Loading...
HomeMy WebLinkAboutPK17-258 - Original - Christensen Inc. General Contractor - Contract - 08/18/17 r;, 1, f err/% n r emull, Recu,,,� rds Ma, KENT Document W,asHoHcrory ' � r r CONTRACT COVER SHEET This is to be completed by the Contract Manager prior to submission to the City Clerk's Office. All portions are to be completed. If you have questions, please contact the City Clerk's Office at 253 S5b-5725. Vendor Name: Christensen Inc., General Contractor Vendor Number: JID Edwards Number Contract Number: . / 1_], This is assigned by City Clerk's Office Project Name: Legal Department TI Description: ❑ Interlocal Agreement ❑ Change Order El Amendment X❑ Contract ❑ Other: Contract Effective Date: 08/18/17 Termination mate: 11/17/17 Contract Renewal Notice (Days):. Number of days required notice for termination or renewal or amendment Contract Manager: Nancy Clary Department: Parks, Facilities Contract Amount: $28,594.50 Approval Authority: [] Director X❑ Mayor F-1 City Council Meeting Date Detail: (i.e. address, location, parcel number, tax id, etc.): KENT PUBLIC WORKS AGREEMENT between City of Kent and Christensen Inc. General Contractor THIS AGREEMENT is made by and between the City of Kent, a Washington municipal corporation (hereinafter the "City"), and Christensen Inc. General Contractor, organized under the laws of the State of Washington, located and doing business at 2840 Crites Street SW, #100, Tumwater, WA 98512, Kevin Christensen, 360 709-0330, (hereinafter the "Contractor"). AGREEMENT The parties agree as follows: I. DESCRIPTION OF WORK. Contractor shall perform the following services for the City in accordance with the following described plans and/or specifications: Christensen Inc. General Contractor shall provide all labor and material to renovate office space in the City of Kent Legal Department, 220 4th Avenue South, Kent, 98032. The renovation consists of reducing the size of an existing office and creation of a second office, in accordance with Quote dated June 30, 2017 which is incorporated as Exhibit A. Contractor further represents that the services furnished under this Agreement will be performed in accordance with generally accepted professional practices within the Puget Sound region in effect at the time such services are performed. II. TIME OF COMPLETION. The parties agree that work will begin on the tasks described in Section I above immediately upon execution of this Agreement. Upon the effective date of this Agreement, Contractor shall complete the work described in Section I within 90 days. III. COMPENSATION. The City shall pay the Contractor a total amount not to exceed $28,594.50, including any applicable Washington State Sales Tax, for the work and services contemplated In this Agreement. The Contractor shall invoice the City monthly. The City will pay for the portion of the work described in the invoice that has been completed by the Contractor and approved by the City. The City's payment shall not constitute a waiver of the City's right to final inspection and acceptance of the project. A. Payment and Performance Bond. Pursuant to Chapter 39.08 RCW, the Contractor, shall provide the City a payment and performance bond for the full contract amount. B. Retainage. The City shall hold back a retainage in the amount of five percent (5%) of any and all payments made to contractor for a period of sixty (60) days after the date of final acceptance, or until receipt of all necessary releases from the State Department of Revenue, the State Department of Labor & Industries, and the State Employment Security Department, and until settlement of any liens filed under Chapter 60.28 RCW, whichever is later. The amount retained shall be placed in a PUBLIC WORKS AGREEMENT - 1 (Over$20K, but$65K or Less, and Performance Bond) fund by the City pursuant to RCW 60.28.011(4)(a), unless otherwise instructed by the Contractor within fourteen (14) calendar days of Contractor's signature on the Agreement. C. Defective or Unauthorized Work. The City reserves its right to withhold payment from Contractor for any defective or unauthorized work. Defective or unauthorized work includes, without limitation: work and materials that do not conform to the requirements of this Agreement; and extra work and materials furnished without the City's written approval. If Contractor is unable, for any reason, to satisfactorily complete any portion of the work, the City may complete the work by contract or otherwise, and Contractor shall be liable to the City for any additional costs incurred by the City. "Additional costs" shall mean all reasonable costs, including legal costs and attorney fees, incurred by the City beyond the maximum Contract price specified above. The City further reserves its right to deduct the cost to complete the Contract work, including any Additional Costs, from any and all amounts due or to become due the Contractor. D. Final Payment: Waiver of Claims. THE CONTRACTOR'S ACCEPTANCE OF FINAL PAYMENT (EXCLUDING WITHHELD RETAINAGE) SHALL CONSTITUTE A WAIVER OF CONTRACTOR'S CLAIMS, EXCEPT THOSE PREVIOUSLY AND PROPERLY MADE AND IDENTIFIED BY CONTRACTOR AS UNSETTLED AT THE TIME FINAL PAYMENT IS MADE AND ACCEPTED. IV. INDEPENDENT CONTRACTOR. The parties intend that an Independent Contractor- Employer Relationship will be created by this Agreement. By their execution of this Agreement, and in accordance with Ch. 51.08 RCW, the parties make the following representations: A. The Contractor has the ability to control and direct the performance and details of its work, the City being interested only in the results obtained under this Agreement. B. The Contractor maintains and pays for its own place of business from which Contractor's services under this Agreement will be performed. C. The Contractor has an established and independent business that is eligible for a business deduction for federal income tax purposes that existed before the City retained Contractor's services and is a service other than that furnished by the City, or the Contractor is engaged in an independently established trade, occupation, profession, or business of the same nature as that involved under this Agreement. D. The Contractor is responsible for filing as they become due all necessary tax documents with appropriate federal and state agencies, including the Internal Revenue Service and the state Department of Revenue. E. The Contractor has registered its business and established an account with the state Department of Revenue and other state agencies as may be required by Contractor's business, and has obtained a Unified Business Identifier (UBI) number from the State of Washington. F. The Contractor has a valid contractor registration pursuant to Ch. 18.27 RCW or an electrical contractor license pursuant to Ch. 19.28 RCW, G. The Contractor maintains a set of books dedicated to the expenses and earnings of its business. V. TERMINATION. The City may terminate this Agreement for good cause. "Good cause" shall include, without limitation, any one or more of the following events: PUBLIC WORKS AGREEMENT- 2 (Over$20K, but$65K or Less, and Performance Bond) A. The Contractor's refusal or failure to supply a sufficient number of properly skilled workers or proper materials for completion of the Contract work. B. The Contractor's failure to complete the work within the time specified in this Agreement. C. The Contractor's failure to make full and prompt payment to subcontractors or for material or labor. D. The Contractor's persistent disregard of federal, state or local laws, rules or regulations. E. The Contractor's filing for bankruptcy or becoming adjudged bankrupt. F. The Contractor's breach of any portion of this Agreement. If the City terminates this Agreement for good cause, the Contractor shall not receive any further money due under this Agreement until the Contract work is completed. After termination, the City may take possession of all records and data within the Contractor's possession pertaining to this project which may be used by the City without restriction. VI. PREVAILING WAGES. Contractor shall file a "Statement of Intent to Pay Prevailing Wages," with the State of Washington Department of Labor& Industries prior to commencing the Contract work. Contractor shall pay prevailing wages in effect on the date the bid Is accepted or executed by Contractor, and comply with Chapter 39.12 of the Revised Code of Washington, as well as any other applicable prevailing wage rate provisions. The latest prevailing wage rate revision issued by the Department of Labor and Industries is attached. VII. CHANGES. The City may issue a written change order for any change in the Contract work during the performance of this Agreement. If the Contractor determines, for any reason, that a change order is necessary, Contractor must submit a written change order request to the person listed in the notice provision section of this Agreement, section XV(D), within fourteen (14) calendar days of the date Contractor knew or should have known of the facts and events giving rise to the requested change. If the City determines that the change increases or decreases the Contractor's costs or time for performance, the City will make an equitable adjustment. The City will attempt, in good faith, to reach agreement with the Contractor on all equitable adjustments. However, if the parties are unable to agree, the City will determine the equitable adjustment as it deems appropriate. The Contractor shall proceed with the change order work upon receiving either a written change order from the City or an oral order from the City before actually receiving the written change order. If the Contractor fails to require a change order within the time specified in this paragraph, the Contractor waives its right to make any claim or submit subsequent change order requests for that portion of the contract work. If the Contractor disagrees with the equitable adjustment, the Contractor must complete the change order work; however, the Contractor may elect to protest the adjustment as provided in subsections A through E of Section VIII, Claims, below. The Contractor accepts all requirements of a change order by: (1) endorsing it, (2) writing a separate acceptance, or (3) not protesting in the way this section provides. A change order that is accepted by Contractor as provided in this section shall constitute full payment and final settlement of all claims for contract time and for direct, indirect and consequential costs, including costs of delays related to any work, either covered or affected by the change. VIII. CLAIMS. If the Contractor disagrees with anything required by a change order, another written order, or an oral order from the City, including any direction, instruction, interpretation, or determination by the City, the Contractor may file a claim as provided in this section. The Contractor shall give written notice to the City of all claims within fourteen (14) calendar days of the occurrence of the events giving rise to the claims, or within fourteen (14) calendar days of the date the Contractor knew or should have known of the facts or events giving rise to the claim, whichever occurs first . Any claim for damages, additional payment for any reason, or extension of time, whether under this Agreement or PUBLIC WORKS AGREEMENT- 3 (Over$20K, but$65K or Less, and Performance Bond) otherwise, shall be conclusively deemed to have been waived by the Contractor unless a timely written claim is made In strict accordance with the applicable provisions of this Agreement. At a minimum, a Contractor's written claim shall include the information set forth in subsections A, items 1 through 5 below. FAILURE TO PROVIDE A COMPLETE, WRITTEN NOTIFICATION OF CLAIM WITHIN THE TIME ALLOWED SHALL BE AN ABSOLUTE WAIVER OF ANY CLAIMS ARISING IN ANY WAY FROM THE FACTS OR EVENTS SURROUNDING THAT CLAIM OR CAUSED BY THAT DELAY. A. Notice of Claim. Provide a signed written notice of claim that provides the following information: 1. The date of the Contractor's claim; 2. The nature and circumstances that caused the claim; 3. The provisions in this Agreement that support the claim; 4. The estimated dollar cost, if any, of the claimed work and how that estimate was determined; and 5. An analysis of the progress schedule showing the schedule change or disruption if the Contractor is asserting a schedule change or disruption. B. Records. The Contractor shall keep complete records of extra costs and time incurred as a result of the asserted events giving rise to the claim. The City shall have access to any of the Contractor's records needed for evaluating the protest. The City will evaluate all claims, provided the procedures in this section are followed. If the City determines that a claim is valid, the City will adjust payment for work or time by an equitable adjustment. No adjustment will be made for an Invalid protest. C. Contractor's Duty to Complete Protested Work. In spite of any claim, the Contractor shall proceed promptly to provide the goods, materials and services required by the City under this Agreement. D. Failure to Protest Constitutes Waiver. By not protesting as this section provides, the Contractor also waives any additional entitlement and accepts from the City any written or oral order (including directions, instructions, interpretations, and determination). E. Failure to Follow Procedures Constitutes Waiver. By failing to follow the procedures of this section, the Contractor completely waives any claims for protested work and accepts from the City any written or oral order (including directions, Instructions, interpretations, and determination). IX. LIMITATION OF ACTIONS. CONTRACTOR MUST, IN ANY EVENT, FILE ANY LAWSUIT ARISING FROM OR CONNECTED WITH THIS AGREEMENT WITHIN 120 CALENDAR DAYS FROM THE DATE THE CONTRACT WORK IS COMPLETE OR CONTRACTOR'S ABILITY TO FILE THAT CLAIM OR SUIT SHALL BE FOREVER BARRED. THIS SECTION FURTHER LIMITS ANY APPLICABLE STATUTORY LIMITATIONS PERIOD. X. WARRANTY. Contractor warrants that it will faithfully and satisfactorily perform all work provided under this Agreement in accordance with the provisions of this Agreement. The Contractor shall promptly correct all defects in workmanship and materials: (1) when Contractor knows or should have known of the defect, or (2) upon Contractor's receipt of notification from the City of the existence or discovery of the defect. In the event any parts are repaired or replaced, only original replacement parts shall be used—rebuilt or used parts will not be acceptable. When defects are corrected, the warranty for that portion of the work shall extend for an additional year beyond the original warranty period applicable to the overall work. The Contractor shall begin to correct any defects within seven (7) calendar days of Its receipt of notice from the City of the defect. If the Contractor does not accomplish the corrections within PUBLIC WORKS AGREEMENT - 4 (Over$20K, but$65K or Less, and Performance Bond) a reasonable time as determined by the City, the City may complete the corrections and the Contractor shall pay all costs incurred by the City in order to accomplish the correction. XI. DISCRIMINATION. In the hiring of employees for the performance of work under this Agreement or any sub-contract, the Contractor, its sub-contractors, or any person acting on behalf of the Contractor or sub-contractor shall not, by reason of race, religion, color, sex, age, sexual orientation, national origin, or the presence of any sensory, mental, or physical disability, discriminate against any person who is qualified and available to perform the work to which the employment relates. Contractor shall execute the attached City of Kent Equal Employment Opportunity Policy Declaration, Comply with City Administrative Policy 1.2, and upon completion of the contract work, file the attached Compliance Statement. XII. INDEMNIFICATION. Contractor shall defend, indemnify and hold the City, its officers, officials, employees, agents and volunteers harmless from any and all claims, Injuries, damages, losses or suits, including all legal costs and attorney fees, arising out of or in connection with the Contractor's performance of this Agreement, except for that portion of the injuries and damages caused by the City's negligence. The City's inspection or acceptance of any of Contractor's work when completed shall not be grounds to avoid any of these covenants of indemnification. Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Contractor and the City, its officers, officials, employees, agents and volunteers, the Contractor's duty to defend, indemnify, and hold the City harmless, and Contractor's liability accruing from that obligation shall be only to the extent of the Contractor's negligence. IT IS FURTHER SPECIFICALLY AND EXPRESSLY UNDERSTOOD THAT THE INDEMNIFICATION PROVIDED HEREIN CONSTITUTES THE CONTRACTOR'S WAIVER OF IMMUNITY UNDER INDUSTRIAL INSURANCE, TITLE 51 RCW, SOLELY FOR THE PURPOSES OF THIS INDEMNIFICATION. THE PARTIES FURTHER ACKNOWLEDGE THAT THEY HAVE MUTUALLY NEGOTIATED THIS WAIVER. In the event Contractor refuses tender of defense in any suit or any claim, if that tender was made pursuant to this indemnification clause, and if that refusal is subsequently determined by a court having jurisdiction (or other agreed tribunal) to have been a wrongful refusal on the Contractor's part, then Contractor shall pay all the City's costs for defense, including all reasonable expert witness fees and reasonable attorneys' fees, plus the City's legal costs and fees incurred because there was a wrongful refusal on the Contractor's part. The provisions of this section shall survive the expiration or termination of this Agreement. XIII. INSURANCE. The Contractor shall procure and maintain for the duration of the Agreement, insurance of the types and in the amounts described in Exhibit B attached and incorporated by this reference. XIV. WORK PERFORMED AT CONTRACTOR'S RISK. Contractor shall take all necessary precautions and shall be responsible for the safety of its employees, agents, and subcontractors in the performance of the contract work and shall utilize all protection necessary for that purpose. All work shall be done at Contractor's own risk, and Contractor shall be responsible for any loss of or damage to materials, tools, or other articles used or held for use in connection with the work. XV. MISCELLANEOUS PROVISIONS. PUBLIC WORKS AGREEMENT - 5 (Over$20K, but$65K or Less, and Performance Bond) A. Recyclable Materials. Pursuant to Chapter 3.80 of the Kent City Code, the City requires its contractors and consultants to use recycled and recyclable products whenever practicable. A price preference may be available for any designated recycled product. B. Non-Waiver of Breach. The failure of the City to insist upon strict performance of any of the covenants and agreements contained In this Agreement, or to exercise any option conferred by this Agreement in one or more instances shall not be construed to be a waiver or relinquishment of those covenants, agreements or options, and the same shall be and remain in full force and effect. C. Resolution of Disputes and Governing Law. This Agreement shall be governed by and construed In accordance with the laws of the State of Washington. If the parties are unable to settle any dispute, difference or claim arising from the parties' performance of this Agreement, the exclusive means of resolving that dispute, difference or claim, shall only be by filing suit exclusively under the venue, rules and jurisdiction of the King County Superior Court, King County, Washington, unless the parties agree in writing to an alternative dispute resolution process. In any claim or lawsuit for damages arising from the parties' performance of this Agreement, each party shall pay all its legal costs and attorney's fees incurred In defending or bringing such claim or lawsuit, including all appeals, in addition to any other recovery or award provided by law; provided, however, nothing in this paragraph shall be construed to limit the City's right to indemnification under Section XII of this Agreement. D. Written Notice. All communications regarding this Agreement shall be sent to the parties at the addresses listed on the signature page of the Agreement, unless notified to the contrary. Any written notice hereunder shall become effective three (3) business days after the date of mailing by registered or certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated in this Agreement or such other address as may be hereafter specified in writing. E. Assignment. Any assignment of this Agreement by either party without the written consent of the non-assigning party shall be void. If the non-assigning party gives its consent to any assignment, the terms of this Agreement shall continue in full force and effect and no further assignment shall be made without additional written consent. F. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of the City and Contractor. G. Entire Agreement. The written provisions and terms of this Agreement, together with any Exhibits attached hereto, shall supersede all prior verbal statements of any officer or other representative of the City, and such statements shall not be effective or be construed as entering into or forming a part of or altering in any manner this Agreement. All of the above documents are hereby made a part of this Agreement. However, should any language in any of the Exhibits to this Agreement conflict with any language contained in this Agreement, the terms of this Agreement shall prevail. H. Compliance with Laws. The Contractor agrees to comply with all federal, state, and municipal laws, rules, and regulations that are now effective or in the future become applicable to Contractor's business, equipment, and personnel engaged in operations covered by this Agreement or accruing out of the performance of those operations. I. Public Records Act. The Contractor acknowledges that the City is a public agency subject to the Public Records Act codified in Chapter 42.56 of the Revised Code of Washington and documents, notes, emails, and other records prepared or gathered by the Contractor in its performance of this Agreement may be subject to public review and disclosure, even if those records are not produced to or possessed by the City of Kent. As such, the Contractor agrees to cooperate fully with the City in satisfying the City's duties and obligations under the Public Records Act. J. City Business License Required. Prior to commencing the tasks described in Section I, Contractor agrees to provide proof of a current city of Kent business license pursuant to Chapter 5.01 of the Kent City Code. PUBLIC WORKS AGREEMENT - 6 (Over$20K, but$65K or Less, and Performance Bond) K. Co.0 LterpaL Ls and !jIgrL -es by Fax or ErnaLl, This Agreement may be executed in any - -- g- - -g- - atm number of counterparts, each of which shall constitute an original, and all of which will together constitute this one Agreement. Further, upon executing this Agreement, either party may deliver the signature page to the other by fax or email and that signature shall have the same force and effect as If the Agreement bearing the original signature was received in person, IN WITNESS, the parties bellow execute this Agreement, which shall become effective on the last date entered below. All acts consistent with the authority of this Agreement and prior to its effective date are ratified and affirmed, and the terms of the Agreement shall be deemed to have applied. CONTRACTOR: CITY OF KENT: lz� By ✓: By: orsignawre) (signature) Prinl ame: ..b(LVL�j L)5c--Aj Print 7a)mQoke$uzette Co its �z -i —t Its ayo[ DATE: (title) DATE: .......... NOTICES TO BE SENT TO: NOTICES TO BE SENT TO: CONTRACTOR: CITY OF KENT". Kevin Christensen Nancy Clary Christensen Inc, General Contractor 2840 Crites Street SW, #100 City of Kent Turnwater, WA 98512 220 Fourth Avenue South Kent, WA 98032 360 709-0330 (telephone) 360 709-01220 (facsimiile) (253) 856-5084 (telephone) (253) 856-6080 (facsimile) ........... APPROVED AS TO FORM: - W& 12A , 1 Kerk Law Department PUBLIC WORKS AGREEMENT - 7 (Over$20K, but$65K or Less, and Performance Bond) DECLARATION CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY POLICY The City of Kent is committed to conform to Federal and State laws regarding equal opportunity. As such!, all contractors, subcontractors and suppiliers who perform work with relation to this Agreement shall comply with the regulatlons of the City's equal employment opportunity policies. The following questions specifically identify the requirements the City deems necessary for any contractor, subcontractor or supplier on this specific Agreement to adhere to. An affirmative response is required on all of the following questions for this Agreement to be valid and binding. If any contractor, subcontractor or supplier willfully misrepresents themselves with regard to the directives Outlines, it will be considered a breach of contract and it will be at the City's sole determination regarding suspension or termination for all or part of the Agreement; The questions are as follows: 1. 1 have read the attached City of Kent administrative policy number 1.2. 2. During the time of this Agreement I will not discriminate in employment on the basis of sex, race, color, national origin, age, or the presence of all sensory, mental or physical disability, 3. During the time of this Agreement thie prime contractor will provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer, 4. During the time of the Agreement 1, the prime contractor, will actively consider hiring aind promotion of women and minorities. 5. Before acceptance of this, Agreement, an adherence statement will be signed by me, the Prime Contractor, that the Prime Contractor complied with the requirements as set forth above,, By signing below, I agree to fulfill the five requirements referenced above. By: For: 5 Title: 67 IDS Date: EEO COMPLIANCE DOCUMENTS - I CITY OF KENT ADMINISTRATIVE POLICY NUMBER: 1.2 EFFECTIVE DATE: January 1, 1998 SUBJECT: MINORITY AND WOMEN SUPERSEDES: April 1, 1996 CONTRACTORS APPROVED BY Jim White, Mayor POLICY: Equal employment opportunity requirements for the City of Kent will conform to federal and state laws. All contractors, subcontractors, consultants and suppliers of the City must guarantee equal employment opportunity within their organization and, if holding Agreements with the City amounting to $10,000 or more within any given year, must take the following affirmative steps: 1. Provide a written statement to all new employees and subcontractors indicating commitment as an equal opportunity employer. 2. Actively consider for promotion and advancement available minorities and women. Any contractor, subcontractor, consultant or supplier who willfully disregards the City's nondiscrimination and equal opportunity requirements shall be considered in breach of contract and subject to suspension or termination for all or part of the Agreement. Contract Compliance Officers will be appointed by the Directors of Planning, Parks, and Public Works Departments to assume the following duties for their respective departments. 1. Ensuring that contractors, subcontractors, consultants, and suppliers subject to these regulations are familiar with the regulations and the City's equal employment opportunity policy. 2. Monitoring to assure adherence to federal, state and local laws, policies and guidelines. EEO COMPLIANCE DOCUMENTS - 2 CITY OF KENT EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE STATEMENT This form shall be filled out AFTER COMPLETION of this project by the Contractor awarded the Agreement. I, the undersigned, a duly represented agent of Company, hereby acknowledge and declare that the before-mentioned company was the prime contractor for the Agreement known as that was entered into on the (date), between the firm I represent and the City of Kent. I declare that I complied fully with all of the requirements and obligations as outlined in the City of Kent Administrative Policy 1.2 and the Declaration City of Kent Equal Employment Opportunity Policy that was part of the before-mentioned Agreement. By: For: Title: Date: EEO COMPLIANCE DOCUMENTS - 3 BIDDER RESPONSIBILITY CRITERIA Certification of Compliance with Wage Payment Statutes This certification is required by state law (RCW 39.04.350(2)) to be submitted to the City before the contract can be awarded. The bidder hereby certifies that, within the three-year period immediately preceding the bid solicitation date (Insert Date), the bidder is not a "willful" violator, as defined in RCW 49,48.082, of any provision of chapters 49.46, 49,48, or 49.52 RCW, as determined by a final and binding citation and notice of assessment issued by the: Department of Labor and Industries or through a civil judgment entered by a court of limited or general jurisdiction. I certify under penalty of perjury under the laws of the State of Washington that the foregoing is true and correct. Insert Bidder's Business Name By: atUre Printed Name: Title: City and Mate: 1-0 M *If a corporation, proposal must be executed in the corporate name by the president or vice- president (or any other corporate officer,accompanied by evidence of authority to sign). If a co- partnership, proposal must be executed by a partner. BIDDER RESPONSIBILITY CRITERIA - 1 Page 1 of 20 State of Washington Department of Labor & Industries Prevailing Wage Section - Telephone 360-902-5335 PO Box 44540, Olympia, WA 98504-4540 Washington State Prevailing Wage The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, worker's wage and benefit rates must add to not less than this total. A brief description of overtime calculation requirements are provided on the Benefit Code Key. Journey Level Prevailing Wage Rates for the Effective Date: 06/30/2017 CountV Trade Job Classification Wage Holiday Overtime Note King Asbestos Abatement Journey Level $45.25 5D 1 H Workers King Boilermakers Journey Level $64.54 5N 1C King Brick Mason Journey Level $54.32 5A 1M King Brick Mason Pointer-Caulker-Cleaner $54.32 5A 1M King Building Service Employees Janitor $22.84 5S 2F King Building Service Employees Traveling $23.29 5S 2F Waxer/Shampooer King Building Service Employees Window Cleaner (Non- $24.54 5S 2F Scaffold) King Building Service Employees Window Cleaner $27.33 5S 2F (Scaffold) King Cabinet Makers (In Shop) Journey Level $22.74 1 King Carpenters Acoustical Worker $55.51 5D 4C King Carpenters Bridge, Dock And Wharf $55.51 5D 4C Carpenters King Carpenters Carpenter $55.51 5D 4C King Carpenters Carpenters on $55.64 5D 4C Stationary Tools King Carpenters Creosoted Material $55.61 5D 4C King Carpenters Floor Finisher $55.51 5D 4C King Carpenters Floor Layer $55.51 5D 4C King Carpenters Scaffold Erector $55.51 5D 4C .King Cement Masons Journey Level $55.56 7A 1M King Divers Et Tenders Diver $108.77 5D 4C 8A King Divers ix Tenders Diver On Standby $66.05 5D 4C King Divers Et Tenders Diver Tender $59.88 5D 4C https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 2 of 20 King Divers ft Tenders Surface Rcv it Rov $59.88 5D 4C Operator King Divers Et Tenders Surface Rcv Et Rov $55.76 5A 4C Operator Tender King Dredge Workers Assistant Engineer $56.44 5D 3F King Dredge Workers Assistant Mate $56.00 5D 3F (Deckhand) King Dredge Workers Boatmen $56.44 5D 3F King Dredge Workers Engineer Welder $57.51 5D 3F King Dredge Workers Leverman, Hydraulic $58.67 5D 3F King Dredge Workers Mates $56.44 5D 3F King Dredge Workers Oiler $56.00 5D 3F King Drywall Applicator Journey Level $55.51 5D 1 H King Drywall Tapers Journey Level $55.66 5P 1 E King Electrical Fixture Journey Level $27.99 5L 1E Maintenance Workers King Electricians - Inside Cable Splicer $73.20 7C 4E King Electricians - Inside Cable Splicer (tunnel) $78.59 7C 4E King Electricians - Inside Certified Welder $70.75 7C 4E King Electricians - Inside Certified Welder $75.89 7C 4E (tunnel) King Electricians - Inside Construction Stock $38.69 7C 4E Person King Electricians - Inside Journey Level $68.30 7C 4E King Electricians - Inside Journey Level (tunnel) $73.20 7C 4E King Electricians - Motor Shop Craftsman $15.37 1 King Electricians - Motor Shop Journey Level $14.69 1 King Electricians - Powerline Cable Splicer $73.93 5A 4D Construction King Electricians - Powerline Certified Line Welder $67.60 5A 4D Construction King Electricians - Powerline Groundperson $45.49 5A 4D Construction King Electricians - Powerline Heavy Line Equipment $67.60 5A 4D Construction Operator King Electricians - Powerline Journey Level $67.60 5A 4D Construction Lineperson King Electricians - Powerline Line Equipment $57.02 5A 4D Construction Operator King Electricians - Powerline Pole Sprayer $67.60 5A 4D Construction King Electricians - Powerline Powderperson $50.76 5A 4D Construction King Electronic Technicians Journey Level $31.00 1 King Elevator Constructors Mechanic $85.45 7D 4A King Elevator Constructors Mechanic In Charge $92.35 7D 4A King Fabricated Precast All Classifications - In- $17.20 5B 1 R Concrete Products Factory Work Only King Fence Erectors Fence Erector $15.18 1 King Flaggers I Journey Level $38.36 7A 31 https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 3 of 20 King IGiaziers Journey Level $59.31 7L 1y King Heat £t Frost Insulators And Journeyman $65.68 5J 4H Asbestos Workers King Heating Equipment Journey Level $75.46 7F 1 E Mechanics King Hod Carriers £t Mason Journey Level $46.66 7A 31 Tenders King Industrial Power Vacuum Journey Level $11.00 1 Cleaner King Inland Boatmen Boat Operator $59.86 5B 1K King Inland Boatmen Cook $56.18 5B 1K King Inland Boatmen Deckhand $56.18 5B 1K King Inland Boatmen Deckhand Engineer $57.26 5B 1K King Inland Boatmen Launch Operator $58.59 5B 1K King Inland Boatmen Mate $58.59 5B 1K ,King Inspection/Cleaning,/Sealing Cleaner Operator, $31.49 1 Of Sewer Et Water Systems Foamer Operator By Remote Control King Inspection/Cleaninig/Sealing Grout Truck Operator $11.48 1 Of Sewer $ Water Systems By Remote Control King Inspection/Cleaning/Sealinp, Head Operator $24.91 1 Of Sewer Ft Water Systems By Remote Control King Inspection/Cleaning/Sealing Technician $19.33 1 Of Sewer It Water Systems By Remote Control King Inspection/Cleaning,/Sealing Tv Truck Operator $20.45 1 Of Sewer at Water Systems By Remote Control King Insulation Applicators Journey Level $55.51 5D 4C King Ironworkers Journeyman $65.48 7N 10 King Laborers Air, Gas Or Electric $45.25 7A 31 Vibrating Screed King Laborers Airtrac Drill Operator $46.66 7A 31 King Laborers Ballast Regular Machine $45.25 7A 31 ;King Laborers Batch Weighman $38.36 7A 31 King Laborers Brick Pavers $45.25 7A 31 King Laborers Brush Cutter $45.25 7A 31 King Laborers Brush Hog Feeder $45.25 7A 31 ;King Laborers Burner $45.25 7A 31 King Laborers Caisson Worker $46.66 7A 31 King Laborers Carpenter Tender $45.25 7A 31 King Laborers Caulker $45.25 7A 31 King Laborers Cement Dumper-paving $46.09 7A 31 King Laborers Cement Finisher Tender $45.25 7A 31 King Laborers Change House Or Dry $45.25 7A 31 Shack King Laborers Chipping Gun (under 30 $45.25 7A 31 Lbs.) https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 4 of 20 King Laborers Chipping Gun(30 Lbs. $46.09 7A 31 And Over) King Laborers Choker Setter $45.25 7A 31 King Laborers Chuck Tender $45.25 7A 31 King Laborers Clary Power Spreader $46.09 7A 31 King Laborers Clean-up Laborer $45.25 7A 31 King Laborers Concrete Dumper/chute $46.09 7A 31 Operator King Laborers Concrete Form Stripper $45.25 7A 31 ;King Laborers Concrete Placement $46.09 7A 31 Crew King Laborers Concrete Saw $46.09 7A 31 Operator/core Driller King Laborers Crusher Feeder $38.36 7A 31 King Laborers Curing Laborer $45.25 7A 31 King Laborers Demolition: Wrecking Et $45.25 7A 31 Moving (incl. Charred Material) King Laborers Ditch Digger $45.25 7A 31 King Laborers Diver $46.66 7A 31 King Laborers Drill Operator $46.09 7A 31 (hydraulic,diamond) King Laborers Dry Stack Walls $45.25 7A 31 King Laborers Dump Person $45.25 7A 31 King Laborers Epoxy Technician $45.25 7A 31 King Laborers Erosion Control Worker $45.25 7A 31 King Laborers Faller Et Bucker Chain $46.09 7A 31 Saw King Laborers Fine Graders $45.25 7A 31 King Laborers Firewatch $38.36 7A 31 King Laborers Form Setter $45.25 7A 31 King Laborers Gabian Basket Builders $45.25 7A 31 King Laborers General Laborer $45.25 7A 31 King Laborers Grade Checker Ft $46.66 7A 31 Transit Person King Laborers Grinders $45.25 7A 31 King Laborers Grout Machine Tender $45.25 7A 31 King Laborers Groutmen (pressure) $46.09 7A 31 including Post Tension Beams King Laborers Guardrail Erector $45.25 7A 31 King Laborers Hazardous Waste $46.66 7A 31 Worker (level A) 'King Laborers Hazardous Waste $46.09 7A 31 Worker (level B) :King Laborers Hazardous Waste $45.25 7A 31 Worker (level C) King Laborers High Scaler $46.66 7A 31 King I Laborers IJackhammer 1 $46.09 7A 31 King Laborers Laserbeam Operator $46.09 7A 31 https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 5 of 20 King ILaborers Maintenance Person $45.25 7A 31 King Laborers Manhole Builder- $46.09 7A 31 mudman King Laborers Material Yard Person $45.25 7A 31 King Laborers Motorman-dinky $46.09 7A 31 Locomotive King Laborers Nozzleman (concrete $46.09 7A 31 Pump, Green Cutter When Using Combination Of High Pressure Air Et Water On Concrete & Rock, Sandblast, Gunite, Shotcrete, Water Bla King Laborers Pavement Breaker $46.09 7A 31 King Laborers Pilot Car $38.36 7A 31 King Laborers Pipe Layer Lead $46.66 7A 31 King Laborers Pipe Layer/tailor $46.09 7A 31 King Laborers Pipe Pot Tender $46.09 7A 31 King Laborers Pipe Reliner $46.09 7A 31 King Laborers Pipe Wrapper $46.09 7A 31 King Laborers Pot Tender $45.25 7A 31 King Laborers Powderman $46.66 7A 31 King Laborers Powderman's Helper $45.25 7A 31 King Laborers Power Jacks $46.09 7A 31 King Laborers Railroad Spike Puller - $46.09 7A 31 Power King Laborers Raker - Asphalt $46.66 7A 31 King Laborers Re-timberman $46.66 7A 31 King Laborers Remote Equipment $46.09 7A 31 Operator King Laborers Rigger/signal Person $46.09 7A 31 King Laborers Rip Rap Person $45.25 7A 31 King Laborers Rivet Buster $46.09 7A 31 King Laborers Rodder $46.09 7A 31 King Laborers Scaffold Erector $45.25 7A 31 King Laborers Scale Person $45.25 7A 31 King Laborers Sloper (over 20") $46.09 7A 31 King Laborers Sloper Sprayer $45.25 7A 31 King Laborers Spreader (concrete) $46.09 7A 31 King Laborers Stake Hopper $45.25 7A 31 King Laborers Stock Piler $45.25 7A 31 King Laborers Tamper Et Similar $46.09 7A 31 Electric, Air Et Gas Operated Tools King Laborers Tamper (multiple Et $46.09 7A 31 Self-propelled) King Laborers Timber Person - Sewer $46.09 7A 31 (lagger, Shorer Ft Cribber) https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 6 of 20 King Laborers Toolroom Person (at $45.25 7A 31 Jobsite) King Laborers Topper $45.25 7A 31 King Laborers Track Laborer $45.25 7A 31 King Laborers Track Liner (power) $46.09 7A 31 King Laborers Traffic Control Laborer $41.02 7A 31 811 King Laborers Traffic Control $41.02 7A 31 811 Supervisor King Laborers Truck Spotter $45.25 7A 31 King Laborers Tugger Operator $46.09 7A 31 King Laborers Tunnel Work- $83.12 7A 31 8�( Compressed Air Worker 0-30 psi King Laborers Tunnel Work- $88.15 7A 31 88 Compressed Air Worker 30.01-44.00 psi King Laborers Tunnel Work- $91.83 7A 31 Compressed Air Worker 44.01-54.00 psi King Laborers Tunnel Work- $97.53 7A 31 S Compressed Air Worker 54.01-60.00 psi King Laborers Tunnel Work- $99.65 7A 31 Compressed Air Worker 60.01-64.00 psi King Laborers Tunnel Work- $104.75 7A 31 88 Compressed Air Worker 64.01-68.00 psi King Laborers Tunnel Work- $106.65 7A 31 88 Compressed Air Worker 68.01-70.00 psi King Laborers Tunnel Work- $108.65 7A 31 Compressed Air Worker 70.01-72.00 psi King Laborers Tunnel Work- $110.65 7A 31 8�( Compressed Air Worker 72.01-74.00 psi King Laborers Tunnel Work-Guage and $46.76 7A 31 Lock Tender King Laborers Tunnel Work-Miner $46.76 7A 31 8 King Laborers Vibrator $46.09 7A 31 King Laborers Vinyl Seamer $45.25 7A 31 King Laborers Watchman $34.86 7A 31 King Laborers Welder $46.09 7A 31 King Laborers Well Point Laborer $46.09 7A 31 King Laborers Window Washer/cleaner $34.86 7A 31 King Laborers - Undereround General Laborer£t $45.25 7A 31 Sewer Et Water Topman King Laborers - Underground Pipe Layer $46.09 7A 31 Sewer & Water King Landscape Construction Irrigation Or Lawn $13.56 1 Sprinkler Installers https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 7 of 20 King Landscape Construction Landscape Equipment $28.17 1 Operators Or Truck Drivers `King Landscape Construction Landscaping or Planting $17.87 1 Laborers King Lathers Journey Level $55.51 5D 1H King Marble Setters Journey Level $54.32 5A 1M King Metal Fabrication (in Shop) Fitter $15.86 1 King Metal Fabrication (i� Laborer $11.00 1 King Metal Fabrication (In Shop) Machine Operator $13.04 1 King Metal Fabrication In Shop) Painter $11.10 1 King Metal Fabrication (in Shop) Welder $15.48 1 King Millwright Journey Level $57.01 5D 4C King Modular Buildings Cabinet Assembly $11.56 1 King Modular Buildings Electrician $11.56 1 King Modular Buildings Equipment Maintenance $11.56 1 King Modular Buildings Plumber $11.56 1 King Modular Buildings Production Worker $11.00 1 King Modular Buildings Tool Maintenance $11.56 1 King Modular Buildings Utility Person $11.56 1 'King Modular Buildings Welder $11.56 1 King Painters Journey Level $40.60 6Z 2B King Pile Driver Journey Level $55.76 5D 4C King Plasterers Journey Level $53.20 7� 1R King Playground Et Park Journey Level $11.00 1 Equipment Installers King Plumbers Et Pipefitters Journey Level $76.69 6Z 1G King Power Equipment Operators Asphalt Plant Operators $58.69 7A 3C 8P King Power Equipment Operators Assistant Engineer $55.21 7A 3C 8P King Power Equipment Operators Barrier Machine (zipper) $58.17 7A 3C 8P King Power Equipment Operators Batch Plant Operator, $58.17 7A 3C 8P Concrete King Power Equipment Operators Bobcat $55.21 7A 3C 8P King Power Equipment Operators Brokk- Remote $55.21 7A 3C 8P Demolition Equipment King Power Equipment Operators Brooms $55.21 7A 3C 8P King Power Equipment Operators Bump Cutter $58.17 7A 3C 8P King Power Equipment Operators Cableways $58.69 7A 3C 8P King Power Equipment Operators Chipper $58.17 7A 3C 8P King Power Equipment Operators Compressor $55.21 7A 3C 8P King Power Equipment Operators Concrete Pump: Truck $58.69 7A 3C 8P Mount With Boom Attachment Over 42 M King Power Equipment Operators Concrete Finish Machine $55.21 7A 3C 8P -laser Screed King Power Equipment Operators Concrete Pump - $57.72 7A 3C 8P Mounted Or Trailer High Pressure Line Pump, Pump High Pressure. https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 8 of 20 King Power Equipment Operators Concrete Pump: Truck $58.17 7A 3C 8P Mount With Boom Attachment Up To 42m King Power Equipment Operators Conveyors $57.72 7A 3C 8P King Power Equipment Operators Cranes Friction: 200 $60.47 7A 3C 8P tons and over King Power Equipment Operators Cranes: 20 Tons $58.17 7A 3C 8P Through 44 Tons With Attachments King Power Equipment Operators Cranes: 100 Tons $59.28 7A 3C 8P Through 199 Tons, Or 150'Of Boom (Including Jib With Attachments) King Power Equipment Operators Cranes: 200 tons- 299 $59.88 7A 3C 8P tons, or 250' of boom including jib with attachments King Power Equipment Operators Cranes: 300 tons and $60.47 7A 3C 8P over or 300' of boom including jib with attachments King Power Equipment Operators Cranes: 45 Tons $58.69 7A 3C 8P Through 99 Tons, Under 150'Of Boom (including Jib With Attachments) King Power Equipment Operators Cranes: A-frame- 10 $55.21 7A 3C 8P Tons And Under King Power Equipment Operators Cranes: Friction cranes $59.88 7A 3C 8P through 199 tons King Power Equipment Operators Cranes: Through 19 $57.72 7A 3C 8P Tons With Attachments A-frame Over 10 Tons King Power Equipment Operators Crusher $58.17 7A 3C 8P King Power Equipment Operators Deck Engineer/deck $58.17 7A 3C 8P Winches (power) King Power Equipment Operators Derricks, On Building $58.69 7A 3C 8P Work King Power Equipment Operators Dozers D-9 Et Under $57.72 7A 3C 8P King Power Equipment Operators Drill Oilers: Auger Type, $57.72 7A 3C 8P Truck Or Crane Mount King Power Equipment Operators Drilling Machine $59.28 7A 3C 8P King _Power Equipment Operators Elevator And Man-lift: $55.21 7A 3C 8P Permanent And Shaft Type King Power Equipment Operators Finishing Machine, $58.17 7A 3C 8P Bidwell And Gamaco Et Similar Equipment King Power Equipment Operators Forklift: 3000 Lbs And $57.72 7A 3C 8P Over With Attachments King Power Equipment Operators Forklifts: Under 3000 $55.21 7A 3C 8P Lbs. With Attachments King Power Equipment Operators Grade Engineer: Using $58.17 7A 3C 8P Blue Prints, Cut Sheets, Etc https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 9 of 20 King jPower Equipment Operators Gradechecker/stakeman $55.21 7A 3C 8P King Power Equipment Operators Guardrail Punch $58.17 7A 3C 8P King Power Equipment Operators Hard Tail End Dump $58.69 7A X 8P Articulating Off- Road Equipment 45 Yards. & Over King Power Equipment Operators Hard Tail End Dump $58.17 7A 3C 8P Articulating Off-road Equipment Under 45 Yards King Power Equipment Operators Horizontal/directional $57.72 7A 3C 8P Drill Locator King Power Equipment Operators Horizontal/directional $58.17 7A 3C 8P Drill Operator King Power Equipment Operators Hydralifts/boom Trucks $57.72 7A 3C 8P Over 10 Tons King Power Equipment Operators Hydralifts/boom Trucks, $55.21 7A 3C 8P 10 Tons And Under King Power Equipment Operators Loader, Overhead 8 $59.28 7A 3C 8P Yards. Et Over King Power Equipment Operators Loader, Overhead, 6 $58.69 7A 3C 8P Yards. But Not Including 8 Yards King Power Equipment Operators Loaders, Overhead $58.17 7A 3C 8P Under 6 Yards King Power Equipment Operators Loaders, Plant Feed $58.17 7A 3C 8P King Power Equipment Operators Loaders: Elevating Type $57.72 7A 3C 8P Belt King Power Equipment Operators Locomotives, All $58.17 7A 3C 8P King Power Equipment Operators Material Transfer Device $58.17 7A 3C 8P King Power Equipment Operators Mechanics, All (leadmen $59.28 7A 3C 8P - $0.50 Per Hour Over Mechanic) King Power Equipment Operators Motor Patrol Graders $58.69 7A 3C 8P King Power Equipment Operators Mucking Machine, Mole, $58.69 7A 3C 8P Tunnel Drill, Boring, Road Header And/or Shield King Power Equipment Operators Oil Distributors, Blower $55.21 7A 3C 8P Distribution Et Mulch Seeding Operator King _Power Equipment Operators Outside Hoists $57.72 7A 3C 8P (elevators And Manlifts), Air Tuggers,strato King Power Equipment Operators Overhead, Bridge Type $58.17 7A 3C 8P Crane: 20 Tons Through 44 Tons King Power Equipment Operators Overhead, Bridge Type: $59.28 7A 3C 8P 100 Tons And Over King Power Equipment Operators Overhead, Bridge Type: $58.69 7A 3C 8P 45 Tons Through 99 Tons https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 10 of 20 King jPower Equipment Operators Pavement Breaker $55.21 7A 3C 8P King Power Equipment Operators Pile Driver (other Than $58.17 7A 3C 8P Crane Mount) King Power Equipment Operators Plant Oiler-Asphalt, $57.72 7A 3C 8P Crusher King Power Equipment Operators Posthole Digger, $55.21 7A 3C 8P Mechanical King Power Equipment Operators Power Plant $55.21 7A 3C 813 King Power Equipment Operators Pumps - Water $55.21 7A 3C 8P King Power Equipment Operators Quad 9, Hd 41, D10 And $58.69 7A 3C 8P Over King Power Equipment Operators Quick Tower - No Cab, $55.21 7A 3C 8P Under 100 Feet In Height Based To Boom King Power Equipment Operators Remote Control $58.69 7A 3C 8P Operator On Rubber Tired Earth Moving Equipment King Power Equipment Operators Rigger And Bellman $55.21 7A 3C 8P King Power Equipment Operators Rigger/Signal Person, $57.72 7A 3C 8P Bellman (Certified) King Power Equipment Operators Rollagon $58.69 7A 3C 8P King Power Equipment Operators Roller, Other Than Plant $55.21 7A 3C 8P Mix King Power Equipment Operators Roller, Plant Mix Or $57.72 7A 3C 8P Multi-lift Materials King Power Equipment Operators Roto-mill, Roto-grinder $58.17 7A 3C 8P King Power Equipment Operators Saws - Concrete $57.72 7A 3C 8P King Power Equipment Operators Scraper, Self Propelled $58.17 7A 3C 8P Under 45 Yards King Power Equipment Operators Scrapers - Concrete & $57.72 7A 3C 8P Carry All King Power Equipment Operators Scrapers, Self- $58.69 7A 3C 8P propelled: 45 Yards And Over King Power Equipment Operators Service Engineers - $57.72 7A 3C 8P Equipment King Power Equipment Operators Shotcrete/gunite $55.21 7A 3C 8P Equipment King Power Equipment Operators Shovel , Excavator, $57.72 7A 3C 8P Backhoe, Tractors Under 15 Metric Tons. King Power Equipment Operators Shovel, Excavator, $58.69 7A 3C 8P Backhoe: Over 30 Metric Tons To 50 Metric Tons King Power Equipment Operators Shovel, Excavator, $58.17 7A 3C 8P Backhoes, Tractors: 15 To 30 Metric Tons King Power Equipment Operators Shovel, Excavator, $59.28 7A 3C 8P Backhoes: Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators $59.88 7A 3C 8P hups:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 11 of 20 Shovel, Excavator, Backhoes: Over 90 Metric Tons King Power Equipment Operators Slipform Pavers $58.69 7A 3C 8P King Power Equipment Operators Spreader, Topsider & $58.69 7A 3C 8P Screedman King Power Equipment Operators Subgrader Trimmer $58.17 7A 3C 8P King Power Equipment Operators Tower Bucket Elevators $57.72 7A 3C 8P King Power Equipment Operators Tower Crane Up To 175' $59.28 7A 3C 8P In Height Base To Boom King Power Equipment Operators Tower Crane: over 175' $59.88 7A 3C 8P through 250' in height, base to boom King Power Equipment Operators Tower Cranes: over 250' $60.47 7A 3C 8P in height from base to boom King Power Equipment Operators Transporters, All Track $58.69 7A 3C 8P Or Truck Type "King Power Equipment Operators Trenching Machines $57.72 7A 3C 8P King Power Equipment Operators Truck Crane $58.17 7A 3C 8P Oiler/driver- 100 Tons And Over King Power Equipment Operators Truck Crane $57.72 7A 3C 8P Oiler/driver Under 100 Tons King Power Equipment Operators Truck Mount Portable $58.17 7A 3C 8P Conveyor King Power Equipment Operators Welder $58.69 7A 3C 8P King Power Equipment Operators Wheel Tractors, Farman $55.21 7A 3C 8P Type King Power Equipment Operators Yo Yo Pay Dozer $58.17 7A 3C 8P King Power Equipment Asphalt Plant Operators $58.69 7A 3C 8P Operators- Underground Sewer I# Water King Power Equipment Assistant Engineer $55.21 7A 3C 8P Operators- Underground Sewer Ft Water King Power Equipment Barrier Machine (zipper) $58.17 7A 3C 8P Operators- Underground Sewer £t Water King Power Equipment Batch Plant Operator, $58.17 7A 3C 8P Operators- Underground Concrete Sewer It Water King Power Equipment Bobcat $55.21 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Brokk- Remote $55.21 7A 3C 8P Operators- Underground Demolition Equipment Sewer Et Water King Power Equipment Brooms $55.21 7A 3C 8P Operators- Underground Sewer & Water King Bump Cutter $58.17 7A 3C 8P https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 12 of 20 Power Equipment Operators- Underground Sewer Et Water King Power Equipment Cableways $58.69 7A 3C 8P Operators- Underground Sewer Et Water King Power E ui meat Chipper $58.17 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Compressor $55.21 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Concrete Pump: Truck $58.69 7A 3C 8P Operators- Underground Mount With Boom Sewer Et Water Attachment Over 42 M King Power Equipment Concrete Finish Machine $55.21 7A 3C 8P Operators- Underground -laser Screed Sewer Et Water King Power Equipment Concrete Pump - $57.72 7A 3C 8P Operators- Underground Mounted Or Trailer High Sewer Et Water Pressure Line Pump, Pump High Pressure. King Power Equipment Concrete Pump: Truck $58.17 7A 3C 8P Operators Underground Mount With Boom Sewer Et Water Attachment Up To 42m King Power Equipment Conveyors $57.72 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Cranes Friction: 200 $60.47 7A 3C 8P Operators- Underground tons and over Sewer Et Water King Power Equipment Cranes: 20 Tons $58.17 7A 3C 8P Operators- Underground Through 44 Tons With Sewer Et Water Attachments King Power Equipment Cranes: 100 Tons $59.28 7A 3C 8P Operators- Underground Through 199 Tons, Or Sewer Et Water 150'Of Boom (Including Jib With Attachments) King Power Equipment Cranes: 200 tons- 299 $59.88 7A 3C 8P Operators- Underground tons, or 250' of boom Sewer Et Water including jib with attachments King Power Equipment Cranes: 300 tons and $60.47 7A 3C 8P Operators- Underground over or 300' of boom Sewer Et Water including jib with attachments King Power Equipment Cranes: 45 Tons $58.69 7A 3C 8P Operators- Underground Through 99 Tons, Under Sewer Et Water 150'Of Boom (including Jib With Attachments) King Power Equipment Cranes: A-frame - 10 $55.21 7A 3C 8P Operators- Underground Tons And Under Sewer Et Water King Cranes: Friction cranes $59.88 7A 3C 8P through 199 tons https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 13 of 20 Power Equipment Operators- Underground Sewer &Water King Power Equipment Cranes: Through 19 $57.72 7A 3C 8P Operators- Underground Tons With Attachments Sewer Et Water A-frame Over 10 Tons King Power Equipment Crusher $58.17 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Deck Engineer/deck $58.17 7A 3C 8P Operators- Underground Winches (power) Sewer Et Water King Power Equipment Derricks, On Building $58.69 7A 3C 8P Operators Underground Work Sewer Et Water King Power Equipment Dozers D-9 £t Under $57.72 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Drill Oilers: Auger Type, $57.72 7A 3C 8P Operators- Underground Truck Or Crane Mount Sewer Et Water King Power Equipment Drilling Machine $59.28 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Elevator And Man-lift: $55.21 7A 3C 8P Operators- Underground Permanent And Shaft Sewer Et Water Type King Power Equipment Finishing Machine, $58.17 7A 3C 8P Operators- Underground Bidwell And Gamaco Et Sewer Et Water Similar Equipment King Power Equipment Forklift: 3000 Lbs And $57.72 7A 3C 8P Operators- Underground Over With Attachments Sewer Et Water King Power Equipment Forklifts: Under 3000 $55.21 7A 3C 8P Operators- Underground Lbs. With Attachments Sewer Et Water King Power Equipment Grade Engineer: Using $58.17 7A 3C 8P Operators- Underground Blue Prints, Cut Sheets, Sewer Et Water Etc King Power Equipment Gradechecker/stakeman $55.21 7A 3C 8P Operators- Underground Sewer Et Water King Power E ui ment Guardrail Punch $58.17 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Hard Tail End Dump $58.69 7A 3C 8P Operators- Underground Articulating Off- Road Sewer Et Water Equipment 45 Yards. Et Over King Power Equipment Hard Tail End Dump $58.17 7A 3C 8P Operators- Underground Articulating Off-road Sewer Et Water Equipment Under 45 Yards King Horizontal/directional $57.72 7A 3C 8P Drill Locator https:Hfortress.wa.gov/lni/wagelookup/PrvWagelookup.aspx 7/20/2017 Page 14 of 20 Power Equipment Operators- Underground Sewer &Water King Power Equipment Horizontal/directional $58.17 7A 3C 8P Operators- Underground Drill Operator Sewer &Water King Power Equipment Hydralifts/boom Trucks $57.72 7A 3C 8P Operators- Underground Over 10 Tons Sewer Et Water King Power Equipment Hydralifts/boom Trucks, $55.21 7A 3C 8P Operators- Underground 10 Tons And Under Sewer Et Water King Power Equipment Loader, Overhead 8 $59.28 7A 3C 8P Operators- Underground Yards. Et Over Sewer Et Water King Power Equipment Loader, Overhead, 6 $58.69 7A 3C 8P Operators- Underground Yards. But Not Including Sewer Et Water 8 Yards King Power Equipment Loaders, Overhead $58.17 7A 3C 8P Operators- Underground Under 6 Yards Sewer & Water King Power Equipment Loaders, Plant Feed $58.17 7A 3C 8P Operators- Underground Sewer & Water King Power Equipment Loaders: Elevating Type $57.72 7A 3C 8P Operators- Underground Belt Sewer &Water King Power Equipment Locomotives, All $58.17 7A 3C 8P Operators- Underground Sewer & Water King Power Equipment Material Transfer Device $58.17 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Mechanics, All (leadmen $59.28 7A 3C 8P Operators- Underground - $0.50 Per Hour Over Sewer Et Water Mechanic) King Power Equipment Motor Patrol Graders $58.69 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Mucking Machine, Mole, $58.69 7A 3C 8P Operators- Underground Tunnel Drill, Boring, Sewer & Water Road Header And/or Shield King Power Equipment Oil Distributors, Blower $55.21 7A 3C 8P Operators Underground Distribution &Mulch Sewer &Water Seeding Operator King Power Equipment Outside Hoists $57.72 7A 3C 8P Operators- Underground (elevators And Sewer & Water Manlifts), Air Tuggers,strato King Power Equipment Overhead, Bridge Type $58.17 7A 3C 8P Operators- Underground Crane: 20 Tons Through Sewer & Water 44 Tons King Overhead, Bridge Type: $59.28 7A 3C 8P 100 Tons And Over https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 15 of 20 Power Equipment Operators- Underground Sewer it Water King Power Equipment Overhead, Bridge Type: $58.69 7A 3C 8P Operators Underground 45 Tons Through 99 Sewer Et Water Tons King Power Equipment Pavement Breaker $55.21 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Pile Driver (other Than $58.17 7A 3C 8P Operators- Underground Crane Mount) Sewer Et Water King Power Equipment Plant Oiler-Asphalt, $57.72 7A 3C 8P Operators- Underground Crusher Sewer Et Water King Power Equipment Posthole Digger, $55.21 7A 3C 8P Operators- Underground Mechanical Sewer Et Water King Power Equipment Power Plant $55.21 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Pumps - Water $55.21 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Quad 9, Hd 41, D10 And $58.69 7A 3C 8P Operators- Underground Over Sewer Et Water King Power Equipment Quick Tower - No Cab, $55.21 7A 3C 8P Operators- Underground Under 100 Feet In Sewer Et Water Height Based To Boom King Power Equipment Remote Control $58.69 7A 3C 8P Operators- Underground Operator On Rubber Sewer Et Water Tired Earth Moving Equipment King Power Equipment Rigger And Bellman $55.21 7A 3C 8P Operators- Underground Sewer & Water King Power Equipment Rigger/Signal Person, $57.72 7A 3C 8P Operators- Underground Bellman (Certified) Sewer Et Water King Power Equipment Rollagon $58.69 7A 3C 8P Operators- Underground Sewer it Water King Power Equipment Roller, Other Than Plant $55.21 7A 3C 8P Operators- Underground Mix Sewer £t Water King Power Equipment Roller, Plant Mix Or $57.72 7A 3C 8P Operators- Underground Multi-lift Materials Sewer Et Water King Power Equipment Roto-mill, Roto-grinder $58.17 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Saws - Concrete $57.72 7A 3C 8P Operators- Underground Sewer Et Water https:Hfortress.wa.gov/lni/wagelookup/PrvWagelookup.aspx 7/20/2017 Page 16 of 20 King Power Equipment Scraper, Self Propelled $58.17 7A 3C 8P Operators- Underground Under 45 Yards Sewer &Water King Power Equipment Scrapers - Concrete & $57.72 7A 3C 8P Operators- Underground Carry All Sewer & Water King Power Equipment Scrapers, Self- $58.69 7A 3C 8P Operators- Underground propelled: 45 Yards And Sewer Er Water Over King Power Equipment Service Engineers - $57.72 7A 3C 8P Operators- Underground Equipment Sewer Et Water King Power Equipment Shotcrete/gunite $55.21 7A 3C 8P Operators- Underground Equipment Sewer Et Water King Power Equipment Shovel , Excavator, $57.72 7A 3C 8P Operators- Underground Backhoe, Tractors Sewer & Water Under 15 Metric Tons. King Power Equipment Shovel, Excavator, $58.69 7A 3C 8P Operators- Underground Backhoe: Over 30 Metric Sewer Et Water Tons To 50 Metric Tons King Power Equipment Shovel, Excavator, $58.17 7A 3C 8P Operators- Underground Backhoes, Tractors: 15 Sewer 8 Water To 30 Metric Tons King Power Equipment Shovel, Excavator, $59.28 7A 3C 8P Operators- Underground Backhoes: Over 50 Sewer Et Water Metric Tons To 90 Metric Tons King Power Equipment Shovel, Excavator, $59.88 7A 3C 8P Operators- Underground Backhoes: Over 90 Sewer &Water Metric Tons King Power Equipment Slipform Pavers $58.69 7A 3C 8P Operators- Underground Sewer&Water King Power Equipment Spreader, Topsider & $58.69 7A 3C 8P Operators- Underground Screedman Sewer &Water King Power Equipment Subgrader Trimmer $58.17 7A 3C 8P Operators- Underground Sewer & Water King Power Equipment Tower Bucket Elevators $57.72 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Tower Crane Up To 175' $59.28 7A 3C 8P Operators- Underground In Height Base To Boom Sewer Et Water King Power Equipment Tower Crane: over 175' $59.88 7A 3C 8P Operators- Underground through 250' in height, Sewer & Water base to boom King Power Equipment Tower Cranes: over 250' $60.47 7A 3C 8P Operators- Underground in height from base to Sewer&Water boom King Power Equipment Transporters, All Track $58.69 7A 3C 8P Operators- Underground Or Truck Type Sewer It Water https://fortress.wa.gov/lni/wageIookup/prvWagelookup.aspx 7/20/2017 Page 17 of 20 King Power Equipment Trenching Machines $57.72 7A 3C 8P Operators- Underground Sewer &Water King Power Equipment Truck Crane $58.17 7A 3C 8P Operators- Underground Oiler/driver - 100 Tons Sewer i*Water And Over King Power Equipment Truck Crane $57.72 7A 3C 8P Operators- Underground Oiler/driver Under 100 Sewer Et Water Tons King Power Equipment Truck Mount Portable $58.17 7A 3C 8P Operators- Underground Conveyor Sewer & Water King Power Equipment Welder $58.69 7A 3C 8P Operators- Underground Sewer Et Water King Power Equipment Wheel Tractors, Farmall $55.21 7A 3C 8P Operators- Underground Type Sewer Et Water King Power Equipment Yo Yo Pay Dozer $58.17 7A 3C 8P Operators- Underground Sewer Et Water King Power Line Clearance Tree Journey Level In Charge $48.54 5A 4A Trimmers King Power Line Clearance Tree Spray Person $46.03 5A 4A Trimmers King Power Line Clearance Tree Tree Equipment $48.54 5A 4A Trimmers Operator King Power Line Clearance Tree Tree Trimmer $43.32 5A 4A Trimmers King Power Line Clearance Tree Tree Trimmer $32.68 5A 4A Trimmers Groundperson King Refrigeration Et Air Journey Level $75.36 6Z 1G Conditioning Mechanics King Residential Brick Mason Journey Level $54.32 5A 1M King Residential Carpenters Journey Level $28.20 1 King Residential Cement Masons Journey Level $22.64 1 King Residential Drywall Journey Level $41.69 5D 4C Applicators King Residential D[y all Tapers Journey Level $55.66 5P 1E King Residentiat Electricians Journey Level $30.44 1 King Residential Glaziers Journey Level $39.40 7L 1 H King Residential Insulation Journey Level $26.28 1 Applicators 'King Residential Laborers Journey Level $23.03 1 King Residential Marble Setters Journey Level $24.09 1 King Residential Painters Journey Level $24.46 1 King Residential Plumbers E Journey Level $34.69 1 Pipefitters King Residential Refrigeration & Journey Level $75.36 6Z 1G Air Conditioning Mechanics King Residential Sheet Metal Journey Level (Field or $45.99 7F 9 R Workers Shop) https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 18 of 20 King Residential Soft Floor Journey Level $45.86 5A 3D Lavers King Residential Sprinkler Fitters Journey Level $44.98 5C 3R (Fire Protection) King Residential Stone Masons Journey Level $54.32 5A 1M King Residential Terrazzo Journey Level $50.26 5A 1M Workers King Residential Terrazzo/Tile Journey Level $21.46 1 Finishers King Residential Tile Setters Journey Level $25.17 1 King Roofers Journey Level $47.51 5A 3H King Roofers Using Irritable $50.51 5A 3H Bituminous Materials King Sheet Metal Workers Journey Level (Field or $75.46 7F 1 E Shop) King Shipbuilding £t Ship Repair Boilermaker $41.72 7M 1H King Shipbuilding Et Ship Repair Carpenter $41.06 7T 2B King Shipbuilding & Ship Repair Electrician $41.09 7T 4B King Shipbuilding& Ship Repair Heat &t Frost Insulator $65.68 5.1 4H King Shipbuilding & Ship Repair Laborer $41.08 7T 4B King Shipbuilding Et Ship Repair Machinist $41.32 7T 413 King Shipbuilding Et Ship Repair Operator $41.03 7T 413 King Shipbuilding& Ship Repair Painter $41.05 7T 4B King Shipbuilding & Ship Repair Pipefitter $41.05 7T 4B King Shipbuilding &t Ship Repair Rigger $41.12 7T 4B King Shipbuilding & Ship Repair Sheet Metal $41.04 7T 4B King Shipbuilding Ft Ship Repair Shipfitter $41.12 7T 4B King Shipbuilding & Ship Repair Trucker $41.26 7T 4B King Shipbuilding & Ship Repair Warehouse $41.02 7T 4B King Shipbuilding & Ship Repair Welder/Burner $41.12 7T 4B King Sign Makers & Installers Sign Installer $22.92 1 (Electrical) King Sign Makers &t Installers Sign Maker $21.36 1 (Electrical) King Sign Makers Et Installers Sign Installer $27.28 1 (Non-Electrical} King Sign Makers & Installers Sign Maker $33.25 1 (Non-Electrical? King Soft Floor Lavers Journey Level $45.86 5A 3D King Solar Controls For Windows Journey Level $12.44 1 King Sprinkler Fitters (Fire Journey Level $72.89 5C 1X Protection) King Stage Rigging Mechanics Journey Level $13.23 1 (Non Structural! King Stone Masons Journey Level $54.32 5A 1M King Street And Parking Lot Journey Level $19.09 1 Sweeper Workers King Surveyors Assistant Construction $57.72 7A 3C 5P Site Surveyor King Surveyors Chainman $57.17 7A 3C 8P https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 19 of 20 King Surveyors Construction Site $58.69 7A 3C 8P Surveyor King Telecommunication Journey Level $22.76 1 Technicians King Telephone Line Cable Splicer $38.84 5A 2B Construction - Outside King Telephone Line Hole Digger/Ground $21.45 5A 2B Construction - Outside Person King Telephone Line Installer (Repairer) $37.21 5A 2B Construction - Outside King Telephone Line Special Aparatus $38.84 5A 2B Construction - Outside Installer King Telephone Line Special Apparatus $38.03 5A 2B Construction - Outside Installer II King Telephone Line Telephone Equipment $38.84 5A 2B Construction - Outside Operator (Heavy) King Telephone Line Telephone Equipment $36.09 5A 2B Construction - Outside Operator (Light) King Telephone Line Telephone Lineperson $36.09 5A 2B Construction - Outside King Telephone Line Television $20.33 5A 2B Construction - Outside Groundperson King Telephone Line Television $27.21 5A 2B Construction - Outside Lineperson/Installer King Telephone Line Television System $32.55 5A 2B Construction - Outside Technician King Telephone Line Television Technician $29.18 5A 2B Construction - Outside King Tele hoe ne Line Tree Trimmer $36.09 5A 2B Construction - Outside King Terrazzo Workers Journey Level $50.26 5A 1M King Tile Setters Journey Level $21.65 1 King Tile, Marble 8 Terrazzo Finisher $41.09 5A 1B Finishers King Traffic Control Stripers Journey Level $44.85 7A 1K King Truck Drivers Asphalt Mix Over 16 $52.70 5D 3A 8L Yards (W. WA-Joint Council 28) King Truck Drivers Asphalt Mix To 16 Yards $51.86 5D 3A 8L (W. WA-Joint Council 28) King Truck Drivers Dump Truck I*Trailer $52.70 5D 3A 8L King Truck Drivers Dump Truck (W. WA- $51.86 5D 3A 8L Joint Council 28) King Truck Drivers Other Trucks (W. WA- $52.70 5D 3A 8L Joint Council 28) King Truck Drivers Transit Mixer $43.23 1 King Well Drillers Et Irrigation Irrigation Pump Installer $17.71 1 Pum Ine stalters King Well Drillers & Irrigation Oiler $12.97 1 Pump Installers King Well Driller $18.00 1 https:Hfortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 7/20/2017 Page 20 of 20 Well Pumi) installers Diliters Et Irrigation https://fortress.wa.gov/lni/Wagelookup/PrvWagelookup.aspx 7/20/2017 R L I Cb!C POWER OF ATTORNEY an RI'l Company RLI Insurance Com parry 9025 N.Lindbergh Dr.I Peoria,11,61615 Contractors Bonding and Insurance Company Phone:(800)645-2402 1 Fax:(309)689-2036 Know All Men by'lliese Presents: That this Power of Attorney is not valid or in effect unless attached to the bond which it authorizes executed, but may be detached by the approving officer if desired. That this Power of Attorney may be effective and given to either or both of RIA Insurance Company and Contractors Bonding and Insurance Company,required for the applicable bond. That RLI Insurance Company and/or Contractors Bonding and Insurance Company, each Illinois corporations (as applicable), each authorized and licensed to do business in all states and the District of Columbia do hereby make,constitute and appoint: Ben'amin M.Houk.Drake G.Nicholson,Tiffany Kargavicius.Cindy Chambers,Kim Wenrich,Eric Belgau,Tandv Hepner,Gretchen Flenrie,Mallori Peck,Billie Stuart, iointly or severaliv in the City of Olympia , State of Washington as Attorney in Fact,with full power and authority hereby conferred upon him/her to sign, execute, acknowledge and deliver for and on its behalf as Surety, in general, ally and all bonds, undertakings, and recognizances in all amount not to exceed Ten Million Dollars $10,000,000.00 )for any single obligation. The acknowledgment and execution of such bond by the said Attorney in Fact shall be as binding, upon this Company as if such bond had been executed and acknowledged by the regularly elected officers of this Company. RLI Insurance Company and Contractors Bonding and Insurance Company, as applicable, have each further certified that the following is a true and exact copy of the Resolution adopted by the Board of Directors of each such corporation,and now in force,to-wit: ......................................................... ............ "All bonds, policies, undertakings, Powers of Attorney or other obligations of the Corporation shall be executed in the corporate name of the Corporation by the President,,Secretary,any Assistant Secretary,Treasurer,or any Vice President,or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or Agents who shall have authority to issue bonds, policies or undertakings in the name of the Corporation. The corporate seal is not necessary for the validity of any bonds, policies, undertakings,Powers of Attorney or other obligations of the Corporation. The signature of any such officer and the corporate seal may be printed by facsimile or other electronic image." ............ .............._­­­........................ IN WITNESS WHEREOF, RLI Insurance Company and/or Contractors Bonding and Insurance Company,as applicable, have caused these presents to be executed by its respective Vice President with its corporate seal affixed this J1 day of June,-201 Z. " RLI Insurance Company o Contractors Bonding and Insurance Company A Nolev"" 11`` ;0 �, U A , Y j State of Illinois S E A 1 SEAL Barton W.Davis Vice President SS County of Peoria CERTIFICATE On this 5th day of June 2017 1, the undersigned officer of RLI Insurance Company, and/or before tile, a Notary Public, personally appeared Barton W. Davis Contractors Bonding and Insurance Company, each Illinois who being by me duty sworn,acknowledged that he signed the above Power corporations, do hereby certify that the attached PoNver of Attorney is or Attorney as the atbresaid officer of the RLI Insurance Company and/or in full force and effect and is irrevocable; and furthennore, that the Contractors Bonding and Insurance Company, and acknowledged said Resolution of the Company as set forth in the Power of Attorney, is instrument to be the voluntary act and deed of'said corporation. no",in 6orce. In testimony whereof,I have hereunto set my hand and the seal of the RIA Insurance C and/or Cntrac ors upany tjlllgy�day of &V o Bonding and Insurance Coi RLI Insurance Company V Gretchen L.Jolinigk Notary Public Contractors on and Ins ranee Company k ,r). k/. G RETCH T EN L JOHNIGK,R 'MT T 'OFPICLALSEAL B n W arto .Davis Vice P Aresident .er ! .A.�. a').....M. Ccj&%�anx pres 'axXN ymMay 28,2020 4675336020212 A00591 IS RLI® Contractors Bonding and Insurance Company 9025 N.Lindbergh Dr.Peoria,IL 61615 Performance and Payment Bond P.O.Box 3967 Peoria,IL 61612-3967 Phone: 309-692-1000 Fax: 309-683-1610 (Public Work) Bond Number: RC60006307 Premium: KNOW ALL PERSONS BY THESE PRESENTS,That we, Christensen Inc. General Contractor , called the Principal, and Contractors Bonding and Insurance Company , an Illinois corporation,called the Surety, are held and firmly bound unto City of Kent , called the Obligee, in the sum of Twenty Eight Thousand Five Hundred Ninety Four and 50/100 Dollars (s 28,594.50 ) for the payment whereof said Principal and Surety bind themselves firmly by these presents. WHEREAS, the Principal has entered into a Contract with the Obligee dated 7/26/2017 to perform construction work at the City of Kent Legal Department Tenant Improvement Project ("Contract"). NOW,THEREFORE,the condition of this obligation is such that if the Principal shall promptly and faithfully perform the construction work to be performed under the Contract and shall promptly make payment to all Claimants, as hereinafter defined, for all labor and material used, consumed or incorporated in the performance of the work under the Contract,then this obligation shall be null and void; otherwise to remain in full force and effect. Whenever Principal shall be,and be declared by Obligee to be in default under the Contract for failing to perform the construction work, the Obligee having performed Obligee's obligations thereunder, Surety shall, within a reasonable time: 1. Upon entering into an acceptable takeover agreement with the Obligee, undertake to complete the construction work to be done under the Contract; or 2. Obtain bids or negotiated proposals from qualified contractors for completion of the construction work to be done under the Contract, and arrange for a contract to be prepared for execution by the Obligee and the contractor, to be secured with a performance and payment bond executed by a qualified surety; or 3. Waive its right to perform and complete, arrange for completion, or obtain a new contractor. 4. The Contract balance, as defined below, shall be credited against the reasonable cost of completing the construction work to be performed under the Contract.If completed by the Obligee pursuant to paragraphs .2 or 3 above, and the reasonable cost of completing the construction work exceeds the Contract balance, the Surety shall pay to the Obligee such excess, but in no event shall the aggregate liability of the Surety exceed the amount of this bond. If the Surety completes the work pursuant to paragraph 1 above, that portion of the Contract balance as may be required to complete the construction work to be done under the Contract and to reimburse the Surety for its outlays shall be paid to the Surety at the times and in the manner as said sums would have been payable to Principal had there been no default under the Contract. To the extent that the Surety's outlays exceed the Contract balance paid to Surety by Obligee, the Surety shall be entitled to a dollar for dollar reduction of its liability under this bond, and the Surety's aggregate liability shall not exceed the penal sum of this bond. The term "Contract balance" as used herein shall mean the total amount payable to Obligee under the Contract and any amendments thereto, less the amounts properly paid by Obligee to the Principal under the Contract.The term "construction work," as used herein shall mean the providing by the Principal of all labor and/or material necessary to complete the Principal's scope of work under the Contract. Notwithstanding any language in the Contract to the contrary, the Surety shall not be liable to the Obligee or others for obligations of the Principal that are unrelated to the performance of the work under the Contract,and the Contract balance shall not be reduced or set off on account of any such unrelated obligations, nor for any related obligations that would not be covered under this bond. S. Any suit by the Obligee under this bond must be instituted before the earlier of: (a) the expiration of one year from the date of substantial completion of the work, or (b) one year after the Principal ceased performing the construction work under the Contract. If this bond is provided to comply with pubic works bond statutes in the location where the construction work is being performed and the public works bond statutes contain a statute of limitations for suits on the performance bond, then the limitation period set forth herein shall be read out of this bond and the statute of limitation set forth in the public works bond statutes shall be read into this bond. If the limitation set forth in this bond is void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 0006s_CBIC BndPerPyPuW.01-040112 6. A Claimant is defined as one other than the Obligee having a contract with the Principal or with a direct Contractor of the Principal to supply labor and/or materials and said labor and/or materials are actually used, consumed or incorporated in the performance of the construction work, 7. The above-named Principal and Surety hereby jointly and severally agree with the Obligee that every Claimant as herein defined who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the last of such Claimant's work or labor was done or performed or materials were furnished by such Claimant, may bring suit on this bond, prosecute the suit to final judgment for the amount due under Claimant's contract for the labor and/or materials supplied by the Claimant which were used, consumed or incorporated in performance of the construction work, and have execution thereon; provided, however,that Claimant having a direct contractual relationship with a Contractor of the Principal shall have a right of action on this bond only if said Claimant notifies the Surety in writing of its claim within ninety (90) days from the date on which said Claimant did or performed the last labor and/or materials for which the claim is made.The Obligee shall not be liable for the payment of any costs or expenses of any such suit. 8, No suit or action shall be commenced hereunder by any Claimant after the expiration of one years after the day on which the Claimant last supplied the labor and/or materials for which the claim is made or (b) the limitation period set forth in the public work bond statutes if any, in the location where the construction work is being preformed. Any limitation contained in this bond, which is prohibited by any law controlling in the state where the suit is filed, shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by the law of that state. 9. No suit or action shall be commenced hereunder by the Obligee or any Claimant other than in a state court of competent jurisdiction in the county or other political subdivision of the state in which the project, or any part thereof, is situated, or in the United States District Court for the district in which the project, or any part thereof, is situated, and not elsewhere. 10. The arnount of this bond shall be reduced by and to the extent of any payment or payments made by Surety in good faith hereunder whether made directly to Obligee or Claimant(s) or otherwise in discharge of Principal's obligations.The Surety's liability hereunder to the Obligee and all Claimants is limited,singly, or in the aggregate, to the penal sum of the bond set forth herein.The Surety may, at its option, discharge all obligations under this bond by interpleading into the registry of any court of competent jurisdiction of the full unused penal sum of this bond, or such portion thereof that will satisfy the obligations owed to the Obligee and/or the Clairnant(s).No right of action shall accrue on this bond to any person or entity other than the Obligee and/or the Claimant(s). The bond shall not be liable for any liability of Principal for tortious acts, whether or riot said liability is direct or is imposed by the Contract, and shall not serve as or be a substitute for or Supplemental to any liability or other insurance required by the Contract. 11. If this bond is provided to comply with a statutory or other legal requirement for performing construction contracts for public owners in the location where the construction work is being performed, all provisions in the bond are in addition to or differ from those statutory or legal requirements shall be read out of this bond, and all pertinent statutes and other legal requirements shall be read into the bond. Signed and sealed this 4th -,.-,day of.Aul ust AG AND/& aa. .00 0 0 Christensen Inc. General Contractor Contractors Bonding and lnwrance-Ca�itpany (Principal's Name) ILLIN05 B y,:— By:, Tiff ny al aVi iUS,Attorney-in-fact Its: President C0068 CBIC BndPerPyPuW.01-040112 EXHIBIT lk,hristensen Inc. ( ; f J V4 1 d�A l � \_, C,' ( .) N -F 11" c = 'F (:.) d 29-10 ('rites ,Strcct S\V :etc 100 'Funiwatcr '+VA 98,512 360 709-0330 FAX t-360 7(31)-0220 BID PROPOSAL Proposal Submitted To: Phone: City of Kent 253-856-5084 N-Cslgry kentwa_clov Street: Project Name. Dates 400 West Gowe Law Dept TI 6/30/2017 City, State &Zip Code: Project Location: Kent WA 98032 City Hall Fourth Floor SCOPE OF WORK: Fourth Floor Office Reconfiguration Tenant Improvement Dust proff, demo,framing, drywall, electrical and data re-route, relocate lighting, paint, relocate one (1) door, add one (1) new door, in fill, owner provided carpet, rubber base. WE PROPOSE hereby to furnish material and labor-complete in accordance with the above specifications,for the sum of: Estimate excludes permits and fees,temporary power,utility hookups,special inspections,and anything not listed above. 25,995.00 plus sales tax. All material is guaranteed to be as specified. Ail work.Is guarameed for one year after date of Substantial Completion. All worst to be. completed In a workmanlike manner according to standard practices. Any alterations or deviation from above specifications involving extra cost will be executed only upon written orders,and will becorne an extra charge over and above the estimate. All agreements contingent upon strikes,accidents or delays,beyond our control, Owner is it)carry fare and other necessary Insurance, our workers are fully covered by workman's compensation insurance.Interest charged at l.al per month on past due accounts. If collection proceedings required,Attorney fees and other costs will be paid by the Customer. Christensen Inc.,Ceneral Contractor is registered with the State,of WA, registration no. CHR1SIG066LB as a general contractor and has posted woth the state a bond of S 10,000 for the purpose of satisfying claims against the contractor for negligent or improper work or breach of contract in the conduct of the contractor's business. The expiration date of this contractor's registration is annual on May 31. This bond may not be sufficient to cover a claim which might arise from the work done under your contract. If any supplier of material used in ymar construction project or any employee of the contractor or subcontractor is not paid by the contractor Or subcontractor on your job,a lien may be attached to your property to force payment. If you wish additional protection,you may request the contractor to provide you with original"lien release"documents from each supplier or subcontractor on your project. The contractor is required to provide you with further information about lien release documents if you request it.General information is also available from the Department of tabor anti Industries. Christensen Inc., General Contractor Acceptance of Proposal ;Authorized Signature; The above prices,specifications and conditions are satisfactory and �l are hereby accepted. -Upon acceptance a contract will be issued, This proposal may be withdrawn if not accepted in 30 days. Signature Date 7/25 20179:43 AM EXHIBIT B INSURANCE REQUIREMENTS FOR SERVICE CONTRACTS Insurance The Contractor shall procure and maintain for the duration of the Agreement, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees or subcontractors. A. Minimum Scope of Insurance Contractor shall obtain insurance of the types described below: 1. A:utomobile Liability Insurance covering all owned, non-owned, hired and leased vehicles. Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. 2. Commercial General Liability Insurance shall be written on ISO occurrence form CG 00 01 and shall cover liability arising from premises, operations, independent contractors, products-completed operations, personal Injury and advertising injury, and liability assumed under an insured contract. The Commercial General Liability insurance shall be endorsed to provide the Aggregate Per Project Endorsement ISO form CG 25 03 11 85, The City shall be named as an insured under the Contractor's Commercial General Liability Insurance policy with respect to the work performed for the City using ISO additional insured endorsement CG 20 10 1185 or a substitute endorsement providing equivalent coverage. 3. Workers' Compensation coverage as required by the Industrial Insurance laws of the State of Washington. B. Minimum Amounts of Insurance Contractor shall maintain the following insurance limits: 1. A,utomobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1,000,000 per accident. 2. Commercial General Liability Insurance shall be written with limits no less than $2,000,000 each occurrence, $2,000,000 general aggregate and a $2,000,000 products-completed operations aggregate limit. EXHIBIT B (Continued ) C. Other Insurance Provisions The insurance policies are to contain, or be endorsed to contain, the following provisions for Automobile Liability and Commercial General Liability insurance: 1. The Contractor's insurance coverage shall be primary insurance as respect the City. Any Insurance, self-insurance, or insurance pool coverage maintained by the City shall be excess of the Contractors insurance and shall not contribute with It. 2. The Contractor's insurance shall be endorsed to state that coverage shall not be cancelled by either party, except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City, 3. The City of Kent shall be named as an additional Insured on all policies (except Professional Liability) as respects work performed by or on behalf of the contractor and a copy of the endorsement naming the City as additional insured shall be attached to the Certificate of Insurance. The City reserves the right to receive a certified copy of all required insurance policies. The Contractor's Commercial General Liability insurance shall also contain a clause stating that coverage shall apply separately to each insured against whom claim is made or suit is brought, except with respects to the limits of the insurer's liability. D. Acceptability of Insurers Insurance is to be placed with Insurers with a current A.M. Best rating of not less than ANII. E. Verification of Coverage Contractor shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the Insurance requirements of the Contractor before commencement of the work. F. Subcontractors Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor. All coverages for subcontractors shall be subject to all of the same insurance requirements as stated herein for the Contractor. CHRIS01 OP ID:AS ACC7R0' DATE(MMIDDIYYYY) CERTIFICATE OF LIABILITY INSURANCE 08/11/2017 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Billie Tripp Nicholson&Associates 1802 Black Lake Blvd.SW AHD"No E,�:360-352-8444 AIc No:360-943.9712 Olympia,WA 98512 ADDRE Ben M.Houk SS:mail@nichinsure.com INSURERS AFFORDING COVERAGE NAIC p INSURER A:Associated Industries Insuranc INSURED Christensen,Inc. INSURER B:Ohio Security Insurance 24082 General Contractor 2840 Crites St SW,Suite 100 INSURER C:StarStone Specialty Insurance Tumwater,WA 98512 INSURER D INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE D e POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER MMIDDIYYYY MMIDDJYYYY A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE OCCUR X X AES1039530 06/1612017 0611612018 DAMAGE:TO HENTE15- PREMISES(Ea occurrence) $ 100,000 MED EXP(Any one person) $ 6,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY a JEC LOC PRODUCTS-COMPIOPAGG $ 2,000,000 OTHER: S AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea ccident $ 1,000,000 a A X ANY AUTO BASS7232670 06/16/2017 06/16/2018 BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURY(Par accident) $ AUTOS X NON-OWNED PROPERTY DAMA X E $ HIREDAUTOS AUTOS Per accident S X UMBRELLA LIAB X OCCUR EACH OCCURRENCE S 4,000,000 C EXCESS LIAR CLAIMS-MADE 89039R160ALI 06/16/2017 06/16/2018 AGGREGATE S 4,000,000 DED I X I RETENTION$ 10,000 S WORKERS COMPENSATION X AND EMPLOYERS'LIABILITY STATUTE ER A ANY PROPRIETORIPARTNER/EXECUTIVE Y�N WA STOP GAP AES1039530 06116/2017 06/16/2018 E.L.EACH ACCIDENT $ 1,000,000 OFFICERIMEMBER EXCLUDED? NIA (Mandatory In NH} E.L.DISEASE-EA EMPLOYE $ 1,000,000 It es,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ B Installation BM057232670 06/16/2017 06/16/2018 Limit: 915,874 Floater DESCRIPTION OF OPERATIONS!LOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached If more space is required) RE:Kent Legal Department office renovation The City of Kent its officers,officials,employees,agents and volunteers are included as Additional Insureds as their Interest may appear when required by written contract. CERTIFICATE HOLDER CANCELLATION CITY023 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Kent ACCORDANCE WITH THE POLICY PROVISIONS. 220-4th Avenue South Kent,WA 98032 AUTHORIZED REPRESENTATIVE ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014101) The ACORD name and logo are registered marks of ACORD Policy#AES1039530-Christensen Inc COMMERCIAL GENERAL LIABILITY CG88100413 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL GENERAL LIABILITY EXTENSION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART INDEX SUBJECT PAGE NON-OWNED AIRCRAFT 2 NON-OWNED WATERCRAFT 2 PROPERTY DAMAGE LIABILITY—ELEVATORS 2 EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) 2 MEDICAL PAYMENTS EXTENSION 3 EXTENSION OF SUPPLEMENTARY PAYMENTS—COVERAGES A AND B 3 ADDITIONAL INSUREDS—BY CONTRACT,AGREEMENT OR PERMIT 3 PRIMARY AND NON-CONTRIBUTORY—ADDITIONAL INSURED EXTENSION 5 ADDITIONAL INSUREDS—EXTENDED PROTECTION OF YOUR"LIMITS OF INSURANCE" 6 WHO IS AN INSURED—INCIDENTAL MEDICAL ERRORS/MALPRACTICE AND WHO IS AN INSURED— 6 FELLOW EMPLOYEE EXTENSION—MANAGEMENT EMPLOYEES NEWLY FORMED OR ADDITIONALLY ACQUIRED ENTITIES 7 FAILURE TO DISCLOSE HAZARDS AND PRIOR OCCURRENCES 7 KNOWLEDGE OF OCCURRENCE, OFFENSE, CLAIM OR SUIT 7 LIBERALIZATION CLAUSE 7 BODILY INJURY REDEFINED 7 EXTENDED PROPERTY DAMAGE 8 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US— 8 WHEN REQUIRED IN A CONTRACT OR AGREEMENT WITH YOU ©2013 Liberty Mutual Insurance CG 88 10 0413 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 1 of 8 With respect to coverage afforded by this endorsement, the provisions of the policy apply unless modified by the endorsement. A. NON-OWNED AIRCRAFT Under Paragraph 2. Exclusions of Section I—Coverage A-Bodily Injury And Property Damage Liability, exclusion g.Aircraft,Auto Or Watercraft does not apply to an aircraft provided: 1. It is not owned by any insured; 2. It is hired, chartered or loaned with a trained paid crew; 3. The pilot in command holds a currently effective certificate, issued by the duly constituted authority of the United States of America or Canada, designating her or him a commercial or airline pilot; and 4. It is not being used to carry persons or property for a charge. However, the insurance afforded by this provision does not apply if there is available to the insured other valid and collectible insurance,whether primary, excess(other than insurance written to apply specifically in excess of this policy), contingent or on any other basis,that would also apply to the loss covered under this provision. B. NON-OWNED WATERCRAFT Under Paragraph 2. Exclusions of Section I—Coverage A—Bodily Injury And Property Damage Liability, Subparagraph (2)of exclusion g.Aircraft,Auto Or Watercraft is replaced by the following: This exclusion does not apply to: (2) A watercraft you do not own that is: (a) Less than 52 feet long; and (b) Not being used to carry persons or property for a charge. C. PROPERTY DAMAGE LIABILITY—ELEVATORS 1. Under Paragraph 2. Exclusions of Section I—Coverage A—Bodily Injury And Property Damage Liability, Subparagraphs (3), (4)and (6) of exclusion j. Damage To Property do not apply if such "property damage" results from the use of elevators. For the purpose of this provision, elevators do not include vehicle lifts. Vehicle lifts are lifts or hoists used in automobile service or repair operations. 2. The following is added to Section IV—Commercial General Liability Conditions, Condition 4. Other Insurance, Paragraph b. Excess Insurance: The insurance afforded by this provision of this endorsement is excess over any property insurance, whether primary, excess, contingent or on any other basis. D. EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) If Damage To Premises Rented To You is not otherwise excluded from this Coverage Part: 1. Under Paragraph 2. Exclusions of Section I -Coverage A- Bodily Injury and Property Damage Liability: a. The fourth from the last paragraph of exclusion j. Damage To Property is replaced by the following: Paragraphs (1), (3)and (4)of this exclusion do not apply to"property damage"(other than damage by fire, lightning, explosion, smoke, or leakage from an automatic fire protection system) to: (i) Premises rented to you for a period of 7 or fewer consecutive days; or (ii) Contents that you rent or lease as part of a premises rental or lease agreement for a period of more than 7 days. Paragraphs(1), (3)and (4)of this exclusion do not apply to"property damage"to contents of premises rented to you for a period of 7 or fewer consecutive days. A separate limit of insurance applies to this coverage as described in Section III—Limits of Insurance. ©2013 Liberty Mutual Insurance CG 8810 0413 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 2 of 8 b. The last paragraph of subsection 2. Exclusions is replaced by the following: Exclusions c.through n.do not apply to damage by fire, lightning, explosion, smoke or leakage from automatic fire protection systems to premises while rented to you or temporarily occupied by you with permission of the owner.A separate limit of insurance applies to Damage To Premises Rented To You as described in Section III—Limits Of Insurance. 2. Paragraph 6. under Section III—Limits Of Insurance is replaced by the following: 6. Subject to Paragraph 5.above,the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of"property damage"to: a. Any one premise: (1) While rented to you; or (2) While rented to you or temporarily occupied by you with permission of the owner for damage by fire, lightning, explosion, smoke or leakage from automatic protection systems; or b. Contents that you rent or lease as part of a premises rental or lease agreement. 3. As regards coverage provided by this provision D. EXTENDED DAMAGE TO PROPERTY RENTED TO YOU (Tenant's Property Damage) -Paragraph 9.a. of Definitions is replaced with the following: 9.a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire, lightning, explosion, smoke, or leakage from automatic fire protection systems to premises while rented to you or temporarily occupied by you with the permission of the owner, or for damage to contents of such premises that are included in your premises rental or lease agreement, is not an "insured contract". E. MEDICAL PAYMENTS EXTENSION If Coverage C Medical Payments is not otherwise excluded, the Medical Payments provided by this policy are amended as follows: Under Paragraph 1. Insuring Agreement of Section I —Coverage C—Medical Payments, Subparagraph (b)of Paragraph a. is replaced by the following: (b) The expenses are incurred and reported within three years of the date of the accident; and F. EXTENSION OF SUPPLEMENTARY PAYMENTS—COVERAGES A AND B 1. Under Supplementary Payments—Coverages A and B, Paragraph 1.b. is replaced by the following: b. Up to$3,000 for cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds. 2. Paragraph 1.d. is replaced by the following: d. All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or"suit", including actual loss of earnings up to$600 a day because of time off from work. G. ADDITIONAL INSUREDS-BY CONTRACT,AGREEMENT OR PERMIT 1. Paragraph 2. under Section II—Who Is An Insured is amended to include as an insured any person or organization whom you have agreed to add as an additional insured in a written contract,written agreement or permit. Such person or organization is an additional insured but only with respect to liability for"bodily injury", "property damage"or"personal and advertising injury" caused in whole or in part by: a. Your acts or omissions, or the acts or omissions of those acting on your behalf, in the performance of your on going operations for the additional insured that are the subject of the written contract or written agreement provided that the"bodily injury"or"property damage"occurs, or the"personal and advertising injury' is committed, subsequent to the signing of such written contract or written agreement; or m 2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 3 of 8 b. Premises or facilities rented by you or used by you; or C. The maintenance, operation or use by you of equipment rented or leased to you by such person or organization; or d. Operations performed by you or on your behalf for which the state or political subdivision has issued a permit subject to the following additional provisions: (1) This insurance does not apply to"bodily injury", "property damage", or"personal and advertising injury"arising out of the operations performed for the state or political subdivision; (2) This insurance does not apply to"bodily injury" or"property damage" included within the "completed operations hazard". (3) Insurance applies to premises you own, rent, or control but only with respect to the following hazards: a) The existence, maintenance, repair, construction, erection, or removal of advertising signs, awnings, canopies, cellar entrances, coal holes, driveways, manholes, marquees, hoist away openings, sidewalk vaults, street banners, or decorations and similar exposures; or (b) The construction, erection, or removal of elevators; or (c) The ownership, maintenance, or use of any elevators covered by this insurance. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. With respect to Paragraph 1.a.above, a person's or organization's status as an additional insured under this endorsement ends when: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project(other than service, maintenance or repairs)to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or (2) That portion of"your work"out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. With respect to Paragraph 1.1b. above, a person's or organization's status as an additional insured under this endorsement ends when their written contract or written agreement with you for such premises or facilities ends. With respects to Paragraph 1.c. above,this insurance does not apply to any"occurrence"which takes place after the equipment rental or lease agreement has expired or you have returned such equipment to the lessor. The insurance provided by this endorsement applies only if the written contract or written agreement is signed prior to the"bodily injury"or"property damage". We have no duty to defend an additional insured under this endorsement until we receive written notice of a"suit" by the additional insured as required in Paragraph b.of Condition 2. Duties In the Event Of Occurrence, Offense, Claim Or Suit under Section IV—Commercial General Liability Conditions. ©2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 4 of 8 2. With respect to the insurance provided by this endorsement, the following are added to Paragraph 2. Exclusions under Section I -Coverage A-Bodily Injury And Property Damage Liability: This insurance does not apply to: a. "Bodily injury" or"property damage" arising from the sole negligence of the additional insured. b. "Bodily injury" or"property damage"that occurs prior to you commencing operations at the location where such"bodily injury" or"property damage"occurs. C. "Bodily injury", "property damage"or"personal and advertising injury"arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys,field orders, change orders or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment,training or monitoring of others by that insured, if the"occurrence"which caused the"bodily injury"or"property damage", or the offense which caused the"personal and advertising injury", involved the rendering of, or the failure to render, any professional architectural, engineering or surveying services. d. "Bodily injury"or"property damage"occurring after: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or (2) That portion of"your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. e. Any person or organization specifically designated as an additional insured for ongoing operations by a separate ADDITIONAL INSURED—OWNERS, LESSEES OR CONTRACTORS endorsement issued by us and made a part of this policy. 3. With respect to the insurance afforded to these additional insureds, the following is added to Section III— Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: a. Required by the contract or agreement; or b. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. H. PRIMARY AND NON-CONTRIBUTORY ADDITIONAL INSURED EXTENSION This provision applies to any person or organization who qualifies as an additional insured under any form or endorsement under this policy. Condition 4. Other Insurance of SECTION IV—COMMERCIAL GENERAL LIABILITY CONDITIONS is amended as follows: a. The following is added to Paragraph a. Primary Insurance: If an additional insured's policy has an Other Insurance provision making its policy excess, and you have agreed in a written contract or written agreement to provide the additional insured coverage on a primary and noncontributory basis, this policy shall be primary and we will not seek contribution from the additional insured's policy for damages we cover. ®2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 5 of 8 b. The following is added to Paragraph b. Excess Insurance: When a written contract or written agreement, other than a premises lease, facilities rental contract or agreement, an equipment rental or lease contract or agreement, or permit issued by a state or political subdivision between you and an additional insured does not require this insurance to be primary or primary and non-contributory,this insurance is excess over any other insurance for which the additional insured is designated as a Named Insured. Regardless of the written agreement between you and an additional insured,this insurance is excess over any other insurance whether primary, excess, contingent or on any other basis for which the additional insured has been added as an additional insured on other policies. I. ADDITIONAL INSUREDS-EXTENDED PROTECTION OF YOUR"LIMITS OF INSURANCE" This provision applies to any person or organization who qualifies as an additional insured under any form or endorsement under this policy. 1. The following is added to Condition 2. Duties In The Event Of Occurrence,Offense,Claim or Suit: An additional insured under this endorsement will as soon as practicable: a. Give written notice of an"occurrence"or an offense that may result in a claim or"suit"under this insurance to us; b. Tender the defense and indemnity of any claim or"suit"to all insurers whom also have insurance available to the additional insured; and C. Agree to make available any other insurance which the additional insured has for a loss we cover under this Coverage Part. d. We have no duty to defend or indemnify an additional insured under this endorsement until we receive written notice of a"suit"by the additional insured. 2. The limits of insurance applicable to the additional insured are those specified in a written contract or written agreement or the limits of insurance as stated in the Declarations of this policy and defined in Section III—Limits of Insurance of this policy, whichever are less.These limits are inclusive of and not in addition to the limits of insurance available under this policy. J. WHO IS AN INSURED-INCIDENTAL MEDICAL ERRORS!MALPRACTICE WHO IS AN INSURED-FELLOW EMPLOYEE EXTENSION -MANAGEMENT EMPLOYEES Paragraph 2.a.(1)of Section II -Who Is An Insured is replaced with the following: (1) "Bodily injury"or"personal and advertising injury": (a) To you,to your partners or members (if you are a partnership or joint venture),to your members (if you are a limited liability company), to a co-"employee"while in the course of his or her employment or performing duties related to the conduct of your business, or to your other "volunteer workers"while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co-"employee"or"volunteer worker"as a consequence of Paragraph (1)(a)above; (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraphs (1) (a)or(b)above; or (d) Arising out of his or her providing or failing to provide professional health care services. However, if you are not in the business of providing professional health care services or providing professional health care personnel to others, or if coverage for providing professional health care services is not otherwise excluded by separate endorsement, this provision (Paragraph (d))does not apply. ®2013 Liberty Mutual Insurance CG 88 10 0413 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 6 of 8 Paragraphs(a)and (b)above do not apply to"bodily injury"or"personal and advertising injury"caused by an "employee"who is acting in a supervisory capacity for you. Supervisory capacity as used herein means the "employee's"job responsibilities assigned by you, includes the direct supervision of other"employees"of yours. However, none of these"employees"are insureds for"bodily injury"or"personal and advertising injury" arising out of their willful conduct,which is defined as the purposeful or willful intent to cause"bodily injury"or"personal and advertising injury", or caused in whole or in part by their intoxication by liquor or controlled substances. The coverage provided by provision J. is excess over any other valid and collectable insurance available to your "employee". K. NEWLY FORMED OR ADDITIONALLY ACQUIRED ENTITIES Paragraph 3.of Section II-Who Is An Insured is replaced by the following: 3. Any organization you newly acquire or form and over which you maintain ownership or majority interest, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the expiration of the policy period in which the entity was acquired or formed by you; b. Coverage A does not apply to"bodily injury"or"property damage"that occurred before you acquired or formed the organization; and C. Coverage B does not apply to"personal and advertising injury"arising out of an offense committed before you acquired or formed the organization. d. Records and descriptions of operations must be maintained by the first Named Insured. No person or organization is an insured with respect to the conduct of any current or past partnership,joint venture or limited liability company that is not shown as a Named Insured in the Declarations or qualifies as an insured under this provision. L. FAILURE TO DISCLOSE HAZARDS AND PRIOR OCCURRENCES Under Section IV—Commercial General Liability Conditions,the following is added to Condition 6. Representations: Your failure to disclose all hazards or prior"occurrences"existing as of the inception date of the policy shall not prejudice the coverage afforded by this policy provided such failure to disclose all hazards or prior"occurrences" is not intentional. M. KNOWLEDGE OF OCCURRENCE,OFFENSE, CLAIM OR SUIT Under Section IV—Commercial General Liability Conditions,the following is added to Condition 2. Duties In The Event of Occurrence,Offense,Claim Or Suit: Knowledge of an "occurrence", offense, claim or"suit" by an agent, servant or"employee"of any insured shall not in itself constitute knowledge of the insured unless an insured listed under Paragraph 1.of Section II—Who Is An Insured or a person who has been designated by them to receive reports of "occurrences",offenses, claims or"suits" shall have received such notice from the agent, servant or "employee". N. LIBERALIZATION CLAUSE If we revise this Commercial General Liability Extension Endorsement to provide more coverage without additional premium charge, your policy will automatically provide the coverage as of the day the revision is effective in your state. O. BODILY INJURY REDEFINED Under Section V—Definitions, Definition 3. is replaced by the following: 3. "Bodily Injury" means physical injury, sickness or disease sustained by a person. This includes mental anguish, mental injury, shock, fright or death that results from such physical injury, sickness or disease. ©2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 7 of 8 P. EXTENDED PROPERTY DAMAGE Exclusion a.of COVERAGE A. BODILY INJURY AND PROPERTY DAMAGE LIABILITY is replaced by the following: a. Expected Or Intended Injury "Bodily injury"or"property damage"expected or intended from the standpoint of the insured. This exclusion does not apply to"bodily injury"or"property damage" resulting from the use of reasonable force to protect persons or property. Q. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US—WHEN REQUIRED IN A CONTRACT OR AGREEMENT WITH YOU Under Section IV— Commercial General Liability Conditions, the following is added to Condition 8. Transfer Of Rights Of Recovery Against Others To Us: We waive any right of recovery we may have against a person or organization because of payments we make for injury or damage arising out of your ongoing operations or"your work"done under a contract with that person or organization and included in the"products-completed operations hazard"provided: 1. You and that person or organization have agreed in writing in a contract or agreement that you waive such rights against that person or organization; and 2. The injury or damage occurs subsequent to the execution of the written contract or written agreement. ©2013 Liberty Mutual Insurance CG 88 10 04 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 8 Of 8 Page 1 of 4 State of Washington Department of Labor & Industries Prevailing Wage Section - Telephone 360-902-5335 PO Box 44540, Olympia, WA 98504-4540 Statement of Intent to Pay Prevailing Wage Pro Project Detail - Dashboard Document Intent Affidavit ID: Status: Approved Received Date: ID: On 8/7/2017 8/7/2017 852932 Company Details Company Name: CHRISTENSEN INC GENERAL CONTR Address: 2840 CRITES ST SW #100 OLYMPIA, WA, 98512 Contractor Registration No. CHRISIG066LB WA UBI Number 601546765 Phone Number 360-709-0330 Industrial Insurance Account ID 86797300 Email Address infoCchristensenincgc.com Filed By Christensen, Kevin Prime Contractor Company Name CHRISTENSEN INC GENERAL CONTR https://fortress.wa.gov/lni/wagelookup/IntentDetails.aspx 8/8/2017 Page 2 of 4 Contractor Registration No. CHRISIG066LB WA UBI Number 601546765 Phone Number 360-709-0330 Project Information Awarding Agency KENT, CITY OF 220 - 4TH AVE S KENT, WA - 98032-5895 Awarding Agency Contact Nancy Clary Awarding Agency Contact Phone 253-856-5084 Number Contract Number Project Name Law Dept TI Fourth Flr Contract Amount $28,594.50 Bid due date 6/30/2017 Award Date 7/26/2017 Project Site Address or Directions 400 West Gowe Fourth Flr Kent WA 98032 Payment Details Check Number: Transaction Id: 105878757 Intent Details Expected project start date: (MM- 8/14/2017 DD-YYYY) In what county (or counties) will the King work be performed? In what city (or nearest city) will Kent the work be performed? $282 594.50 https://fortress.wa.gov/lni/wagelookup/IntentDetails.aspx 8/8/2017 Page 3 of 4 What is the estimated contract amount? OR is this a time and materials estimate? Will this project utilize American No Recovery and Reinvestment Act (ARRA) funds? Specifically, will this project utilize No any weatherization or energy efficiency upgrade funds (ARRA or otherwise)? Does your company intend to hire Yes ANY subcontractors? Does your company intend to hire No subcontractors to perform ALL work? Will your company have employees Yes perform work on this project? Do you intend to use any No apprentices? (Apprentices are considered employees. ) How many owner/operators 0 performing work on the project own 30% or more of the company? Journey Level Wages County Trade Occupation Wage Fringe # Workers King Carpenters Carpenter $55.51 $0.00 1 King Laborers General Laborer $45.25 $0.00 1 Public Notes https:Hfortress.wa.gov/lni/wagelookup/IntentDetails.aspx 8/8/2017 Page 4 of 4 o Show/Hide Existing Notes No note exists https://fortress.wa.gov/lni/wagelookup/IntentDetails.aspx 8/8/201.7 City of Kent • Business License KENO" 'WASHING TON CHRISTENSEN INC GENERAL CONTRACTOR 2840 CRITES ST SW STE 100 TUMWATER,WA 98512 Please tear at perforation - ----------------------------------------------- Per RCW 82.14 local sales BUSINESS LICENSE and use tax must be cooled LICENSE MUST BE PAID ANNUALLY BY No. 1715 for all qualified JANUARY 1st TO AVOID PENALTY sales within the city of \%: KEN T Issuance of License Does Not Imply Licensee's Kent. W A S H I N O T O N Compliance with State and Local Laws THIS LICENSE MUST BE POSTED IN A CONSPICUOUS Year : 2017 PLACE.NOT TRANSFERABLE OR ASSIGNABLE NAME AND ADDRESS OF BUSINESS BLOC-2170046 CHRISTENSEN INC GENERAL CONTRACTOR MAYOR 2840 CRITES ST SW STE 100 The City of Kent TUMWATER,WA 98512 At 220 4TH AVE SO KENT,wASHMGTON 98032 . ..... pw Nw/ O/or ............. 50/01 x/o, ........... I'T ..........."I r ntovi— FA .... ....... AW ...................... MAE, A, .. ........ All A IRS, If WON PRE ox, gglIgg p plplllgl��l IV ............ IR its, s' ke ALL J et/ �s im AE/ X "U _111 ............ ...................... 'A 11 ',g ......... ......W" A "//,/. A, // ///, ,0",v0A, 'Salt AW low ............ SAW' T'//'/"��.......... AWW In/ "�/p""' WWW"l/ ONE M./s REE01000 SPIN a /0' 4 CA' d" Rios POE_'' m IME ...............