Loading...
HomeMy WebLinkAboutPK17-277 - Original - All City Fence Company - Contract - 08/30/17 r// 00 r cordsrr ,a KENT WA6 H(N CtO M /// �/��//�-ii L.F ocu me. it CONTRACT COVER SHEET This is to be completed by the Contract Manager prior to submission to City Clerks Office. All portions are to be completed. If you have questions, please contact City Clerk's Office. Vendor Name: All City Fence Company Vendor Number: JD Edwards Number Contract Number: V I-) — This is assigned by City Clerk's Office Project Name: Kent Senior Center South Rail Fence Installation Description: ❑ Interlocal Agreement 0 Change Order 0 Amendment 0 Contract Other: Contract Effective Date: 8/30/17 Termination Date: 12/31/17 Contract Renewal Notice (Days): 0 Number of days required notice for termination or renewal or amendment Contract Manager: Bryan Higgins/Lynn Osborn Department: Parks Planning & Dev. Contract Amount: 8,488.70 Approval Authority: Z Department Director ❑Mayor ®City Council Detail: (i.e. address, location, parcel number, tax id, etc.): w __..._.._ _...__.._.._.__._... _..._.__ .._.w._ ......_._____....___._.. ..n_._... .w._w._.r_ _ ...... ___.._._ Install a 42" tall, 85' long, black powder-coated 3-rail! fence to the south of the Senior Center building. Division Contract #PPD17-28 adccW10877'_8_14 KENT W's-OT0. PUBLIC WORKS AGREEMENT between City of Kent and All City Fence Company THIS AGREEMENT is made by and between the City of Kent, a Washington municipal corporation (hereinafter the "City"), and All City Fence Company organized under the laws of the State of Washington, located and doing business at 36 South Hudson Street, Seattle, WA 98134 (hereinafter the "Contractor"). AGREEMENT The parties agree as follows: I. DESCRIPTION OF WORK. Contractor shall perform the following services for the City in accordance with the following described plans and/or specifications: As described in attached Exhibit A, contractor will erect a 42-inch high, 85-foot long, three- rail fence to the south of the Kent Senior Activity Center. The fence will be constructed of black, galvanized, powder coated material. Contractor further represents that the services furnished under this Agreement will be performed in accordance with generally accepted professional practices within the Puget Sound region in effect at the time such services are performed. II. TIME OF COMPLETION. The parties agree that work will begin on the tasks described in Section I above immediately upon execution of this Agreement. Upon the effective date of this Agreement, Contractor shall complete the work described in Section I by December 31, 2017. III. COMPENSATION. The City shall pay the Contractor a total amount not to exceed $8,488.70, including any applicable Washington State Sales Tax, for the work and services contemplated in this Agreement. The City shall pay the Contractor the following amounts according to the following schedule: Contractor will submit a single invoice. A. No Payment and Performance Bond: No Retainage. Because this contract is $20,000 or less, the City has elected to waive both the performance/payment bond requirement of Chapter 39.08 RCW and the retainage requirement of Chapter 60.28 RCW. PUBLIC WORKS AGREEMENT - 1 ($20,000 or Less - OPTIONAL PROCESS) B. Defective or Unauthorized Work. The City reserves its right to withhold payment from Contractor for any defective or unauthorized work. Defective or unauthorized work includes, without limitation: work and materials that do not conform to the requirements of this Agreement; and extra work and materials furnished without the City's written approval. If Contractor is unable, for any reason, to satisfactorily complete any portion of the work, the City may complete the work by contract or otherwise, and Contractor shall be liable to the City for any additional costs incurred by the City. "Additional costs" shall mean all reasonable costs, including legal costs and attorney fees, incurred by the City beyond the maximum Contract price specified above. The City further reserves its right to deduct the cost to complete the Contract work, including any Additional Costs, from any and all amounts due or to become due the Contractor. C. Final Payment: Waiver of Claims. THE CONTRACTOR'S ACCEPTANCE OF FINAL PAYMENT SHALL CONSTITUTE A WAIVER OF CONTRACTOR'S CLAIMS, EXCEPT THOSE PREVIOUSLY AND PROPERLY MADE AND IDENTIFIED BY CONTRACTOR AS UNSETTLED AT THE TIME FINAL PAYMENT IS MADE AND ACCEPTED. IV. INDEPENDENT CONTRACTOR. The parties intend that an Independent Contractor- Employer Relationship will be created by this Agreement. By their execution of this Agreement, and in accordance with Ch. 51.08 RCW, the parties make the following representations: A. The Contractor has the ability to control and direct the performance and details of its work, the City being interested only in the results obtained under this Agreement. B. The Contractor maintains and pays for its own place of business from which Contractor's services under this Agreement will be performed. C. The Contractor has an established and independent business that is eligible for a business deduction for federal income tax purposes that existed before the City retained Contractor's services and is a service other than that furnished by the City, or the Contractor is engaged in an independently established trade, occupation, profession, or business of the same nature as that involved under this Agreement. D. The Contractor is responsible for filing as they become due all necessary tax documents with appropriate federal and state agencies, including the Internal Revenue Service and the state Department of Revenue. E. The Contractor has registered its business and established an account with the state Department of Revenue and other state agencies as may be required by Contractor's business, and has obtained a Unified Business Identifier (UBI) number from the State of Washington. F. The Contractor has a valid contractor registration pursuant to Ch. 18.27 RCW or an electrical contractor license pursuant to Ch. 19.28 RCW. G. The Contractor maintains a set of books dedicated to the expenses and earnings of its business. V. TERMINATION. The City may terminate this Agreement for good cause. "Good cause" shall include, without limitation, any one or more of the following events: A. The Contractor's refusal or failure to supply a sufficient number of properly skilled workers or proper materials for completion of the Contract work. B. The Contractor's failure to complete the work within the time specified in this Agreement. PUBLIC WORKS AGREEMENT - 2 ($20,000 or Less - OPTIONAL PROCESS) C. The Contractor's failure to make full and prompt payment to subcontractors or for material or labor. D. The Contractor's persistent disregard of federal, state or local laws, rules or regulations. E. The Contractor's filing for bankruptcy or becoming adjudged bankrupt. F. The Contractor's breach of any portion of this Agreement. If the City terminates this Agreement for good cause, the Contractor shall not receive any further money due under this Agreement until the Contract work is completed. After termination, the City may take possession of all records and data within the Contractor's possession pertaining to this project which may be used by the City without restriction. VI. PREVAILING WAGES. Contractor shall file a "Statement of Intent to Pay Prevailing Wages," with the State of Washington Department of Labor & Industries prior to commencing the Contract work. Contractor shall pay prevailing wages in effect on the date the bid is accepted or executed by Contractor, and comply with Chapter 39.12 of the Revised Code of Washington, as well as any other applicable prevailing wage rate provisions. The latest prevailing wage rate revision issued by the Department of Labor and Industries is attached. VII. CHANGES. The City may issue a written change order for any change in the Contract work during the performance of this Agreement. If the Contractor determines, for any reason, that a change order is necessary, Contractor must submit a written change order request to the person listed in the notice provision section of this Agreement, section XV(D), within fourteen (14) calendar days of the date Contractor knew or should have known of the facts and events giving rise to the requested change. If the City determines that the change increases or decreases the Contractor's costs or time for performance, the City will make an equitable adjustment. The City will attempt, in good faith, to reach agreement with the Contractor on all equitable adjustments. However, if the parties are unable to agree, the City will determine the equitable adjustment as it deems appropriate. The Contractor shall proceed with the change order work upon receiving either a written change order from the City or an oral order from the City before actually receiving the written change order. If the Contractor fails to require a change order within the time specified in this paragraph, the Contractor waives its right to make any claim or submit subsequent change order requests for that portion of the contract work. If the Contractor disagrees with the equitable adjustment, the Contractor must complete the change order work; however, the Contractor may elect to protest the adjustment as provided in subsections A through E of Section VIII, Claims, below. The Contractor accepts all requirements of a change order by: (1) endorsing it, (2) writing a separate acceptance, or (3) not protesting in the way this section provides. A change order that is accepted by Contractor as provided in this section shall constitute full payment and final settlement of all claims for contract time and for direct, indirect and consequential costs, including costs of delays related to any work, either covered or affected by the change. VIII. CLAIMS. If the Contractor disagrees with anything required by a change order, another written order, or an oral order from the City, including any direction, instruction, interpretation, or determination by the City, the Contractor may file a claim as provided in this section. The Contractor shall give written notice to the City of all claims within fourteen (14) calendar days of the occurrence of the events giving rise to the claims, or within fourteen (14) calendar days of the date the Contractor knew or should have known of the facts or events giving rise to the claim, whichever occurs first . Any claim for damages, additional payment for any reason, or extension of time, whether under this Agreement or otherwise, shall be conclusively deemed to have been waived by the Contractor unless a timely written claim is made in strict accordance with the applicable provisions of this Agreement. At a minimum, a Contractor's written claim shall include the information set forth in subsections A, items 1 through 5 below. FAILURE TO PROVIDE A COMPLETE, WRITTEN NOTIFICATION OF CLAIM WITHIN PUBLIC WORKS AGREEMENT- 3 ($20,000 or Less - OPTIONAL PROCESS) THE TIME ALLOWED SHALL BE AN ABSOLUTE WAIVER OF ANY CLAIMS ARISING IN ANY WAY FROM THE FACTS OR EVENTS SURROUNDING THAT CLAIM OR CAUSED BY THAT DELAY. A. Notice of Claim. Provide a signed written notice of claim that provides the following information: 1. The date of the Contractor's claim; 2. The nature and circumstances that caused the claim; 3. The provisions in this Agreement that support the claim; 4. The estimated dollar cost, if any, of the claimed work and how that estimate was determined; and 5. An analysis of the progress schedule showing the schedule change or disruption if the Contractor is asserting a schedule change or disruption. B. Records. The Contractor shall keep complete records of extra costs and time incurred as a result of the asserted events giving rise to the claim. The City shall have access to any of the Contractor's records needed for evaluating the protest. The City will evaluate all claims, provided the procedures in this section are followed. If the City determines that a claim is valid, the City will adjust payment for work or time by an equitable adjustment. No adjustment will be made for an invalid protest. C. Contractor's Duty to Comolete Protested Work. In spite of any claim, the Contractor shall proceed promptly to provide the goods, materials and services required by the City under this Agreement. D. Failure to Protest Constitutes Waiver. By not protesting as this section provides, the Contractor also waives any additional entitlement and accepts from the City any written or oral order (including directions, instructions, interpretations, and determination). E. Failure to Follow Procedures Constitutes Waiver. By failing to follow the procedures of this section, the Contractor completely waives any claims for protested work and accepts from the City any written or oral order (including directions, instructions, interpretations, and determination). IX. LIMITATION OF ACTIONS. CONTRACTOR MUST, IN ANY EVENT, FILE ANY LAWSUIT ARISING FROM OR CONNECTED WITH THIS AGREEMENT WITHIN 120 CALENDAR DAYS FROM THE DATE THE CONTRACT WORK IS COMPLETE OR CONTRACTOR'S ABILITY TO FILE THAT CLAIM OR SUIT SHALL BE FOREVER BARRED. THIS SECTION FURTHER LIMITS ANY APPLICABLE STATUTORY LIMITATIONS PERIOD. X. WARRANTY. Contractor warrants that it will faithfully and satisfactorily perform all work provided under this Agreement in accordance with the provisions of this Agreement. The Contractor shall promptly correct all defects in workmanship and materials: (1) when Contractor knows or should have known of the defect, or (2) upon Contractor's receipt of notification from the City of the existence or discovery of the defect. In the event any parts are repaired or replaced, only original replacement parts shall be used—rebuilt or used parts will not be acceptable. When defects are corrected, the warranty for that portion of the work shall extend for an additional year beyond the original warranty period applicable to the overall work. The Contractor shall begin to correct any defects within seven (7) calendar days of its receipt of notice from the City of the defect. If the Contractor does not accomplish the corrections within a reasonable time as determined by the City, the City may complete the corrections and the Contractor shall pay all costs incurred by the City in order to accomplish the correction. XI. DISCRIMINATION. In the hiring of employees for the performance of work under this Agreement or any sub-contract, the Contractor, its sub-contractors, or any person acting on behalf of the Contractor or sub-contractor shall not, by reason of race, religion, color, sex, age, sexual orientation, national origin, or the presence of any sensory, mental, or physical disability, discriminate against any person who is qualified and available to perform the work to which the employment relates. PUBLIC WORKS AGREEMENT - 4 ($20,000 or Less - OPTIONAL PROCESS) Contractor shall execute the attached City of Kent Equal Employment Opportunity Policy Declaration, Comply with City Administrative Policy 1.2, and upon completion of the contract work, file the attached Compliance Statement. XII. INDEMNIFICATION. Contractor shall defend, indemnify and hold the City, its officers, officials, employees, agents and volunteers harmless from any and all claims, injuries, damages, losses or suits, including all legal costs and attorney fees, arising out of or in connection with the Contractor's performance of this Agreement, except for that portion of the injuries and damages caused by the City's negligence. The City's inspection or acceptance of any of Contractor's work when completed shall not be grounds to avoid any of these covenants of indemnification. Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Contractor and the City, its officers, officials, employees, agents and volunteers, the Contractor's duty to defend, indemnify, and hold the City harmless, and Contractor's liability accruing from that obligation shall be only to the extent of the Contractor's negligence. IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THE INDEMNIFICATION PROVIDED HEREIN CONSTITUTES THE CONTRACTOR'S WAIVER OF IMMUNITY UNDER INDUSTRIAL INSURANCE, TITLE 51 RCW, SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PARTIES FURTHER ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER. In the event Contractor refuses tender of defense in any suit or any claim, if that tender was made pursuant to this indemnification clause, and if that refusal is subsequently determined by a court having jurisdiction (or other agreed tribunal) to have been a wrongful refusal on the Contractor's part, then Contractor shall pay all the City's costs for defense, including all reasonable expert witness fees and reasonable attorneys' fees, plus the City's legal costs and fees incurred because there was a wrongful refusal on the Contractor's part. The provisions of this section shall survive the expiration or termination of this Agreement. XIII. INSURANCE. The Contractor shall procure and maintain for the duration of the Agreement, insurance of the types and in the amounts described in Exhibit B attached and incorporated by this reference. XIV. WORK PERFORMED AT CONTRACTOR'S RISK. Contractor shall take all necessary precautions and shall be responsible for the safety of its employees, agents, and subcontractors in the performance of the contract work and shall utilize all protection necessary for that purpose. All work shall be done at Contractor's own risk, and Contractor shall be responsible for any loss of or damage to materials, tools, or other articles used or held for use in connection with the work. XV. MISCELLANEOUS PROVISIONS. A. Recyclable Materials. Pursuant to Chapter 3.80 of the Kent City Code, the City requires its contractors and consultants to use recycled and recyclable products whenever practicable. A price preference may be available for any designated recycled product. B. Non-Waiver of Breach. The failure of the City to insist upon strict performance of any of the covenants and agreements contained in this Agreement, or to exercise any option conferred by this Agreement in one or more instances shall not be construed to be a waiver or relinquishment of those covenants, agreements or options, and the same shall be and remain in full force and effect. C. Resolution of Disputes and Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of Washington. If the parties are unable to settle any PUBLIC WORKS AGREEMENT - 5 ($20,000 or Less - OPTIONAL PROCESS) dispute, difference or claim arising from the parties' performance of this Agreement, the exclusive means of resolving that dispute, difference or claim, shall only be by filing suit exclusively under the venue, rules and jurisdiction of the King County Superior Court, King County, Washington, unless the parties agree in writing to an alternative dispute resolution process. In any claim or lawsuit for damages arising from the parties' performance of this Agreement, each party shall pay all its legal costs and attorney's fees incurred in defending or bringing such claim or lawsuit, including all appeals, in addition to any other recovery or award provided by law; provided, however, nothing in this paragraph shall be construed to limit the City's right to indemnification under Section XII of this Agreement. D. Written Notice. All communications regarding this Agreement shall be sent to the parties at the addresses listed on the signature page of the Agreement, unless notified to the contrary. Any written notice hereunder shall become effective three (3) business days after the date of mailing by registered or certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated in this Agreement or such other address as may be hereafter specified in writing. E. Assignment. Any assignment of this Agreement by either party without the written consent of the non-assigning party shall be void. If the non-assigning party gives its consent to any assignment, the terms of this Agreement shall continue in full force and effect and no further assignment shall be made without additional written consent. F. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of the City and Contractor. G. Entire Agreement. The written provisions and terms of this Agreement, together with any Exhibits attached hereto, shall supersede all prior verbal statements of any officer or other representative of the City, and such statements shall not be effective or be construed as entering into or forming a part of or altering in any manner this Agreement. All of the above documents are hereby made a part of this Agreement. However, should any language in any of the Exhibits to this Agreement conflict with any language contained in this Agreement, the terms of this Agreement shall prevail. H. Compliance with Laws. The Contractor agrees to comply with all federal, state, and municipal laws, rules, and regulations that are now effective or in the future become applicable to Contractor's business, equipment, and personnel engaged in operations covered by this Agreement or accruing out of the performance of those operations. I. Public Records Act. The Contractor acknowledges that the City is a public agency subject to the Public Records Act codified in Chapter 42.56 of the Revised Code of Washington and documents, notes, emails, and other records prepared or gathered by the Contractor in its performance of this Agreement may be subject to public review and disclosure, even if those records are not produced to or possessed by the City of Kent. As such, the Contractor agrees to cooperate fully with the City in satisfying the City's duties and obligations under the Public Records Act. J. City Business License Required. Prior to commencing the tasks described in Section I, Contractor agrees to provide proof of a current city of Kent business license pursuant to Chapter 5.01 of the Kent City Code. K. Counterparts and Signatures by Fax or Email. This Agreement may be executed in any number of counterparts, each of which shall constitute an original, and all of which will together constitute this one Agreement. Further, upon executing this Agreement, either party may deliver the signature page to the other by fax or email and that signature shall have the same force and effect as if the Agreement bearing the original signature was received in person. PUBLIC WORKS AGREEMENT - 6 ($20,000 or Less- OPTIONAL PROCESS) IN WITNESS, the parties below execute this Agreement, which shall become effective on the last date entered below. All acts consistent with the authority of this Agreement and prior to its effective date are ratified and affirmed, and the terms of the Agreement shall be deemed to have applied. CONTRACTOR: CITY OF KENT: By: By: �- ( � ure) (signature) Print Name: Print Name: Hope Gibson Its e✓ Its: Parks Planning & Development (title) Manager DATE: 2 Z DATE: NOTICES TO BE SENT TO: NOTICES TO BE SENT TO: CONTRACTOR: CITY OF KENT: Gene Claiborne Bryan Higgins All City Fence Company City of Kent 36 South Hudson Street 220 Fourth Avenue South Seattle, WA 98134 Kent, WA 98032 206-324-3747 (telephone) (253) 856-5113 (telephone) gclaiborne@allcityfence.com bhiggins@kentwa.gov P:%Planning%Senior Center\AII City Fence-South Rail Fence-CONTRACT PUBLIC WORKS AGREEMENT- 7 ($20,000 or Less - OPTIONAL PROCESS) DECLARATION CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY POLICY The City of Kent is committed to conform to Federal and State laws regarding equal opportunity. As such all contractors, subcontractors and suppliers who perform work with relation to this Agreement shall comply with the regulations of the City's equal employment opportunity policies. The following questions specifically identify the requirements the City deems necessary for any contractor, subcontractor or supplier on this specific Agreement to adhere to. An affirmative response is required on all of the following questions for this Agreement to be valid and binding. If any contractor, subcontractor or supplier willfully misrepresents themselves with regard to the directives outlines, it will be considered a breach of contract and it will be at the City's sole determination regarding suspension or termination for all or part of the Agreement; The questions are as follows: 1. I have read the attached City of Kent administrative policy number 1.2. 2. During the time of this Agreement I will not discriminate in employment on the basis of sex, race, color, national origin, age, or the presence of all sensory, mental or physical disability. 3. During the time of this Agreement the prime contractor will provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 4. During the time of the Agreement I, the prime contractor, will actively consider hiring and promotion of women and minorities. 5. Before acceptance of this Agreement, an adherence statement will be signed by me, the Prime Contractor, that the Prime Contractor complied with the requirements as set forth above. By signing below, I agree to fulfill the five requirements referenced above. By: For: �Y / �r�u Az Co. Title: e✓; Date: zZ EEO COMPLIANCE DOCUMENTS - 1 CITY OF KENT ADMINISTRATIVE POLICY NUMBER: 1.2 EFFECTIVE DATE: January 1, 1998 SUBJECT: MINORITY AND WOMEN SUPERSEDES: April 1, 1996 CONTRACTORS APPROVED BY Jim White, Mayor POLICY: Equal employment opportunity requirements for the City of Kent will conform to federal and state laws. All contractors, subcontractors, consultants and suppliers of the City must guarantee equal employment opportunity within their organization and, if holding Agreements with the City amounting to $10,000 or more within any given year, must take the following affirmative steps: 1. Provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 2. Actively consider for promotion and advancement available minorities and women. Any contractor, subcontractor, consultant or supplier who willfully disregards the City's nondiscrimination and equal opportunity requirements shall be considered in breach of contract and subject to suspension or termination for all or part of the Agreement. Contract Compliance Officers will be appointed by the Directors of Planning, Parks, and Public Works Departments to assume the following duties for their respective departments. 1. Ensuring that contractors, subcontractors, consultants, and suppliers subject to these regulations are familiar with the regulations and the City's equal employment opportunity policy. 2. Monitoring to assure adherence to federal, state and local laws, policies and guidelines. EEO COMPLIANCE DOCUMENTS - 2 CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE STATEMENT This form shall be filled out AFTER COMPLETION of this project by the Contractor awarded the Agreement. I, the undersigned, a duly represented agent of Company, hereby acknowledge and declare that the before-mentioned company was the prime contractor for the Agreement known as that was entered into on the (date), between the firm I represent and the City of Kent. I declare that I complied fully with all of the requirements and obligations as outlined in the City of Kent Administrative Policy 1.2 and the Declaration City of Kent Equal Employment Opportunity Policy that was part of the before-mentioned Agreement. By: For: Title: Date: EEO COMPLIANCE DOCUMENTS - 3 BIDDER RESPONSIBILITY CRITERIA Certification of Compliance with Wage Payment Statutes This certification is required by state law (RCW 39.04.350(2)) to be submitted to the City before the contract can be awarded. The bidder hereby certifies that, within the three-year period immediately preceding the bid solicitation date (July 28, 2017), the bidder is not a "willful" violator, as defined in RCW 49.48.082, of any provision of chapters 49.46, 49.48, or 49.52 RCW, as determined by a final and binding citation and notice of assessment issued by the Department of Labor and Industries or through a civil judgment entered by a court of limited or general jurisdiction. I certify under penalty of perjury under the laws of the State of Washington that the foregoing is true and correct. All City Fence Company By: Signatur orized Official* Printed Name: GG� Title: 4e 1jXe411_ Date: 2 City and State: /��G�/lam✓'/f,`ya�✓ *If a corporation, proposal must be executed in the corporate name by the president or vice- president (or any other corporate officer accompanied by evidence of authority to sign). If a co- partnership, proposal must be executed by a partner. BIDDER RESPONSIBILITY CRITERIA - 1 EXHIBIT A AAAFA NM 40 MASTER BUILDERS 1 Y_ F Amo,k n A S S 0 C t A T 1 0 N ALL 'tPNCE CO. Asswimilan Cq'�d C'.m­ 36 South Hudson Street - Seattle, WA 98134 - Phone (206) 324-3747 - Fax (206) 324-1508 Bonded and Insured - Contractor Registration No. ALLCICF927KW rqpqp�al and t.;ontra02.___._.___ 7C'us t—om er—'--ER ........... Phonie Numbers City of Ke, Home Business 253-856-5113 City Of Kent Fax Cell/Pager 253-632-7139 Attn Bryan Higgins 220 4th Ave S Purchase Order Kent Senior Activity Center Kent Wa 98032 Job Address 600 E Smith St bhiggins(a-)kentwa.gov Kent Wa 98030 We propose to Install on your property the fencing materials listed below subject to the TERMS AND CONDITIONS ON THE REVERSE SIDE OF THIS PROPOSAL AND CONTRACT PVC Fencing Specifications Ornamental Iron Fence Specifications FENCE HEIGHT FENCE HEIGHT -42-1— FENCE STYLE FENCE STYLE 3-Rail Majestic Montage Plus_ MATERIAL GRADE FENCE COLOR Black LINEAL FOOTAGE MATERIAL GRADE G-alvanized& Powder Coated POST SIZE LINEAL FOOTAGE 85, POST THICKNESS POST SIZE 2.511 POST SPAaNG POST TYPE 16 Caine POST SPACING/DEPTH 8' Plated POST DEPTH RAIL SIZE 1.15' RAIL SIZE RAIL TYPE 16 Gauge RAIL THICKNESS PICKET SIZE ? ()"�Sttare PICKET SIZE/THICKNESS PICKETS SPACED PICKET SPACED PANEL LENGTH 81 PICKET FACED FENCE CONTOUR —Level FENCE CONTOUR GATE SIZE I TYPE GATE SIZE/TYPE GATE SIZE/TYPE GATE SIZE/TYPE POST SIZE 1/2 FENCE COLOR OTHER OTHER TAX RATE 10.00% PRICE S7,717.00 STATE SALES TAX $771.70 TOTAL $8,488.70 TERMS Net It Days Visa/Master Card .............j _ L Cash or Check Specials: Labor and [Material to Install Fence per Attached: BID IS GOOD FOR 30 DAYS) Customer to Clear and/or Show Fence Line Install new Montage Plus 3 rail iron. Attach 6" x 6" plates to existing walk way. THIS PROD ECTCOMES WITH A THREE YEAR WARRANTY ON MATERIALS AND LABOR FbAlfGMEW orAfteMtet AfftIlCAAVP99M BY All City Fence Co., Inc. SIGNING AND DATING THIS AGREEMENT AT THE Gene Claiborne 15l 8/14/2017 SIGNATURE LINE AND DATELINE ON THE REVERSE Representauve DATE SIDE. WHEN $0 SIGNED, THIS PROPOSAL SHALL BECOME A LEGALLY BINDING CONTRACT EXHIBIT A (Continued) 1.PLACEMENT Customer is responsible for marking the location of all underground utilities,pipes, plumbing,sprinklers, wiring, easements, right-of-ways, and covenants. Customer can obtain the location of all underground utilities by calling 1.8004244566.Customer is responsible for the condition of the soil and, in the absence of written notice from Customer, ALL CITY will proceed with the work on the assumption that the soil is suitable for the proposed construction and no extra excavation or backfill is required. Cusl umer is responsible to establish the finish grade and dear the area where the work is to be performed of ail obstructions prior to the scheduled date of work. 2.PROPERTY OWNERSHIP. Customer advises and warrants that Customer is either the owner or the authorized agent of the owner of the property on which the work will be performed.Customer agrees to be liable for all payments due under this contract whether or not paid by the owner.If Customer is not the owner of the property,Customer states the actual owner of the property is' NAME PHONE ADDRESS _ CITY ZIP 3.DISPUTES AND REMEDIES. In the event either party to this contract alleges a breach of the contract by the other party Contractor.All City,out not customer,shall have the option of electing,by giving written notice to customer,of resolution of any such dispute by binding arbitration pursuant to the provisions of chapter 7.04A,RCW,or,in the alternative,contractor may elect a Superior Court lien foreclosure action to foreclose any claim of lien which contractor may have recorded against the property which is the location of the work of the contract. In any such dispute.it is specifically agreed that neither party shall be entitled to consequential,punitive.or exemplary damages.Regardless of whether binding arbitration,or court lien foreclosure is elected,the prevailing party in any such proceeding shall be entitled to award of its reasonable attorney's fees and costs of litigationlarbitraton. 4_CANCELLATION,SCHEDULING AND PAYMENT.This signed contract is cancelable by either party prior to ALL CITY ordering material for Customers fob.Performance of the work will be scheduled within a reasonable time after receipt by ALL CITY of a fully completed and signed contract unless Customer specifies an exact time to perform work in the body of this contract. ALL CITY shall not be Irable for any delays in completing the work.Interest on all past due accounts, whether liquidated or unliquidated,shall be at the rate of 12%per arnum 5.HOLD HARMLESS. Customer agrees to indemnify and hold ALL CITY harmless from any and all claims arising from or which relate to Customers resoonsihilitles in this contract. 6.PERMITS. Any governmental permits required to complete the scope of work to be performed under this contract shall be the responsihrtity of Customer All required permits will be obtained,paid for,and posted on the property by Customer prior to the commencement of work by ALL CITY 7.WARRANTIES.ALL CITY warrants that all labor.material and taxes will be paid for and that there will be no potential lien claimants upon final payment by Customer. All work wilt be performed in a commercially reasonable manner.ALL CITY warrants that all labor and materials will be free of any material defects for a period of 36 months from the date of installation. The sole remedy for a warranty claim by Customer Is the repair or replacement of the defect and there are no other warranties expressed or Implied. All warranty claims must be made in writing within the 36 month period or any claim based upon any warranty is waived.This warranty is void if any other person or entity other than ALL CITY attempts to repair or replace ALL CITY Is not responsible for consequential damages. I ACCEPT THE ABOVE CONTRACT TERMS: SIGNATURE OF CUSTOMER DATE NOTICE TO CUSTOMER This contractor is registered with the state of Washington, registration number ALLCICF927KW, and has posted with the state a bond or deposit of$6000.00 for the purpose of satisfying claims against the contractor for breach of contract including negligent or improper work in the conduct of the contractor's business. The expiration date of this contractor's registration is December 31 of each year. THIS BOND OR DEPOSIT MIGHT NOT BE SUFFICIENT TO COVER A CLAIM THAT MIGHT ARISE FROM THE WORK DONE UNDER YOUR CONTRACT. This bond or deposit is not for your exclusive use because it covers all work performed by this contractor. The bond or deposit is intended to pay valid claims up to $6000.00 that you and other customers, suppliers, subcontractors, or taxing authorities may have. FOR GREATER PROTECTION YOU MAY WITHHOLD A PERCENTAGE OF YOUR CONTRACT. You may withhold a contractually defined percentage of your construction contract as retainage for a stated period of time to provide protection to you and help insure that your project will be completed as required by your contract. YOUR PROPERTY MAY BE LIENED. If a supplier of materials used in your construction project or an employee or subcontractor of your contractor or subcontractors is not paid, your property may be liened to force payment and you could pay twice for the same work. FOR ADDITIONAL PROTECTION Y12U MAY REQUEST THE CONTRACTOR TO PROVIDE YOU WITH ORIGINAL"LIEN RELEASE" DOCUMENTS FROM EACH SUPPLIER OR SUBCONTRACTOR ON YOUR PROJECT. The contractor is required to provide you with further information about lien release documents if you request it. General information is also available from the state Department of Labor and Industries. I have received a copy of this disclosure statement. Dated this day of of the year Signature of Customer ALL CITY FENCE CO. EXHIBIT A (Continued) www.aticityfence.com NAME: 5!� c, r•e-1 ��-4i&4 Z"l CONTACT PERSON: _ }!c ADDRESS: L> .�,: G(< PHONE: ,I S " -. •3 OL 7137 CITY: C:t7 f' MAP PAGE REF: ACCESS: FENCE OVERALL LINE POSTS TOP TERM GATE GATE FRAMES TYPE HEIGHT FILL TYPE Size T e RAIL POST POST SPACING Swin Slide SPECIALS ,: TOTAL FOOTAGE ��' CIRCLE: `` LEVEL HILLY EARTH ASPH CON TTG ` LEVEL T. '� NTOU STEP BIAS . + LATES AA t SKILL B (W T/W BRACE LV. _._... . IN UT JACKHAMMER l WELDER ENERATOR i�iOTOHAMMER _._ . .. D/DIGGE ROCK DRILL CORE DRILL TORCH LADDER CHAIN SAW DISCOUNT MATERIAL LABOR HRS TOTAL $ $ OFFICE COPY EXHIBIT B INSURANCE REQUIREMENTS FOR: Kent Senior Center South Rail Fence Installation Insurance The Contractor shall procure and maintain for the duration of the Agreement, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees or subcontractors. A. Minimum Scope of Insurance Contractor shall obtain insurance of the types described below: 1. Automobile Liability insurance covering all owned, non-owned, hired and leased vehicles. Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. 2. Commercial General Liability insurance shall be written on ISO occurrence form CG 00 01 and shall cover liability arising from premises, operations, independent contractors, products-completed operations, personal injury and advertising injury, and liability assumed under an insured contract. The Commercial General Liability insurance shall be endorsed to provide the Aggregate Per Project Endorsement ISO form CG 25 03 11 85. The City shall be named as an insured under the Contractor's Commercial General Liability insurance policy with respect to the work performed for the City using ISO additional insured endorsement CG 20 10 11 85 or a substitute endorsement providing equivalent coverage. 3. Workers' Compensation coverage as required by the Industrial Insurance laws of the State of Washington. B. Minimum Amounts of Insurance Contractor shall maintain the following insurance limits: 1. Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1,000,000 per accident. 2. Commercial General Liability insurance shall be written with limits no less than $1,000,000 each occurrence, $2,000,000 general aggregate and a $2,000,000 products-completed operations aggregate limit. EXHIBIT B (Continued ) C. Other Insurance Provisions The insurance policies are to contain, or be endorsed to contain, the following provisions for Automobile Liability and Commercial General Liability insurance: 1. The Contractor's insurance coverage shall be primary insurance as respect the City. Any Insurance, self-insurance, or insurance pool coverage maintained by the City shall be excess of the Contractor's insurance and shall not contribute with it. 2. The Contractor's insurance shall be endorsed to state that coverage shall not be cancelled by either party, except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City. 3. The City of Kent shall be named as an additional insured on all policies (except Professional Liability) as respects work performed by or on behalf of the contractor and a copy of the endorsement naming the City as additional insured shall be attached to the Certificate of Insurance. The City reserves the right to receive a certified copy of all required insurance policies. The Contractor's Commercial General Liability insurance shall also contain a clause stating that coverage shall apply separately to each insured against whom claim is made or suit is brought, except with respects to the limits of the insurer's liability. D. Acceptability of Insurers Insurance is to be placed with insurers with a current A.M. Best rating of not less than ANII. E. Verification of Coverage Contractor shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the insurance requirements of the Contractor before commencement of the work. F. Subcontractors Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor. All coverages for subcontractors shall be subject to all of the same insurance requirements as stated herein for the Contractor. ALLCITY-01 TRISTANVAUGHN ACORO' CERTIFICATE OF LIABILITY INSURANCE DATD1YYYYJ ar211221r2o17 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: McGriff,Seibels&Williams,Inc. PHONE FAX 7525 SE 24th Street (A/C,No,Ext): (A/C,No): Suite 520 E-MAIL s:seattle@mcgriff.com Mercer Island,WA 98040 INSURER(S)AFFORDING COVERAGE NAIC 0 INSURERA:Ohio Security Insurance Company 24082 INSURED INSURER B:Ohio Casualty Insurance Company 24074 Koch Holdings Inc.dba All City Fence Co. INSURERC: 36 South Hudson Street INSURER D: Seattle,WA 98134 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP - LIMITS LTR INSO WVD POLICY NUMBER MM/DD/YYYY MMIDONM A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE S 1,000,000 CLAIMS-MADE X OCCUR X X BKS(18)56088508 05/19/2017 0511912018 DAMAGE PREMISES Ea occurrence) S 1,000,000 MEO EXP(Any one person) S 15,000 PERSONAL&ADV INJURY S 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER GENERAL AGGREGATE $ 2,000,000 POLICY X JET LOC PRODUCTS-COMP/OP AGG S 2,000,000 OTHER: STOP GAP S 1,000,000 AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT S 1,000,000 (Ea accident) A X ANYAUTO BAS(18)56088508 05/19/2017 05/19/2018 BODILY INJURY(Per person) S ALL OWNED SCHEDULED BODILY INJURY(Per accident) S AUTOS AUTOS X PROPERTY DAMAGE X HIRED AUTOS AUTOS NON-OWNED (Per accident) S S X UMBRELLA LIAO X OCCUR EACH OCCURRENCE $ 7,000,000 B EXCESS LIAR CLAIMS-MADE USO(18)56088508 0511912017 0511912018 AGGREGATE $ 7,000,00 DED X RETENTIONS 10,000 S WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER A ANY PROPRIETOR/PARTNERfEXECUIIVE YIN BKS(18)56088508 0511912017 05119/2018 EL.EACH ACCIDENT S 1,000,000 OFFICERIMEMBER EXCLUDED? NIA (Mandatory in NH) E L DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below EL DISEASE-POLICY LIMIT S 1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS 1 VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Re:Work performed by the Named Insured for the City of Kent City of Kent is included as Additional Insured as required by written contract per attached endorsement.Coverage is Primary&Non-Contributory,Per Project Aggregate and Waiver of Subrogation apply per attached endorsements- CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City Of Kent THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Attn:Timothy J.LaPorte,P.E. 220 4th Ave S Kent,WA 98032 AUTHORIZED REPRESENTATIVE 01988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014101) The ACORD name and logo are registered marks of ACORD COMMERCIAL GENERAL LIABILITY CG88100413 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL GENERAL LIABILITY EXTENSION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART INDEX SUBJECT PAGE NON-OWNED AIRCRAFT 2 NON-OWNED WATERCRAFT 2 PROPERTY DAMAGE LIABILITY -ELEVATORS 2 EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) 2 MEDICAL PAYMENTS EXTENSION 3 EXTENSION OF SUPPLEMENTARY PAYMENTS -COVERAGES A AND B 3 ADDITIONAL INSUREDS -BY CONTRACT, AGREEMENT OR PERMIT 3 PRIMARY AND NON-CONTRIBUTORY- ADDITIONAL INSURED EXTENSION 5 ADDITIONAL INSUREDS -EXTENDED PROTECTION OF YOUR "LIMITS OF INSURANCE" 6 WHO IS AN INSURED -INCIDENTAL MEDICAL ERRORS/MALPRACTICE AND WHO IS AN INSURED -FELLOW EMPLOYEE EXTENSION -MANAGEMENT EMPLOYEES 6 NEWLY FORMED OR ADDITIONALLY ACQUIRED ENTITIES 7 FAILURE TO DISCLOSE HAZARDS AND PRIOR OCCURRENCES 7 KNOWLEDGE OF OCCURRENCE, OFFENSE, CLAIM OR SUIT 7 LIBERALIZATION CLAUSE 7 BODILY INJURY REDEFINED 7 EXTENDED PROPERTY DAMAGE 8 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US - 8 WHEN REQUIRED IN A CONTRACT OR AGREEMENT WITH YOU © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 1 of 8 With respect to coverage afforded by this endorsement, the provisions of the policy apply unless modified by the endorsement. A. NON-OWNED AIRCRAFT Under Paragraph 2. Exclusions of Section I - Coverage A - Bodily Injury And Property Damage Liability, exclusion g.Aircraft, Auto Or Watercraft does not apply to an aircraft provided: 1. It is not owned by any insured; 2. It is hired, chartered or loaned with a trained paid crew; 3. The pilot in command holds a currently effective certificate, issued by the duly constituted authority of the United States of America or Canada, designating her or him a commercial or airline pilot; and 4. It is not being used to carry persons or property for a charge. However, the insurance afforded by this provision does not apply if there is available to the insured other valid and collectible insurance, whether primary, excess (other than insurance written to apply specifically in excess of this policy), contingent or on any other basis, that would also apply to the loss covered under this provision. B. NON-OWNED WATERCRAFT Under Paragraph 2. Exclusions of Section I-Coverage A-Bodily Injury And Property Damage Liability, Subparagraph (2) of exclusion g. Aircraft, Auto Or Watercraft is replaced by the following: This exclusion does not apply to: (2) A watercraft you do not own that is: (a) Less than 52 feet long; and (b) Not being used to carry persons or property for a charge. C. PROPERTY DAMAGE LIABILITY -ELEVATORS 1. Under Paragraph 2. Exclusions of Section I - Coverage A - Bodily Injury And Property Damage Liabil- ity, Subparagraphs (3), (4) and (6) of exclusion j. Damage To Property do not apply if such "property damage" results from the use of elevators. For the purpose of this provision, elevators do not include vehicle lifts. Vehicle lifts are lifts or hoists used in automobile service or repair operations. 2. The following is added to Section IV - Commercial General Liability Conditions, Condition 4. Other Insurance, Paragraph b. Excess Insurance: The insurance afforded by this provision of this endorsement is excess over any property insurance, whether primary, excess, contingent or on any other basis. D. EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) If Damage To Premises Rented To You is not otherwise excluded from this Coverage Part: 1. Under Paragraph 2. Exclusions of Section I-Coverage A -Bodily Injury and Property Damage Liability: a. The fourth from the last paragraph of exclusion j. Damage To Property is replaced by the follow- ing: Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" (other than damage by fire, lightning, explosion, smoke, or leakage from an automatic fire protection system) to: (i) Premises rented to you for a period of 7 or fewer consecutive days; or (ii) Contents that you rent or lease as part of a premises rental or lease agreement for a period of more than 7 days. Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" to contents of premises rented to you for a period of 7 or fewer consecutive days. A separate limit of insurance applies to this coverage as described in Section III - Limits of Insurance. © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 2 of 8 b. The last paragraph of subsection 2. Exclusions is replaced by the following: Exclusions c. through n. do not apply to damage by fire, lightning, explosion, smoke or leakage from automatic fire protection systems to premises while rented to you or temporarily occupied by you with permission of the owner. A separate limit of insurance applies to Damage To Premises Rented To You as described in Section III -Limits Of Insurance. 2. Paragraph 6. under Section III -Limits Of Insurance is replaced by the following: 6. Subject to Paragraph S. above, the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of"property damage" to: a. Any one premise: (1) While rented to you; or (2) While rented to you or temporarily occupied by you with permission of the owner for damage by fire, lightning, explosion, smoke or leakage from automatic protection sys- tems; or b. Contents that you rent or lease as part of a premises rental or lease agreement. 3. As regards coverage provided by this provision D. EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) -Paragraph 9.a. of Definitions is replaced with the following: 9.a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire, lightning, explosion, smoke, or leakage from automatic fire protection systems to premises while rented to you or temporarily occupied by you with the permission of the owner, or for damage to contents of such premises that are included in your premises rental or lease agreement, is not an "insured contract'. E. MEDICAL PAYMENTS EXTENSION If Coverage C Medical Payments is not otherwise excluded, the Medical Payments provided by this policy are amended as follows: Under Paragraph 1. Insuring Agreement of Section I -Coverage C-Medical Payments, Subparagraph (b) of Paragraph a. is replaced by the following: (b) The expenses are incurred and reported within three years of the date of the accident; and F. EXTENSION OF SUPPLEMENTARY PAYMENTS -COVERAGES A AND B 1. Under Supplementary Payments -Coverages A and B, Paragraph 1.b. is replaced by the following.. b. Up to $3,000 for cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds. 2. Paragraph 1.d. is replaced by the following: ° d. All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work. G. ADDITIONAL INSUREDS -BY CONTRACT, AGREEMENT OR PERMIT 1. Paragraph 2. under Section 11 -Who Is An Insured is amended to include as an insured any person or organization whom you have agreed to add as an additional insured in a written contract, written agreement or permit. Such person or organization is an additional insured but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused in whole or in part by: a. Your acts or omissions, or the acts or omissions of those acting on your behalf, in the performance of your on going operations for the additional insured that are the subject of the written contract or written agreement provided that the "bodily injury" or "property damage" occurs, or the "per- sonal and advertising injury" is committed, subsequent to the signing of such written contract or written agreement; or © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 3 of 8 b. Premises or facilities rented by you or used by you; or c. The maintenance, operation or use by you of equipment rented or leased to you by such person or organization; or d. Operations performed by you or on your behalf for which the state or political subdivision has issued a permit subject to the following additional provisions: (1) This insurance does not apply to "bodily injury", "property damage", or "personal and ad- vertising injury" arising out of the operations performed for the state or political subdivision; (2) This insurance does not apply to "bodily injury" or "property damage" included within the "completed operations hazard". (3) Insurance applies to premises you own, rent, or control but only with respect to the following hazards: R (a) The existence, maintenance, repair, construction, erection, or removal of advertising $ signs, awnings, canopies, cellar entrances, coal holes, driveways, manholes, marquees, " hoist away openings, sidewalk vaults, street banners, or decorations and similar expo- sures; or (b) The construction, erection, or removal of elevators; or s (c) The ownership, maintenance, or use of any elevators covered by this insurance. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insur- ance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. With respect to Paragraph 1.a. above, a person's or organization's status as an additional insured under this endorsement ends when: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or (2) That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. With respect to Paragraph 1.b. above, a person's or organization's status as an additional insured under this endorsement ends when their written contract or written agreement with you for such premises or facilities ends. With respects to Paragraph 1.c. above, this insurance does not apply to any "occurrence" which takes place after the equipment rental or lease agreement has expired or you have returned such equipment to the lessor. x The insurance provided by this endorsement applies only if the written contract or written agreement is signed prior to the "bodily injury" or "property damage". We have no duty to defend an additional insured under this endorsement until we receive written notice of a "suit" by the additional insured as required in Paragraph b. of Condition 2. Duties In the Event Of Occurrence, Offense, Claim Or Suit under Section IV - Commercial General Liability Condi- tions. ® 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 4 of 8 2. With respect to the insurance provided by this endorsement, the following are added to Paragraph 2. Exclusions under Section 1-Coverage A-Bodily Injury And Property Damage Liability: This insurance does not apply to: a. "Bodily injury" or"property damage" arising from the sole negligence of the additional insured. b. "Bodily injury" or "property damage" that occurs prior to you commencing operations at the location where such "bodily injury" or "property damage" occurs. c. "Bodily injury", "property damage" or "personal and advertising injury" arising out of the render- ing of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occur- rence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of, or the failure to render, any professional architectural, engineering or surveying services. d. "Bodily injury" or "property damage" occurring after: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or (2) That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. e. Any person or organization specifically designated as an additional insured for ongoing operations by a separate ADDITIONAL INSURED -OWNERS, LESSEES OR CONTRACTORS endorsement is- sued by us and made a part of this policy. 3. With respect to the insurance afforded to these additional insureds, the following is added to Section III -Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: a. Required by the contract or agreement; or b. Available under the applicable Limits of Insurance shown in the Declarations; ie whichever is less. a This endorsement shall not increase the applicable Limits of Insurance shown in the Declaratio ns. H. PRIMARY AND NON-CONTRIBUTORY ADDITIONAL INSURED EXTENSION This provision applies to any person or organization who qualifies as an additional insured under any form or endorsement under this policy. Condition 4. Other Insurance of SECTION IV -COMMERCIAL GENERAL LIABILITY CONDITIONS is amend- ed as follows: a. The following is added to Paragraph a. Primary Insurance: If an additional insured's policy has an Other Insurance provision making its policy excess, and you have agreed in a written contract or written agreement to provide the additional insured coverage on a primary and noncontributory basis, this policy shall be primary and we will not seek contribution from the additional insured's policy for damages we cover. © 2013Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 5 of 8 b. The following is added to Paragraph b. Excess Insurance: When a written contract or written agreement, other than a premises lease, facilities rental contract or agreement, an equipment rental or lease contract or agreement, or permit issued by a state or political subdivision between you and an additional insured does not require this insurance to be primary or primary and non-contributory, this insurance is excess over any other insurance for which the addi- tional insured is designated as a Named Insured. Regardless of the written agreement between you and an additional insured, this insurance is excess over any other insurance whether primary, excess, contingent or on any other basis for which the additional insured has been added as an additional insured on other policies. I. ADDITIONAL INSUREDS -EXTENDED PROTECTION OF YOUR "LIMITS OF INSURANCE" This provision applies to any person or organization who qualifies as an additional insured under any form or endorsement under this policy. N 1. The following is added to Condition 2. Duties In The Event Of Occurrence, Offense, Claim or Suit: An additional insured under this endorsement will as soon as practicable: a. Give written notice of an "occurrence" or an offense that may result in a claim or "suit" under this insurance to us; b. Tender the defense and indemnity of any claim or "suit" to all insurers whom also have insurance available to the additional insured; and c. Agree to make available any other insurance which the additional insured has for a loss we cover under this Coverage Part. d. We have no duty to defend or indemnify an additional insured under this endorsement until „ we receive written notice of a"suit" by the additional insured. 2. The limits of insurance applicable to the additional insured are those specified in a written contract or written agreement or the limits of insurance as stated in the Declarations of this policy and defined in Section III - Limits of Insurance of this policy, whichever are less. These limits are inclusive of and not in addition to the limits of insurance available under this policy. J. WHO IS AN INSURED -INCIDENTAL MEDICAL ERRORS/MALPRACTICE WHO IS AN INSURED -FELLOW EMPLOYEE EXTENSION -MANAGEMENT EMPLOYEES Paragraph 2.a.(1) of Section II -Who Is An Insured is replaced with the following: (1) "Bodily injury" or"personal and advertising injury": (a) To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), to a co-"employee" while in the course of his or her employ- ment or performing duties related to the conduct of your business, or to your other "volunteer workers" while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co-"employee" or "volunteer worker" as a consequence of Paragraph (1) (a) above; a (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraphs (1) (a) or (b) above; or (d) Arising out of his or her providing or failing to provide professional health care services. However, if you are not in the business of providing professional health care services or providing profes- sional health care personnel to others, or if coverage for providing professional health care ser- vices is not otherwise excluded by separate endorsement, this provision (Paragraph (d)) does not apply. Paragraphs (a) and (b) above do not apply to "bodily injury" or "personal and advertising injury" caused by an "employee" who is acting in a supervisory capacity for you. Supervisory capacity as used herein means the "employee's" job responsibilities assigned by you, includes the direct supervision of other "employ- ees" of yours. However, none of these "employees" are insureds for "bodily injury" or "personal and © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 6 of 8 advertising injury" arising out of their willful conduct, which is defined as the purposeful or willful intent to cause "bodily injury" or "personal and advertising injury", or caused in whole or in part by their intoxica- tion by liquor or controlled substances. The coverage provided by provision J. is excess over any other valid and collectable insurance available to your "employee". K. NEWLY FORMED OR ADDITIONALLY ACQUIRED ENTITIES Paragraph 3. of Section II -Who Is An Insured is replaced by the following: 3. Any organization you newly acquire or form and over which you maintain ownership or majority interest, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the expiration of the policy period in which the entity was acquired or formed by you; b. Coverage A does not apply to "bodily injury" or "property damage" that occurred before you acquired or formed the organization; and c. Coverage B does not apply to "personal and advertising injury" arising out of an offense committed before you acquired or formed the organization. d. Records and descriptions of operations must be maintained by the first Named Insured. No person or organization is an insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations or qualifies as an insured under this provision. L. FAILURE TO DISCLOSE HAZARDS AND PRIOR OCCURRENCES Under Section IV -Commercial General Liability Conditions, the following is added to Condition 6. Repre- sentations: Your failure to disclose all hazards or prior 'occurrences" existing as of the inception date of the policy shall not prejudice the coverage afforded by this policy provided such failure to disclose all hazards or prior 'occurrences" is not intentional. M. KNOWLEDGE OF OCCURRENCE, OFFENSE, CLAIM OR SUIT Under Section IV -Commercial General Liability Conditions, the following is added to Condition 2. Duties In The Event of Occurrence, Offense, Claim Or Suit: Knowledge of an 'occurrence", offense, claim or "suit" by an agent, servant or "employee" of any insured shall not in itself constitute knowledge of the insured unless an insured listed under Paragraph 1. of Section II -Who Is An Insured or a person who has been designated by them to receive reports of "occurrences", offenses, claims or "suits" shall have received such notice from the agent, servant or "employee". N. LIBERALIZATION CLAUSE If we revise this Commercial General Liability Extension Endorsement to provide more coverage without additional premium charge, your policy will automatically provide the coverage as of the day the revision is effective in your state. O. BODILY INJURY REDEFINED Under Section V -Definitions, Definition 3. is replaced by the following: 3. 'Bodily Injury" means physical injury, sickness or disease sustained by a person. This includes mental anguish, mental injury, shock, fright or death that results from such physical injury, sick- ness or disease. © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 7 of 8 P. EXTENDED PROPERTY DAMAGE Exclusion a. of COVERAGE A. BODILY INJURY AND PROPERTY DAMAGE LIABILITY is replaced by the following: a. Expected Or Intended Injury "Bodily injury" or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. Q. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US - WHEN REQUIRED IN A CONTRACT OR AGREEMENT WITH YOU Under Section IV - Commercial General Liability Conditions, the following is added to Condition 8. Trans- fer Of Rights Of Recovery Against Others To Us: We waive any right of recovery we may have against a person or organization because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products-completed operations hazard" provided: 1. You and that person or organization have agreed in writing in a contract or agreement that you a waive such rights against that person or organization; and 2. The injury or damage occurs subsequent to the execution of the written contract or written agree- ment. N O b © 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 8 of 8 COMMERCIAL GENERAL LIABILITY CG 88 70 12 08 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CONSTRUCTION PROJECT(S) - GENERAL AGGREGATE LIMIT (PER PROJECT) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. For all sums which the insured becomes legally obligated to pay as damages caused by 'occurrences" under Section I - Coverage A - Bodily Injury And Property Damage Liability, and for all medical ex- penses caused by accidents under Section I - Coverage C Medical Payments, which can be attributed only to ongoing operations at a single construction project away from premises owned by or rented to you: 1. A separate Construction Project General Aggregate Limit applies to each construction project, and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations . 2. The Construction Project General Aggregate Limit is the most we will pay for the sum of all damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products-completed operations hazard", and for medical expenses under Cov- erage C regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 3. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the Construction Project General Aggregate Limit for that construction project. Such payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Construction Project General Aggregate Limit for any other construction project. 4. The limits shown in the Declarations for Each Occurrence, Fire Damage and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, such limits will be subject to the applicable Construction Project General Aggregate Limit. B. For all sums which the insured becomes legally obligated to pay as damages caused by 'occurrences" under Section I - Coverage A - Bodily Injury And Property Damage Liability, and for all medical ex- penses caused by accidents under Section I - Coverage C Medical Payments, which cannot be attrib- uted only to ongoing operations at a single construction project away from premises owned by or rented to you: 1. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the amount available under the General Aggregate Limit or the Products-Completed Operations Aggregate Limit, whichever is applicable; and 2. Such payments shall not reduce any Construction Project General Aggregate Limit. C. When coverage for liability arising out of the "products-completed operations hazard" is provided, any payments for damages because of "bodily injury" or "property damage" included in the "products- completed operations hazard" will reduce the Products-Completed Operations Aggregate Limit, and not reduce the General Aggregate Limit nor the Construction Project General Aggregate Limit. D. If the applicable construction project has been abandoned, delayed, or abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints, designs, specifications or timetables, the project will still be deemed to be the same construction project. E. The provisions of Section III - Limits Of Insurance not otherwise modified by this endorsement shall continue to apply. CG 88 70 12 08 Includes copyrighted material of ISO Properties,Inc.,with its permission. Page 1 of 1