste Worker (Level $50.86 7A 4V 8Y View C) King Laborers High Scaler $52.44 7A 4V 8Y View King Laborers Jackhammer $51.80 7A 4V 8Y View King Laborers Laserbeam Operator $51.80 7A 4V 8Y View kf+"r • .,n nn-/Ini m/nr, re n m- i n/1 r)f-Mir) rays ✓ vi iv King Laborers Maintenance Person $50.86 7A 4V 8Y View King Laborers Manhole Builder-Mudman $51.80 7A 4V 8Y View King Laborers Material Yard Person $50.86 7A 4V 8Y View King Laborers Motorman-Dinky Locomotive $51.80 7A 4V 8Y View King Laborers Nozzleman (Concrete Pump, $51.80 7A 4V 8Y View Green Cutter When Using Combination Of High Pressure Air Et Water On Concrete Et Rock, Sandblast, Gunite, Shotcrete, Water Blaster, Vacuum Blaster) King Laborers Pavement Breaker $51.80 7A 4V 8Y View King Laborers Pilot Car $43.11 7A 4V 8Y View King Laborers Pipe Layer Lead $52.441 7A 4V 8Y View King Laborers Pipe Layer/Tailor $51.80 7A 4V 8Y View King Laborers Pipe Pot Tender $51.80 7A 4V 8Y View King Laborers Pipe Reliner $51.80 7A 4V 8Y View King Laborers Pipe Wrapper $51.80 7A 4V 8Y View King Laborers Pot Tender $50.861 7A 4V 8Y View King Laborers Powderman $52.44 7A 4V 8Y View King Laborers Powderman's Helper $50.86 7A 4V 8Y View King Laborers Power Jacks $51.80 7A 4V 8Y View King Laborers Railroad Spike Puller - Power $51.80 7A 4V 8Y View King Laborers Raker - Asphalt $52.44 7A 4V 8Y View King Laborers Re-timberman $52.44 7A 4V 8Y View King Laborers Remote Equipment Operator $51.80 7A 4V 8Y View King Laborers Rigger/Signal Person $51.80 7A 4V 8Y View King Laborers Rip Rap Person $50.86 7A 4V 8Y View King Laborers Rivet Buster $51.80 7A 4V 8Y View King Laborers Rodder $51.80 7A 4V 8Y View King Laborers Scaffold Erector $50.86 7A 4V 8Y View King Laborers Scale Person $50.861 7A 4V 8Y View King Laborers Sloper (Over 20") $51.80 7A 4V 8Y View King Laborers Sloper Sprayer $50.86 7A 4V 8Y View King Laborers Spreader (Concrete) $51.80 7A 4V 8Y View King Laborers Stake Hopper $50.86 7A 4V 8Y View King Laborers Stock Piler $50.86 7A 4V 8Y View King Laborers Swinging Stage/Boatswain Chair $43.11 7A 4V 8Y View King Laborers Tamper Et Similar Electric, Air Et $51.80 7A 4V 8Y View Gas Operated Tools King Laborers Tamper (Multiple Et Self- $51.80 7A 4V 8Y View propelled) King Laborers Timber Person - Sewer (Lagger, $51.80 7A 4V 8Y View Shorer Et Cribber) King Laborers Toolroom Person (at Jobsite) $50.86 7A 4V 8Y View King Laborers Topper $50.86 7A 4V 8Y View King Laborers Track Laborer $50.861 7A 4V 8Y View King Laborers Track Liner (Power) $51.80 7A 4V 8Y View King Laborers Traffic Control Laborer $46.10 7A 4V 9C View King Laborers Traffic Control Supervisor $46.10 7A 4V 9C View King Laborers Truck Spotter $50.86 7A 4V 8Y View King Laborers Tugger Operator 1 $51.801 7A 4V 8Y View h��nr• //fnr�rnr�r u nni/Ini/ u- nnlnnlnn/nri1A/ �nnlnnliin - rn�i 1r)/ir)IInir) rays v vi iv King Laborers Tunnel Work-Compressed Air $120.61 7A 4V 9B View Worker 0-30 psi King Laborers Tunnel Work-Compressed Air $125.64 7A 4V 9B View Worker 30.01-44.00 psi King Laborers Tunnel Work-Compressed Air $129.32 7A 4V 9B View Worker 44.01-54.00 psi King Laborers Tunnel Work-Compressed Air $135.02 7A 4V 9B View Worker 54.01-60.00 psi King Laborers Tunnel Work-Compressed Air $137.14 7A 4V 9B View Worker 60.01-64.00 psi King Laborers Tunnel Work-Compressed Air $142.24 7A 4V 9B View Worker 64.01-68.00 psi King Laborers Tunnel Work-Compressed Air $144.14 7A 4V 9B View Worker 68.01-70.00 psi King Laborers Tunnel Work-Compressed Air $146.14 7A 4V 9B View Worker 70.01-72.00 psi King Laborers Tunnel Work-Compressed Air $148.14 7A 4V 9B View Worker 72.01-74.00 psi King Laborers Tunnel Work-Guage and Lock $52.54 7A 4V 8Y View Tender King Laborers Tunnel Work-Miner $52.54 7A 4V 8Y View King Laborers Vibrator $51.80 7A 4V 8Y View King Laborers Vinyl Seamer $50.86 7A 4V 8Y View King Laborers Watchman $39.18 7A 4V 8Y View King Laborers Welder $51.80 7A 4V 8Y View King Laborers Well Point Laborer $51.80 7A 4V 8Y View King Laborers Window Washer/Cleaner $39.18 7A 4V 8Y View King Laborers Underground Sewer $ General Laborer if Topman $50.86 7A 4V 8Y View Water King Laborers - Underground Sewer & Pipe Layer $51.80 7A 4V 8Y View Water King Landscape Construction Landscape $39.18 7A 4V 8Y View Construction/Landscaping Or Planting Laborers King Landscape Construction Landscape Operator $68.02 7A 3K 8X View King Landscape Maintenance Groundskeeper $17.871 1 View King Lathers Journey Level $62.441 5D 1 H View King Marble Setters Journey Level $58.82 5A 1M View King Metal Fabrication (In Shop) Fitter $15.86 1 View King Metal Fabrication (In Shop) Laborer $12.00 1 View King Metal Fabrication (In Shop) Machine Operator $13.04 1 View King Metal Fabrication (In Shop) Painter $12.001 1 View King Metal Fabrication (In Shop) Welder $15.48 1 View King Millwright Journey Level $63.94 7A 4C View King Modular Buildings Cabinet Assembly $12.00 1 View King Modular Buildings Electrician $12.00 1 View King Modular Buildings Equipment Maintenance $12.001 1 View King Modular Buildings Plumber $12.00 1 View King Modular Buildings Production Worker $12.00 1 View King Modular Buildings Tool Maintenance $12.00 1 View King Modular Buildings Utility Person $12.00 1 View King Modular Buildings Welder $12.00 1 View King Painters Journey Level $43.40 6Z 2B View h��ne�• //Fn n nn�I/Ini n1r e% 1A/nnnlnn Its in nrrr i ir1/Ir) f)Ir) rays i vi iv King Pile Driver Crew Tender $67.311 7A I 4C View King Pile Driver Crew Tender/Technician $67.31 7A 4C View King Pile Driver Hyperbaric Worker - Compressed $77.93 7A 4C View F Air Worker 0-30.00 PSI King Pile Driver Hyperbaric Worker - Compressed $82.93 7A 4C View Air Worker 30.01 - 44.00 PSI King Pile Driver Hyperbaric Worker - Compressed $86.93 7A 4C View Air Worker 44.01 - 54.00 PSI King Pile Driver Hyperbaric Worker - Compressed $91.93 7A 4C View Air Worker 54.01 - 60.00 PSI King Pile Driver Hyperbaric Worker - Compressed $94.43 7A 4C View Air Worker 60.01 - 64.00 PSI King Pile Driver Hyperbaric Worker - Compressed $99.43 7A 4C View 3 Air Worker 64.01 - 68.00 PSI King Pile Driver Hyperbaric Worker - Compressed $101.43 7A 4C View Air Worker 68.01 - 70.00 PSI King Pile Driver Hyperbaric Worker - Compressed $103.43 7A 4C View l Air Worker 70.01 - 72.00 PSI King Pile Driver Hyperbaric Worker - Compressed $105.43 7A 4C View Air Worker 72.01 74.00 PSI King Pile Driver Journey Level $62.69 7A 4C View King Plasterers Journey Level $59.42 1 R View King Playground Et Park Equipment Journey Level $12.00 1 View Installers King Plumbers Et Pipefitters Journey Level $87.69 6Z 1G View King Power Equipment Operators Asphalt Plant Operators $69.16 7A 3K 8X View King Power Equipment Operators Assistant Engineer $65.05 7A 3K 8X View King Power Equipment Operators Barrier Machine (zipper) $68.55 7A 3K 8X View King Power Equipment Operators Batch Plant Operator: concrete $68.55 7A 3K 8X View King Power Equipment Operators Bobcat $65.05 7A 3K 8X View King Power Equipment Operators Brokk - Remote Demolition $65.05 7A 3K 8X View Equipment King Power Equipment Operators Brooms $65.05 7A 3K 8X View King Power Equipment Operators Bump Cutter $68.55 7A 3K 8X View King Power Equipment Operators Cableways $69.16 7A 3K 8X View King Power Equipment Operators Chipper $68.55 7A 3K 8X View King Power Equipment Operators Compressor $65.05 7A 3K 8X View King Power Equipment Operators Concrete Finish Machine - Laser $65.05 7A 3K 8X View Screed King Power Equipment Operators Concrete Pump - Mounted Or $68.02 7A 3K 8X View Trailer High Pressure Line Pump, Pump High Pressure King Power Equipment Operators Concrete Pump: Truck Mount $69.16 7A 3K 8X View With Boom Attachment Over 42 M King Power Equipment Operators Concrete Pump: Truck Mount $68.55 7A 3K 8X View With Boom Attachment Up To 42m King Power Equipment Operators Conveyors $68.02 7A 3K 8X View King Power Equipment Operators Cranes friction: 200 tons and over $71.26 7A 3K 8X View King Power Equipment Operators Cranes: 100 tons through 199 $69.85 7A 3K 8X View tons, or 150' of boom (including jib with attachments) King Power Equipment Operators Cranes: 20 Tons Through 44 Tons $68.55 7A 3K 8X View With Attachments hi-+nrr- //Fn iAin nn�,/Ini/uinnnI^^It.inIninAAInei nnIti.in ne-m- Ir)11 •1/7r)Ir) rays v vi Iv King Power Equipment Operators Cranes: 200 tons- 299 tons, or $70.57 7A 3K 8X View 250' of boom including jib with attachments King Power Equipment Operators Cranes: 300 tons and over or 300' $71.26 7A 3K 8X View of boom including jib with attachments King Power Equipment Operators Cranes: 45 Tons Through 99 Tons, $69.16 7A 3K 8X View Under 150' Of Boom (including Jib With Attachments) King Power Equipment Operators Cranes: A-frame - 10 Tons And $65.05 7A 3K 8X View Under King Power Equipment Operators Cranes: Friction cranes through $70.57 7A 3K 8X View 199 tons King Power Equipment Operators Cranes: through 19 tons with $68.02 7A 3K 8X View attachments, A-frame over 10 tons King Power Equipment Operators Crusher $68.551 7A 3K 8X View King Power Equipment Operators Deck Engineer/Deck Winches $68.55 7A 3K 8X View (power) King Power Equipment Operators Derricks, On Building Work $69.16 7A 3K 8X View King Power Equipment Operators Dozers D-9 Et Under $68.02 7A 3K 8X View King Power Equipment Operators Drill Oilers: Auger Type, Truck Or $68.02 7A 3K 8X View Crane Mount King Power Equipment Operators Drilling Machine $69.85 7A 3K 8X View King Power Equipment Operators Elevator And Man-lift: Permanent $65.05 7A 3K 8X View And Shaft Type King Power Equipment Operators Finishing Machine, Bidwell And $68.55 7A 3K 8X View Gamaco Et Similar Equipment King Power Equipment Operators Forklift: 3000 Lbs And Over With $68.02 7A 3K 8X View Attachments King Power Equipment Operators Forklifts: Under 3000 Lbs. With $65.05 7A 3K 8X View Attachments King Power Equipment Operators Grade Engineer: Using Blue $68.55 7A 3K 8X View Prints, Cut Sheets, Etc King Power Equipment Operators Gradechecker/Stakeman $65.05 7A 3K 8X View King Power Equipment Operators Guardrail Punch $68.55 7A 3K 8X View King Power Equipment Operators Hard Tail End Dump Articulating $69.16 7A 3K 8X View Off- Road Equipment 45 Yards. Et Over King Power Equipment Operators Hard Tail End Dump Articulating $68.55 7A 3K 8X View Off-road Equipment Under 45 Yards King Power Equipment Operators Horizontal/Directional Drill $68.02 7A 3K 8X View Locator King Power Equipment Operators Horizontal/Directional Drill $68.55 7A 3K 8X View Operator King Power Equipment Operators Hydralifts/Boom Trucks Over 10 $68.02 7A 3K 8X View Tons King Power Equipment Operators Hydralifts/Boom Trucks, 10 Tons $65.05 7A 3K 8X View And Under King Power Equipment Operators Loader, Overhead 8 Yards. Et $69.85 7A 3K 8X View Over King Power Equipment Operators Loader, Overhead, 6 Yards. But $69.16 7A 3K 8X View Not Including 8 Yards King Power Equipment Operators Loaders, Overhead Under 6 Yards $68.55 7A 3K 8X View King Power Equipment Operators Loaders, Plant Feed $68.55 7A 3K 8X View ht�nr• //Fnr�rnrr u � nn,r/InihAt'%eYnlnnlllln/met AA/-tnnlnr,Iei I r)fir)/-)n I r) rays :7 vi iv King Power Equipment Operators Loaders: Elevating Type Belt $68.021 7A 3K 8X View King Power Equipment Operators Locomotives, All $68.55 7A 3K 8X View King Power Equipment Operators Material Transfer Device $68.55 7A 3K 8X View King Power Equipment Operators Mechanics, All (leadmen - $0.50 $69.85 7A 3K 8X View 's Per Hour Over Mechanic) King Power Equipment Operators Motor Patrol Graders $69.161 7A 3K 8X View King Power Equipment Operators Mucking Machine, Mole, Tunnel $69.16 7A 3K 8X View Drill, Boring, Road Header And/or Shield King Power Equipment Operators Oil Distributors, Blower $65.05 7A 3K 8X View Distribution Et Mulch Seeding Operator King Power Equipment Operators Outside Hoists (Elevators And $68.02 7A 3K 8X View Manlifts), Air Tuggers, Strato King Power Equipment Operators Overhead, Bridge Type Crane: 20 $68.55 7A 3K 8X View Tons Through 44 Tons King Power Equipment Operators Overhead, Bridge Type: 100 Tons $69.85 7A 3K 8X View And Over King Power Equipment Operators Overhead, Bridge Type: 45 Tons $69.16 7A 3K 8X View Through 99 Tons King Power Equipment Operators Pavement Breaker $65.05 7A 3K 8X View King Power Equipment Operators Pile Driver (other Than Crane $68.55 7A 3K 8X View Mount) King Power Equipment Operators Plant Oiler - Asphalt, Crusher $68.02 7A 3K 8X View King Power Equipment Operators Posthole Digger, Mechanical $65.051 7A 3K 8X View King Power Equipment Operators Power Plant $65.05 7A 3K 8X View King Power Equipment Operators Pumps - Water $65.05 7A 3K 8X View King Power Equipment Operators Quad 9, Hd 41, D10 And Over $69.16 7A 3K 8X View King Power Equipment Operators Quick Tower - No Cab, Under 100 $65.05 7A 3K 8X View Feet In Height Based To Boom King Power Equipment Operators Remote Control Operator On $69.16 7A 3K 8X View Rubber Tired Earth Moving Equipment King Power Equipment Operators Rigger and Bellman $65.05 7A 3K 8X View King Power Equipment Operators Rigger/Signal Person, Bellman $68.02 7A 3K 8X View (Certified) King Power Equipment Operators Rollagon $69.161 7A 3K 8X View King Power Equipment Operators Roller, Other Than Plant Mix $65.05 7A 3K 8X View King Power Equipment Operators Roller, Plant Mix Or Multi-lift $68.02 7A 3K 8X View Materials King Power Equipment Operators Roto-mill, Roto-grinder $68.55 7A 3K 8X View King Power Equipment Operators Saws - Concrete $68.02 7A 3K 8X View King Power Equipment Operators Scraper, Self Propelled Under 45 $68.55 7A 3K 8X View Yards King Power Equipment Operators Scrapers - Concrete Et Carry All $68.02 7A 3K 8X View King Power Equipment Operators Scrapers, Self-propelled: 45 Yards $69.16 7A 3K 8X View And Over King Power Equipment Operators Service Engineers - Equipment $68.021 7A 3K 8X View King Power Equipment Operators Shotcrete/Gunite Equipment $65.05 7A 3K 8X View King Power Equipment Operators Shovel , Excavator, Backhoe, $68.02 7A 3K 8X View Tractors Under 15 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoe: Over $69.16 7A 3K 8X View 30 Metric Tons To 50 Metric Tons King Power Equipment Operators $68.55 7A 3K 8X View h�trr• //Fnr�rnrr urn nnir/Ini/ u- nnI^^It.,n/nrir\AInnnlnnIt..n nor^ 1r)/i (1/"1r)IC) rayc iv vi lv Shovel, Excavator, Backhoes, Tractors: 15 To 30 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes: $69.85 7A 3K 8X View Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes: $70.57 7A 3K 8X View Over 90 Metric Tons King Power Equipment Operators Slipform Pavers $69.16 7A 3K 8X View King Power Equipment Operators Spreader, Topsider Et Screedman $69-161 7A 3K 8X View King Power Equipment Operators Subgrader Trimmer $68.55 7A 3K 8X View King Power Equipment Operators Tower Bucket Elevators $68.02 7A 3K 8X View King Power Equipment Operators Tower Crane Up To 175' In Height $69.85 7A 3K 8X View Base To Boom King Power Equipment Operators Tower Crane: over 175' through $70.57 7A 3K 8X View 250' in height, base to boom King Power Equipment Operators Tower Cranes: over 250' in height $71.26 7A 3K 8X View from base to boom King Power Equipment Operators Transporters, All Track Or Truck $69.16 7A 3K 8X View Type King Power Equipment Operators Trenching Machines $68.02 7A 3K 8X View King Power Equipment Operators Truck Crane Oiler/driver - 100 $68.55 7A 3K 8X View Tons And Over King Power Equipment Operators Truck Crane Oiler/Driver Under $68.02 7A 3K 8X View 100 Tons King Power Equipment Operators Truck Mount Portable Conveyor $68.551 7A 3K 8X View King Power Equipment Operators Welder $69.16 7A 3K 8X View King Power Equipment Operators Wheel Tractors, Farmall Type $65.05 7A 3K 8X View King Power Equipment Operators Yo Yo Pay Dozer $68.55 7A 3K 8X View King Power Equipment Operators- Asphalt Plant Operators $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Assistant Engineer $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Barrier Machine (zipper) $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Batch Plant Operator, Concrete $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Bobcat $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Brokk - Remote Demolition $65.05 7A 3K 8X View Underground Sewer Et Water Equipment King Power Equipment Operators- Brooms $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Bump Cutter $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Cableways $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Chipper $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Compressor $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Concrete Finish Machine - Laser $65.05 7A 3K 8X View Underground Sewer Et Water Screed King Power Equipment Operators- Concrete Pump - Mounted Or $68.02 7A 3K 8X View Underground Sewer Et Water Trailer High Pressure Line Pump, Pump High Pressure h�Fnr• //Fnrirnrr ui � nni#/Ini InnIriin/n-AA/nnn1^^I-in n m%r 1r)11 !1/"l/lIr) rays li Ui lv King Power Equipment Operators- Concrete Pump: Truck Mount $69.16 7A 3K 8X View Underground Sewer Et Water With Boom Attachment Over 42 M King Power Equipment Operators- Concrete Pump: Truck Mount $68.55 7A 3K 8X View Underground Sewer Et Water With Boom Attachment Up To 42m King Power Equipment Operators- Conveyors $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Cranes friction: 200 tons and over $71.26 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Cranes: 100 tons through 199 $69.85 7A 3K 8X View Underground Sewer Et Water tons, or 150' of boom (including jib with attachments) King Power Equipment Operators- Cranes: 20 Tons Through 44 Tons $68.55 7A 3K 8X View Underground Sewer Et Water With Attachments King Power Equipment Operators- Cranes: 200 tons- 299 tons, or $70.57 7A 3K 8X View Underground Sewer Et Water 250' of boom including jib with attachments King Power Equipment Operators- Cranes: 300 tons and over or 300' $71.26 7A 3K 8X View Underground Sewer Et Water of boom including jib with attachments King Power Equipment Operators- Cranes: 45 Tons Through 99 Tons, $69.16 7A 3K 8X View Underground Sewer Et Water Under 150' Of Boom (including Jib With Attachments) King Power Equipment Operators- Cranes: A-frame - 10 Tons And $65.05 7A 3K 8X View Underground Sewer Et Water Under King Power Equipment Operators- Cranes: Friction cranes through $70.57 7A 3K 8X View Underground Sewer Er Water 199 tons King Power Equipment Operators- Cranes: through 19 tons with $68.02 7A 3K 8X View Underground Sewer Et Water attachments, A-frame over 10 tons King Power Equipment Operators- Crusher $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Deck Engineer/Deck Winches $68.55 7A 3K 8X View Underground Sewer Et Water (power) King Power Equipment Operators- Derricks, On Building Work $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Dozers D-9 Et Under $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Drill Oilers: Auger Type, Truck Or $68.02 7A 3K 8X View Underground Sewer Et Water Crane Mount King Power Equipment Operators- Drilling Machine $69.85 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Elevator And Man-lift: Permanent $65.05 7A 3K 8X View Underground Sewer Et Water And Shaft Type King Power Equipment Operators- Finishing Machine, Bidwell And $68.55 7A 3K 8X View Underground Sewer Et Water Gamaco Et Similar Equipment King Power Equipment Operators- Forklift: 3000 Lbs And Over With $68.02 7A 3K 8X View Underground Sewer Et Water Attachments King Power Equipment Operators- Forklifts: Under 3000 Lbs. With $65.05 7A 3K 8X View Underground Sewer Et Water Attachments King Power Equipment Operators- Grade Engineer: Using Blue $68.55 7A 3K 8X View Underground Sewer Et Water Prints, Cut Sheets, Etc King Power Equipment Operators- Gradechecker/Stakeman $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Guardrail Punch $68.55 7A 3K 8X View Underground Sewer Et Water King $69.16 7A 3K 8X I View h++ //Fnrlrnrr u.n nnli/Ini/.0 nnIti. /I � AA/nnnlnn lee im nrrn%f in/1n/1)nIn rays lZ- vi iv Power Equipment Operators- Hard Tail End Dump Articulating Underground Sewer £t Water Off- Road Equipment 45 Yards. Et Over King Power Equipment Operators- Hard Tail End,Dump Articulating $68.55 7A 3K 8X View Underground Sewer Et Water Off-road Equipment Under 45 Yards King Power Equipment Operators- Horizontal/Directional Drill $68.02 7A 3K 8X View Underground Sewer it Water Locator King Power Equipment Operators- Horizontal/Directional Drill $68.55 7A 3K 8X View Underground Sewer Et Water Operator King Power Equipment Operators- Hydralifts/Boom Trucks Over 10 $68.02 7A 3K 8X View Underground Sewer Et Water Tons King Power Equipment Operators- Hydralifts/Boom Trucks, 10 Tons $65.05 7A 3K 8X View Underground Sewer Et Water And Under King Power Equipment Operators- Loader, Overhead 8 Yards. Et $69.85 7A 3K 8X View Underground Sewer Et Water Over King Power Equipment Operators- Loader, Overhead, 6 Yards. But $69.16 7A 3K 8X View Underground Sewer Et Water Not Including 8 Yards King Power Equipment Operators- Loaders, Overhead Under 6 Yards $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Loaders, Plant Feed $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Loaders: Elevating Type Belt $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Locomotives, All $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Material Transfer Device $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Mechanics, All (leadmen - $0.50 $69.85 7A 3K 8X View Underground Sewer Et Water Per Hour Over Mechanic) King Power Equipment Operators- Motor Patrol Graders $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Mucking Machine, Mole, Tunnel $69.16 7A 3K 8X View Underground Sewer Et Water Drill, Boring, Road Header And/or Shield King Power Equipment Operators- Oil Distributors, Blower $65.05 7A 3K 8X View Underground Sewer Et Water Distribution Et Mulch Seeding Operator King Power Equipment Operators- Outside Hoists (Elevators And $68.02 7A 3K 8X View Underground Sewer Et Water Manlifts), Air Tuggers, Strato King Power Equipment Operators- Overhead, Bridge Type Crane: 20 $68.55 7A 3K 8X View Underground Sewer Et Water Tons Through 44 Tons King Power Equipment Operators- Overhead, Bridge Type: 100 Tons $69.85 7A 3K 8X View Underground Sewer Et Water And Over King Power Equipment Operators- Overhead, Bridge Type: 45 Tons $69.16 7A 3K 8X View Underground Sewer Et Water Through 99 Tons King Power Equipment Operators- Pavement Breaker $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Pile Driver (other Than Crane $68.55 7A 3K 8X View Underground Sewer Et Water Mount) King Power Equipment Operators- Plant Oiler - Asphalt, Crusher $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Posthole Digger, Mechanical $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Power Plant $65.05 7A 3K 8X View Underground Sewer Et Water King jPumps - Water $65.05 7A 3K 8X I View kI-+rt •- //frtr]-rr%� tat notr/Inii—nrtrtlnnlr,in/e%,%AAInrl � 1^^1 .m nrnv 1 rl/1 rl/7/11 C1 royc i.) vi lv Power Equipment Operators- Underground Sewer Et Water King Power Equipment Operators- Quad 9, Hd 41, D10 And Over $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Quick Tower - No Cab, Under 100 $65.05 7A 3K 8X View Underground Sewer Et Water Feet In Height Based To Boom King Power Equipment Operators- Remote Control Operator On $69.16 7A 3K 8X View Underground Sewer Et Water Rubber Tired Earth Moving Equipment King Power Equipment Operators- Rigger and Bellman $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Rigger/Signal Person, Bellman $68.02 7A 3K 8X View Underground Sewer Et Water (Certified) King Power Equipment Operators- Rollagon $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Roller, Other Than Plant Mix $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Roller, Plant Mix Or Multi-lift $68.02 7A 3K 8X View Underground Sewer Et Water Materials King Power Equipment Operators- Roto-mill, Roto-grinder $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Saws - Concrete $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Scraper, Self Propelled Under 45 $68.55 7A 3K 8X View Underground Sewer Et Water Yards King Power Equipment Operators- Scrapers - Concrete Et Carry All $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Scrapers, Self-propelled: 45 Yards $69.16 7A 3K 8X View Underground Sewer Et Water And Over King Power Equipment Operators- Service Engineers - Equipment $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Shotcrete/Gunite Equipment $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Shovel , Excavator, Backhoe, $68.02 7A 3K 8X View Underground Sewer Et Water Tractors Under 15 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoe: Over $69.16 7A 3K 8X View Underground Sewer Et Water 30 Metric Tons To 50 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes, $68.55 7A 3K 8X View Underground Sewer Et Water Tractors: 15 To 30 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes: $69.85 7A 3K 8X View Underground Sewer Et Water Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes: $70.57 7A 3K 8X View Underground Sewer Et Water Over 90 Metric Tons King Power Equipment Operators- Slipform Pavers $69.16 7A 3K 8X View Underground Sewer E` Water King Power Equipment Operators- Spreader, Topsider Et Screedman $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Subgrader Trimmer $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Tower Bucket Elevators $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Tower Crane Up To 175' In Height $69.85 7A 3K 8X View Underground Sewer Et Water Base To Boom King Power Equipment Operators- Tower Crane: over 175' through $70.57 7A 3K 8X View Underground Sewer Et Water 250' in height, base to boom h��nr-• //fnri—n %&in nn,r/Ini/ Ain I^e%lnin/nrirlAIn"^Innln n n,r "w 1 /1/irl/7(11 (1 rays l-r vi 1V King Power Equipment Operators- Tower Cranes: over 250' in height $71.26 7A 3K 8X View Underground Sewer Et Water from base to boom King Power Equipment Operators- Transporters, All Track Or Truck $69.16 7A 3K 8X View Underground Sewer Et Water Type King Power Equipment Operators- Trenching Machines $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Truck Crane Oiler/driver - 100 $68.55 7A 3K 8X View Underground Sewer Et Water Tons And Over King Power Equipment Operators- Truck Crane Oiler/Driver Under $68.02 7A 3K 8X View Underground Sewer Et Water 100 Tons King Power Equipment Operators- Truck Mount Portable Conveyor $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Welder $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Wheel Tractors, Farman Type $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Yo Yo Pay Dozer $68.55 7A 3K 8X View Underground Sewer Et Water King Power Line Clearance Tree Journey Level In Charge $50.96 5A 4A View Trimmers King Power Line Clearance Tree Spray Person $48.35 5A 4A View Trimmers King Power Line Clearance Tree Tree Equipment Operator $50.96 5A 4A View Trimmers King Power Line Clearance Tree Tree Trimmer $45.54 5A 4A View Trimmers King Power Line Clearance Tree Tree Trimmer Groundperson $34.51 5A 4A View Trimmers King Refrigeration Et Air Conditioning Journey Level $82.51 6Z 1G View Mechanics King Residential Brick Mason Journey Level $58.82 5A 1M View King Residential Carpenters Journey Level $32.06 1 View King Residential Cement Masons Journey Level $29.25 1 View King Residential Drywall Applicators Journey Level $46.43 7A 4C View King Residential Drywall Tapers Journey Level $47.171 5P 1 E View King Residential Electricians Journey Level $36.01 1 View King Residential Glaziers Journey Level $44.15 7L 1 H View King Residential Insulation Applicators Journey Level $29.87 1 View King Residential Laborers Journey Level $26.18 1 View King Residential Marble Setters Journey Level $27.381 1 View King Residential Painters Journey Level $27.80 1 View King Residential Plumbers Et Journey Level $39.43 1 View Pipefitters King Residential Refrigeration Et Air Journey Level $54.12 5A 1G View Conditioning Mechanics King Residential Sheet Metal Workers Journey Level (Field or Shop) $51.89 7F 1 R View King Residential Soft Floor Layers Journey Level $51.07 5A 3J View King Residential Sprinkler Fitters (Fire Journey Level $48.18 5C 211 View Protection) King Residential Stone Masons Journey Level $58.821 5A 1M View King Residential Terrazzo Workers Journey Level $54.06 5A 1M View King Residential Terrazzo/Tile Journey Level $24.39 1 View Finishers King Residential Tile Setters Journey Level $21.04 1 View h��nr• //fnr�rnr-'- u-� nn /Ini/ - nnlnnlnin/nri1A/-�nnlnnliin -+rni i (1/i /1/')(lift rays l.) Ui iv King Roofers Journey Level $53.271 5A 3H I View King Roofers Using Irritable Bituminous $56.27 5A 3H View Materials King Sheet Metal Workers Journey Level (Field or Shop) $85.88 7F 1 E View King Shipbuilding Et Ship Repair New Construction Boilermaker $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Carpenter $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Crane Operator $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Electrician $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Heat Et Frost $76.61 5J 4H View Insulator King Shipbuilding Et Ship Repair New Construction Laborer $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Machinist $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Operating $36.36 7V 1 View Engineer King Shipbuilding Et Ship Repair New Construction Painter $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Pipefitter $36.361 7V 1 View King Shipbuilding Et Ship Repair New Construction Rigger $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Sheet Metal $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Shipfitter $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction $36.36 7V 1 View Warehouse/Teamster King Shipbuilding Et Ship Repair New Construction Welder / $36.36 7V 1 View Burner King Shipbuilding Et Ship Repair Ship Repair Boilermaker $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Carpenter $44.95 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Crane Operator $45.06 7Y 4K View King Shipbuilding Et Ship Repair Ship Repair Electrician $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Heat Et Frost Insulator $76.611 5J 4H View King Shipbuilding Et Ship Repair Ship Repair Laborer $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Machinist $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Operating Engineer $45.06 7Y 4K View King Shipbuilding Et Ship Repair Ship Repair Painter $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Pipefitter $46.15 7X 4J View King Shipbuilding; Et Ship Repair Ship Repair Rigger $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Sheet Metal $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Shipwright $44.95 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Warehouse / $45.06 7Y 4K View Teamster King Sign Makers Et Installers Journey Level $50.90 0 1 View (Electrical) King Sign Makers Et Installers (Non- Journey Level $31.52 0 1 View Electrical) King Soft Floor Lavers Journey Level $51.07 5A 3J View King Solar Controls For Windows Journey Level $12.44 1 View King Sprinkler Fitters (Fire Protection) Journey Level $81.39 5C 1X View King Stage Rigging Mechanics (Non Journey Level $13.23 1 View Structural) King Stone Masons Journey Level $58.82 5A 1M View King Street And Parking Lot Sweeper Journey Level $19.09 1 View Workers King Surveyors Assistant Construction Site $68.02 7A 3K 8X View Surveyor h��nr�• //fnr�rnrr u -i nn /Ini/ u- nnI^nlninIninAAIn e%Inn lei m n nv ir)/Ir)1-)/girl rayc iv vi iv King Surveyors Chainman $65.05 7A 3K 8X View King Surveyors Construction Site Surveyor $69.16 7A 3K 8X View King Telecommunication Technicians Journey Level $51.07 7E 1 E View King Telephone Line Construction - Cable Splicer $41.81 5A 2B View Outside King Telephone Line Construction - Hole Digger/Ground Person $23.53 5A 2B View Outside King Telephone Line Construction - Installer (Repairer) $40.09 5A 2B View Outside King Telephone Line Construction - Special Aparatus Installer 1 $41.81 5A 2B View Outside King Telephone Line Construction - Special Apparatus Installer II $40.99 5A 2B View Outside King Telephone Line Construction - Telephone Equipment Operator $41.81 5A 2B View Outside (Heavy) King Telephone Line Construction - Telephone Equipment Operator $38.92 5A 2B View Outside (Light) King Telephone Line Construction - Telephone Lineperson $38.92 5A 2B View Outside King Telephone Line Construction - Television Groundperson $22.32 5A 2B View Outside King Telephone Line Construction - Television Lineperson/Installer $29.60 5A 2B View Outside King Telephone Line Construction - Television System Technician $35.20 5A 2B View Outside King Telephone Line Construction - Television Technician $31.67 5A 2B View Outside King Telephone Line Construction - Tree Trimmer $38.92 5A 2B View Outside King Terrazzo Workers Journey Level $54.06 5A 1M View King Tile Setters Journey Level $54.06 5A 1M View King Tile, Marble Et Terrazzo Finishers Finisher $44.891 5A 1 B View King Traffic Control Stripers Journey Level $47.68 7A 1 K View King Truck Drivers Asphalt Mix Over 16 Yards $61.59 5D 4Y 8L View King Truck Drivers Asphalt Mix To 16 Yards $60.75 5D 4Y 8L View King Truck Drivers Dump Truck $60.75 5D 4Y 8L View King Truck Drivers Dump Truck Et Trailer $61.59 5D 4Y 8L View King Truck Drivers Other Trucks $61.59 5D 4Y 8L View King Truck Drivers - Ready Mix Transit Mix $61.59 5D 4Y 8L View King Well Drillers Et Irrigation Pump Irrigation Pump Installer $17.71 1 View Installers King Well Drillers Et Irrigation Pump Oiler $12.97 1 View Installers King Welt Drillers Et Irrigation Pump Well Driller $18.00 1 View Installers /Fnr}rnrr ui-+ AA/ r)/i (1 IIr)i r) Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 Overtime Codes Overtime calculations are based on the hourly rate actually paid to the worker.On public works projects,the hourly rate must be not less than the prevailing rate of wage minus the hourly rate of the cost of fringe benefits actually provided for the worker. 1. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40)HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. B. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. C. The first two(2)hours after eight(8)regular hours Monday through Friday and the first ten(10)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. D. The first two(2)hours before or after a five-eight(8)hour workweek day or a four-ten(10)hour workweek day and the first eight(8)hours worked the next day after either workweek shall be paid at one and one-half times the hourly rate of wage.All additional hours worked and all worked on Sundays and holidays shall be paid at double the hourly rate of wage. E. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. F. The first two(2)hours after eight(8)regular hours Monday through Friday and the first ten(10)hours on Saturday shall be paid at one and one-half times the hourly rate of wage.All other overtime hours worked,except Labor Day, shall be paid at double the hourly rate of wage.All hours worked on Labor Day shall be paid at three times the hourly rate of wage. G. The first ten(10)hours worked on Saturdays and the first ten(10)hours worked on a fifth calendar weekday in a four- ten hour schedule,shall be paid at one and one-half times the hourly rate of wage.All hours worked in excess of ten (10)hours per day Monday through Saturday and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. H. All hours worked on Saturdays(except makeup days if work is lost due to inclement weather conditions or equipment breakdown) shall be paid at one and one-half times the hourly rate of wage. All hours worked Monday through Saturday over twelve(12)hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. I. All hours worked on Sundays and holidays shall also be paid at double the hourly rate of wage. J. The first two(2)hours after eight(8)regular hours Monday through Friday and the first ten(10)hours on Saturday shall be paid atone and one-half times the hourly rate of wage. All hours worked over ten(10)hours Monday through Saturday,Sundays and holidays shall be paid at double the hourly rate of wage. K. All hours worked on Saturdays and Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. M. All hours worked on Saturdays(except makeup days if work is lost due to inclement weather conditions)shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. N. All hours worked on Saturdays(except makeup days)shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. 1 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 Overtime Codes Continued 1. O. The first ten(10)hours worked on Saturday shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays,holidays and after twelve(12)hours,Monday through Friday and after ten(10)hours on Saturday shall be paid at double the hourly rate of wage. P. All hours worked on Saturdays(except makeup days if circumstances warrant)and Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. Q. The first two (2) hours after eight (8) regular hours Monday through Friday and up to ten (10) hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of ten (10) hours per day Monday through Saturday and all hours worked on Sundays and holidays(except Christmas day)shall be paid at double the hourly rate of wage.All hours worked on Christmas day shall be paid at two and one-half times the hourly rate of wage. R. All hours worked on Sundays and holidays shall be paid at two times the hourly rate of wage. S. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays and all other overtime hours worked, except Labor Day, shall be paid at double the hourly rate of wage. All hours worked on Labor Day shall be paid at three times the hourly rate of wage. U. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays (except Labor Day) shall be paid at two times the hourly rate of wage. All hours worked on Labor Day shall be paid at three times the hourly rate of wage. V. All hours worked on Sundays and holidays(except Thanksgiving Day and Christmas day) shall be paid at one and one-half times the hourly rate of wage. All hours worked on Thanksgiving Day and Christmas day shall be paid at double the hourly rate of wage. W. All hours worked on Saturdays and Sundays (except make-up days due to conditions beyond the control of the employer))shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. X. The first four(4)hours after eight(8)regular hours Monday through Friday and the first twelve(12)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked over twelve (12) hours Monday through Saturday, Sundays and holidays shall be paid at double the hourly rate of wage. When holiday falls on Saturday or Sunday, the day before Saturday, Friday, and the day after Sunday, Monday, shall be considered the holiday and all work performed shall be paid at double the hourly rate of wage. Y. All hours worked outside the hours of 5:00 am and 5:00 pm (or such other hours as may be agreed upon by any employer and the employee)and all hours worked in excess of eight(8)hours per day(10 hours per day for a 4 x 10 workweek)and on Saturdays and holidays(except labor day) shall be paid at one and one-half times the hourly rate of wage.(except for employees who are absent from work without prior approval on a scheduled workday during the workweek shall be paid at the straight-time rate until they have worked 8 hours in a day(10 in a 4 x 10 workweek)or 40 hours during that workweek.)All hours worked Monday through Saturday over twelve (12)hours and all hours worked on Sundays and Labor Day shall be paid at double the hourly rate of wage. Z. All hours worked on Saturdays and Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid the straight time rate of pay in addition to holiday pay. 2 Benefit Code Key— Effective 8/31/2019 thru 4/1/2020 Overtime Codes Continued 2. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40)HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. B. All hours worked on holidays shall be paid at one and one-half times the hourly rate of wage. C. All hours worked on Sundays shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays shall be paid at two times the hourly rate of wage. F. The first eight(8)hours worked on holidays shall be paid at the straight hourly rate of wage in addition to the holiday pay.All hours worked in excess of eight(8)hours on holidays shall be paid at double the hourly rate of wage. G. All hours worked on Sunday shall be paid at two times the hourly rate of wage.All hours worked on paid holidays shall be paid at two and one-half times the hourly rate of wage including holiday pay. H. All hours worked on Sunday shall be paid at two times the hourly rate of wage. All hours worked on holidays shall be paid at one and one-half times the hourly rate of wage. O. All hours worked on Sundays and holidays shall be paid at one and one-half times the hourly rate of wage. R. All hours worked on Sundays and holidays and all hours worked over sixty(60)in one week shall be paid at double the hourly rate of wage. U. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage.All hours worked over 12 hours in a day or on Sundays and holidays shall be paid at double the hourly rate of wage. W. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. On a four-day,ten- hour weekly schedule,either Monday thru Thursday or Tuesday thru Friday schedule,all hours worked after ten shall be paid at double the hourly rate of wage. The first eight(8)hours worked on the fifth day shall be paid at one and one-half times the hourly rate of wage. All other hours worked on the fifth, sixth, and seventh days and on holidays shall be paid at double the hourly rate of wage. 3. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40)HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. A. Work performed in excess of eight(8)hours of straight time per day,or ten(10)hours of straight time per day when four ten (10) hour shifts are established, or forty (40) hours of straight time per week, Monday through Friday, or outside the normal shift, and all work on Saturdays shall be paid at time and one-half the straight time rate. Hours worked over twelve hours (12)in a single shift and all work performed after 6:00 pm Saturday to 6:00 am Monday and holidays shall be paid at double the straight time rate of pay.Any shift starting between the hours of 6:00 pm and midnight shall receive an additional one dollar($1.00)per hour for all hours worked that shift. The employer shall have the sole discretion to assign overtime work to employees.Primary consideration for overtime work shall be given to employees regularly assigned to the work to be performed on overtime situations. After an employee has worked eight(8)hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours or more. C. Work performed in excess of eight(8)hours of straight time per day,or ten(10)hours of straight time per day when four ten (10) hour shifts are established, or forty (40) hours of straight time per week, Monday through Friday, or outside the normal shift, and all work on Saturdays shall be paid at one and one-half times the hourly rate of wage. All work performed after 6:00 pm Saturday to 5:00 am Monday and Holidays shall be paid at double the hourly rate of wage.After an employee has worked eight(8)hours at an applicable overtime rate,all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours or more. 3 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 Overtime Codes Continued 3. E. All hours worked Sundays and holidays shall be paid at double the hourly rate of wage.Each week,once 40 hours of straight time work is achieved,then any hours worked over 10 hours per day Monday through Saturday shall be paid at double the hourly wage rate. F. All hours worked on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sunday shall be paid at two times the hourly rate of wage.All hours worked on paid holidays shall be paid at two and one-half times the hourly rate of wage including holiday pay. H. All work performed on Sundays between March 16th and October 14th and all Holidays shall be compensated for at two (2) times the regular rate of pay. Work performed on Sundays between October 15th and March 15th shall be compensated at one and one half(1-1/2)times the regular rate of pay. J. All hours worked between the hours of 10:00 pm and 5:00 am, Monday through Friday, and all hours worked on Saturdays shall be paid at a one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. K. Work performed in excess of eight(8)hours of straight time per day,or ten(10)hours of straight time per day when four ten (10) hour shifts are established, or forty (40) hours of straight time per week, Monday through Friday, or outside the normal 5 am to 6pm shift, and all work on Saturdays shall be paid at one and one-half times the hourly rate of wage.All work performed after 6:00 pm Saturday to 5:00 am Monday and Holidays,and all hours worked in excess of twelve(12)hours in a single shift shall be paid at double the hourly rate of wage. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours or more.When an employee returns to work without at least eight(8)hours time off since their previous shift,all such time shall be a continuation of shift and paid at the applicable overtime rate until he/she shall have the eight(8)hours rest period. 4. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40)HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. A. All hours worked in excess of eight(8)hours per day or forty(40)hours per week shall be paid at double the hourly rate of wage.All hours worked on Saturdays,Sundays and holidays shall be paid at double the hourly rate of wage. B. All hours worked over twelve(12)hours per day and all hours worked on holidays shall be paid at double the hourly rate of wage. C. On Monday through Friday, the first four(4) hours of overtime after eight(8) hours of straight time work shall be paid at one and one half(1-1/2)times the straight time rate of pay,unless a four(4)day ten(10)hour workweek has been established. On a four (4) day ten (10) hour workweek scheduled Monday through Thursday, or Tuesday through Friday,the first two(2)hours of overtime after ten(10)hours of straight time work shall be paid at one and one half(1-1/2)times the straight time rate of pay. On Saturday,the first twelve(12)hours of work shall be paid at one and one half(1-1/2)times the straight time rate of pay,except that if the job is down on Monday through Friday due to weather conditions or other conditions outside the control of the employer,the first ten(10)hours on Saturday may be worked at the straight time rate of pay.All hours worked over twelve(12)hours in a day and all hours worked on Sunday and Holidays shall be paid at two(2)times the straight time rate of pay. Overtime Codes Continued 4. D. All hours worked in excess of eight(8)hours per day or forty(40)hours per week shall be paid at double the hourly rate of wage.All hours worked on Saturday,Sundays and holidays shall be paid at double the hourly rate of pay.Rates include all members of the assigned crew. 4 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 EXCEPTION: On all multipole structures and steel transmission lines, switching stations,regulating, capacitor stations, generating plants, industrial plants, associated installations and substations, except those substations whose primary function is to feed a distribution system,will be paid overtime under the following rates: The first two (2)hours after eight(8)regular hours Monday through Friday of overtime on a regular workday, shall be paid at one and one-half times the hourly rate of wage.All hours in excess of ten(10)hours will be at two(2)times the hourly rate of wage. The first eight(8)hours worked on Saturday will be paid at one and one-half(1-1/2)times the hourly rate of wage.All hours worked in excess of eight(8)hours on Saturday,and all hours worked on Sundays and holidays will be at the double the hourly rate of wage. All overtime eligible hours performed on the above described work that is energized, shall be paid at the double the hourly rate of wage. 4. E. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. On a four-day, ten-hour weekly schedule, either Monday thru Thursday or Tuesday thru Friday schedule, all hours worked after ten shall be paid at double the hourly rate of wage.The Monday or Friday not utilized in the normal four- day,ten hour work week,and Saturday shall be paid at one and one half(I V2)times the regular shift rate for the first eight(8) hours. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. F. All hours worked between the hours of 6:00 pm and 6:00 am,Monday through Saturday, shall be paid at a premium rate of 20%over the hourly rate of wage. All hours worked on Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. G. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked Monday through Saturday over twelve (12) hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. H. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours worked,except Labor Day, and all hours on Sunday shall be paid at double the hourly rate of wage.All hours worked on Labor Day shall be paid at three times the hourly rate of wage. I. The First eight(8)hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of eight(8)per day on Saturdays shall be paid at double the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. J. The first eight(8)hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of eight(8)hours on a Saturday shall be paid at double the hourly rate of wage. All hours worked over twelve(12)in a day, and all hours worked on Sundays and Holidays shall be paid at double the hourly rate of wage. K. All hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage, so long as Saturday is the sixth consecutive day worked. All hours worked over twelve(12)in a day Monday through Saturday,and all hours worked on Sundays and Holidays shall be paid at double the hourly rate of wage. L. The first twelve(12)hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage.All hours worked on a Saturday in excess of twelve (12)hours shall be paid at double the hourly rate of pay. All hours worked over twelve(12)in a day Monday through Friday, and all hours worked on Sundays shall be paid at double the hourly rate of wage.All hours worked on a holiday shall be paid at one and one-half times the hourly rate of wage, except that all hours worked on Labor Day shall be paid at double the hourly rate of pay. 5 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 4. M. All hours worked on Sunday and Holidays shall be paid at double the hourly rate. Any employee reporting to work less than nine (9)hours from their previous quitting time shall be paid for such time at time and one-half times the hourly rate. N. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays,and all work performed between the hours of midnight(12:00 AM)and eight AM(8:00 AM) every day shall be paid at double the hourly rate of wage. O. All hours worked between midnight Friday to midnight Sunday shall be paid at one and one-half the hourly rate of wage. After an employee has worked in excess of eight(8) continuous hours in any one or more calendar days, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of six (6) hours or more. All hours worked on Holidays shall be paid at double the hourly rate of wage. P. All hours worked on Holidays shall be paid at one and one-half times the hourly rate of wage. Q. The first four(4)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked over twelve (12) hours Monday through Saturday shall be paid at double the hourly rate. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. R. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage,so long as Saturday is the sixth consecutive day worked. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. S. All hours worked on Saturdays and Holidays shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays shall be paid at double the hourly rate of wage. T. The first two(2)hours of overtime for hours worked Monday-Friday shall be paid at one and one-half times the hourly rate of wage.All hours worked in excess of ten(10)hours per day shall be paid at double the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage.For work on Saturday which is scheduled prior to the end of shift on Friday,the first six(6)hours work shall be paid at one and one-half times the hourly rate of wage,and all hours over(6)shall be paid double the hourly rate of wage.For work on Saturday which was assigned following the close of shift on Friday,all work shall be paid at double the hourly rate of wage. U. The first four(4)hours after eight(8)regular hours Monday through Friday and the first twelve(12)hours on Saturday shall be paid at one and one-half times the hourly rate of wage.(Except on makeup days if work is lost due to inclement weather,then the first eight(8)hours on Saturday may be paid the regular rate.)All hours worked over twelve(12) hours Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. V. Work performed in excess of ten(10)hours of straight time per day when four ten(10)hour shifts are established or outside the normal shift(5 am to 6pm),and all work on Saturdays,except for make-up days shall be paid at time and one-half(1 ''/z)the straight time rate. In the event the job is down due to weather conditions,then Saturday may,be worked as a voluntary make-up day at the straight time rate. However, Saturday shall not be utilized as a make-up day when a holiday falls on Friday. All work performed on Sundays and holidays and work in excess of twelve(12)hours per day shall be paid at double(2x) the straight time rate of pay. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours. When an employee returns to work without a break of eight(8)hours since their previous shift,all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight (8)hours. 6 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 4. W. All hours worked on Saturdays(except makeup days if work is lost due to inclement weather conditions)shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. When an employee returns to work without at least eight(8)hours time off since their previous shift, all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight(8)hours. X. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage.Work performed outside the normal shift of 6 am to 6pm shall be paid at one and one-half the straight time rate,(except for special shifts or three shift operations). All work performed on Sundays and holidays shall be paid at double the hourly rate of wage.Shifts may be established when considered necessary by the Employer. The Employer may establish shifts consisting of eight(8)or ten(10)hours of work(subject to WAC 296-127-022), that shall constitute a normal forty (40) hour work week. The Employer can change from a 5-eight to a 4-ten hour schedule or back to the other. All hours of work on these shifts shall be paid for at the straight time hourly rate.Work performed in excess of eight hours(or ten hours per day(subject to WAC 296-127-022)shall be paid atone and one- half the straight time rate. When due to conditions beyond the control of the Employer, or when contract specifications require that work can only be performed outside the regular day shift,then by mutual agreement a special shift may be worked at the straight time rate, eight(8)hours work for eight(8)hours pay. The starting time shall be arranged to fit such conditions of work. When an employee returns to work without at a break of eight (8) hours since their previous shift, all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight (8)hours. Holiday Codes 5. A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day,and Christmas Day(7). B. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day,the day before Christmas,and Christmas Day(8). C. Holidays: New Year's Day, Presidents' Day,Memorial Day, Independence Day, Labor Day, Thanksgiving Day,the Friday after Thanksgiving Day,And Christmas Day(8). D. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8). H. Holidays:New Year's Day,Memorial Day,Independence Day,Thanksgiving Day,the Day after Thanksgiving Day, And Christmas(6). I. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day (6). J. Holidays: New Year's Day, Memorial Day, Independence Day, Thanksgiving Day, Friday after Thanksgiving Day, Christmas Eve Day,And Christmas Day(7). K. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday After Thanksgiving Day,The Day Before Christmas,And Christmas Day(9). 7 I i Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 5. L. Holidays:New Year's Day,Martin Luther King Jr.Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day,Friday after Thanksgiving Day,And Christmas Day(8). N. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day,The Friday After Thanksgiving Day,And Christmas Day(9). P. Holidays:New Year's Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day,Friday And Saturday After Thanksgiving Day, The Day Before Christmas, And Christmas Day (9). If A Holiday Falls On Sunday, The Following Monday Shall Be Considered As A Holiday. Q. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day(6). R. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Day After Thanksgiving Day,One-Half Day Before Christmas Day,And Christmas Day.(7 1/2). S. Paid Holidays:New Year's Day,Presidents' Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, And Christmas Day(7). T. Paid Holidays: New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day,The Friday After Thanksgiving Day,Christmas Day,And The Day Before Or After Christmas(9). Z. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans Day, Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(8). Holiday Codes Continued 6. A. Paid Holidays:New Year's Day,Presidents'Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(8). E. Paid Holidays: New Year's Day, Day Before Or After New Year's Day, Presidents Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and a Half- Day On Christmas Eve Day.(9 1/2). G. Paid Holidays: New Year's Day, Martin Luther King Jr. Day, Presidents' Day, Memorial Day, Independence Day, Labor Day,Veterans'Day,Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Day,and Christmas Eve Day(11). H. Paid Holidays:New Year's Day,New Year's Eve Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day,Friday After Thanksgiving Day,Christmas Day,The Day After Christmas,And A Floating Holiday(10). I. Paid Holidays:New Year's Day, Memorial Day, Independence Day,Labor Day,Thanksgiving Day,Friday After Thanksgiving Day,And Christmas Day(7). T. Paid Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day,The Friday After Thanksgiving Day,The Last Working Day Before Christmas Day,And Christmas Day(9). Z. Holidays:New Year's Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, Friday after Thanksgiving Day, And Christmas Day (7). If a holiday falls on Saturday, the preceding Friday shall be considered as the holiday. If a holiday falls on Sunday, the following Monday shall be considered as the holiday. 8 Benefit Code Key— Effective 8/31/2019 thru 4/1/2020 7. A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8).Any Holiday Which Falls On A Sunday Shall Be Observed As A Holiday On The Following Monday. If any of the listed holidays falls on a Saturday,the preceding Friday shall be a regular work day. B. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. C. Holidays:New Year's Day,Martin Luther King Jr.Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas'Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. D. Paid Holidays: New Year's Day,Memorial Day,Independence Day,Labor Day,Veteran's Day,Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (8). Unpaid Holidays: President's Day. Any paid holiday which falls on a Sunday shall be observed as a holiday on the following Monday.Any paid holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. E. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. F. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, the last working day before Christmas day and Christmas day(8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. G. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day (6).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. H. Holidays:New Year's Day,Martin Luther King Jr.Day,Independence Day,Memorial Day,Labor Day,Thanksgiving Day, the Friday after Thanksgiving Day,the Last Working Day before Christmas Day and Christmas Day(9). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. I. Holidays:New Year's Day,President's Day,Independence Day,Memorial Day,Labor Day,Thanksgiving Day,The Friday After Thanksgiving Day,The Day Before Christmas Day And Christmas Day(9).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. J. Holidays:New Year's Day,Independence Day,Memorial Day,Labor Day,Thanksgiving Day and Christmas Day(6). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. K. Holidays: New Year's Day, Memorial Day, Independence Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. 9 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 7. L. Holidays: New Year's Day, Memorial Day, Labor Day, Independence Day, Thanksgiving Day,the Last Work Day before Christmas Day,And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. M. Paid Holidays: New Year's Day, The Day after or before New Year's Day, President's Day, Memorial Day, Independence Day,Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Day,And the Day after or before Christmas Day (10). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. N. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.When Christmas falls on a Saturday,the preceding Friday shall be observed as a holiday. P. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day,And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Q. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,the Last Working Day before Christmas Day and Christmas Day(8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.If any of the listed holidays falls on a Saturday,the preceding Friday shall be a regular work day. R. Paid Holidays: New Year's Day, the day after or before New Year's Day, President's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and the day after or before Christmas Day(10).If any of the listed holidays fall on Saturday,the preceding Friday shall be observed as the holiday. If any of the listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly. S. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day,Christmas Day,the Day after Christmas,and A Floating Holiday(9).If any of the listed holidays falls on a Sunday,the day observed by the Nation shall be considered a holiday and compensated accordingly. T. Paid Holidays: New Year's Day, the Day after or before New Year's Day, President's Day, Memorial Day, Independence Day,Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Day,and The Day after or before Christmas Day. (10). If any of the listed holidays falls on a Sunday, the day observed by the Nation shall be considered a holiday and compensated accordingly.Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. V. Holidays:New Year's Day,President's Birthday,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, the Friday after Thanksgiving Day,Christmas Day,the day before or after Christmas,and the day before or after New Year's Day. If any of the above listed holidays falls on a Sunday,the day observed by the Nation shall be considered a holiday and compensated accordingly. W. Holidays: New Year's Day, Day After New Year's, Memorial Day, Independence Day, Labor Day, Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Eve Day,Christmas Day,the day after Christmas,the day before New Year's Day,and a Floating Holiday. X. Holidays:New Year's Day,Day before or after New Year's Day,Presidents'Day,Memorial Day,Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and the day before or after Christmas day.If a holiday falls on a Saturday or on a Friday that is the normal day off,then the holiday will be taken 10 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 on the last normal workday.If the holiday falls on a Monday that is the normal day off or on a Sunday,then the holiday will be taken on the next normal workday. 7. Y. Holidays:New Year's Day,Presidents' Day,Memorial Day, Independence Day,Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,and Christmas Day.(8)If the holiday falls on a Sunday,then the day observed by the federal government shall be considered a holiday and compensated accordingly. Z. Holidays:New Year's Day,President's Day,Independence Day,Memorial Day,Labor Day,Thanksgiving Day,The Friday After Thanksgiving Day,And Christmas Day(8).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. Holiday Codes Continued 15. A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,the day before Christmas Day and Christmas Day. (8)Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. B. Holidays:New Year's Day,Martin Luther King Jr. Day,President's Day,Memorial Day,Independence Day,Labor Day,Veteran's Day,Thanksgiving Day,and Christmas Day. (9) C. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,the day before Christmas Day and Christmas Day.(8) D. Holidays:New Year's Day,Presidents'Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day,Friday after Thanksgiving Day,Christmas Day,and the day after Christmas. E. Holidays:the day before New Years's Day,New Year's Day,Martin Luther King,Jr.Day,Presidents'Day,Memorial Day,Independence Day,Labor Day,Veteran's Day,Thanksgiving Day,Friday after Thanksgiving Day,the day before Christmas,and Christmas Day. (12) Note Codes 8. D. Workers working with supplied air on hazmat projects receive an additional$1.00 per hour. L. Workers on hazmat projects receive additional hourly premiums as follows -Level A: $0.75, Level B: $0.50, And Level C: $0.25. M. Workers on hazmat projects receive additional hourly premiums as follows: Levels A& B: $1.00, Levels C & D: $0.50. N. Workers on hazmat projects receive additional hourly premiums as follows-Level A: $1.00,Level B: $0.75,Level C: $0.50,And Level D: $0.25. P. Workers on hazmat projects receive additional hourly premiums as follows-Class A Suit: $2.00,Class B Suit:$1.50, Class C Suit: $1.00,And Class D Suit$0.50. Q. The highest pressure registered on the gauge for an accumulated time of more than fifteen (15) minutes during the shift shall be used in determining the scale paid. 11 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 8. S. Effective August 31,2012—A Traffic Control Supervisor shall be present on the project whenever flagging or spotting or other traffic control labor is being utilized.Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer.All flaggers and spotters shall possess a current flagging card issued by the State of Washington, Oregon, Montana, or Idaho. This classification is only effective on or after August 31, 2012. T. Effective August 31,2012—A Traffic Control Laborer performs the setup,maintenance and removal of all temporary traffic control devices and construction signs necessary to control vehicular, bicycle, and pedestrian traffic during construction operations. Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer. All flaggers and spotters shall possess a current flagging card issued by the State of Washington,Oregon,Montana,or Idaho.This classification is only effective on or after August 31,2012. U. Workers on hazmat projects receive additional hourly premiums as follows—Class A Suit:$2.00,Class B Suit:$1.50, And Class C Suit: $1.00.Workers performing underground work receive an additional$0.40 per hour for any and all work performed underground, including operating, servicing and repairing of equipment. The premium for underground work shall be paid for the entire shift worked. Workers who work suspended by a rope or cable receive an additional$0.50 per hour.The premium for work suspended shall be paid for the entire shift worked.Workers who do"pioneer"work(break open a cut,build road, etc.)more than one hundred fifty(150)feet above grade elevation receive an additional$0.50 per hour. V. In addition to the hourly wage and fringe benefits, the following depth and enclosure premiums shall be paid. The premiums are to be calculated for the maximum depth and distance into an enclosure that a diver reaches in a day. The premiums are to be paid one time for the day and are not used in calculating overtime pay. Depth premiums apply to depths of fifty feet or more.Over 50'to 100'-$2.00 per foot for each foot over 50 feet.Over 101'to 150'-$3.00 per foot for each foot over 101 feet.Over 15l'to 220'-$4.00 per foot for each foot over 220 feet. Over 221'-$5.00 per foot for each foot over 221 feet. Enclosure premiums apply when divers enter enclosures(such as pipes or tunnels)where there is no vertical ascent and is measured by the distance travelled from the entrance. 25' to 300' -$1.00 per foot from entrance.300' to 600' -$1.50 per foot beginning at 300'.Over 600' -$2.00 per foot beginning at 600'. W. Meter Installers work on single phase 120/240V self-contained residential meters.The Lineman/Groundmen rates would apply to meters not fitting this description. X. Workers on hazmat projects receive additional hourly premiums as follows-Class A Suit: $2.00,Class B Suit: $1.50,Class C Suit: $1.00,and Class D Suit: $0.50. Special Shift Premium: Basic hourly rate plus$2.00 per hour. When due to conditions beyond the control of the Employer or when an owner(not acting as the contractor),a government agency or the contract specifications requires that work can only be performed outside the normal 5 am to 6pm shift,then the special shift premium will be applied to the basic hourly rate.When an employee works on a special shift,they shall be paid a special shift premium for each hour worked unless they are in OT or Double-time status.(For example,the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) Y. Tide Work:When employees are called out between the hours of 6:00 p.m.and 6:00 a.m.to work on tide work (work located in the tide plane)all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair: Employees working on a swinging state or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents($0.75)per hour above the classification rate. 12 Benefit Code Key—Effective 8/31/2019 thru 4/1/2020 8. Z. Workers working with supplied air on hazmat projects receive an additional$1.00 per hour. Special Shift Premium:Basic hourly rate plus$2.00 per hour.When due to conditions beyond the control of the Employer or when an owner(not acting as a contractor),a government agency or the contract specifications require that more than(4)hours of a special shift can only be performed outside the normal 6 am to 6pm shift,then the special shift premium will be applied to the basic straight time for the entire shift. When an employee works on a special shift,they will be paid a special shift premium for each hour worked unless they are in overtime or double- time status.(For example,the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) Note Codes Continued 9. A. Workers working with supplied air on hazmat projects receive an additional$1.00 per hour. Special Shift Premium: Basic hourly rate plus $2.00 per hour. When due to conditions beyond the control of the Employer or when an owner(not acting as the contractor),a government agency or the contract specifications require that more than four(4)hours of a special shift can only be performed outside the normal 6 am to 6pm shift,then the special shift premium will be applied to the basic straight time for the entire shift. When an employee works on a special shift, they shall be paid a special shift premium for each hour worked unless they are in overtime or double- time status.(For example,the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) Certified Crane Operator Premium: Crane operators requiring certifications shall be paid$0.50 per hour above their classification rate. Boom Pay Premium: All cranes including tower shall be paid as follows based on boom length: (A)— 130'to 199'—$0.50 per hour over their classification rate. (B)—200'to 299'—$0.80 per hour over their classification rate. (C)—300' and over—$1.00 per hour over their classification rate. B. The highest pressure registered on the gauge for an accumulated time of more than fifteen(15)minutes during the shift shall be used in determining the scale paid. Tide Work:When employees are called out between the hours of 6:00 p.m.and 6:00 a.m.to work on tide work(work located in the tide plane) all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair:Employees working on a swinging stage or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents ($0.75) per hour above the classification rate. C. Tide Work:When employees are called out between the hours of 6:00 p.m.and 6:00 a.m.to work on tide work(work located in the tide plane) all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair:Employees working on a swinging stage or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents ($0.75) per hour above the classification rate. Effective August 31,2012—A Traffic Control Supervisor shall be present on the project whenever flagging or spotting or other traffic control labor is being utilized.A Traffic Control Laborer performs the setup,maintenance and removal of all temporary traffic control devices and construction signs necessary to control vehicular,bicycle,and pedestrian traffic during construction operations.Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer. All flaggers and spotters shall possess a current flagging card issued by the State of Washington,Oregon,Montana,or Idaho.These classifications are only effective on or after August 31,2012. 13